Loading...
HomeMy WebLinkAbout8377-021 - Contract Executed DocuSign Transmittal Coversheet File Name Purchasing Contact Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD Christina Dormady 8377-021 Sherman at Long and Hartlee Improvements City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 1 of 15 CITY OF DENTON, TEXAS STANDARD AGREEMENT FOR ENGINEERING RELATED PROFESSIONAL SERVICES This AGREEMENT is between the City of Denton, a Texas home-rule municipality ("CITY"), and Kimley-Horn and Associates, Inc., with its corporate office at 421 Fayetteville Street, Suite 600, Raleigh, NC 27601 and authorized to do business in Texas, ("ENGINEER"), for a PROJECT generally described as: 8377-021 E Sherman Drive at Long Road and Hartlee Field Road Traffic Signal and Pavement Markings Improvements Design (the "PROJECT"). SECTION 1 Scope of Services A. The CITY hereby agrees to retain the ENGINEER, and the ENGINEER hereby agrees to perform, professional engineering services set forth in the Scope of Services attached hereto as Attachment A. These services shall be performed in connection with the PROJECT. B. Additional services, if any, will be requested in writing by the CITY. CITY shall not pay for any work performed by ENGINEER or its consultants, subcontractors and/or suppliers that has not been ordered in advance and in writing. It is specifically agreed that ENGINEER shall not be compensated for any additional work resulting from oral orders of any person. SECTION 2 Compensation and Term of Agreement A. The ENGINEER shall be compensated for all services provided pursuant to this AGREEMENT in an amount not to exceed $77,000 in the manner and in accordance with the fee schedule as set forth in Attachment B. Payment shall be considered full compensation for all labor, materials, supplies, and equipment necessary to complete the services described in Attachment A. B. Unless otherwise terminated pursuant to Section 6. D. herein, this AGREEMENT shall be for a term beginning upon the effective date, as described below, and shall continue for a period which may reasonably be required for the completion of the PROJECT, until the expiration of the funds, or completion of the PROJECT and acceptance by the CITY, whichever occurs first. ENGINEER shall proceed diligently with the PROJECT to completion as described in the PROJECT schedule as set forth in Attachment D. SECTION 3 Terms of Payment Payments to the ENGINEER will be made as follows: Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 2 of 15 A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation, including but not limited to meeting the requirements set forth in the PROJECT schedule as set forth in Attachment D to reasonably substantiate the invoices. (2) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices for the uncontested performance of the particular services are due and payable within 30 days of receipt by City. (3) Upon completion of services enumerated in Section 1, the final payment of any balance for the uncontested performance of the services will be due within 30 days of receipt of the final invoice. (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the CITY because of such suspension of services. SECTION 4 Obligations of the Engineer General The ENGINEER will serve as the CITY's professional engineering representative under this AGREEMENT, providing professional engineering consultation and advice and furnishing customary services incidental thereto. A. Standard of Care The ENGINEER shall perform its services: (1) with the professional skill and care ordinarily provided by competent engineers practicing in the same or similar locality and under the same or similar circumstances and professional license; and (2) as expeditiously as is prudent considering the ordinary professional skill and care of a competent engineer. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 3 of 15 B. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. C. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible mylar sheets and electronic files in .pdf format, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. D. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on-site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the AGREEMENT Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 4 of 15 the work on the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the AGREEMENT Documents, nor shall anything in the AGREEMENT Documents or this AGREEMENT between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on-site inspections to discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If the ENGINEER makes on-site observation(s) of a deviation from the AGREEMENT Documents, the ENGINEER shall inform the CITY. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the AGREEMENT Documents. E. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. F. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the AGREEMENT Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 5 of 15 encumbrances; or that there are not other matters at issue between the CITY and the construction contractor that affect the amount that should be paid. G. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. I. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of five (5) years after final payment under this AGREEMENT, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this AGREEMENT. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of five (5) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this section together with subsection (3) hereof. CITY shall give subconsultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 6 of 15 J. INSURANCE During the performance of the services under this Agreement, ENGINEER shall maintain insurance in compliance with the requirements of Attachment E which is attached hereto and made a part of this Agreement as if written word for word herein. K. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. The doctrine of respondeat superior shall not apply. L. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this AGREEMENT and prior to final payment under the AGREEMENT. M. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the CITY may request the ENGINEER to assist in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. N. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this AGREEMENT was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this AGREEMENT which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. O. Schedule Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 7 of 15 ENGINEER shall manage the PROJECT in accordance with the schedule developed per Attachment D to this AGREEMENT. P. Equal Opportunity (1) Equal Employment Opportunity: ENGINEER and ENGINEER’s agents shall not engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, sexual orientation, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this AGREEMENT. (2) Americans with Disabilities Act (ADA) Compliance: ENGINEER and ENGINEER’s agents shall not engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. SECTION 5 Obligations of the City A. City-Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. B. Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance of its services. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights-of-way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 8 of 15 manner in accordance with the PROJECT schedule prepared in accordance with Attachment D. E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER’s negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the PROJECT. G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV.E. regarding the ENGINEER's Personnel at Construction Site, and provisions providing for contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third-Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third-party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 9 of 15 person regarding the PROJECT a provision that such entity or person shall have no third-party beneficiary rights under this AGREEMENT. (4) Nothing contained in this Section H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY may secure Builders Risk/Installation insurance at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. SECTION 6 General Legal Provisions A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 10 of 15 service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER that prevent ENGINEER’s performance of its obligations hereunder. D. Termination (1) This AGREEMENT may be terminated: a. by the City for its convenience upon 30 days' written notice to ENGINEER. b. by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and the nonperforming party does not commence correction of such nonperformance within 5 days’ written notice or thereafter fails to diligently complete the correction. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a. Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b. Out-of-pocket expenses for purchasing electronic data files and other data storage supplies or services; c. The time requirements for the ENGINEER'S personnel to document the work underway at the time of the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 11 of 15 F. Indemnification IN ACCORDANCE WITH TEXAS LOCAL GOVERNMENT CODE SECTION 271.904, THE ENGINEER SHALL INDEMNIFY OR HOLD HARMLESS THE CITY AGAINST LIABILITY FOR ANY DAMAGE COMMITTED BY THE ENGINEER OR ENGINEER’S AGENT, ENGINEER UNDER CONTRACT, OR ANOTHER ENTITY OVER WHICH THE ENGINEER EXERCISES CONTROL TO THE EXTENT THAT THE DAMAGE IS CAUSED BY OR RESULTING FROM AN ACT OF NEGLIGENCE, INTENTIONAL TORT, INTELLECTUAL PROPERTY INFRINGEMENT, OR FAILURE TO PAY A SUBCONTRACTOR OR SUPPLIER. CITY IS ENTITLED TO RECOVER ITS REASONABLE ATTORNEY’S FEES IN PROPORTION TO THE ENGINEER’S LIABILITY. G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of the other party. H. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Denton County, Texas. I. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Sections 5.F., 6.B., 6.D., 6.F., 6.H., and 6.I. shall survive termination of this AGREEMENT for any cause. J. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding or ignorance thereof shall be considered. ENGINEER AGREES TO DEFEND, INDEMNIFY AND HOLD HARMLESS CITY AND ALL OF ITS OFFICERS, AGENTS AND EMPLOYEES FROM AND AGAINST ALL CLAIMS OR LIABILITY ARISING OUT OF THE VIOLATION OF ANY SUCH ORDER, LAW, ORDINANCE, OR REGULATION, WHETHER IT BE BY ITSELF OR ITS EMPLOYEES. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 12 of 15 K. Immigration Nationality Act ENGINEER shall verify the identity and employment eligibility of its employees who perform work under this AGREEMENT, including completing the Employment Eligibility Verification Form (I-9). Upon request by CITY, ENGINEER shall provide CITY with copies of all I-9 forms and supporting eligibility documentation for each employee who performs work under this AGREEMENT. ENGINEER shall adhere to all Federal and State laws as well as establish appropriate procedures and controls so that no services will be performed by any ENGINEER employee who is not legally eligible to perform such services. ENGINEER SHALL INDEMNIFY CITY AND HOLD CITY HARMLESS FROM ANY PENALTIES, LIABILITIES, OR LOSSES DUE TO VIOLATIONS OF THIS PARAGRAPH BY ENGINEER, ENGINEER’S EMPLOYEES, SUBCONTRACTORS, AGENTS, OR LICENSEES. CITY, upon written notice to ENGINEER, shall have the right to immediately terminate this AGREEMENT for violations of this provision by ENGINEER. L. Prohibition On Contracts With Companies Boycotting Israel Engineer acknowledges that in accordance with Chapter 2271 of the Texas Government Code, City is prohibited from entering into a contract with a company for goods or services unless the contract contains a written verification from the company that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract. The terms “boycott Israel” and “company” shall have the meanings ascribed to those terms in Section 808.001 of the Texas Government Code. By signing this agreement, Engineer certifies that Engineer’s signature provides written verification to the City that Engineer: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the agreement. Failure to meet or maintain the requirements under this provision will be considered a material breach. M. Prohibition On Contracts With Companies Doing Business with Iran, Sudan, or a Foreign Terrorist Organization Sections 2252 and 2270 of the Texas Government Code restricts CITY from contracting with companies that do business with Iran, Sudan, or a foreign terrorist organization. By signing this agreement, Engineer certifies that Engineer’s signature provides written verification to the City that Engineer, pursuant to Chapters 2252 and 2270, is not ineligible to enter into this agreement and will not become ineligible to receive payments under this agreement by doing business with Iran, Sudan, or a foreign terrorist organization. Failure to meet or maintain the requirements under this provision will be considered a material breach. N. Prohibition on Contracts with Companies Boycotting Certain Energy Companies Engineer acknowledges that in accordance with Chapter 2274 of the Texas Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 13 of 15 Government Code, City is prohibited from entering into a contract with a company for goods or services unless the contract contains written verification from the company that it (1) does not boycott energy companies; and (2) will not boycott energy companies during the term of the contract. The terms “boycott energy company” and “company” shall have the meanings ascribed to those terms in Section 809.001 of the Texas Government Code. By signing this agreement, Engineer certifies that Engineer’s signature provides written verification to the City that Engineer: (1) does not boycott energy companies; and (2) will not boycott energy companies during the term of the agreement. Failure to meet or maintain the requirements under this provision will be considered a material breach. O. Prohibition on Contracts with Companies Boycotting Certain Firearm Entities and Firearm Trade Associations Engineer acknowledges that in accordance with Chapter 2274 of the Texas Government Code, City is prohibited from entering into a contract with a company for goods or services unless the contract contains written verification from the company that it (1) does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association; and (2) will not discriminate during the term of the contract against a firearm entity or firearm trade association. The terms “discriminate against a firearm entity or firearm trade association,” “firearm entity” and “firearm trade association” shall have the meanings ascribed to those terms in Chapter 2274 of the Texas Government Code. By signing this agreement, Engineer certifies that Engineer’s signature provides written verification to the City that Engineer: (1) does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association; and (2) will not discriminate during the term of the contract against a firearm entity or firearm trade association. Failure to meet or maintain the requirements under this provision will be considered a material breach. P. Termination Right for Contracts with Companies Doing Business with Certain Foreign-Owned Companies The City of Denton may terminate this Contract immediately without any further liability if the City of Denton determines, in its sole judgment, that this Contract meets the requirements under Chapter 2274, and Engineer is, or will be in the future, (i) owned by or the majority of stock or other ownership interest of the company is held or controlled by individuals who are citizens of China, Iran, North Korea, Russia, or other designated country (ii) directly controlled by the Government of China, Iran, North Korea, Russia, or other designated country, or (iii) is headquartered in China, Iran, North Korea, Russia, or other designated country. Q. Prohibition Against Personal Interest in Contracts No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision-making process of the performance Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 14 of 15 of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation as defined in the City’s Ethic Ordinance 23-1165 and in the City Charter chapter 2 article XI(Ethics). Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City’s Conflict of Interest Questionnaire. R. Agreement Documents This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, which supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. This AGREEMENT may be executed in one or more counterparts and each counterpart shall, for all purposes, be deemed an original, but all such counterparts shall together constitute but one and the same instrument. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A - Scope of Services Attachment B – Compensation Attachment C – Changes and Amendments to Standard Agreement Attachment D - Project Schedule Attachment E - Insurance These documents make up the AGREEMENT documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the AGREEMENT documents, the inconsistency or conflict shall be resolved by giving precedence first to the written AGREEMENT then to the AGREEMENT documents in the order in which they are listed above. The parties agree to transact business electronically. Any statutory requirements that certain terms be in writing will be satisfied using electronic documents and signing. Electronic signing of this document will be deemed an original for all legal purposes. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Standard Agreement for Engineering Related Design Services Revised Date: 3/22/22 Page 15 of 15 Duly executed by each party’s designated representative to be effective on _____________________________. BY: ENGINEER Kimley-Horn and Associates, Inc. Authorized Agent, Title Full Name: ________________________ BY: CITY OF DENTON, TEXAS PURCHASING AGENT APPROVED AS TO LEGAL FORM: MACK REINWAND, CITY ATTORNEY BY: ______________________________ THIS AGREEMENT HAS BEEN BOTH REVIEWED AND APPROVED as to financial and operational obligations and business terms. ___________________________ SIGNATURE ___________________________ TITLE ___________________________ DEPARTMENT Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD Vice President Scott Arnold Director Development Services 5/26/2026 ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 1 of 10 ATTACHMENT "A" Scope for Engineering Design Related Services for: E Sherman Drive (FM 428) at Long Road and Hartlee Field Road Traffic Signal and Pavement Markings Improvements Design The ENGINEER will perform its services pursuant to the requirements delineated below. Services under this attachment consist of engineering services for the preparation of preliminary, final plans, and the construction phase for the traffic signal, pavement markings and signing improvements at E Sherman Drive at Long Road and Hartlee Field Road. Project Understanding ENGINEER will provide services for the design of a traffic signal and pedestrian improvements at the intersection of FM 428 (E Sherman Drive) at Long Road and pavement markings and signing improvements design for E Sherman Road between Hartlee Field Road and Long Road. The ENGINEER will develop plans for the proposed improvements consisting of traffic signal poles, pedestrian poles, controller, curb ramps, sidewalk, and crosswalk for the pedestrian accommodations at these intersections. Following is our understanding of the project. ·The traffic signal warrants are completed by the CITY for traffic signal installations. ·Install/update curb ramps and push buttons as per the ADA/ PROWAG requirements. ·Paving work is limited to sidewalk and curb ramp at the intersection. The project does not include any paving work associated with travel lane and turn lanes widening. ·Roadway widening and additional turn lane are not required. ·Roadway and pedestrian lighting evaluations are not required. Luminaires will be provided on signal poles if there are no overhead conflicts. ·The project will not require environmental clearance. ·TxDOT permit is required for the construction as this signal is located along FM 428. ·The project will be bid for construction by the CITY. ·Coordination with TxDOT is required during design phase. Work under this agreement consists of project management, topographic survey, preliminary and final design, bid phase services, and construction phase services. WORK TO BE PERFORMED Task 1. Design Management Task 2. Traffic Data Collection Task 3. Traffic Signal Design Task 4. Pavement Markings and Signing Design Task 5. Topographic Survey Services Task 6. Bidding Phase Services Task 7. Construction Phase Services Task 8. TxDOT Permit Assistance Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 2 of 10 TASK 1. DESIGN MANAGEMENT. ENGINEER will manage the work outlined in this scope to ensure efficient and effective use of ENGINEER’s and CITY’s time and resources. ENGINEER will manage change, communicate effectively, coordinate internally and externally as needed, and proactively address issues with the CITY’s Project Manager and others as necessary to make progress on the work. 1.1.Managing the Team: ·Lead, manage and direct design team activities. ·Ensure Quality Control / Quality Assurance (QC/QA) is practiced in the performance of the work. ·Communicate internally among team members. ·Task and allocate team resources. 1.2.Communications and Reporting: ·Attend pre-design project kickoff/charter meeting with CITY staff to confirm and clarify scope, understand CITY’s objectives, and ensure economical and functional designs that meet CITY’s requirements. ·Attend one (1) field meeting with CITY representatives prior to the 60% submittal. ·Conduct and document monthly project update meetings with CITY’s Project Manager and CITY staff. ·Conduct review meetings with CITY at the end of each design phase. ·Conduct QC/QA reviews and document those activities. ·Prepare invoices and submit monthly in the format requested by the CITY. ·Prepare and submit monthly project status reports in the format provided by the CITY. ·Prepare and submit baseline project schedule initially, and project schedule updates as necessary. ·Coordinate with TxDOT throughout the project duration. ·Coordinate with other agencies and entities as necessary for the design of the proposed infrastructure and provide and obtain information needed to prepare the design. ·With respect to coordination with permitting authorities, ENGINEER shall communicate with permitting authorities such that their regulatory requirements are appropriately reflected in the designs. ENGINEER shall work with regulatory authorities to obtain approval of the designs, and make changes necessary to meet their requirements, as part of the design scope. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 3 of 10 ASSUMPTIONS ·One (1) pre-design project kickoff/chartering meeting ·One (1) field review meeting ·Three (3) plan review meetings ·Project design phase is estimated to be four (4) months. Bidding and construction Phase is estimated to be twelve (12) months. DELIVERABLES ·Meeting summaries with action items ·Baseline design schedule and schedule updates ·Monthly project status reports. ·Monthly invoices TASK 2. TRAFFIC DATA COLLECTION ENGINEER will, via a sub-consultant, collect 13 hour turning movement traffic volume counts for E Sherman Drive at Hartlee Field Road to evaluate the need of traffic signal at Hartlee Field Road intersection. DELIVERABLES ·Traffic Data TASK 3. TRAFFIC SIGNAL DESIGN PRELIMINARY (60 PERCENT) Preliminary traffic signal plans and specifications shall be submitted to CITY per the approved Project Schedule. The purpose of the preliminary design is for the ENGINEER to identify, develop, communicate through the defined deliverables, and recommend the design concept that successfully addresses the design problem, and to obtain the CITY’s endorsement of the preliminary design. ENGINEER will develop the preliminary design of the infrastructure as follows. 3.1.Record Drawing Research and Basemap Assembly ·In addition to data obtained from the CITY, ENGINEER will research and make efforts to obtain pertinent information to aid in the coordination of the proposed improvements with any planned future improvements that may influence the project. ENGINEER will also identify and seek to obtain data for existing conditions that may impact the project including; utilities, agencies (CITY, TxDOT, etc), CITY Master Plans, and property ownership as available from the Tax Assessor's office. ·The ENGINEER will consult with the CITY’s Public Works Department, public utilities, private utilities, and government agencies to determine the approximate Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 4 of 10 location of above and underground utilities, and other facilities (current and future) that have an impact or influence on the project. 3.2.Utility Clearance ·ENGINEER will develop the design of CITY facilities to avoid or minimize conflicts with existing utilities, and where known and possible consider potential future utilities in designs. Where conflicts cannot be avoided, coordination of Utility Conflicts will begin at the Preliminary Design phase. ·In the case of a public utility conflict, the ENGINEER will design CITY facilities to avoid or minimize conflicts with existing utilities, and where known and possible, consider potential future utilities in designs. 3.3.The Preliminary Design Package will consist of the following: ·Preliminary cover and index of sheets including project limits, area location map and beginning and end station limits. ·Quantity Summary page. ·Existing topography of the project area which will consist of existing ROW, existing curbs, sidewalks, and curb ramps. ·Preliminary design plan sheets showing existing and proposed improvements consisting of curb ramps, signal poles, foundations, conduit, service connection, controller etc. The preliminary plans also consist of existing and proposed ROW, existing and proposed drainage structures, and CITY owned and franchise utilities. ·Documentation of key design decisions. ·Opinion of probable construction cost (OPCC). 3.4.Constructability Review ·After 60% percent submittal with the CITY, the ENGINEER shall schedule and attend a project site visit with the CITY Project Manager and CITY staff to walk the project. The ENGINEER shall summarize the comments from the field visit and submit this information to the CITY in writing. FINAL PLANS AND FINAL CONSTRUCTION DOCUMENTS (90 PERCENT AND 100%) Upon approval of the Preliminary plans, ENGINEER will prepare construction plans as follows: ·Final draft construction plans (90%) and specifications will be submitted to CITY per the approved Project Schedule. ·Following a 90% construction plan review meeting with the CITY, the ENGINEER shall submit Final Plans (100%) to the CITY per the approved Project Schedule. Each plan sheet shall be stamped, dated, and signed by the ENGINEER registered in the State of Texas. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 5 of 10 ·A Quantity Summary page will be included in both the 90% and 100% design packages. Each design sheet of those packages will include a quantity take off table. ·The ENGINEER shall submit an OPCC with both the 90% and 100% design packages. This estimate will use TxDOT’s bid items. ASSUMPTIONS ·The ENGINEER has no control over the cost of labor, materials, equipment, or over the Contractor's methods of determining prices or over competitive bidding or market conditions. Opinions of probable costs provided herein are based on the information known to ENGINEER at this time and represent only the ENGINEER's judgment as a design professional familiar with the construction industry. The ENGINEER cannot and does not guarantee that proposals, bids, or actual construction costs will not vary from its opinions of probable costs. ·PDF of 11”x17” size plans will be delivered to CITY for the 60% design. ENGINEER shall not proceed with Final Design activities without written approval by the CITY of the 60% Design Package. ·PDF of 11”x17” size drawings will be delivered for the 90% Design package. ·PDF of 11”x17” size drawings will be delivered for the 100% Design package. DELIVERABLES ·60% preliminary Plans ·90% construction plans. ·100% construction plans and applicable letting forms and documents. ·Key Design Decision Documents ·OPCC including summaries of bid items and quantities using CITY’s standard bid items and format. TASK 4. PAVEMENT MARKING AND SIGNING DESIGN. ENGINEER will provide the pavement marking and signing plan as follows. ·The pavement marking design on Sherman Road will extend from approximately 300 feet south of Hartlee Field Road to 300 feet north of Long Road. ·A new southbound left turn lane will be provided at the intersection of Sherman Road and Hartlee Field Road. ·New lane assignment signs will be provided for the southbound left turn lane at Sherman Road and Hartlee Field Road intersection. ·Existing traffic signs within the limit of striping will be replaced as necessary. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 6 of 10 ASSUMPTIONS ·Pavement marking and signing plans will be included with the traffic signal plans completed under task 3. DELIVERABLES ·60% pavement markings and signing layout. ·90% and Final pavement markings and signing layout. TASK 5. TOPOGRAPHIC SURVEY SERVICES. ENGINEER will provide survey support as follows. 5.1 Design Survey ·ENGINEER will perform field surveys to collect horizontal and vertical elevations and other information needed by ENGINEER in the design and preparation of traffic signal plans for the project. Information gathered during the survey will consist of topographic data, elevations of all sanitary and adjacent storm sewers, rim/invert elevations, structures, trees (measure caliper, identify overall canopy, and other features relevant to the final plan sheets. ·The minimum survey information to be provided on the plans shall consist of the following: -A Project Control Sheet, showing ALL Control Points, used or set while gathering data. Generally, on a scale of not less than 1:400: -The following information about each Control Point; a.Identified (Existing. CITY Monument #8901, PK Nail, 5/8” Iron Rod) b.X, Y and Z Coordinates, in an identified coordinate system, and a referred bearing base. Z coordinate on CITY Datum only. c.Descriptive Location. -Coordinates on all P.C.’s, P.T.’s, P.I.’s, Manholes, Valves, etc., in the same coordinate system, as the Control. -No less than two horizontal bench marks, per line or location. -Bearings given on all proposed centerlines, or baselines. -Station equations relating utilities to paving, when appropriate. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 7 of 10 ASSUMPTIONS ·Survey will extend approximately 200 feet from the center of Sherman Road and Long Road intersection on all approaches. ·Pavement markings design beyond the survey limit will be provided using aerial imagery. DELIVERABLES ·Drawing of the project layout with dimensions and coordinate list. TASK 6. BIDDING PHASE SERVICES ENGINEER will complete the following tasks for the bidding phase of the project. 6.1. Bidding Support ·Prepare project manual and construction specifications for project bidding. ·Attend pre-bid meeting and bid opening meeting. ·Assist with bidder questions. ·Prepare bid tabulations for the bid received to check the accuracy. DELIVERABLES ·Addenda. ·Responses to bidder questions. ·Bid Tabulation for received bids. TASK 7. CONSTRUCTION PHASE SERVICES. ENGINEER will support the construction phase of the project as follows. 7.1. Construction Support ·The ENGINEER shall attend the preconstruction conference. ·Visits to Site and Observation of Construction. ENGINEER will make up to ten (10) visits as directed by CITY in order to observe the progress of the work. Such observations will not be exhaustive or extend to every aspect of Contractor's work. Observations will be limited to spot checking, selective measurement, and similar methods of general observation. Based on information obtained during site visits, ENGINEER will evaluate whether Contractor's work is generally proceeding in accordance with the Contract Documents, and ENGINEER will keep CITY informed of the general progress of the work. ENGINEER will not supervise, direct, or have control over Contractor's work, nor shall ENGINEER have authority to stop the Work or have responsibility for the means, methods, techniques, equipment choice and usage, schedules, or procedures of construction selected by Contractor, for safety programs incident to Contractor's work, or for any failure of Contractor to comply with any laws. ENGINEER does not Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 8 of 10 guarantee the performance of any Contractor and has no responsibility for Contractor's failure to perform its work in accordance with the Contract Documents. ·Clarifications and Interpretations. ENGINEER will respond to reasonable and appropriate Contractor requests for information and issue necessary clarifications and interpretations of the Contract Documents. Any orders authorizing variations from the Contract Documents will be made by CITY or TxDOT. ·Shop Drawings and Samples. ENGINEER will review and approve or take other appropriate action in respect to Shop Drawings and Samples and other data which Contractor is required to submit, but only for conformance with the information given in the Contract Documents. Such review and approvals or other action will not extend to means, methods, techniques, equipment choice and usage, schedules, or procedures of construction or to related safety programs. ·Substantial Completion. ENGINEER will, after notice from Contractor that it considers the Work ready for its intended use, in company with City, TxDOT, and Contractor, conduct a site visit to determine if the Work is substantially complete. Work will be considered substantially complete following satisfactory completion of all items with the exception of those identified on a final punch list. ·Final Notice of Acceptability of the Work. ENGINEER will conduct a final site visit to determine if the completed Work of Contractor is generally in accordance with the Contract Documents and the final punch list. ASSUMPTIONS ·Five (5) site visits are assumed. ·Three (3) submittal reviews are assumed. ·Two (2) RFI’s are assumed. DELIVERABLES ·Response to Contractor’s Request for Information. ·Review of shop drawings. ·Final Punch List items. TASK 8. TxDOT PERMIT ASSISTANCE. ENGINEER will provide permitting support for the CITY in an effort to obtain any and all agreements and/or permits normally required for a project of this size and type, as follows: 8.1 Texas Department of Transportation (TxDOT) Permit ·ENGINEER will submit plans for TxDOT review and approval. ENGINEER will address any comments TxDOT has on the design. ·ENGINEER will prepare and complete the TxDOT permit application on behalf of the CITY for this traffic signal and submit it to TxDOT. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 9 of 10 ·TxDOT permit application will be signed by the CITY Staff. ·TxDOT permit required for this project is assumed to be Form 1058. Any additional permit requirements will be considered as additional services. ·It is assumed that Local On-System Agreement (LOSA) with TxDOT will not be required for this project. ASSUMPTIONS ·Permit preparation will begin after approval of the Final Design. ·One (1) on-site meeting with TxDOT is assumed. DELIVERABLES A.Copies of Permit Applications B.Copies of Approved Permits Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT ADESIGN SERVICES FOR E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment A Page 10 of 10 ADDITIONAL SERVICES NOT INCLUDED IN THE EXISTING SCOPE OF SERVICES Additional Services not included in the existing Scope of Services – CITY and ENGINEER agree that the following services are beyond the Scope of Services described in the tasks above. However, ENGINEER can provide these services, if needed, upon the CITY’s written request. Any additional amounts paid to the ENGINEER as a result of any material change to the Scope of the Project shall be agreed upon in writing by both parties before the services are performed. These additional services include the following: ·Sub-surface Utility Engineering (SUE). ·Roadway design and drainage design. ·Preparation of ROW acquisition or easement documents. ·Negotiation of easements or property acquisition. ·Additional traffic analysis including crash research, analysis and crash exhibit. ·Landscaping and irrigation design. ·Environmental permitting or studies. ·Submittal and permitting fees. ·Color renderings and graphics ·Services related to the development of the CITY’s project financing and/or budget. ·Construction management services. ·Services necessary due to the default of the Contractor. ·Services related to damages caused by fire, flood, earthquake or other acts of God. ·Services related to warranty claims, enforcement and inspection after final completion. ·Services to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. ·Performance of miscellaneous and supplemental services related to the project as requested by the CITY. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD ATTACHMENT B E SHERMAN DRIVE AT LONG ROAD AND HARTLEE FIELD ROAD TRAFFIC SIGNAL AND PAVEMENT MARKING IMPROVEMETNS DESIGN City of Denton, Texas Attachment B Page 1 of 1 ATTACHMENT "B" Compensation for Engineering Design Related Services for: E Sherman Drive (FM 428) at Long Road and Hartlee Field Road Traffic Signal and Pavement Markings Improvements Design Total compensation for the ENGINEER contemplated under the terms of this agreement shall be lump sum total not-to-exceed $77,000 for all services including reimbursable expenses. The CITY shall compensate the ENGINEER as follows: The total compensation for Task 1 – Task 8 shall be on a lump sum basis and not to exceed $77,000. Progress payments for shall be paid monthly based on the actual work satisfactorily completed per month. ·Task 1 – Design Management $ 7,000 ·Task 2 – Traffic Data Collection $ 1,000 ·Task 3 – Traffic Signal Design $ 38,000 ·Task 4 – Pavement Markings and Signing Design $ 10,000 ·Task 5 – Topographic Survey Services $ 8,500 ·Task 6 – Bidding Phase $ 4,000 ·Task 7 – Construction Phase Services $ 5,000 ·Task 8 – TxDOT Permit Assistance $ 3,500 Sub-total: $ 77,000 Grand Total $ 77,000 ENGINEER will not exceed the total maximum fee shown without authorization from the CITY. Individual task amounts are provided for budgeting purposes only. All permitting, application, and similar project fees will be paid directly by the CITY. Payment will be due within 30 days of your receipt of the invoice and should include the invoice number and ENGINEER project number. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD City of Denton, Texas Page 1 of 1 ATTACHMENT “C” CHANGES AND AMENDMENTS TO STANDARD AGREEMENT Design Services for E Sherman Drive (FM 428) at Long Road and Hartlee Field Road Traffic Signal and Pavement Markings Improvements Design No modifications to the Standard Agreement are necessary for this project. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD TASK START DATE END DATE Project Initiation Design Notice to Proceed May-26 May-26 Design Data Collection/Survey May-26 Jun-26 60% Submittal Jun-26 Jul-26 City Review Jul-26 Jul-26 90% Submittal Jul-26 Aug-26 City Review Aug-26 Sep-26 Final Design Submittal Sep-26 Sep-26 Bid Package Submittal Sep-26 Oct-26 Bidding Bid Advertisement Oct-26 Dec-26 Contractor Selection Dec-26 Feb-27 Contractor Notice to Proceed Feb-27 Construction Construction Feb-27 Aug-27 Attachment "D" E Sherman Drive at Long Road and Hartlee Field Road Traffic Signal and Pavement Markings Improvements Design Kimley-Horn and Associates, Inc. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD Attachment E INSURANCE REQUIREMENTS Respondent’s attention is directed to the insurance requirements below. It is highly recommended that respondents confer with their respective insurance carriers or brokers to determine in advance of Proposal/Bid submission the availability of insurance certificates and endorsements as prescribed and provided herein. If an apparent low respondent fails to comply strictly with the insurance requirements, that respondent may be disqualified from award of the contract. Upon contract award, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. As soon as practicable after notification of contract award, Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractors are strongly advised to make such requests prior to proposal/bid opening, since the insurance requirements may not be modified or waived after proposal/bid opening unless a written exception has been submitted with the proposal/bid. Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the AGREEMENT, or longer, if so noted: • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- or better. • Any deductibles or self-insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its officials, agents, employees, and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. • Liability policies shall be endorsed to provide the following: o Name as Additional Insured the City of Denton, its Officials, Agents, Employees, and volunteers. o That such insurance is primary to any other insurance available to the Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. o Provide a Waiver of Subrogation in favor of the City of Denton, its officials, agents, employees, and volunteers. • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this AGREEMENT shall additionally comply with the following specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the AGREEMENT, or longer, if so noted: A. COMMERCIAL GENERAL LIABILITY INSURANCE Commercial General Liability Insurance including, but not limited to, Premises/Operations, Personal & Advertising Injury, Products/Completed Operations, Independent Contractors, and Contractual Liability with minimum combined bodily injury (including death) and property damage limits of $1,000,000.00 per occurrence and $2,000,000.00 general aggregate. B. PROFESSIONAL LIABILITY INSURANCE If CONTRACTOR is a licensed or certified person who renders professional services, then Professional Liability Insurance to provide coverage against any claim which the CONTRACTOR becomes legally obligated to pay as damages arising out of the performance of professional services caused by Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD any negligent error, omission or act with minimum limits of $1,000,000.00 per claim, $2,000,000.00 annual aggregate. SUBCONTRACTING LIABILITY (1) Without limiting any of the other obligations or liabilities of the CONTRACTOR, the CONTRACTOR shall require each Subcontractor performing work under the contract, at the Subcontractor's own expense, to maintain during the engagement with the CITY, types and limits of insurance that are appropriate for the services/work being performed, comply with all applicable laws and are consistent with industry standards. The Subcontractor’s liability insurance shall name CONTRACTOR as an additional insured. (2) CONTRACTOR shall obtain and monitor the certificates of insurance from each Subcontractor. CONTRACTOR must retain the certificates of insurance for the duration of the contract and shall have the responsibility of enforcing insurance requirements among its subcontractors. The CITY shall be entitled, upon request and without expense, to receive copies of these certificates. Docusign Envelope ID: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD Certificate Of Completion Envelope Id: 6B513A8A-C3DC-8CF3-8171-8A781E3A2AFD Status: Completed Subject: ***Purchasing Approval*** 8377-021 Sherman at Long and Hartlee Improvements Source Envelope: Document Pages: 32 Signatures: 4 Envelope Originator: Certificate Pages: 6 Initials: 1 Christina Dormady AutoNav: Enabled EnvelopeId Stamping: Enabled Time Zone: (UTC-06:00) Central Time (US & Canada) 901B Texas Street Denton, TX 76209 christina.dormady@cityofdenton.com IP Address: 198.49.140.10 Record Tracking Status: Original 5/19/2026 9:28:56 AM Holder: Christina Dormady christina.dormady@cityofdenton.com Location: DocuSign Signer Events Signature Timestamp Christina Dormady christina.dormady@cityofdenton.com Buyer City of Denton Security Level: Email, Account Authentication (None) Completed Using IP Address: 198.49.140.10 Sent: 5/19/2026 9:32:08 AM Viewed: 5/19/2026 9:32:17 AM Signed: 5/19/2026 9:32:23 AM Electronic Record and Signature Disclosure: Not Offered via Docusign Christa Christian Christa.christian@cityofdenton.com Purchasing Supervisor City of Denton Security Level: Email, Account Authentication (None) Signature Adoption: Pre-selected Style Using IP Address: 198.49.140.10 Sent: 5/19/2026 9:32:24 AM Viewed: 5/20/2026 8:37:16 AM Signed: 5/20/2026 8:37:20 AM Electronic Record and Signature Disclosure: Not Offered via Docusign Leah Bush leah.bush@cityofdenton.com Assistant City Attorney Security Level: Email, Account Authentication (None)Signature Adoption: Pre-selected Style Using IP Address: 198.49.140.104 Sent: 5/20/2026 8:37:22 AM Viewed: 5/22/2026 11:59:28 AM Signed: 5/22/2026 12:53:14 PM Electronic Record and Signature Disclosure: Not Offered via Docusign Scott Arnold Scott.Arnold@kimley-horn.com Vice President Kimley-Horn and Associates, Inc. Security Level: Email, Account Authentication (None) Signature Adoption: Uploaded Signature Image Using IP Address: 216.76.52.25 Signed using mobile Sent: 5/22/2026 12:53:16 PM Viewed: 5/22/2026 1:28:10 PM Signed: 5/22/2026 1:29:49 PM Electronic Record and Signature Disclosure: Accepted: 3/27/2020 10:55:11 AM ID: a1f38400-e5cc-4b57-8548-4dd7e031355d Signer Events Signature Timestamp Charlie Rosendahl Charlie.rosendahl@cityofdenton.com Director Development Services Security Level: Email, Account Authentication (None) Signature Adoption: Pre-selected Style Using IP Address: 198.49.140.10 Sent: 5/22/2026 1:29:51 PM Viewed: 5/22/2026 2:25:44 PM Signed: 5/22/2026 3:08:30 PM Electronic Record and Signature Disclosure: Accepted: 5/22/2026 2:25:44 PM ID: c8c21acb-0eb4-4c42-8ab6-78c4b5cc5648 Christina Dormady christina.dormady@cityofdenton.com Buyer City of Denton Security Level: Email, Account Authentication (None) Signature Adoption: Pre-selected Style Using IP Address: 198.49.140.104 Sent: 5/22/2026 3:08:32 PM Viewed: 5/26/2026 7:42:14 AM Signed: 5/26/2026 7:42:30 AM Electronic Record and Signature Disclosure: Not Offered via Docusign In Person Signer Events Signature Timestamp Editor Delivery Events Status Timestamp Agent Delivery Events Status Timestamp Intermediary Delivery Events Status Timestamp Certified Delivery Events Status Timestamp Carbon Copy Events Status Timestamp Cheyenne Defee cheyenne.defee@cityofdenton.com Procurement Administration Supervisor City of Denton Security Level: Email, Account Authentication (None) Sent: 5/26/2026 7:42:32 AM Electronic Record and Signature Disclosure: Not Offered via Docusign Chandrakanth Muruganandham chandrakanth.muruganandham@cityofdenton.com Security Level: Email, Account Authentication (None) Sent: 5/26/2026 7:42:33 AM Electronic Record and Signature Disclosure: Accepted: 4/29/2026 4:57:21 PM ID: 544c9e87-9ca7-4a5b-9805-dd819ac855bb Witness Events Signature Timestamp Notary Events Signature Timestamp Envelope Summary Events Status Timestamps Envelope Sent Hashed/Encrypted 5/19/2026 9:32:08 AM Certified Delivered Security Checked 5/26/2026 7:42:14 AM Signing Complete Security Checked 5/26/2026 7:42:30 AM Completed Security Checked 5/26/2026 7:42:33 AM Payment Events Status Timestamps Electronic Record and Signature Disclosure ELECTRONIC RECORD AND SIGNATURE DISCLOSURE From time to time, City of Denton (we, us or Company) may be required by law to provide to you certain written notices or disclosures. Described below are the terms and conditions for providing to you such notices and disclosures electronically through your DocuSign, Inc. (DocuSign) Express user account. Please read the information below carefully and thoroughly, and if you can access this information electronically to your satisfaction and agree to these terms and conditions, please confirm your agreement by clicking the 'I agree' button at the bottom of this document. Getting paper copies At any time, you may request from us a paper copy of any record provided or made available electronically to you by us. For such copies, as long as you are an authorized user of the DocuSign system you will have the ability to download and print any documents we send to you through your DocuSign user account for a limited period of time (usually 30 days) after such documents are first sent to you. After such time, if you wish for us to send you paper copies of any such documents from our office to you, you will be charged a $0.00 per-page fee. You may request delivery of such paper copies from us by following the procedure described below. Withdrawing your consent If you decide to receive notices and disclosures from us electronically, you may at any time change your mind and tell us that thereafter you want to receive required notices and disclosures only in paper format. How you must inform us of your decision to receive future notices and disclosure in paper format and withdraw your consent to receive notices and disclosures electronically is described below. Consequences of changing your mind If you elect to receive required notices and disclosures only in paper format, it will slow the speed at which we can complete certain steps in transactions with you and delivering services to you because we will need first to send the required notices or disclosures to you in paper format, and then wait until we receive back from you your acknowledgment of your receipt of such paper notices or disclosures. To indicate to us that you are changing your mind, you must withdraw your consent using the DocuSign 'Withdraw Consent' form on the signing page of your DocuSign account. This will indicate to us that you have withdrawn your consent to receive required notices and disclosures electronically from us and you will no longer be able to use your DocuSign Express user account to receive required notices and consents electronically from us or to sign electronically documents from us. All notices and disclosures will be sent to you electronically Unless you tell us otherwise in accordance with the procedures described herein, we will provide electronically to you through your DocuSign user account all required notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you during the course of our relationship with you. To reduce the chance of you inadvertently not receiving any notice or disclosure, we prefer to provide all of the required notices and disclosures to you by the same method and to the same address that you have given us. Thus, you can receive all the disclosures and notices electronically or in paper format through the paper mail delivery system. If you do not agree with this process, please let us know as described below. Please also see the paragraph immediately above that describes the consequences of your electing not to receive delivery of the notices and disclosures electronically from us. Electronic Record and Signature Disclosure created on: 7/21/2017 3:59:03 PM Parties agreed to: Scott Arnold, Charlie Rosendahl, Chandrakanth Muruganandham How to contact City of Denton: You may contact us to let us know of your changes as to how we may contact you electronically, to request paper copies of certain information from us, and to withdraw your prior consent to receive notices and disclosures electronically as follows: To contact us by email send messages to: purchasing@cityofdenton.com To advise City of Denton of your new e-mail address To let us know of a change in your e-mail address where we should send notices and disclosures electronically to you, you must send an email message to us at melissa.kraft@cityofdenton.com and in the body of such request you must state: your previous e-mail address, your new e-mail address. We do not require any other information from you to change your email address.. In addition, you must notify DocuSign, Inc to arrange for your new email address to be reflected in your DocuSign account by following the process for changing e-mail in DocuSign. To request paper copies from City of Denton To request delivery from us of paper copies of the notices and disclosures previously provided by us to you electronically, you must send us an e-mail to purchasing@cityofdenton.com and in the body of such request you must state your e-mail address, full name, US Postal address, and telephone number. We will bill you for any fees at that time, if any. To withdraw your consent with City of Denton To inform us that you no longer want to receive future notices and disclosures in electronic format you may: i. decline to sign a document from within your DocuSign account, and on the subsequent page, select the check-box indicating you wish to withdraw your consent, or you may; ii. send us an e-mail to purchasing@cityofdenton.com and in the body of such request you must state your e-mail, full name, IS Postal Address, telephone number, and account number. We do not need any other information from you to withdraw consent.. The consequences of your withdrawing consent for online documents will be that transactions may take a longer time to process.. Required hardware and software Operating Systems: Windows2000? or WindowsXP? Browsers (for SENDERS): Internet Explorer 6.0? or above Browsers (for SIGNERS): Internet Explorer 6.0?, Mozilla FireFox 1.0, NetScape 7.2 (or above) Email: Access to a valid email account Screen Resolution: 800 x 600 minimum Enabled Security Settings: •Allow per session cookies •Users accessing the internet behind a Proxy Server must enable HTTP 1.1 settings via proxy connection ** These minimum requirements are subject to change. If these requirements change, we will provide you with an email message at the email address we have on file for you at that time providing you with the revised hardware and software requirements, at which time you will have the right to withdraw your consent. Acknowledging your access and consent to receive materials electronically To confirm to us that you can access this information electronically, which will be similar to other electronic notices and disclosures that we will provide to you, please verify that you were able to read this electronic disclosure and that you also were able to print on paper or electronically save this page for your future reference and access or that you were able to e-mail this disclosure and consent to an address where you will be able to print on paper or save it for your future reference and access. Further, if you consent to receiving notices and disclosures exclusively in electronic format on the terms and conditions described above, please let us know by clicking the 'I agree' button below. By checking the 'I Agree' box, I confirm that: • I can access and read this Electronic CONSENT TO ELECTRONIC RECEIPT OF ELECTRONIC RECORD AND SIGNATURE DISCLOSURES document; and • I can print on paper the disclosure or save or send the disclosure to a place where I can print it, for future reference and access; and • Until or unless I notify City of Denton as described above, I consent to receive from exclusively through electronic means all notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to me by City of Denton during the course of my relationship with you.