7651 Bid Invitation Addendum 57651 Addendum 5
Dry Auger Bore
Issue Date:5/28/2021
Questions Deadline:8/6/2021 03:00 PM (CT)
Response Deadline:8/17/2021 11:00 AM (CT)
Denton - Purchasing
Contact Information
Contact:Christa Christian, CPPB
Address:Procurement and Compliance
901-B Texas Street
Denton, TX 76209
Phone:(940) 349-7100
Email:christa.christian@cityofdenton.com
Page 1 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Event Information
Number:7651 Addendum 5
Title:Dry Auger Bore
Type:Competitive Sealed Proposal
Issue Date:5/28/2021
Question Deadline:8/6/2021 03:00 PM (CT)
Response Deadline:8/17/2021 11:00 AM (CT)
Notes:
CSP 7651 Dry Auger Bore
The submittal process may take significant time.
The City highly recommends that respondents do not wait until minutes before
the due date and time to submit proposal.
Submissions via email will not be accepted.
Hard copy bid bonds are required.
To Join the Virtual Opening:
Microsoft Teams meeting
Join on your computer or mobile app
Click here to join the meeting
Or call in (audio only)
+1 940-208-1678,,841598666# United States, Denton
Phone Conference ID: 841 598 666#
Tuesday, August 17, 2021 at 11:30 AM
OR
To attend Opening in Person:
City of Denton Development Services Center
401 N. Elm Street
Denton, TX 76201
Training Room One
GENERAL DESCRIPTION OF WORK
The major work will consist of the (approximate) following:
Page 2 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Bores and casings
In accordance with the provisions of Texas State Law, the City of Denton (the City) is
requesting submissions to contract with an individual or business with considerable
experience in providing goods or services of this solicitation. The responses and the
cost solutions shall be submitted to the City of Denton in a sealed submission.
The awarded individual or business shall possess a proven track record of using
innovative approaches to providing goods and services that represent the best value to
their clients. The awarded individual or business shall have the ability to accomplish all
aspects of the requested services. The selected individual or firm should be able to
provide innovative methods to deal with municipal challenges, and cost effective
solutions.
A firm may submit a solicitation response for one or more of the categories of product
or services requested in this solicitation.
Virtual Opening
Ship To Information
Address:901B Texas Street
Denton, TX 76209
Billing Information
Contact:City of Denton
Address:Accounts Payable
215 E McKinney St
Denton, TX 76201-4299
Bid Attachments
7651 - Dry Auger Bore -SOW and Specifications 3-26-21.pdf Download
Specifications
Substitute_W-9_Form_10.18.18.pdf View Online
Substitue w-9
CIQ.docx Download
Conflict of Interest Questionnaire
Contractor Wage Information.docx Download
Contractor Wage Information
SAFETY RECORD QUESTIONNAIRE.docx Download
Safety Record Questionairre
Project Manual.pdf Download
Project manual
Page 3 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Requested Attachments
Construction Bid Documents
(Attachment required)
Must attach all required documents listed in section 4 of the proposal Form.
Conflict of Interest Questionnaire
(Attachment required)
The individual or business must disclose any business relationship that would have an effect, of a conflict of interest.
Please attach a signed copy of the conflict of interest questionnaire.
Substitute W9
(Attachment required)
This will be used if awarded to set you up in our system.
Bid Acceptance - Exceptions
If you answered yes - with exceptions to the bid acceptance question please attach a list of the exceptions
Bid Attributes
1 SECTION 1
General Information
2 Submittal Instructions
The City of Denton will accept electronic in Ionwave submittals until the date and time on the cover sheet of this
solicitation. Any submission received after the date and/or hour set for solicitation opening will be automatically
rejected. Do not wait until the last minute, incomplete submission will be automatically rejected. The City will not allow
late submissions due to technical difficulties.
Electronic submissions require hard copy of Bid Bonds. Hard copy bid bonds must be submitted using hard
submission requirements. Electronic proposals without hard copy bonds will be automatically rejected.
Hard copy submissions may be hand delivered (by firm or express courier) to the address listed below:
City of Denton
Materials Management
SOLICITATION NUMBER AND NAME
901B Texas Street
Denton, TX 76209
The City of Denton reserves the right to accept or reject in part or in whole any submission, and to waive technicalities
of the submission, in the best interest of obtaining best value for the City.
Each respondent is responsible for taking the necessary steps to ensure their submission is received by the date and
time noted herein. The City is not responsible for technical difficulties that may result in the submission arriving after
the set time.
3 Submittal Requirement Acknowledgement
In addition to completing all required sections of the Proposal Documents, the Offeror shall provide documentation
demonstrating the Offeror’s qualifications and experience. This documentation shall be included with the Offeror’s
Ionwave submissions. The Offeror shall address each of the following items in the same order in which they are set
forth below. Qualification and experience documentation shall be submitted on letter-size (8-1/2” x 11”) PDF. The
qualifications and experience data provided shall include, but may not be limited to the following:
Proposal Form - Provide the information as required in Sections 00 41 01 - Proposal Form, and 00 42 44 – Unit
Price Proposal Form, to establish:
Page 4 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Offeror's General Information
Proposal Price
Quality, Reputation, and Ability to Complete Similar Projects on Schedule and Within Budget: The Offeror shall
demonstrate experience in delivering similar work as expressed in the Proposal Documents on schedule and
within budget. Submit details of three (3) similar projects completed within the last five (5) years. The Offeror
should include the following items for each project submitted:
Project Name
Owner Name
Project Owner Contact Name, Phone Number, and Email Address
Contract Time and Actual Completion Time
Original Contract Cost and Final Contract Cost
Detailed Project Description
The Offeror should present projects that demonstrate experience in the following categories:
Bores with Casings
Offeror’s Key Personnel: The Offeror shall include an organizational chart (maximum of 1 page) and resume
(maximum of 1 page per person) of key team members that will be assigned to the Project. The Offeror should,
at a minimum,provide personnel experience for the Project Manager and Superintendent. The Key Personnel
resumes should include the following information:
Name and Job Title
Role and Responsibility
Total number of years of experience and total number of years with current firm.
Licenses and Certifications.
Project Role and Responsibilities.
Relevant experience for the categories listed in 13.1.2.7, specifically within the last 5 years. Identify if
projects were completed with current firm or previous firm.
List of other active projects Key Personnel will be assigned to for the duration of this project and include
percentage of time allocated for each.
Detailed Schedule and Written Plan to Achieve Completion and Final Acceptance within the Contract Time: The
Offeror shall demonstrate means and methods to achieve Completion and Final Acceptance within the Contract
Time. The Offeror shall include the following:
Baseline Schedule – The Offeror shall submit a detailed Baseline Schedule in accordance with Section 01
32 16. The schedule should demonstrate the Offeror’s ability to complete the Project within the Contract
Time. The Plan should clearly identify the Critical Path Items and the Plan to keep the project on
schedule. The Plan should include, but not be limited to:
Critical Path Plan
Equipment and material delivery
Hours of Operation
Offeror’s Resources to reach Substantial Completion, including the number of shifts or crews
working in parallel.
Offeror’s Safety Record: The Offeror shall provide responses and any supporting documentation necessary for
the Owner to evaluate the safety record for the Offeror and proposed Subcontractors. The response shall
include, but may not be limited to the following:
Documentation of any complaints to, or final orders entered by, the Occupational Safety and Health Review
Commission (OSHRC) against the Offeror or a proposed Subcontractor for violation(s) of OSHA regulations
within the last five (5) years.
Documentation of any complaints to, or final orders entered by, the Occupational Safety and Health
Review Commission (OSHRC) against the Offeror or a proposed Subcontractor for violation(s) of OSHA
regulations within the last five (5) years.
Documentation of any citations received by the Offeror or a proposed Subcontractor from any federal,
state, or local environmental protection enforcement agency.
Provide records showing Total Recordable Incident Rate (TRIR) for each year for the last five (5) years
for the Offeror and each proposed Subcontractor.
Provide records documenting the Experience Modification Rate (EMR) for the last five (5) years for the
Offeror and each proposed Subcontractor.
List any fatalities in the safety history for the last ten (10) years for the Offeror and each proposed
Subcontractor.
Page 5 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Section 00 45 14 – Safety Record Questionnaire.
In addition to the information provided above the Offeror shall submit the following forms as part of the Proposal:
Section 00 35 14 – Conflict of Interest Affidavit – CSP
Section 00 41 01 – Proposal Form – CSP
Section 00 42 44 – Unit Price Proposal Form – CSP
Section 00 43 38 – Proposed Subcontractors Form – CSP
Section 00 43 39 – Vendor Compliance to State Law Non-Resident Offeror – CSP
Section 00 45 14 – Safety Record Questionnaire – CSP
Section 00 45 27 – Contractors Compliance with Workers Compensation Law – CSP
Section 00 45 44 – Corporate Resolution of Authorized Signatories – CSP
4 Evaluation Procedures
Selection of a firm(s) to provide the aforementioned materials and services shall be in accordance with the City of
Denton Purchasing Policies and procedures. The City of Denton shall open all submissions and evaluate each
respondent in accordance to the below criteria:
Step 1: The City of Denton will evaluate the submission in accordance with the selection criteria and will rank the firms
on the basis of the submittals. The City of Denton, reserves the right to consider information obtained in addition to
the data submitted in the response. The selection criterion is listed below:
Offeror’s Key Personnel (FACTOR:10 %)
Key Personnel will be awarded points for the listed role and responsibility that the resume demonstrates with a
maximum score of ten (10) points for a single team member that demonstrates all desirable characteristics. The
scores of the individual team members will then be averaged to determine the score for the Offeror’s Key Personnel.
Quality, Reputation, and Ability to Complete Similar Projects on Schedule and Within Budget (FACTOR: 30%)
Points will be awarded based on the Offeror’s experience relevant to this Project, the reputation of the Offeror in
performance of similar past projects, overall reputation and experience of the Offeror, and percentage of time Key
Personnel is committed to this project. The City will evaluate the projects submitted in accordance with the Submittal
Requirements Paragraph, to determine relevancy to the specified scope of this Project and review the Offeror’s
performance on the submitted projects. The City may contact the references provided by the Offeror, as well as any
other additional references, as may be necessary to verify the qualifications, experience, and reputation of the
Offeror.
Detailed Schedule and Written Plan to achieve Substantial Completion and Final Acceptance within the
Contract Time (FACTOR: 10%)
The schedule and plan should clearly show the Critical Path and the means and methods the Offeror will use to
achieve Substantial Completion and Final Acceptance within the Contract Time. Scoring will be based on the Offeror’s
ability to communicate the plan and schedule.
Offeror’s Safety Record (FACTOR: 10%)
The Owner will award points based on evaluation of the safety documentation provided by the Offeror as required in
the Submittal Requirements paragraph. Safety documentation for the Offeror and Subcontractors will be evaluated
and considered in awarding points for this item.
Price, Total Cost of Ownership (FACTOR: 40%)
The price of items, to include total cost of ownership, such as installation costs, life cycle costs, and warranty
provisions.
Page 6 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
The total possible score of the submissions shall be scored and weighted as indicated above. Based on the outcome
of the computations performed, each submission will be assigned a raw score. The assigned weight will then be
applied to these scores to calculate an overall score for each submission for completion of the final scoring process.
Step 2: After the final ranking of the submissions and determination of the firm that provide the best value to the City
and are within the competitive range, provided the City of Denton elects to proceed without oral discussions, the City
will immediately proceed to negotiate Best and Final pricing, terms and conditions with the highest ranked firm. The
best and final pricing cannot be higher than the original proposal submitted. The City of Denton may elect to conduct
oral discussions, request clarifications, and presentations concerning the project approach and ability to furnish the
requirements, as part of the negotiation process. If an agreement cannot be reached with the top ranked firm, the City
will terminate negotiations and move to the next highest ranked firm. The process will continue until an agreement is
reached of the submissions are formally rejected by the City.
Step 3: Upon selection of the submission or Best and Final Offer that represents the “best value”, a written
recommendation will be presented to the appropriate approving authority for the City of Denton (the City Manager,
Public Utility Board, City Council) requesting authorization to proceed with contract execution for the proposed
services.
In accordance with Texas State Law, trade secrets and confidential information in competitive sealed proposals are not
open for public inspection. A virtual public opening will be conducted. Respondent names and pricing will be
read thirty minutes after the opening.
After the contract has been awarded all submissions will be open for public inspection, and the unsuccessful
respondent(s) may request a debriefing regarding their submittal. Please contact the City of Denton Materials
Management staff to document the request for a debriefing. A meeting with the City of Denton Materials Management
Staff and the using Division will be scheduled within a reasonable time.
5 Protests
Any interested party who is aggrieved in connection with a solicitation or award of a contract may protest per the City
of Denton policy located here on page 52 - "https://www.cityofdenton.com/CoD/media/City-of-
Denton/Business/Solicitations%20and%20Contracting/Denton-Procurement-Policy_Final.pdf
6 Section 2
Terms and Conditions
7 General Provisions - Additional for Construction
1. AVAILABILITY OF TECHNICAL DRAWINGS AND SPECIFICATIONS
If applicable, Technical Specifications and Drawings/Plans related to this project are attached to this solicitation.
2. EXAMINATION OF PLANS, SPECIFICATIONS AND SITE OF THE
WORK
Respondents are advised that the scope of work, attachments, plans (if applicable), specifications, and other
Page 7 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
documents on file as stated in the proposal documents shall constitute all the information which the City shall
furnish. Respondents are required, prior to submitting any response, to review all documents (scope of
work, plans, specifications, exhibits, contract, amendments, bond forms, etc.,) carefully; to visit the site of the
work (if applicable); to examine carefully the local conditions; to inform themselves with their independent
research, tests, and investigations of the difficulties to be encountered and judge for themselves the
accessibility of the work and all attending circumstances affecting the cost of doing the work or the time required
for its completion and to obtain all information required to make an intelligent proposal.
No information given by the City or any official thereof, other than that shown on the scope of work, plans (if
available) and contained in the specifications, exhibits, and other contract documents, shall be binding upon the
City. Respondents shall rely exclusively upon their own estimates, investigations, test and other data which is
necessary to full and complete information upon which the submission may be based. Any respondent, by
submitting a response, represents and warrants that he has prepared his submittal in accordance with the
specifications, with full knowledge and understanding of the terms and provisions thereof; that he has reviewed,
studied and examined the response prior to the signing and submission of same; and that he was cognizant of
the terms of his submittal, verified his calculations and found them to be correct and agrees to be bound
thereby.
3. BONDS
Successful awarded contractor will be required to sign original contract and submit a blanket performance and
payment bond as outlined in specifications before work is to commence. Bonds shall be in accordance with the
V.T.C.A Government Code Section 2253.021, as amended.
4. PREVAILING WAGE RATES
In accordance with Texas Government Code 2258, the awarded contractor shall comply with prevailing wage
rates as defined by the United States Department of Labor Davis-Bacon Wage Determination
at http://www.dol.gov/whd/contracts/dbra.htm and at the Wage Determinations website www.wdol.gov for Denton
County, Texas.
Notwithstanding any other provision of this Contract, the awarded contractor hereby represents and warrants
that the contractor shall pay to each of its employees a wage not less than what is currently known as the
"Federal Minimum Wage" and any increase or amendments thereto. Furthermore, contractor shall produce
proof of compliance with this provision by contractor to the City. The City shall withhold payments due to
contractor until contractor has complied with this provision. Prior to any payment being made for work
satisfactorily completed and accepted, contractor shall submit wage rate affidavits with its billing documents
affirming that all employees have been paid not less than the current "Federal Minimum Wage”.
5. PAYMENT AND PERFORMANCE REQUIREMENTS
a. PAYMENT AND INVOICES:
Payment processing: The City review, inspection, and processing procedures for invoices ordinarily require
thirty (30) days after receipt of invoices, materials, or services. Submissions which call for payment before thirty
(30) days from receipt of invoice, or cash discounts given on such payment, will be considered only if, in the
opinion of the Purchasing Manager, the review, inspection, and processing procedures can be completed as
specified. It is the intention of the City of Denton to make payment within thirty days after receipt of valid
invoices for which items or services have been received unless unusual circumstances arise. The 30 day
processing period for invoices will begin on the date the invoice is received or the date the items or services are
received, whichever is later.
Direct deposit for payments: Contractors are encouraged to arrange for receiving payments through direct
deposit. Information regarding direct deposit payments is available from the City of Denton Purchasing website:
www.dentonpurchasing.com.
Page 8 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Invoices shall be sent directly to the City of Denton Accounts Payable Department, 215 E McKinney St,
Denton, TX, 76201-4299. A pro-forma invoice shall be sent to the contract administrator as identified in the
Notice to Proceed. It is the intention of the City of Denton to make payment on completed orders within thirty
days after receipt of invoice or items; whichever is later, unless unusual circumstances arise. Invoices must
be fully documented as to labor, materials, and equipment provided, if applicable, and must
reference the City of Denton Purchase Order Number in order to be processed. No payments shall
be made on invoices not listing a Purchase Order Number.
b. PAYMENT TO PERFORMANCE MILESTONES
Awarded contractor shall prepare and submit monthly pay apps per the schedule of values outlined in the
attached STANDARD PURCHASE TERMS AND CONDITIONS FOR FACILITY CONSTRUCTION SERVICES, Article
9 Payments and Completion.
c. TAX EXEMPTION
The City of Denton qualifies for sales tax exemption pursuant to the provisions of Article 20.04 (F) of the Texas
Limited Sales, Excise and Use Tax Act. Any Contractor performing work under this contract for the City of
Denton may purchase materials and supplies and rent or lease equipment sales tax free. This is accomplished
by issuing exemption certificates to suppliers. Certificates must comply with State Comptroller’s ruling #95-0.07
and #95-0.09.
d. RELEASE OF LIENS AND CERTIFICATE OF CONTRACTOR
Upon award of the contract, the Contractor shall inform the City of the subcontractors and material sources that
will be used. Upon the completion by the Contractor of the construction of the project, but prior to final payment
to the Contractor, the Contractor shall deliver to the City releases of all liens, and of rights to claim any lien, from
all manufacturers, material-men, and subcontractors furnishing services or materials for the project, to the effect
that all materials or services used on or for the project have been paid for and indicating that the City is
released from all such claims.
e. PAYMENTS TO MATERIAL-MEN AND SUBCONTRACTORS
The Contractor shall pay each material-men, and each subcontractor, if any, as outlined in the project
specifications, the amount thereof allowed the Contractor for and on account of materials furnished or
construction performed by each material-men or each subcontractor.
6. WARRANTIES
The contractor shall provide a warranty as outlined in the project specifications.
8 Right to Protest
Any interested party who is aggrieved in connection with a solicitation or award of a contract above the formal
threshold may protest to the Procurement Director. Protests based upon alleged improprieties in a solicitation that are
apparent before the solicitation due date shall be filed not less than five (5) working days before the solicitation due
date. In all other cases, protests shall be filed within five (5) days of notice of intent to award or in the absence of a
notice of intent to award, prior to the award date. Filing of a protest must be in accordance with Article 12 of the
Procurement Policy Manual found on the City of Denton webpage, Materials Management department page, under the
Standard Terms, Conditions, and Policies section.
Page 9 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
9 Bid Acceptance
I have read and understand the Terms and Conditions, Specifications, and Insurance requirements, contained herein,
and further agree to abide and accept said Terms, Conditions and Specifications.
Yes Yes - with exceptions (Please Select)
(Required: Check only one)
1
0
Bid Acceptance Exceptions
If you answered yes - with exceptions to the above question you must attach exceptions narrative in attachment tab.
(Additional exceptions will not be allowed during the negotiation process)
Yes, I understand any exceptions must be attached
(Required: Check if applicable)
Page 10 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
1
1
Acknowledgement
The undersigned agrees this submission becomes the property of the City of Denton after the official opening.
The undersigned affirms he has familiarized himself with the specification, drawings, exhibits and other documents; the
local conditions under which the work is to be performed; satisfied himself of the conditions of delivery, handling and
storage of materials and equipment; and all other matters that will be required for the work before submitting a
response.
The undersigned agrees, if this submission is accepted, to furnish any and all items/services upon which prices are
offered, at the price(s) and upon the terms and conditions contained in the specification. The period for acceptance of
this submission will be 120 calendar days unless a different period is noted.
The undersigned affirms that they are duly authorized to execute this contract, that this submission has not been
prepared in collusion with any other respondent, nor any employee of the City of Denton, and that the contents of this
submission have not been communicated to any other respondent or to any employee of the City of Denton prior to
the acceptance of this submission.
Respondent hereby assigns to the City any and all claims for overcharges associated with this contract which arise
under the antitrust laws of the United States, 15 USCA Section 1 et seq., and which arise under the antitrust laws of
the State of Texas, Tex. Bus. & Com. Code, Section 15.01, et seq.
The undersigned affirms that they have read and do understand the specifications, all exhibits and attachments
contained in this solicitation package.
The undersigned agrees that the solicitation package posted on the website are the official specifications and shall not
alter the electronic copy of the specifications and/or pricing sheet, without clearly identifying changes.
The undersigned understands they will be responsible for monitoring the City of Denton Purchasing Website
at: https://www.cityofdenton.com/en-us/business/solicitations-contracting to ensure they have downloaded all
addendum(s).
I certify that I have made no willful misrepresentations in this submission, nor have I withheld information in my
statements and answers to questions. I am aware that the information given by me in this submission will be
investigated, with my full permission, and that any misrepresentations or omissions may cause my submission to be
rejected.
If awarded this construction Contract, the Bidder agrees to complete the work covered by this Contract within one
year as requested in the scope of work.
The Bidder hereby agrees that the City reserves the right to waive informalities in any bid and to reject any or all
bids, or to accept any bid that in its judgment will be for the best interest of the City.
Acknowledge
(Required: Check if applicable)
Page 11 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
1
2
Certificate of Interested Parties Electronic Filing
In 2015, the Texas Legislature adopted House Bill 1295, which added section 2252.908 of the Government Code. The
law states that the City may not enter into this contract unless the Contractor submits a disclosure of interested parties
(Form 1295) to the City at the time the Contractor submits the signed contract. The Texas Ethics Commission has
adopted rules requiring the business entity to file Form 1295 electronically with the Commission.
Contractor will be required to furnish an original Certificate of Interest Parties before the contract is
awarded, in accordance with Government Code 2252.908.
The contractor shall:
1. Log onto the State Ethics Commission Website at :
https://www.ethics.state.tx.us/whatsnew/elf_info_form1295.htm
2. Register utilizing the tutorial provided by the State
3. Print a copy of the completed Form 1295
4. Enter the Certificate Number on page 2 of this contract.
5. Sign the Form 1295
6. Email the form to purchasing@cityofdenton.com with the contract number in the subject line. (EX: Contract 1234
- Form 1295)
7. The City must acknowledge the receipt of the filed Form 1295 not later than the 30th day after Council award.
Once a Form 1295 is acknowledged, it will be posted to the Texas Ethics Commission's website within seven
business days.
Acknowledge
(Optional: Check if applicable)
1
3
Prohibition on Contracts with Companies Boycotting Israel
Pursuant to Section 2270.002 of the Texas Government Code, Respondent certifies that either (i) it meets an
exemption criteria under Section 2270.002; or (ii) it does not boycott Israel and will not boycott Israel during the term of
the contract resulting from this solicitation. Respondent shall state any facts and provide documentation that make it
exempt from the boycott certification in its Response.
Exemption criteria includes the following:
1. Company is a sole proprietorship;
2. Company employs less than 10 full-time employees;
3. Value of the contract is less than $100,000
“Boycott Israel” is defined to mean refusing to deal with, terminating business activities with, or otherwise taking any
action that is intended to penalize, inflict economic harm on, or limit commercial relations specifically with Israel, or with
a person or entity doing business in Israel or in an Israeli-controlled territory, but does not include an action made for
ordinary business purposes. “Company” is defined to mean a for-profit sole proprietorship, organization, association,
corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company,
including a wholly owned subsidiary, majority-owned subsidiary, parent company, or affiliate of those entities or
business associations that exists to make a profit.
Sole proprietorship Employs less than 10 Full time employees
Value of the contract is less than $100,000 Does not Boycott Israel
(Required: Check only one)
1
4
Firm's Legal Name
(Required: Maximum 1000 characters allowed)
Page 12 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
1
5
Agent Authorized to sign contract
The agents name and email who is authorized to sign the contract
(Required: Maximum 1000 characters allowed)
1
6
Organization Class
Partnership Corporation Individual Association
(Required: Check only one)
Bid Lines
1 NOTE 1: Minimum wall thickness criteria for water/wastewate requirements may change if design criteria are
updated. Contact designated City of Denton water/wastewater representative to confirm requirements prior to each
project order.
2 NOTE 2: Minimum wall thickness criteria for water/wastewate requirements will be project specific for bore depths
greater than 20FT. Contact designated City of Denton water/wastewater representative to confirm requirements
prior to each project.
3 SECTION I - DRY AUGER BORE ANNUAL PRICING - INCLUDES ALL COSTS, LABOR, AND SUPPLIES
REQUIRED PER THE SPECIFICATIONS EXCEPT STEEL CASINGS, FOR BORES WITH PITS TO 12 FEET.
4 16in. Bore in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:400 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
5 16in. Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:600 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
6 18in. Bore in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:400 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
Page 13 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
7 18in. Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
8 20in. Bore in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:1300 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
9 20in. Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:800 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
0
24in. Bore in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:500 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
1
24in. Grade Bore > 1% in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
2
24in. Grade Bore < 1% in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
3
24in. Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
Page 14 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
1
4
24in. Grade Bore > 1% in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
5
24in. Grade Bore < 1% in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
6
30in. Bore in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
7
30in. Grade Bore <1% in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
8
30in. Grade Bore > 1% in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:400 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
1
9
30in. Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
0
30in. Grade <1% Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
Page 15 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
2
1
30in. Grade >1% Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
2
36in. Bore in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
3
36in. Grade Bore <1% in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:400 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
4
36in. Grade Bore >1% in Dirt with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
5
36in. Bore in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
6
36in. Grade Bore <1% in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
7
36in. Grade Bore >1% in Rock with Conduit/Lines installed in Steel Casing
(Response required)
Quantity:100 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
2
8
SECTION IIA - STEEL CASING TO BE SUPPLIED BY CONTRACTOR FOR ELECTRIC FACILITIES
Page 16 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
2
9
16in. Diameter steel casing with 0.3125FT minimum thickness
(Response required)
Quantity:700 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
0
20in. Diameter steel casing with 0.3750FT minimum thickness
(Response required)
Quantity:1500 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
1
24in. Diameter steel casing with 0.4375in. minimum thickness
(Response required)
Quantity:700 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
2
SECTION IIB - STEEL CASING TO BE SUPPLIED BY CONTRACTOR FOR WATER/WASTEWATER
FACILITIES1,2
3
3
16in. Diameter steel casing with 0.500in. minimum thickness
(Response required)
Quantity:300 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
4
18in. Diameter steel casing with 0.500in. minimum thickness
(Response required)
Quantity:500 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
5
20in. Diameter steel casing with 0.500in. minimum thickness
(Response required)
Quantity:600 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
6
24in. Diameter steel casing with 0.500in minimum thickness
(Response required)
Quantity:500 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
Page 17 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
3
7
30in. Diameter steel casing with 0.500in. minimum thickness
(Response required)
Quantity:900 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
8
36in. Diameter steel casing with 0.625in. minimum thickness
(Response required)
Quantity:900 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
3
9
SECTION III - ADDITIONAL PRICING
4
0
Unit price for bores less than 50FT in length $_____ per bore job
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
4
1
Unit price $_____ per foot to excavate up to 12FT and weld additional 16in. steel casing onto existing steel casing.
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
4
2
Unit price $_____ per foot to excavate up to 12FT and weld additional 20in. steel casing onto existing steel casing.
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
4
3
Unit price $_____ per foot to excavate up to 12FT and weld additional 24in. steel casing onto existing steel casing.
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
4
4
Per linear foot adder to cut concrete Price shall include restoration of concrete $_____ per square foot.
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
Page 18 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
4
5
Per linear foot adder to cut asphalt Price shall include restoration of asphalt $_____ per square foot.
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
4
6
DIRT BORE: Adder per foot for bore pits depth to 20FT
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
4
7
ROCK BORE: Adder per foot for bore pits depth to 20FT
(Response required)
Quantity:1 UOM:FT Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
4
8
BONDING
4
9
Performance Bond, 100% of $150,000
(Response required)
Quantity:1 UOM:EA Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
5
0
Payment Bond, 100% of $150,000
(Response required)
Quantity:1 UOM:EA Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
5
1
Estimated number of days to deploy once request is submitted:
(Response required)
Quantity:1 UOM:DAYS Price:$Total:$
Supplier Notes:
Additional notes
(Attach separate sheet)
Page 19 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Supplier Information
Company Name:
Contact Name:
Address:
Phone:
Fax:
Email:
Supplier Notes
The undersigned agrees this submission becomes the property of the City of Denton after the official opening.
The undersigned affirms he has familiarized himself with the specification, drawings, exhibits and other documents; the local
conditions under which the work is to be performed; satisfied himself of the conditions of delivery, handling and storage of
materials and equipment; and all other matters that will be required for the work before submitting a response.
The undersigned affirms that they are duly authorized to execute this contract, that this submission has not been prepared
in collusion with any other respondent, nor any employee of the City of Denton, and that the contents of this submission
have not been communicated to any other respondent or to any employee of the City of Denton prior to the acceptance of
this submission.
The undersigned affirms that they have read and do understand the specifications, all exhibits and attachments contained in
this solicitation package.
I certify that I have made no willful misrepresentations in this submission, nor have I withheld information in my statements
and answers to questions. I am aware that the information given by me in this submission will be investigated, with my full
permission, and that any misrepresentations or omissions may cause my submission to be rejected.
Print Name Signature
Page 20 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5
Page 21 of 21 pages Deadline: 8/17/2021 11:00 AM (CT)7651 Addendum 5