HomeMy WebLinkAbout1994-054E:\NGD0CS\0RD\LIGHT.SYN
ORDINANCE NO. %-DS
AN ORDINANCE AUTHORIZING A TRAFFIC LIGHT SYNCHRONIZATION PROGRAM
GRANT APPLICATION (TLS III) TO PROMOTE THE CONSERVATION OF ENERGY
RESOURCES; AND DECLARING AN EFFECTIVE DATE.
WHEREAS, the City of Denton recognizes that it is in the
interest of the national economy to promote the conservation of
energy resources and to reduce our nation's dependence on costly
foreign oil; and
WHEREAS, the retiming of signals by the City of Denton will
provide benefits to the local community in the form of improved
traffic flow, reduced fuel consumption, reduced vehicle operating
costs, reduced air pollutant emissions, and improved safety due to
smoother traffic flow; and
WHEREAS, funds have been established and are available through
the State Department of Highways and Public Transportation for
grants to local governments for traffic signal retiming projects;
NOW, THEREFORE,
THE COUNCIL OF THE CITY OF DENTON HEREBY ORDAINS:
SECTION I. That the City Council of the City of Denton autho-
rizes the submission of an application to the State Department of
Highways and Public Transportation for a Traffic Light Synchro-
nization grant and, if the application is selected for funding, the
City Manager of the City of Denton is hereby authorized and empow-
ered to execute in the name of the City of Denton all necessary
applications, contracts, and agreements to implement and carry out
the purposes specified in this ordinance and commit the expenditure
of funds required by such documents.
SECTION II. That this ordinance shall become effective immed-
iately upon its passage and approval.
PASSED AND APPROVED this the�d day of , 1994.
Contract Number 585TLF6009
TRAFFIC LIGHT SYNCHRONIZATION
GRANT AGREEMENT
THE STATE OF TEXAS **
THE COUNTY OF TRAVIS **
THIS CONTRACT IS MADE BY AND BETWEEN THE STATE OF TEXAS,
acting by and through the Texas Department of Transportation, hereinafter called the
State and the city of Denton , acting by and through its duly authorized officers,
hereinafter called the Local Government.
WITNESSETH
WHEREAS, Article 4413(56), Texas Civil Statutes, declares that the Office of the
Governor may designate State agencies to supervise, manage or administer the imple-
mentation of a grant program financed under the Oil Overcharge Restitutionary Act
(Art. 4413(56)); and,
WHEREAS, pursuant to Article 4413(56), the Texas Department of Transportation
submitted a proposed grant program, hereinafter called Traffic Light Synchronization,
or TLS, designed to increase energy efficiency in the movement of traffic, and the Office
of the Governor did approve the proposed program, and signified its approval by
contract executed between the Texas Department of Transportation and the Office of
the Governor dated September 1, 1990, or as amended; and,
WHEREAS, the Local Government submitted a grant application to the State describ-
ing a plan to re -time a set of traffic signals in accordance with the State's instructions,
and the grant application was approved by the State and the project described therein
was selected for financial assistance; and,
WHEREAS, it is the desire of the Local Government to enter into this grant agreement
for financial assistance for the project described in the grant application in order to
increase energy efficiency in the movement of traffic.
NOW, THEREFORE, in consideration of the premises and of the mutual covenants and
agreements of the parties hereto, the State and the Local Government do mutually
agree as follows.
Page 1 of 7
AGREEMENT
Article 1. Contract Period
This contract becomes effective on the date on which the final signature is added, the
final signature being that of the party whose signing makes the contract fully exe-
cuted by all parties hereto. The contract shall terminate twelve months from that date
or July 14, 1995, whichever comes first, unless terminated or modified as hereinafter
provided.
Article 2. Contract Amount
The maximum amount payable to the Local Government under this contract shall not
exceed $ 54,676.40 This amount constitutes not more than 75% of the total project
cost of $ 72.901.87
The amount may be increased only if the State approves a request for additional
funding submitted by the Local Government, if additional funds are available. Any
such increase must be authorized in a written amendment to this contract.
Article 3. Project Description
Depending upon the availability of funds, the Local Government shall commence and
complete a project providing for the re -timing of traffic signals within its jurisdiction,
generally located on Oak/Hickory
The project is fully described in the grant application, attached hereto and labeled
Exhibit 1. The Local Government shall not perform any activity under this contract
except as described in said Exhibit 1. Additional activity under this contract must be
authorized in a written amendment signed by the parties hereto in which the modi-
fications or additions to the project are fully described.
The Local Government agrees to deliver the following products to the State in accord-
ance with the application:
• A "before" field evaluation
• An "after" field evaluation
In addition to the above products, quarterly progress reports that summarize project
activities are required.
Failure to deliver the products as specified in the application may result in termination
of this agreement as provided hereinafter.
Article 4. Compensation
All payments made hereunder will be made in accordance with the category totals of
the Approved Project Budget included in Exhibit 1. To be eligible for reimbursement
under this contract, a cost must be incurred within the contract period specified in
Article 1 above and be authorized in the Approved Project Budget included in Exhibit 1.
Payment of costs incurred under this contract is further governed by the cost principles
outlined in 48 CFR 1-31, (Federal Acquisition Regulations).
If the Local Government requests to move dollars from one category to another
category, a request in writing must be submitted to the State. The State will reply in
writing approving or disapproving the request.
Page 2 of 7
Article 4. Compensation (cont.)
The Local Government agrees to submit monthly requests for reimbursement,
using billing statements acceptable to the State. The original billing statement and
one copy is to be submitted to the State's District Office, at the address specified on the
signature page of this agreement.
Before 35% of the contract is paid, an approved `Before" field evaluation must be
submitted to the State.
Before 85% of the contract is paid, an approved "After" field evaluation must be
submitted to the State.
Requests for reimbursement must be submitted within 60 days upon completion of the
project, but no later than September 15, 1995.
The State will exercise good faith effort to make payments within thirty days of receipt
of properly prepared and documented requests for reimbursement. All payments,
however, are contingent upon the availability of appropriated funds.
Article 5. Contract Amendments
The Local Government may request an amendment of the contract for additional time,
changes in work, or additional funds for additional tasks to be performed under this
contract, and if the request is justified by the Local Government and the State
determines that the request is beneficial to the State and the Local Government and to
the purpose of the grant, a written amendment is to be executed to authorize additional
time, tasks, or additional funds, if additional funds are available.
The amendment shall be agreed upon by the State and Local Government. Any such
amendment shall be made before the termination of the contract as specified in
Article 1. The Local Government can undertake at its own expense any activities
associated with the approved project, but those additional activities will not be eligible
for reimbursement by the State.
Article 6. Inspection of Work
The State shall have the right at all reasonable times to inspect or otherwise evaluate
the work performed or being performed hereunder and the premises in which it is being
performed. If any inspection or evaluation is made on the premises of the Local
Government or subcontractor, the Local Government shall provide and require his
subcontractor to provide all reasonable facilities and assistance for the safety and
convenience of the inspectors in the performance of their duties. All inspections and
evaluations shall be performed in such a manner as will not unduly delay the work.
Article,7. Disputes and Remedies
The Local Government shall be responsible for the settlement of all contractual and
administrative issues arising out of procurements entered in support of contract work.
Disputes concerning performance or payment shall be submitted to the State for
settlement with the Executive Director of the Texas Department of Transportation
acting as referee.
This agreement shall not be considered as specifying the exclusive remedy for any
dispute or violation or breach of contract terms, but all remedies existing at law and
in equity may be availed of by either party and shall be cumulative.
Page 3 of 7
Article 8. Records
The Local Government agrees to maintain all books, documents, papers, accounting
records, and other evidence pertaining to costs incurred and work performed hereunder
and shall make such materials available at its office during the contract period and
for three years from the date of the final performance report under the contract. Such
materials shall be made available during the specified period for inspection by the State
for the purpose of making audits, examinations, excerpts, and transcriptions.
Article 9. Reporting
The Local Government shall promptly advise the State in writing of events which have
a significant impact upon the contract, including:
• Problems, delays, or adverse conditions which will materially affect the ability to
attain program objectives, prevent the meeting of time schedules or objectives, or pre-
clude the attainment of project work units by established time periods. This disclosure
shall be accompanied by a statement of the action taken, or contemplated, and any
State assistance needed to resolve the situation.
• Favorable developments or events that enable meeting time schedules and objec.
tives sooner than anticipated or producing more work units than originally projected.
Article 10. Audit
This contract shall be subject to audit for a three-year period from the date of the final
financial report.
Article 11. Subcontracts
Any subcontract for professional service rendered by individuals or organizations not
a part of the Local Government's organization shall not be executed without prior
authorization by the State. Subcontracts shall contain all required provisions of this
contract. No subcontract will relieve the Local Government of its responsibility under
this contract.
Article 12. Termination
• For Cause: Insufficient Funding
The State may terminate this contract at any time before the date of completion when-
ever it is determined that sufficient funds are not available to reimburse its share of the
cost of the project. The State shall give written notice to the Local Government at least
seven days prior to the effective date of termination, specifying the date of termination.
The State shall compensate the Local Government for those eligible costs incurred
during the contract period up through the time of termination. The Local Government
shall not incur new obligations for the terminated portion after the effective date of
termination.
Page 4 of 7
Article 12. Termination (coat.)
• For Cause: Nonperformance
The State may terminate this contract at any time before the date of completion if it
determines that the Local Government has failed to comply with the conditions of the
contract.The State shall give written notice to the Local Government at least seven
days prior to the effective date of termination and specify the effective date of termi-
nation and the reason for termination.
The State shall compensate the Local Government for those eligible costs incurred
during the contract period which are directly attributable to the completed portion
of the project covered by this contract, provided that the work has been completed in
a manner satisfactory to the State. The Local Government shall not incur new obliga-
tions for the terminated portion after the effective date of termination.
• For Convenience
If either party to this contract determines that the continuation of the contract in whole
or in part would not produce beneficial results commensurate with the further
expenditure of funds, the determining party shall give notice to the other party of such
determination, including the effective date and the portion to be terminated.
The State may terminate this contract for reasons of its own, not subject to the approval
of the Local Government.
• Ownership of Documents
Upon termination of this contract, whether for cause or for convenience, all finished or
unfinished documents, data, studies, surveys, reports, maps, drawing, models, photo-
graphs, etc. prepared by the Local Government shall at the option of the State become
the property of the State.
• Excepted Conditions
Except with respect to defaults of subcontractors, the Local Government shall not be in
default by reason of any failure in performance of this contract in accordance with its
terms (including any failure by the Local Government to progress in the performance of
the work) if such failure arises out of causes beyond the control and without the default
or negligence of the Local Government. Such causes may include but are not limited to
acts of nature or of the public enemy, acts of the government in either its sovereign or
contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight
embargoes, and unusually severe weather. In every case, however, the failure to
perform must be beyond the control and without the fault or negligence of the Local
Government.
Article 13. Compliance with Laws
The Local Government shall comply with all federal, state, and local laws, statutes,
ordinances, rules and regulations, and the orders and decrees of any courts or admin-
istrative bodies or tribunals in any matter affecting the performance of this contract,
including, without limitation, workers' compensation laws, minimum and maximum
salary and wage statutes and regulations and licensing laws and regulations. When
required, the Local Government shall furnish the State with satisfactory proof of its
compliance therewith.
Page 5 of 7
Article 14. Successors and Assigns
The State and the Local Government each binds itself, its successors, executors,
assigns and administrators to the other party to this agreement and to the successors,
executors, assigns and administrators of such other party in respect to all covenants
of this contract. Neither the State nor the Local Government shall assign, sublet, or
transfer its interest in this agreement without the written consent of the other.
Article 15. Property Management
The Local Government shall use its own property management system to control,
protect, preserve, use, maintain, and dispose of any property furnished to it by the
State or purchased pursuant to this agreement, provided that the procedures are not
in conflict with the State's property management procedures or property manage-
ment standards outlined in 49 CFR 18 (Section 18.32), "Uniform Administrative
Requirements for Grants and Cooperative Agreements to State and Local
Governments."
Article 16. Procurement Standards
The Local Government shall maintain and follow procurement standards which meet
or exceed the requirements of 49 CFR 18, "Uniform Administrative Requirements for
Grants and Cooperative Agreements to State and Local Governments."
Article 17. Debarment/Suspension
The Local Government is prohibited from making any award or permitting any award
at any tier to any party which is debarred or suspended or otherwise excluded from
or ineligible for participation in federal assistance programs under Executive Order
12549, Debarment and Suspension. The Local Government shall require any party to
a subcontract or purchase order awarded under this contract to certify its eligibility to
receive federal grant funds, and, when requested by the State, to furnish a copy of the
certification.
Article 18. Insurance
When directed by the State, the Local Government shall require its subcontractors to
secure insurance in the maximum statutory limits for tort liability, naming the State
as an additional insured under its terms. When so directed, the Local Government
shall require its subcontractor to furnish proof of insurance on forms satisfactory to
the State, and shall maintain the insurance during the contract period specified in
Article 1.
Article 19. Gratuities
Texas Transportation Commission policy mandates that employees of the Department
shall not accept any benefits, gifts or favors from any person doing business with or
who reasonably speaking may do business with the State under this contract. The only
exceptions allowed are ordinary business lunches and items that have received the
advanced written approval of the State's Executive Director.
Any person doing business with or who reasonably speaking may do business with the
State under this contract may not make any offer of benefits, gifts or favors to Texas
Department of Transportation employees, except as mentioned hereabove. Failure on
the part of the Local Government to adhere to this policy may result in termination of
this contract.
Page 6 of 7
Article 20. Indemnification
To the extent permitted by law, the Local Government shall save harmless the State
from all claims and liability due to the acts or omissions of the Local Government, its
agents or employees. The Local Government also agrees to save harmless the State
from any and all expenses, including attorney fees, all court costs and awards for dam-
ages, incurred by the State in litigation or otherwise resisting such claims or liabilities
as a result of any activities of the Local Government, its agents or employees.
Further, the Local Government agrees to protect, indemnify, and save harmless the
State from and against all claims, demands and causes of action of every kind and
character brought by any employee of the Local Government against the State due to
personal injuries and/or death to such employee resulting from any alleged negligent
act, by either commission or omission on the part of the Local Government or the State.
Article 21. Signatory Warranty
The undersigned signatory for the Local Government hereby represents and warrants
that he is an official of the organization for which he has executed this contract and that
he has full and complete authority to enter into the contract on behalf of the Local
Government.
IN WITNESS WHEREOF, THE PARTIES HAVE EXECUTED DUPLICATE
COUNTERPARTS TO EFFECTUATE THIS AGREEMENT.
LOCAL GOVERNMENT:
The City of Denton
Under authority of� ordi-
nance number
For the purpose Athis agreement, the
required notices, reports, claims, and c
For the Local Government:
STATE OF TEXAS
Executed for the Executive Director
and approved by the Texas Highway
Commission under the authority of
Minute Order No. 100002 and
Administrative Circular 26-93, or the
purpose and effect of activating and
carrying out the orders, established
policies or work programs heretofore
approved by the Texas Transportation
Commission.
ons
Date i
addresses shall be used to mail all
For the State (District Office):
fame- Huffman -
Box 1067
i i ..., my 75221 1067
Page 7 of 7
Texas bepartment of Transportation
Oak/Hickory
Traffic Light Synchronization Program III System
Grant Application
1) Legal Applicant
2) Vendor identification Number:
A.
Applicant Name City of Denton
17560005146000
b.
Organizational Unit- Engin�jng Dent
3) Project Traffic Engineer or Manager
c.
Street/P.O.9ox 215 E. McKinney St
(Name 8 Telephone)
d.
City Denton e. County_ Denton
Jerry Clark (817)566-8358
I.
state Tx g. Zip 76201
4) Number of Signalized Intersections:
h.
Population (1990 Census Bureau Figure):
• In jurisdiction 63
38
66,270
• In coordinated systems
I.
Pro!MJ?§A'61yf a et1N Tpb6T�lsphone):
is / b 8 7tl
• In proposed project 5
s) Proposed Funding
Attachments
a.
State Oil Overcharge Funds S54,676.40
a, Standard Assurances
b.
Local 518,225.47
b. Project Area Maps
c.
TxDOT (if signals are maintained
c. Description of Project
and operated by TxDOT) S
d. Quality of Service
d.
Other (Specify) S
e.
Total t72.901.87
e. Budget
NOTE:
The oil overcharge amount for equipment
f. Project Task Responsibility
shall not exceed 70% of the total amountof
g. Debarment Certif ication
oil overcharge funds requested.
6) General information
a.
Are any of your project signals operated or maintained by other agencies? Yes No X
_
If yes, describe
b.
Who currently makes the decisions on how to set your signals? City Engineer's staff
c.
Approximately how many local staff person -years (or fraction thereof) are currently devoted to traffic
signal timing in your jurisdiction? Include all categories of effort, including data acquisition, plan
development, implementation, checking and surveillance.
Approximately 40 person ypnrs
Comments:
d.
Who is currently responsible for maintaining your signals? City Traffi r Dent
e.
Do you have plans for major capital improvements to upgrade your proposed project network?
Yes _ No X
If yes, do you have a schedule, budget proposal or funds already committed? Yes, No
Explain:
f.
Have significant changes in traffic levels or patterns in the project area occurred as a result of new
development, road improvements, etc., since the last retiming effort? Yes _ No X
Explain: This is a new system with no nretionysystem timing efforts-
1
6) General Information, (contd.)
g. Do you anticipate significant changes in traffic levels or patterns in the project area as a result of new
development, road improvements, etc., within the next three years? Yes_ No X
Explain:_ The City is expecting a healthy but steady overall citywide
growth near the next three years Arterial traffic ,growth could
approximate 2-5% annually.
h. Explain how the equipment needs for this project area were determined and the type and features
of the equipment you propose for the project. Attach extra page if needed.
See Attached
I. List below specific local agency staff that would be assigned to this project. Outline local staff traffic
engineering experience, prior training in and use of the TRANSYT 7F and PASSER signal timing pro-
grams, and role in this project. Attach extra page if needed. (Note: Prior experience with TRANSYT 7F
and PASSER is not required.)
See Attached
I. Supply any additional information that would be useful for the review of this application. Also, you
may use this space to expand any of your answers to the previous questions. Attach extra page if
needed.
k. Was your city involved in the first or second TLS or Traffic Management program? %yes_no
If yes, is any additional staff training in the use of the PASSER or TRANSYT X
computer models needed? If yes, please answer question I. _yes_no
I. Indicate course date preference, number of people that would attend and whether they are local
staff and/or consultant.
PASSER II A 111 October4-6, 1994 2 M of people ( 2 local staff 0 consultant)
TRANSYT 7F September 27.29, 1994 2 * of people ( 2 local staff 0 consultant)
7) Applicant Certification: To the best of my knowledge and belief, information in this application is
true and correct, the document has been duly authorized by the governing body of the applicant, and
the applicant will comply with the attached assurances if the application is approved.
Any grant money received will supplement and not supplant any existing local funding presently
dedicated to signal timing efforts.
Signature_ r 0l� —fZ
Typed or Printed Name and Title
—c
Date 3.J,-9'Gc)
2
6. General Information (continued)
h. The City has initiated a program of upgrading their master controllers to Transyt model
3800 EL. To obtain full utilization of the capabilities of this master controller, all five
of existing local controllers and cabinets in this proposed system should be replaced.
Additional equipment needs to hardwire this proposed system into the appropriate master
include 7490' of overhead interconnect cable and 260' of 2" conduit.
The City's past signal related improvement programs have utilized Transyt model
controllers and associated equipment and it is their intention to continue such in order to
simplify maintenance operations, employee learning curves, and equipment purchasing
and stockpiling.
Jerry Clark, P.E., Director of Engineering and Transportation
Engineering experience including traffic: 15 years.
No organized training in PASSER or TRANSYT.
Role in project: Overall project management.
Manuel Coronado, Traffic Control Supervisor
Traffic signal technician experience: 9 years.
Has had prior training in PASSER.
Role in project: Provide technical support to and management of signal technicians.
Jeff Gann, Traffic Signal Technician
Traffic experience: 7 years.
Has had prior training in PASSER and TRANSYT.
Role in project: Field installations, field studies, and technical support.
Mike May, Traffic Signal Technician
Traffic experience: 4 years.
Has had prior training in PASSER and TRANSYT.
Role in project: Field installations, field studies, and technical support.
New Traffic Signal Technician (to be hired)
Traffic experience: Unknown.
Prior training is unknown.
Role in project: Field installations, field studies, and technical support.
3
Applicant City of Denton
Attachment A
Local Governments'
Standard Assurances
The Local Government hereby assures and certifies that it will comply with the
regulations, policies, guidelines, and requirements, including OMB Circulars A-102 and
A-87, as they relate to the application, acceptance, and use of state funds for this project.
Also, the Local Government assures and certifies to the grant that:
1. It possesses legal authority to apply for the grant; that a resolution, motion, or
similar action has been duly adopted or passed as an official act of the applicant's
governing body, authorizing the filing of the application, including all
understandings and assurances contained therein, and directing and authorizing
the person identified as the official representative of the applicant to act in
connection with the application and to provide such additional information as may
be required.
2. It will comply with Title VI of the Civil Rights Act of 1964 (PL 88-352) and in
accordance with Title VI of that Act, no person in the United States shall, on the
grounds of race, color, or national origin be excluded from participation in, be
denied benefits of, or be otherwise subjected to discrimination under any program
or activity for which the applicant receives federal financial assistance and will
immediately take any measures necessary to effectuate this agreement.
I It will comply with Title VI of the Civil Rights Act of 1964 (42 USC 2000d) prohibiting
employment discrimination where (1) the primary purpose of a grant is to provide
employment or (2) discriminatory employyment practices will result in unequal
treatment of persons who are or should be benefiting from the grant -aided
activity.
4. It will comply with requirements of the provisions of the Uniform Relocation
Assistance and Real Property Acquisitions Act of 1970 (PL 91-646) which provides for
fair and equitable treatment of persons displaced as a result of state or federal and
state or federally assisted programs.
It will comply with the provisions of the Hatch Act which limit the political activity
of employees.
6. It will comply with the minimum wage and maximum hours provisions of the
Federal Fair Labor Standards Act, as they apply to hospital and educational
institution employees of state and local governments.
7. It will establish safeguards to prohibit employees from using their positions for a
purpose that is or gives the appearance of being motivated by a desire for private
gain for themselves or others, particularly those with whom they have family,
business, or other ties.
8. It will give the sponsoring agency the access to and the right to examine all records,
books, papers, or documents related to the grant.
9. It will comply with all requirements imposed by the sponsoring agency concerning
special requirements of law, program requirements, and other administrative
requirements.
•4
10. It will insure that the facilities under its ownership, lease, or supervision which
shall be utilized in the accomplishment of the project are not listed on the
Environmental Protection Agency's (EPA) list of violating facilities and that it will
notify the grantor agency of the receipt of any communication from the Director
of the EPA Office of Federal Activities indicating that a facility to be used in the
project is under consideration for listing by the EPA.
11. It will comply with the flood insurance purchase requirements of Section 102(a)
of,the Flood Disaster Protection Act of 1973, PL 93-234, 87 Stat. 975, approved
December 31,1976. Section 102(a) requires, on and after March 2,1975, the pur-
chase of flood insurance in communities where such insurance is available as a con-
dition for the receipt of any federal financial assistance for construction or acquisi-
tion purposes for use in any area that has been identified by the Secretary of the
Department of Housing and Urban Development as an area having special flood ,
hazards. The phrase "federal financial assistance" includes any form of loan, grant,
guaranty, insurance payment, rebate, subsidy, disaster assistance loan or grant, or
any other form of direct or indirect federal assistance.
12. It will assist the grantor agency in its compliance with Section 106 of the National
Historic Preservation Act of 1966 as amended (16 USC 470), Executive Order 11593,
and the Archeological and Historic Preservation Act of 1966 (26 USC469a-1 et seq.)
by (a) consulting with the State Historic Preservation Officer to conduct the
Investigation, as necessary, to identify properties listed in or eligible for inclusion in
the National Register of Historic Places that are subject to adverse effects (see
36 CFR 800.8) by the activity, and notifying the federal grantor agency of the
existence of any such properties, and by (b) complying with all requirements
established by the federal grantor agency to avoid or mitigate adverse effects upon
such properties.
13. It will comply with Texas Civil Statutes, Art. 5996a, by insuring that no officer,
employee, or member of the applicant's governing body or of the applicant's
contract shall vote or confirm the employment of any person related within the
second degree of affinity or third degree by consanguinity to any member of the
governing body or to any other officer or employee authorized to employ or
supervise such person. This prohibition shall not prohibit the employment of a
person who shall have been continuously employed for a period of two years
prior to the election or appointment of the officer, employee, or governing body
member related to such person in the prohibited degree.
It will insure that all information collected, assembled, or maintained by the
applicant relative to this project shall be available to the public during normal
business hours in compliance with Texas Civil Statutes, Art. 6252-17a, unless
otherwise expressly provided by law.
It will comply with Texas Civil Statutes, Art. 6252-17, which requires all regular,
special, or called meetings of governmental bodies to be open to the public, except
as otherwise provided by law or specifically permitted in the Texas Constitution.
*5
Applicant City of Denton
Attachment B
Project Area Maps
Attach two 8 %-inch x 11-inch maps as described below.
A. A map showing the locale of each proposed TLS project within your jurisdiction.
B. A map showing the signalized intersections of each system with the following
information:
t. Average Daily Traffic
2. Circulation Pattern (Identify One -Way Streets)
3. A Scale or Identification of the Distance Between Adjacent Signals
01P
±� /624
JUAN
MAP A
OAK/HICKORY SYSTEM
Pilot
Polnt
76250
AubteY.
IlSlill
_.
nlgerville
�� o
75034.
I
AVE, D
N H
n MARIETTA
A
m ,'p
JAGOE
c
r
w
ANORMAL
O
D N
OD
AVE. B o
BRYAN
ON
0
AVE. A FRY
N PONDER
0
WELCH
FULTON
v
A
rri
N
ty FA
II
N Ft
a
r9 CD
�, o
4
a
Applicant City of Denton
Attachment C
Description of Project
System Name: oak / Hickory No. of Intersections: 5
System Configuration
System Coordination:
Grid x Arterial
Hardwire X
Time -Based
System Controller: Type Transyt model locals and master
Maximum # of Time -of -Day Plans: 9
Current # of Time -of -Day Plans: none
Indicate below each time period cycle length:
AM Period N/A Mid -Day Period N/A PM Period N/A
Last Date Timing Plans Revised for the Entire System: New system
Average Signal Spacing: 750'
#q
Applicant City of Denton
Attachment D
Quality of Service
Study Method
The applicant is to use the following instructions to conduct duality of service tests of
signals proposed to be included in the project. The attached Quality of Service"
Summary is to be completed and submitted with the application.
Introduction
Establishing the demand for traffic signal retiming ppro'ects is particularly difficult unless
extensive data collection and analysis is performed beforehand. Since such effort is an
integral part of the project being proposed, it is beyond the scope of preliminary needs
assessments associated with the grant application. Consequently, the TLS program will
require a simple study of travel time performance for each project proposal which should
be in the range of capabilities of applying local governments and provides a reasonable
summary of the operational situation. This study is just a part of the review process, and
will be used as an inexact guideline to assist in project selection and prioritization.
General Description
The travel time study methods defined here are not intended to be conclusive or
statistically comprehensive, but rather to be implementable by any local government
using only a vehicle and a stopwatch. The studywill be a general summaryof delay on
each street of the project. Data should only be collected on Tuesdays, Wednesdays and
Thursdays. The study will cover only the peak period, as defined by the applicant.
Applicants are encouraged to use the most heavily travelled time period of a typical day
to establish the typical worst case. Travel times on all streets will be done during this time
period, according to the following methodology.
Study Methodoloqv
An intersection is defined as a junction of streets controlled by a traffic signal which is
part of the project being proposed.
Travel time runs will be performed in all legal directions on each street in the project. A
run is defined as a trip from the first network or arterial signal to the last network or
arterial signal in one direction. For grid networks, two runs in each direction will be done
for each network street that passes through two or more network signals. For arterial
systems, three runs in each direction will be done. The time of crossing the stop line at
the first signal will be recorded (or the stop -watch will be started) and the time of
clearing the last intersection will be recorded (or the stop -watch will be stopped).
The driver of the study vehicle should attempt to approach the first signal in a grid
system once at the beginning and once during the middle of the green phase and, for an
arterial, at the beginning, one-third point, and two-thirds point of the green phase. The
driver should then attempt to drive the length of the street at the posted speed limit.
Delay will be caused when other vehicles or traffic control devices impede the progress of
the study vehicle, and the drivershould not take extraordinary measures to avoid delay.
Generally, the driver should stay in the most typically used through lane (such as the
center or median lane).
oja
Accompanying the travel time run will be a description of the street geometry for each
section of the street. A section is defined as the portion of the street extending from
the stop line of one controlled intersection to the stop line of the next controlled inter-
section downstream. Section length, number of lanes, and posted speed limit should be
recorded. If the posted speed changes in the section, a weighted average should be
calculated based on distance.
For example, a section of street is 800 feet long, and is posted for 30 mph in the direction
under consideration for 500 feet and 40 mph for 300 feet. The average posted speed
would be
(30 mph x 500 feet) + (40 mph x 300 feet)
800 eet = 33.75 mph
Number of lanes is measured at the stop line at the beginning of the section, not
including turn bays.
For each street, average daily traffic counts should be provided. Data up to five years old
is acceptable as long as significant changes in traffic patterns have not occurred.
Free flow travel time should be calculated assuming no stops and traffic flow at the
average posted speed limit. The free flow travel time for each section is the section
length divided by the speed in feet/sec. Speed in mph is converted to feet/sec by
multiplying by 1.47. The total free flow travel time is the total of the section free flow
travel times. The delay is the difference between free flow travel time and actual travel
time, averaged from the travel time runs. For example, a street contains two sections.
Section 1 is 800 feet and has a 35 mph average posted speed limit, and Section 2 is 1200
feet long and has a 40 mph average posted speed limit. The free flow travel time would
be
800 feet 1200 feet
35 mpF x 1.47 + 40 mp >�47 = 36 seconds
The Quality of Service Summary form has been provided to allow the convenient orga-
nization of this data. One form should be filled out for each combination of street and
direction. Applicants should duplicate the form as necessary.
Summary
The procedure outlined here will provide a rough synopsis of the existing typical worst
case situation using data that can be collected very quickly. For arterial systems, only data
along the arterial is necessary. The runs have been defined to eliminate the inclusion of
boundary conditions (such as side street delay on an arterial), which, though they may
inhibit a complete understanding of the situation, will allow arterial and grid networks
to be compared in a similar light.
Applicant City of Denton
Attachment D
Traffic Light Synchronization Program III
Quality of Service Summary
Agency: City of Denton
Street Name: Oak
Direction of Travel Time Run: Westbound
Section
Cross Street Name
1
Ave. A
2
Jagoe
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
Dates) of Study: 3/29/94
Time of Study: 12:00 - 1:00 PM
ADT for Street: 2,320 vpd
Comments:
Section Avg.Posted Numberof
Length Speed Lanes
690' 20 2
Total Free Flow Travel Time
Measured Travel Time - Run 1
Run 2
Run 3 (Arterial Systems)
Average Measured Travel Time
.
Delay for this Street and Direction
Free Flow
Travel Time
23.5
62.3
38.8
012.
Applicant City of Denton
Attachment D
Traffic Light Synchronization Program III
Quality of Service Summary
Agency:
City of Denton
Street Name:
Hickory
Direction of Travel Time Run: Eastbound
Section
Cross Street Name
Section
Length
Avg. Posted
Speed
Number of
Lanes
Free Flow
Travel Time
1
Ave. B
_
2
Ave. A
610,
20
3
Welch
665,
20
2,
22.
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
Date(s) of Study: 3/29/94
Total Free Flow Travel Time
Measured Travel Time - Run 1
Run 2
Run 3 (Arterial Systems)
Average Measured Travel Time
Delay for this Street and Direction
43.3
Time, of Study: 12:00 - 1:00 PM
91.0
ADT for Street: 9,835 vpd
70.0
61.0
Comments:
74.0
30.7
*Vs
Applicant City of Denton
Attachment E
Traffic Light Synchronization (TLS) Program III
Budget Form
Applicant Financial Contact: Jerry Clark Phone: (817)566-8358
Personal Services
Salaries and Wages for personnel involved in the planning, development and
implementation of the proposed project
Position Salary Rate Number of Oil Overcharge Local Match*
of�urs— Funds
See Attached
Total Personal Services -
Operating Expenses
Travel: $450/person/trip $ 1,800.00
(PASSER & TRANSYT
(Rates) training in Austin)
Other:
Other:
Total Operating Expenses $ 1,800.00
Equipment Items (List)
See Attached
Total Equipment Items
* Designate if local match is from the City or TxDOT.
$ 5,723.60
$ 38,273.48 $ 3,543.52
1V14
Subcontracts
Oil Overcharge
Funds
Attachment E
(page 2)
Local Match*
Consultant Services** (Cummings & Pewitt) $ 6,761.27 -
Other ** (City Utility Contractor) 8 7,841.65 $ 8,958.35
Total Subcontracts 8 14,602.92 $ 8,958.35
Others
Total Others
Grant Total
Total Local Match
(Indicate % of total project costs)
Indicate TxDOT % of Local Match
TOTAL PROJECT COST
$ 54,676.40
* Designate if local match isfrom the City or TxDOT.
** Attach detailed cost estimate.
$ 18,225.47
( 25.0 %)
( 0.0 %)
$72,901.87
0 16
PERSONAL SERVICES COST ESTIMATE
Oil
Overcharge Local
Position Salary Hours Funds Match
Director
Supervisor
Signal Tech.
Signal Tech.
Signal Tech.
Total Personal Services
$35.47
24
$0.00
$851.28
$20.83
72
$0.00
$1,499.76
$17.02
80
$0.00
$1,361.60
$15.70
72
$0.00
$1,130.40
$12.23
72
$0.00
$880.56
320
$0.00
$5,723.60
Salary Includes hourly rate plus benefits.
✓o
DETAILED EQUIPMENT
COST ESTIMATE
Item Purchased Amount Unit Unit Cost
Cable
2" Condult
Hanger
Hook
Controller & Cabinet
Total Cost
7490
LF
$0.90
260
LF
$2.00
112
EA
$3.00
22
EA
$10.00
5
EA
$6,800.00
Cost
$6,741.00
$520.00
$336.00
$220.00
$34,000.00
$41,817.00
CONSULTANT'S DETAILED
COST ESTIMATE
Staff Salary Hours Cost
Senior Engineer
$28.84
56
$1,615.04
Assistant Engineer
$17.31
36
$623.16
Technician
$8.50
32
$272.00
Secretary
$8.00
8
$64.00
Sub -Total
132
$2,574.20
Overhead (127.3%)
Labor plus Overhead
Fixed Fee (10%)
Total Expenses
Total Cost
$3,276.96
$5,851.16
$585.12
$325.00
$6,761.27
Item Installed
Overhead Cable
2" Conduit
Total Cost
CONTRACTOR'S DETAILED
LABOR COST ESTIMATE
Amount Unit
7490 LF
260 LF
Unit Cost Cost
$2.00 $14,980.00
$7.00 $1,820.00
$16,800.00
Ik
Applicant City of Denton
Attachment F
Project Task Responsibility
(Please check appropriate agency or if Joint responsibility, enter percentage for each.)
Rensible Agency
Loca Sta
Consultant
inn n
10 90
100
0
0
0
20
90
40
0
0
0
100
100
100
SO
10
60
100
100
Task
• Field check Equipment
• Collect field data
• Attend PASSER and TRANSYT
Workshops
• Code data in computer and
complete initial simulation run
• Calibrate model
• Complete "Before" field
evaluation
• Complete optimization runs and
selection of plans
• Implement timing plans
• Fine-tune timing plans
• Complete simulation of plans
implemented in field
• Complete "After" field
evaluation
* Enter "TxDOT" if the task is the department's responsibility.
is ZO
Applicant City of Denton
Attachment G
Debarment Certification
(Negotiated Contracts)
(1) The LOCAL GOVERNMENT certifies to the best of its knowledge and belief, that
it and its principals:
(a) Are not presently debarred, suspended, proposed for debarment, declared
ineligible or voluntarily excluded from covered transactions by any federal
department or agency;
(b) Have not within a three-year period preceding this proposal been convicted
of or had a civil judgment rendered against them for commission of fraud or a
criminal offense in connection with obtaining, attempting to obtain, or performing
a public* transaction or contract under a public transaction; violation of federal or
state antitrust statutes or commission of embezzlement, theft, forgery, bribery,
falsification or destruction of records, making false statements, or receiving stolen
property;
(c) Are not presently indicted for or otherwise criminally or civilly charged by
a governmental entity* with commission of any of the offenses enumerated in
paragraph (1)(b) of this certification; and
(d) Have not within a three-year period preceding this application/proposal had
one or more public transactions* terminated for cause or default.
(2) Where the LOCAL GOVERNMENT is unable to certify to any of the statements
in this certification, such LOCAL GOVERNMENT shall attach an explanation to
this certification.
*federal, state or local
Date
Form 1734-A
4.89
40 2.1
Contract Number 585TLF6010
TRAFFIC LIGHT SYNCHRONIZATION
GRANTAGREEMENT
THE STATE OF TEXAS **
THE COUNTY OF TRAVIS **
THIS CONTRACT IS MADE BY AND BETWEEN THE STATE OF TEXAS,
acting by and through the Texas Department of Transportation, hereinafter called the
State and the City of Denton , acting by and through its duly authorized officers,
hereinafter called the Local Government.
WITNESSETH
WHEREAS, Article 4413(56), Texas Civil Statutes, declares that the Office of the
Governor may designate State agencies to supervise, manage or administer the imple-
mentation of a grant program financed under the Oil Overcharge Restitutionary Act
(Art. 4413(56)); and,
WHEREAS, pursuant to Article 4413(56), the Texas Department of Transportation
submitted a proposed grant program, hereinafter called Traffic Light Synchronization,
or TLS, designed to increase energy efficiency in the movement of traffic, and the Office
of the Governor did approve the proposed program, and signified its approval by
contract executed between the Texas Department of Transportation and the Office of
the Governor dated September 1, 1990, or as amended; and,
WHEREAS, the Local Government submitted a grant application to the State describ-
ing a plan to re -time a set of traffic signals in accordance with the State's instructions,
and the grant application was approved by the State and the project described therein
was selected for financial assistance; and,
WHEREAS, it is the desire of the Local Government to enter into this grant agreement
for financial assistance for the project described in the grant application in order to
increase energy efficiency in the movement of traffic.
NOW, THEREFORE, in consideration of the premises and of the mutual covenants and
agreements of the parties hereto, the State and the Local Government do mutually
agree as follows.
Page 1 of 7
AGREEMENT
Article 1. Contract Period
This contract becomes effective on the date on which the final signature is added, the
final signature being that of the party whose signing makes the contract fully exe-
cuted by all parties hereto. The contract shall terminate twelve months from that date
or July 14, 1995, whichever comes first, unless terminated or modified as hereinafter
provided.
Article2. ContractAmount
The maximum amount payable to the Local Government under this contract shall not
exceed $ 5h, cam. This amount constitutes not more than 75% of the total project
cost of$ 75,905.87
The amount may be increased only if the State approves a request for additional
funding submitted by the Local Government, if additional funds are available. Any
such increase must be authorized in a written amendment to this contract.
Article 3. Project Description
Depending upon the availability of funds, the Local Government shall commence and
complete a project providing for the re -timing of traffic signals within its jurisdiction,
generally located on Wn1 rh RVGrPm
The project is fully described in the grant application, attached hereto and labeled
Exhibit 1. The Local Government shall not perform any activity under this contract
except as described in said Exhibit 1. Additional activity under this contract must be
authorized in a written amendment signed by the parties hereto in which the modi-
fications or additions to the project are fully described.
The Local Government agrees to deliver the following products to the State in accord-
ance with the application:
• A "before" field evaluation
• An "after" field evaluation
In addition to the above products, quarterly progress reports that summarize project
activities are required.
Failure to deliver the products as specified in the application may result in termination
of this agreement as provided hereinafter.
Article 4. Compensation
All payments made hereunder will be made in accordance with the category totals of
the Approved Project Budget included in Exhibit 1. To be eligible for reimbursement
under this contract, a cost must be incurred within the contract period specified in
Article 1 above and be authorized in the Approved Project Budget included in Exhibit 1.
Payment of costs incurred under this contract is further governed by the cost principles
outlined in 48 CFR 1-31, (Federal Acquisition Regulations).
If the Local Government requests to move dollars from one category to another
category, a request in writing must be submitted to the State. The State will reply in
writing approving or disapproving the request.
Page 2 of 7
Article 4. Compensation (cont.)
The Local Government agrees to submit monthly requests for reimbursement,
using billing statements acceptable to the State. The original billing statement and
one copy'is to be submitted to the State's District Office, at the address specified on the
signature page of this agreement.
Before 35% of the contract is paid, an approved "Before" field evaluation must be
submitted to the State.
Before 85% of the contract is paid, an approved "After" field evaluation must be
submitted to the State.
Requests for reimbursement must be submitted within 60 days upon completion of the
project, but no later than September 15, 1995.
The State will exercise good faith effort to make payments within thirty days of receipt
of properly prepared and documented requests for reimbursement. All payments,
however, are contingent upon the availability of appropriated funds.
Article 5. Contract Amendments
The Local Government may request an amendment of the contract for additional time,
changes in work, or additional funds for additional tasks to be performed under this
contract, and if the request is justified by the Local Government and the State
determines that the request is beneficial to the State and the Local Government and to
the purpose of the grant, a written amendment is to be executed to authorize additional
time, tasks, or additional funds, if additional funds are available.
The amendment shall be agreed upon by the State and Local Government, Any such
amendment shall be made before the termination of the contract as specified in
Article 1. The Local Government can undertake at its own expense any activities
associated with the approved project, but those additional activities will not be eligible
for reimbursement by the State.
Article 6. Inspection of Work
The State shall have the right at all reasonable times to inspect or otherwise evaluate
the work performed or being performed hereunder and the premises in which it is being
performed. If any inspection or evaluation is made on the premises of the Local
Government or subcontractor, the Local Government shall provide and require his
subcontractor to provide all reasonable facilities and assistance for the safety and
convenience of the inspectors in the performance of their duties. All inspections and
evaluations shall be performed in such a manner as will not unduly delay the work.
Article:7. Disputes and Remedies
The Local Government shall be responsible for the settlement of all contractual and
administrative issues arising out of procurements entered in support of contract work.
Disputes concerning performance or payment shall be submitted to the State for
settlement with the Executive Director of the Texas Department of Transportation
acting as referee.
This agreement shall not be considered as specifying the exclusive remedy for any
dispute or violation or breach of contract terms, but all remedies existing at law and
in equity may be availed of by either party and shall be cumulative.
Page 3 of 7
Article 8. Records
The Local Government agrees to maintain all books, documents, papers, accounting
records, and other evidence pertaining to costs incurred and work performed hereunder
and shall make such materials available at its office during the contract period and
for three years from the date of the final performance report under the contract. Such
materials shall be made available during the specified period for inspection by the State
for the purpose of making audits, examinations, excerpts, and transcriptions.
Article 9. Reporting
The Local Government shall promptly advise the State in writing of events which have
a significant impact upon the contract, including:
• Problems, delays, or adverse conditions which will materially affect the ability to
attain program objectives, prevent the meeting of time schedules or objectives, or pre-
clude the attainment of project work units by established time periods. This disclosure
shall be accompanied by a statement of the action taken, or contemplated, and any
State assistance needed to resolve the situation.
• Favorable developments or events that enable meeting time schedules and objec-
tives sooner than anticipated or producing more work units than originally projected.
Article 10. Audit
This contract shall be subject to audit for a three-year period from the date of the final
financial report.
Article 11. Subcontracts
Any subcontract for professional service rendered by individuals or organizations not
a part of the Local Government's organization shall not be executed without prior
authorization by the State. Subcontracts shall contain all required provisions of this
contract. No subcontract will relieve the Local Government of its responsibility under
this contract.
Article 12. Termination
• For Cause: Insufficient Funding
The State may terminate this contract at any time before the date of completion when-
ever it is determined that sufficient funds are not available to reimburse its share of the
cost of the project. The State shall give written notice to the Local Government at least
seven days prior to the effective date of termination, specifying the date of termination.
The State shall compensate the Local Government for those eligible costs incurred
during the contract period up through the time of termination. The Local Government
shall not incur new obligations for the terminated portion after the effective date of
termination.
Page 4 of 7
Article 12. Termination (cont.)
• For Cause: Nonperformance
The State may terminate this contract at any time before the date of completion if it
determines that the Local Government has failed to comply with the conditions of the
contract. The State shall give written notice to the Local Government at least seven
days prior to the effective date of termination and specify the effective date of termi-
nation and the reason for termination.
The State shall compensate the Local Government for those eligible costs incurred
during the contract period which are directly attributable to the completed portion
of the project covered by this contract, provided that the work has been completed in
a manner satisfactory to the State. The Local Government shall not incur new obliga-
tions for the terminated portion after the effective date of termination.
• For Convenience
If either party to this contract determines that the continuation of the contract in whole
or in part would not produce beneficial results commensurate with the further
expenditure of funds, the determining party shall give notice to the other party of such
determination, including the effective date and the portion to be terminated.
The State may terminate this contract for reasons of its own, not subject to the approval
of the Local Government.
• Ownership of Documents
Upon termination of this contract, whether for cause or for convenience, all finished or
unfinished documents, data, studies, surveys, reports, maps, drawing, models, photo-
graphs, etc, prepared by the Local Government shall at the option of the State become
the property of the State.
• Excepted Conditions
Except with respect to defaults of subcontractors, the Local Government shall not be in
default by reason of any failure in performance of this contract in accordance with its
terms (including any failure by the Local Government to progress in the performance of
the work) if such failure arises out of causes beyond the control and without the default
or negligence of the Local Government. Such causes may include but are not limited to
acts of nature or of the public enemy, acts of the government in either its sovereign or
contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight
embargoes, and unusually severe weather. In every case, however, the failure to
perform must be beyond the control and without the fault or negligence of the Local
Government.
Article 13. Compliance with Laws
The Local Government shall comply with all federal, state, and local laws, statutes,
ordinances, rules and regulations, and the orders and decrees of any courts or admin-
istrative bodies or tribunals in any matter affecting the performance of this contract,
including, without limitation, workers' compensation laws, minimum and maximum
salary and wage statutes and regulations and licensing laws and regulations. When
required, the Local Government shall furnish the State with satisfactory proof of its
compliance therewith.
Page 5 of 7
Article 14. Successors and Assigns
The State and the Local Government each binds itself, its successors, executors,
assigns and administrators to the other party to this agreement and to the successors,
executors, assigns and administrators of such other party in respect to all covenants
of this contract. Neither the State nor the Local Government shall assign, sublet, or
transfer its interest in this agreement without the written consent of the other.
Article 15. Property Management
The Local Government shall use its own property management system to control,
protect, preserve, use, maintain, and dispose of any property furnished to it by the
State or purchased pursuant to this agreement, provided that the procedures are not
in conflict with the State's property management procedures or property manage-
ment standards outlined in 49 CFR 18 (Section 18.32), "Uniform Administrative
Requirements for Grants and Cooperative Agreements to State and Local
Governments."
Article 16. Procurement Standards
The Local Government shall maintain and follow procurement standards which meet
or exceed the requirements of 49 CFR 18, "Uniform Administrative Requirements for
Grants and Cooperative Agreements to State and Local Governments."
Article 17. Debarment/Suspension
The Local Government is prohibited from making any award or permitting any award
at any tier to any party which is debarred or suspended or otherwise excluded from
or ineligible for participation in federal assistance programs under Executive Order
12549, Debarment and Suspension. The Local Government shall require any party to
a subcontract or purchase order awarded under this contract to certify its eligibility to
receive federal grant funds, and, when requested by the State, to furnish a copy of the
certification.
Article 18. Insurance
When directed by the State, the Local Government shall require its subcontractors to
secure insurance in the maximum statutory limits for tort liability, naming the State
as an additional insured under its terms. When so directed, the Local Government
shall require its subcontractor to furnish proof of insurance on forms satisfactory to
the State, and shall maintain the insurance during the contract period specified in
Article 1.
Article 19. Gratuities
Texas Transportation Commission policy mandates that employees of the Department
shall not accept any benefits, gifts or favors from any person doing business with or
who reasonably speaking may do business with the State under this contract. The only
exceptions allowed are ordinary business lunches and items that have received the
advanced written approval of the State's Executive Director.
Any person doing business with or who reasonably speaking may do business with the
State under this contract may not make any offer of benefits, gifts or favors to Texas
Department of Transportation employees, except as mentioned hereabove. Failure on
the part of the Local Government to adhere to this policy may result in termination of
this contract.
Page 6 of 7
Article 20. Indemnification
To the extent permitted by law, the Local Government shall save harmless the State
from all claims and liability due to the acts or omissions of the Local Government, its
agents or employees. The Local Government also agrees to save harmless the State
from any and all expenses, including attorney fees, all court costs and awards for dam-
ages, incurred by the State in litigation or otherwise resisting such claims or liabilities
as a result of any activities of the Local Government, its agents or employees.
Further, the Local Government agrees to protect, indemnify, and save harmless the
State from and against all claims, demands and causes of action of every kind and
character brought by any employee of the Local Government against the State due to
personal injuries and/or death to such employee resulting from any alleged negligent
act, by either commission or omission on the part of the Local Government or the State.
Article 21. Signatory Warranty
The undersigned signatory for the Local Government hereby represents and warrants
that he is an official of the organization for which he has executed this contract and that
he has full and complete authority to enter into the contract on behalf of the Local
Government.
IN WITNESS WHEREOF, THE PARTIES HAVE EXECUTED DUPLICATE
COUNTERPARTS TO EFFECTUATE THIS AGREEMENT.
LOCAL GOVERNMENT:
The City of Denton
Under authority of i ordi-
nance number q V, , O 5
M
Tit
Lo
STATE OF TEXAS
Executed for the Executive Director
and approved by the Texas Highway
Commission under the authority of
Minute Order No. 100002 and
Administrative Circular 26-93, or the
purpose and effect of activating and
carrying out the orders, established
policies or work programs heretofore
approved by the Texas Transportation
Commission.
By -
irect �Tr�
a�f,,fic Oper ions
A .ST: Date��_7¢
A
For the purpose of this agreement, the following addresses shall be used to mail all
required notices, reports, claims, and correspondence:
For the Local Government:
City of Denton
Engineering Dept
215E McKinney St
Dentont TX 76201
For the State (District Office):
James Huffman -
Dallas De s
P.O. Box 3067 —
Dallas TX 75221-3067 —
Page 7 of 7
Texas Department of Transportation
Traffic light Synchronization Program III welch System
Grant Application
1) Legal
a.
Applicant
Applicant Name City of Denton
2) Vendor Identification Number:
17560005146000
b.
Organisational Unit Engineering Dept
3) Project Traffic Engineer or Manager
c.
Street/P.O. Box 215 E. McKinney
(Name 6 Telephone)
d.
f.
h.
City Denton e. County Denton
State Tx g. Sip 76201
Population (1990 Census Bureau Figure):
66 270
,apee
Jerry Clark (817)566-8358
a) Number of Signalized Intersections:
• In jurisdiction 63
a In coordinated systems 38
s.
ple aao ���� 11 7
Prrtcrt G (;larkn Slr! ha�iiei— 3SWphone):
• In proposed project 5
5) Proposed funding
a. State Oil Overcharge Funds S 56, 929.4
b. Local ; 18,976.47
Attachments
a. Standard Assurances
b. Project Area Maps
c.
d.
e.
NOTE:
TxDOT (if signals are maintained _
and operated by TxDOT)
Other(Specify) ; —
Total ; 75,905.8
The oil overcharge amount for equipment
c. Description of Project
d. Quality of Service
e. Budget
f. Project Task Responsibility
shall not exceed 70% of the total amount of
oil overcharge funds requested.
g. Debarment Certification
6) General Information
a.
Are any of your project signals operated or maintained by other agencies? Yes— No X
If yes, describe
b.
Who currently makes the decisions on how to set your signals? City Engineer's Staff
c.
Approximately how many local staff person -years (or fraction thereof) are currently devoted to traffic
signal timing in your jurisdiction? Include all categories of effort, including data acquisition, plan
development, implementation, checking and surveillance. Approximately 40
Prson years.
Comments:
d.
Who is currently responsible for maintaining your signals? City Traffic Dept
e.
Do you have plans for major capital improvements to upgrade your proposed project network?
Yes— No X
If yes, do you have a schedule, budget proposal or funds already committed? Yes— No
Explain:
I.
Have Significant changes in traffic levels or patterns in the project area occurred as a result of new
development, road improvements, etc., since the last retiming effort? Yes _ No x
Explain: This is a new system with no previous system timing efforts
6) General Information, (contd.)
g. Do you anticipate significant changes in traffic levels or patterns in the project area as a result of new
development, road improvements, etc., within the next three years? Yes _ No X
Explain: The City is expecting a healthly but steady overall citywide
Rrowth over the next three yearn Arterial traffic grawth would
approximate 2-5% annually.
h. Explain how the equipment needs for this project area were determined and the type and features
of the equipment you propose for the project. Attach extra page if needed.
See Attached
I. List below specific local agency staff that would be assigned to this project. Outline local staff traffic
engineering experience, prior training in and use of the TRANSYT 7F and PASSER signal timing pro-
grams, and role in this project. Attach extra page if needed. (Note: Prior experience with TRANSYT 7F
And PASSER is not required.)
See Attached
J. 'Supply any additional information that would be useful for the review of this application. Also, you
may use this space to expand any of your answers to the previous questions. Attach extra page if
needed.
k. Was your city involved in the first or second US or Traffic Management program? R yes_no
If yes, is any additional staff training in the use of the PASSER or TRANSYT
computer models needed? If yes, please answer question I. _yes_no
1. Indicate course date preference, number of people that would attend and whether they are local
staff and/or consultant.
PASSER 111iIll October4.6, 1994 2 #ofpeople(2 localstaff consultant)
TRANSYT 7F September27.29, 1994 2 *of people 1 9. localstaff n _ consultant)
7) Applicant Certification: To the best of my knowledge and belief, information in this application is
true and correct, the document has been duly authorized by the governing body of the applicant, and
the applicant will comply with the attached assurances if the application is approved.
Any grant money received will supplement and not supplant any existing local funding presently
dedicated to signal timing efforts.
Signature.ti _� C_ecij y-
v U
Typed or Printed Name and Title_ �Ie 2. C46�Ic— C' L,
Date 3),-x:i)?ul
2
6. General Information (continued)
h. The City has initiated a program of upgrading their master controllers to Transyt model
3800 EL. To obtain full utilization of the capabilities of this master controller, four of
the existing five local controllers and cabinets in this proposed system should be replaced.
Additional equipment needs to hardwire this proposed system into the appropriate master
include 2930' of overhead interconnect cable, 2780' of underground interconnect cable,
and 2230' of 2" conduit.
The City's past signal related improvement programs have utilized Transyt model
controllers and associated equipment and it is their intention to continue such in order to
simplify maintenance operations, employee learning curves, and equipment purchasing
and stockpiling.
Jerry Clark, P.E., Director of Engineering and Transportation
Engineering experience including traffic: 15 years.
No organized training in PASSER or TRANSYT.
Role in project: Overall project management.
Manuel Coronado, Traffic Control Supervisor
Traffic signal technician experience: 9 years.
Has had prior training in PASSER.
Role in project: Provide technical support to and management of signal technicians.
Jeff Gann, Traffic Signal Technician
Traffic experience: 7 years.
Has had prior training in PASSER and TRANSYT.
Role in project: Field installations, field studies, and technical support.
Mike May, Traffic Signal Technician
Traffic experience: 4 years.
Has had prior training in PASSER and TRANSYT.
Role in project: Field installations, field studies, and technical support.
New Traffic Signal Technician (to be hired)
Traffic experience: Unknown.
Prior training is unknown.
Role in project: Field installations, field studies, and technical support.
3
Applicant City of Denton
Attachment A
Local Governments'
Standard Assurances
The Local Government hereby assures and certifies that it will comply with the
regulations, policies, guidelines, and requirements, including OMB CircularsA-102 and
A-67, as they relate to the application, acceptance, and use of state funds for this project.
Also, the Local Government assures and certifies to the grant that:
1. It possesses legal authority to apply for the grant; that a resolution, motion, or
similar action has been duly adopted or passed as an official act of the applicant's
governing body, authorizing the filing of the application, including all
understandings and assurances contained therein, and directing and authorizing
the person identified as the official representative of the applicant to act in
connection with the application and to provide such additional information as may
be required.
2. It will comply with Title VI of the Civil Rights Act of 1964 (PL BB-352) and in
accordance with Title VI of that Act, no person in the United States shall, on the
grounds of race, color, or national origin be excluded from participation in, be
denied benefits of, or be otherwise subjected to discrimination under any program
or activity for which the applicant receives federal financial assistance and will
immediately take any measures necessary to effectuate this agreement.
3. It will comply with Title VI of the Civil Rights Act of 1964 (42 USC 2000d) prohibiting
employment discrimination where (1) the primary purpose of a grant is to provide
employment or (2) discriminatory employyment practices will result in unequal
treatment of persons who are or should be benefiting from the grant -aided
activity.
4. It will comply with requirements of the provisions of the Uniform Relocation
Assistance and Real Property Acquisitions Act of 1970 (PL 91-646) which provides for
fair and equitable treatment of persons displaced as a result of state or federal and
state or federally assisted programs.
S. It will comply with the provisions of the Hatch Act which limit the political activity
of employees.
6. It will comply with the minimum wage and maximum hours provisions of the
Federal Fair Labor Standards Act, astheyapplyto hospital and educational
institution employees of state and local governments.
7. It will establish safeguards to prohibit employees from using their positions for a
purpose that is or gives the appearance of being motivated by a desire for private
gain for themselves or others, particularly those with whom they have family,
business, or other ties.
B. It will give the sponsoring agency the access to and the right to examine all records,
books, papers, or documents related to the grant.
9. It will comply with all requirements imposed by the sponsoring agency concerning
special requirements of law, program requirements, and other administrative
requirements.
04
10. It will insure that the facilities under its ownership, lease, or supervision which
shall be utilized in the accomplishment of the project are not listed on the
Environmental Protection Agency's (EPA) list of violating facilities and that it will
notify the grantor agency of the receipt of any communication fromthe Director
of the EPA Office of Federal Activities indicating that a facility to be used in the
project is under consideration for listing by the EPA.
11. It will comply with the flood insurance purchase requirements of Section 102(a)
of the Flood Disaster Protection Act of 1973, PL 93-234, 87 Stat. 975, approved
December 31,1976. Section 102(a) requires, on and after March 2,1975. the pur-
chase of flood insurance in communities where such insurance is available as a con-
dition for the receipt of any federal financial assistance for construction or acquisi-
tion purposes for use in any area that has been identified by the Secretary of the
Department of Housing and Urban Development as an area having special flood .
hazards. The phrase "federal financial assistance" includes any form of loan, grant,
guaranty, insurance payment, rebate, subsidy, disaster assistance loan or grant, or
any other form of direct or indirect federal assistance.
12. It will assist the grantor agency in its compliance with Section 106 of the National
Historic Preservation Act of 1966 as amended (16 USC 470), Executive Order 11593,
and the Archeological and Historic Preservation Act of 1966 (26 USC469a-1 et seq.)
by (a) consulting with the State Historic Preservation Officer to conduct the
investigation, as necessary, to identify properties listed in or eligible for inclusion in
the National Register of Historic Places that are subject to adverse effects (see
36 CFR 800.8) by the activity, and notifying the federal grantor agency of the
existence of any such properties, and by (b) complying with all requirements
established by the federal grantor agency toavoid ormitigate adverse effects upon
such properties.
13. It will comply with Texas Civil Statutes, Art. 5996a, by insuring that no officer,
employee, or member of the applicant's governing body or of the applicant's
contract shall vote or confirm the employment of any person related within the
second degree of affinity or third degree by consanguinity to any member of the
governing body or to any other officer or employee authorized to employ or
supervise such person. This prohibition shall not prohibit the employment of a
person who shall have been continuously employed for a period of two years
prior to the election or appointment of the officer, employee, or governing body
member 'related to such person in the prohibited degree.
It will insure that all information collected, assembled, or maintained by the
applicant relative to this project shall be available to the public during normal
business hours in compliance with Texas Civil Statutes, Art. 6252-17a, unless
otherwise expressly provided by law.
It will comply with Texas Civil Statutes, Art. 6252-17, which requires all regular,
special, or called meetings of governmental bodies to be open to the public, except
as otherwise provided by law or specifically permitted in the Texas Constitution.
KS
Applicant City of Denton
Attachment B
Project Area Maps
Attach two B %-inch x 11-inch maps as described below.
A. A map showing the locale of each proposed TLS project within your jurisdiction.
A map showing the signalized intersections of each system with the following
information:
1. Average Daily Traffic
2. Circulation Pattern (Identify One -Way Streets)
3. A Scale or Identification of the Distance Between Adjacent Signals
IN
ova
75034.
MAP A
WELCH SYSTEM
I
COLLINS
H
FANNIN
n
r°di
a
m
<
a
a.
EAGLE
�z
1
A
a
r
OD
CD
0
MAPLE
by
HIGHLAND
PRAIRE
w
W
z
co
a
o
tj
17
CHESTNUT
r,9 o
Ln
r-
o
SYCAMORE
C7
0
a
0
MULBERRY
3>
o
m
V
N
a
rl
ty
W. HICKORY
o�4L
ti
--1
fTl
W, OAK
3
x
Applicant City of Denton
Attachment C
Description of Project
System Name: welch No. of Intersections: 5
System Configuration: Grid Arterial X
System Coordination: Hardwire X Time -Based
System Controller: Type Transyt model locals and master
Maximum # of Time -of -Day Plans: 9
Current # of Time -of -Day Plans: None
Indicate below each time period cycle length:
AM Period N/A Mid -Day Period N/A PM Period N/A
Last Date Timing Plans Revised for the Entire System: New System
Average Signal Spacing: 730'
Applicant City of Denton
Attachment D
Quality of Service
Study Method
The applicant is to use the following ihstructions to conduct quality of service tests of
signals proposed to be included in the project. The attached Quality of Service"
Summary is to be completed and submitted with the application.
Introduction
Establishingthe demand for traffic sig
extensive data collection and analysis
Integral part of the project being pror
assessments associated with the grant
require a simple study of travel time p1
be in the range of capabilities of apply
summary of the operational situation.
will be; used as an inexact guideline to
al retiming pro'ects is particularly difficult unless
Performed beforehand. Since such effort is an
sed, it is beyond the scope of preliminary needs
pplication. Consequently, the TLS program will .
formance for each project proposal which should
ig local governments and provides a reasonable
his study is just a part of the review process, and
ssist in project selection and prioritization.
General Description
The travel time study methods defined here are not intended to be conclusive or
statistically comprehensive, but rather to be implementable by any local government
using only a vehicle and a stopwatch. The study will be a general summary of delay on
each street of the project. Data should only be collected on Tuesdays, Wednesdays and
Thursdays. The study will cover only the peak period, as defined by the applicant.
Applicants are encouraged to use the most heavily travelled time period of atypical day
to establish the typical worst case. Travel times on all streets will be done during this time
period; according to the following methodology.
Study Methodology
An intersection is defined as a junction of streets controlled by a traffic signal which is
part of the project being proposed.
Travel time runs will be performed in all legal directions on each street in the project. A
run is defined as a trip from the first network orarterial signal to the last network or
arterial signal in one direction. For grid networks, two runs in each direction will be done
for each network street that passes through two or more network signals. For arterial
systems, three runs in each direction will be done. The time of crossing the stop line at
the first signal will be recorded (or the stop -watch will be started) and the time of
clearing the last intersection will be recorded (or the stop -watch will be stopped).
The driver of the study vehicle should attempt to approach the first signal in a grid
system once at the beginning and once during the middle of the green phase and, for an
arterial at the beginning, one-third point, and two-thirds point of the green phase. The
driver should then attempt to drive the length of the street at the posted speed limit.
Delay will be caused when other vehicles or traffic control devices impede the progress of
the study vehicle, and the drivershould not take extraordinary measures to avoid delay.
Generally, the driver should stay in the most typically used through lane (such as the
center or median lane).
410
Accompanying the travel time run will be a description of the street geometry for each
section of the street. A section is defined as the portion of the street extending from
the stop line of one controlled intersection to the stop line of the next controlled inter-
section downstream. Section length, number of lanes, and posted speed limit should be
recorded. If the posted speed changes in the section, a weighted average should be
calculated based on distance.
For example, a section of street is 800 feet long, and is posted for 30 mph in the direction
under consideration for 500 feet and 40 mph for 300 feet. The average posted speed
would be
(30 mph x 500 feet) + (40 mph x 300 feet)
800 Vet = 33.75 mph
Number of lanes is measured at the stop line at the beginning of the section, not
including turn bays.
For each street, average daily traffic counts should be provided. Data up to five years old
is acceptable as long as significant changes in traffic patterns have not occurred.
Free flow travel time should be calculated assuming no stops and traffic flow at the
average posted speed limit. The free flow travel time for each section is the section
length divided by the speed in feet/sec. Speed in mph is converted to feet/sec by
multiplying by 1.47. The total free flow travel time is the total of the section free flow
travel times. The delay is the difference between free flow travel time and actual travel
time, averaged from the travel time runs. For example, a street contains two sections.
Section 1 is 800 feet and has a 35 mph average posted speed limit, and Section 2 is 1200
feet long and has a 40 mph average posted speed limit. The free flow travel time would
be
800feet 1200feet
35 mpTi x3.47 + 40 m-pF = 36 seconds
The Qualitof Service Summary form has been provided to allow the convenient orga-
nization &his data. One form should be filled out for each combination of street and
direction. Applicants should duplicate the form as necessary.
Summary
The procedure outlined here will provide a rough synopsis of the existing typical worst
case situation using data that can be collected very quickly. For arterial systems, only data
along the arterial is necessary. The runs have been defined to eliminate the inclusion of
boundary conditions (such as side street delay on an arterial), which, though they may
inhibit a complete understanding of the situation, will allow arterial and grid networks
to be compared in a similar light.
Oil
Applicant City of Denton
Attachment D
Traffic light Synchronization Program III
Quality of Service Summary
Agency:
City of Denton
Street Name:
welch
Direction of Travel Time Run:
Northbound
Section
Cross Street Name
Section
Length
Avg. Posted
Speed
Number of
Lanes
Free Flow
Travel Time
1
Nagle
-
-
_
-
2
Highland
985'
26.2
2
25.6
3
Prairie
395'
20
2
13.4
4
Chestnut
400'
20
2
13.6
5
Hickory
1,135'
23.3
2
33.1
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
Dates) of Study: 3/23/94
Total Free Flow Travel Time
Measured Travel Time - Run 1
Run 2
Run 3 (Arterial Systems)
Average Measured Travel Time
Delay forthis Street and Direction
85.7
Time of Study: 4: 30 - 5 : 30 PM
128.0
ADT for Street: 10,799 vpd
179.0
134.0
Comments:
147.0
61.3
*'IZ
Applicant City of Denton
Attachment D
Traffic Light Synchronization Program III
Quality of Service Summary
Agency: City of Denton
Street Name: Welch
Direction of Travel Time Run: Southbound
Section Cross Street Nb
1 Hickory
2 Chestnut
3 Prairie
4 Highland
5 Eagle
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
Date(s) of Study: 3/23/94
Time of Study: 4: 30 - 5: 30 PM
Nam
Section
Length
1135'
400'
395'
985'
ADT for Street: 10,799 vpd I
Comments:
Avg. Posted
Number of
Speed
Lanes
23.3
2
20
2
20
2
26.2
2
Total Free Flow Travel Time
Measured Travel Time - Run 1
Run 2
Run 3 (Arterial Systems)
Average Measured Travel Time
Delay for this Street and Direction
Free Flow
Travel Time
33.1
13.6
13.4
25.6
85.7
180.0
142.0
185.0
83.3
015
Applicant City of Denton
Attachment E
Traffic Light Synchronization (TLS) Program III
Budget Form
Applicant Financial Contact: Jerry Clark Phone: (817)566-8358
Personal Services
Salaries and Wages for personnel involved in the planning, development and
implementation of the proposed project
Position Salary Rate Number of Oil Overchar a Local Match*
—Aou�s un s
See Attached
Total Personal Services
Operating Expenses
Travel: $450/person/trip
(PASSER & TRANSYT
(Rates) training in Austin)
Other:
Other:
Total Operating Expenses
Equipment Items (List)
$ 5,723.60
See Attached
Total Equipment Items
$
1,800.00
$
1,800.00
$
37,371.00
*Designate if local match is from the City orTxDOT.
0014
Subcontracts OilOverchar e
Funds
Consultant Services** (Cummings & Pewitt) $ 6,761.27
Other** (City Utility Contractor) 10,997.13
Total Subcontracts $ 17,758.40
Others
Total Others
Grant Total
Total Local Match
(Indicate % of total project costs)
Indicate TxDOT % of Local Match
TOTAL PROJECT COST
* Designate if local match isfrom the CityorTxDOT.
** Attach detailed cost estimate.
$ 56,929.40
Attachment E
(page 2)
Local Match*
$ 13,252.87
$ 13,252.87
$ 18,976.47
( 25.0 %)
( 0.0 %
't IS
PERSONAL SERVICES COST ESTIMATE
Oil
Overcharge
Local
Position
Salary
Hours
Funds
Match
Director
$35.47
24
$0.00
$851.28
Supervisor
$20.83
72
$0.00
$1,499.76
Signal Tech.
$17.02
80
$0.00
$1,361.60
Signal Tech.
$15.70
72
$0.00
$1,130.40
Signal Tech.
$12.23
72
$0.00
$880.56
Total Personal Services
320
$0.00
$5,723.60
Salary includes hourly rate plus benefits.
lip
Item Purchased
Cable
2" Conduit
Hanger
Hook
Controller & Cabinet
Service Box
Total Cost
DETAILED EQUIPMENT
COST ESTIMATE
Amount Unit Unit Cost Cost
5710
LF
$0.90
2230
LF
$2.00
44
EA
$3.00
5
EA
$10.00
4
EA
$6,800.00
6
EA
$65.00
$5,139.00
$4,460.00
$132.00
$50.00
$27,200.00
$390.00
$37,371.00
11
CONSULTANT'S DETAILED
COST ESTIMATE
Staff
Salary
Hours
Cost
Senior Engineer
$28.84
56
$1,615.04
Assistant Engineer
$17.31
36
$623.16
Technician
$8.50
32
$272.00
Secretary
$8.00
8
$64.00
Sub -Total
132
$2,574.20
Overhead (127.3%)
Labor plus Overhead
Fixed Fee (10%)
Total Expenses
Total Cost
$3,276.96
$5,851.16
$565.12
$325.00
$6,761.27
CONTRACTOR'S DETAILED
LABOR COST ESTIMATE
Item Installed Amount Unit Unit Cost Cost
Overhead Cable 2930 LF $2.00 $5,860.00
Underground Cable 2780 LF $1.00 $2,780.00
2" Conduit 2230 LF $7.00 $15,610.00
Total Cost $24,250.00
M
Applicant City of Denton
Attachment F
Project Task Responsibility
(Please check appropriate agency o► It joint responsibility, enter percentage for each.)
Responsible A enc
LocaT3—ta-ff Consultant
L00 0
10 90
100
0
0
0
20
90
40
0
0
0
100
100
100
80
10
60
100
100
Task
• Field check Equipment
a Collect field data
• Attend PASSER and TRANSYT
Workshops
W Code data in computer and
complete initial simulation run
• Calibrate model
• Complete "Before" field
evaluation
• Complete optimization runs and
selection of plans
• Implement timing plans
6 Fine-tune timing plans
• Complete simulation of plans
implemented in field
i Complete "After" field
evaluation
" Enter "TxDOT" if the task is the department's responsibility.
Ow
Applicant City of Denton
Attachment G
Debarment Certification
(Negotiated Contracts)
(1) The LOCAL GOVERNMENT certifies to the best of its knowledge and belief, that
it and its principals:
(a) Are not presently debarred, suspended, proposed for debarment, declared
ineligible or voluntarily excluded from covered transactions by any federal
department or agency;
(b) Have not within a three-year period preceding this proposal been convicted
of or had a civil judgment rendered against them for commission of fraud or a
criminal offense in connection with obtaining, attempting to obtain, or performing
a public* transaction or contract under a public transaction; violation of federal or
state antitrust statutes or commission of embezzlement, theft, forgery, bribery,
falsification or destruction of records, making false statements, or receiving stolen
property;
(c) Are not presently indicted for or otherwise criminally or civilly charged by
a governmental entity* with commission of any of the offenses enumerated in
paragraph (1)(b) of this certification; and
(d) Have not within a three-year period preceding this application/proposal had
one or more public transactions* terminated for cause or default.
(2) Where the LOCAL GOVERNMENT is unable to certify to any of the statements
in this certification, such LOCAL GOVERNMENT shall attach an explanation to
this certification.
*federal, state or local
Ttle �
Date
FOTM 1734+A
4.89
0 2t