The URL can be used to link to this page

Home My WebLink About2000-107ORDINANCE NO /�'7 AN ORDINANCE ACCEPTING COMPETITIVE BIDS AND AWARDING A CONTRACT FOR THE PURCHASE OF A 15/20/25 MVA POWER TRANSFORMER, PROVIDING FOR THE EXPENDITURE OF FUNDS THEREFOR, AND PROVIDING AN EFFECTIVE DATE (BID 2408 — POWER 'TRANSFORMER AWARDED TO WAUKESHA ELECTRIC SYSTEM, DIVISION OF GENERAL SIGNAL POWER SYSTEMS, INC IN THE AMOUNT OF $441,877) WHEREAS, the City has solicited, and received competitive sealed bids for the construction of public works or improvements in accordance with the procedures of STATE law and City ordinances, and WHEREAS, the City Manager or a designated employee has received and recommended that the herein described bids are the lowest respondent for the construction of the public works or improvements described in the bid invitation, and plans and specifications therein, NOW, THEREFORE, THE COUNCIL OF THE CITY OF DENTON HEREBY ORDAINS SECTION I That the following competitive sealed bid for the construction of public works or improvements, as described in the "Sealed Bid hivitahons", or plans and specifications on file in the Office of the Crty's Purchasing Agent filed according to the bid number assigned hereto, are hereby accepted and approved as being the lowest responsible bids BID NUMBER CONTRACTOR AMOUNT 2408 Waukesha Electric System, Division $441,877 of General Signal Power Systems, Inc SECTION II That the acceptance and approval of the above competitive sealed bid shall not constitute a contract between the City and the person submitting the bid for construction of such public works or improvements herein accepted and approved, until such person shall comply with all requirements specified in the Notice to Bidders including the timely execution of a written contract and furnishing of performance and payment bonds, and insurance certificate after notification of the award of the bid SSACTION III That the City Manager is hereby authorized to execute all necessary written contracts for the performance of the construction of the public works or improvements in accordance with the bids accepted and approved herein, provided that such contracts are made in accordance with the Notice to Bidders and Request for Sealed Bids, and documents relating thereto specifying the terms, conditions, plans and specifications, standards, quantities and specified sums contained therein SECTION IV That upon acceptance and approval of the above competitive sealed bids and the execution of contracts for the public works and improvements as authorized herein, the City Council hereby authorizes the expenditure of funds in the manner and in the amount as specified in such approved buds and authorized contracts executed pursuant thereto SECTION V That this ordinance shall become effective immediately upon its passage and approval 5t PASSED AND APPROVED this the a _ day of , 2000 MR, M ATTEST JENNIFER WALTERS, CITY SECRETARY /�/ /.. _ ON ./ �i_'� i APPROVED AS TO LEGAL FORM HERBERT L PROUTY, CITY ATTORNEY BY BID 2408 - CON CTUAL ORDINANCE -SECOND AWARD ATTACHMENT TABULATION SHEET • _.. ' 1 POWER TRANSFORMERS N61 MY, I WORIPTION VENDOR VENDOR VENDOR VENDOR VENDOR C , 3 Go<vi r a , '< 116 ; g Y #<ro l>�> Yg 11.< a fi 4€;';, ;. Y Fz��£ Keasler Waukesha Temple Wesco Kuhlman Sunbelt § �I R ° Electric Trans EMS M, ohsi�� or<>p tlYk SY Y4,.tl�,�i§ g yY. hYp'e Electnc Principle Place of Business. Richardeon, TX Grand Prairie, TX Ft Worth, TX Goldsboro, TX Temple, TX Power Transformer El 15/20/25 MVA, 138kV $441,877 $428,892 $446,410 $436,356 $316,800 Wye with load tap Changer Second Award $441,877 Less Discount-$14,418 Cost $427,459 �r CONTRACT AGREEMENT STATE OF TEXAS § COUNTY OF DENTON § THIS AGREEMENT, made and entered into this 21 day of MARCH A D , 2000, by and between CITY OF DENTON of the County of DENTON and State of Texas, acting through MICHAEL W JEZ thereunto duly authorized so to do, hereinafter termed "OWNER," and Waukesha Electric Systems Division of General Signal Power Systems Inc P O Box 268 Goldsboro, North Carolina 27530 of the City of Goldsboro , County of Wayne and State of North Carolina , hereinafter termed "CONTRACTOR" WITNESSETH That for and in consideration of the payments and agreements hereinafter mentioned, to be made and performed by OWNER, and under the conditions expressed in the bonds attached hereto, CONTRACTOR hereby agrees with OWNER to commence and complete performance of the work specified below BID # 2408 - POWER TRANSFORMER in the amount of $427,459 and all extra work in connection therewith, under the terms as stated in the General Conditions of the agreement, and at his (or their) own proper cost and expense to furnish all materials, supplies, machinery, equipment, tools, superintendence, labor, insurance, and other accessories and services necessary to complete the work specified above, in accordance with the conditions and prices stated in the Proposal attached hereto, and in accordance with all the General Conditions of the Agreement, the Special Conditions, the Notice to Bidders (Advertisement for Bids), Instructions to Bidders, and the Performance and Payment, Bonds, all attached hereto, and in CA-1 accordance with the plans, which includes all maps, plats, blueprints, and other drawings and printed or written explanatory matter thereof, and the Specifications therefore, as prepared by ENGINEERING DEPARTMENT all of which are made a part hereof and collectively evidence and constitute the entire contract Independent Status It is mutually understood and agreed by and between City and Contractor that Contractor is an independent contractor and shall not be deemed to be or considered an employee of the City of Denton, Texas, for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit City shall not have supervision and control of Contractor or any employee of Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement Indemnification Contractor shall and does hereby agree to indemnify and hold harmless the City of Denton from any and all damages, loss, or liability of any kind whatsoever, by reason of injury to property or third persons occasioned by any error, omission or negligent act of Contractor, its officers, agents, employees, invitees, and other persons for whom it is legally liable, with regard to the performance of this Agreement, and Contractor will, at its cost and expense, defend and protect the City of Denton against any and all such claims and demands Choice of Law and Venue This agreement shall be governed by the law of the State of Texas and venue for its construction and enforcement shall lie in the courts of Denton County, Texas The CONTRACTOR hereby agrees to commence work on or after the date established for the start of work as set forth in written notice to commence work and complete all work within the time stated in the Proposal, subject to such extensions of time as are provided by the General and Special Conditions The OWNER agrees to pay the CONTRACTOR in current funds the price or prices shown in the Proposal, which forms a part of this contract, such payments to be subject to the General and Special Conditions of the Contract CA-2 IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written ATTEST CITY OF DENTON OWNER BY (SEAL) F fflm� WN M kb6G72T W r '&LDo APPROVED AS TO FORM V CITT ATTORNEY (/(/Rt LKG ��L�Ti c _1uS1�Gm s CONTRACTOR Pr wTIA' / C CA-3 MAILING ADDRESS $00 - E 35 - 12 73 ) PHONE NUMBER �z6a- S1i- 0/98 FAX NUMBER o TITLE si i PRINTEVAME / i i W ;7Os ; ,, N : a .l l STATE OF TEXAS COUNTY OF DENTON Bond No 929142310 KNOW ALL MEN BY THESE PRESENTS That Waukesha Electric Systems Drv4nn of General Sisnal Power Systems, Inc , and Nations t+it insurance a corporation organized and ealsting under the laws of the statif o C�t�nerrt�,, , and duly authorized to transact business in the State of Texas, as Surety, are held and firmly bound unto the City of Denton, a municipal corporation organized and existing under the laws of the State of Texas, hereinafter called Owner, in the penal sum of FOUR HUNDRED TWENTY tea percent or me stated penal sum as an additional sum or money representing additional court expenses, attorneys' fees, and liquidated damages arising out of or connected with the below identified Contract, is lawful money of the United States, to be paid in Denton County, Texas, for the payment of which sum well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally, Maly by these Presents This Bond shall automatically be increased by the amount of any Change Order or Supplemental Agreement which increases the Contract price, but in no event shall a Change Order or Supplemental Agreement which reduces the Contract price decrease the penal sum of this Bond, THE OBLIGATION TO PAY SAME is conditioned as follows Whereas, the Principal entered into a certain Contract, identified by Ordinance Number 2WO-107, with the CIty of Denton, the Owner, dated the 21 day of MARCH A D., 2000, a copy of which is hereto attached and made a part hereof, for BID M 2M — POWER TRANSFORMER NOW, THEREFORE, if the Principal shall well, truly and faithfully perform and fulfill all of the undertakings, covenants, terms, conditions and agreements of soul Contract In accordituce with the Plans, Specifications and Contract Documents during the original term thereof and any extension thereof which may be granted by the Owner, with or without notice to the Surety, and during the life of any guaranty or wanranry required under this Contract, and shall also well and truly perform and fulfill all the undertakings, covenants, terms, conditions and agreements of any and all duly authorized modifications of said Contract that may hereafter be made, notice of which modifications to the Surety being hereby waived, and, if the Principal shall repair and/or replace all defects due to faulty materials and workmanship that appear wuhm a period of one (1) year from the date of final completion and final acceptance of the Work by the Owner, and, if the Principal shall fully indemnify and save harmless the Owner from all costs and damages which Owner may suffer by reason of failure to so perforia herein and shall fully reimburse and repay Owner all outlay and expense which the Owner may Incur in malting good any default or deficiency, then this obligation shall be void, otherwise, it shall remain in foil force and effect PB - 1 T PROVIDED FURTHER, that of any legal action be filed upon this Bond, exclusive venue i shall lie in Denton County, State of Texas. AND PROVIDED FURTHER, that the said Surety, for value received, hereby stipulates and agrees that no change, extension of tune, alteration or addition to the roans of the Contract. or to tits Work to be performed thereunder, or to the Piano, Specifications, Drawings, etc., accompanying the same. shall in atrywise affect its obligation on this Bond, sad it does hereby waive notice of any such change, extension of time, alteration or addition to Me terms of the Contract, or to the Work to be performed thereunder, or to the Plans, Specifications, Drawings, etc This Bond is given pursuant to the provisions of Chapter 2233 of the Texas Government Code, as amended, and any other applicable statutes of the State of Texas The undersigned and designated agent is hereby designated by the Surety herein as the Resident Agent in Denton County to wbom say requisite notices may be delivered and on whom service of process may be had to matters &rising out of such suretyship, as provided by Article 7.19-1 of the Insurance Code, Vernon's Annotated Civil Statutes of the State of Texas IN WITNESS WHEREOF, this instrument is executed in 4 copies, each one of wkuch shall be deemed an original, this the 21 day of MARCH , 2000, ATTEST. PRINCIPAL Ar&&By 4 SECRETARY tom: COUNTERSIGNED BY - Waukesha Electric Systems Division of General Signal,Power Systems. Itnc. BY 1 v 7ce. PRES SURETY National Fire Insurance Company / n BY ofHaHart�forrd(� (�/ i`-�l OX Lawrence W. Waldie BY Texas Resident Agent ATTORNEY- -FACT Ronda L Pekel The Resident Agent of the Surety in Denton County, Texas for dahvery of nonce and service of the process is NAME. Lawrence W Waldie Marsh USA Inc. STREET ADDRESS 1601 Elm St., Suite 2100, Dallas, TX 75201 (NOTE. Date of Performance Bond must be date of Contract. If Resident Agent is not a corporgdon, give a person's name.) PB-2 PAYMENT BOND STATE OF TEXAS ¢ COUNTY OF DENTON § KNOW ALL MEN BY THESE PRESENTS That Waukesha Electric Syatems Divh of General Sind Power Siam, Inc , whose address is P 0 Boxed$ 00100M. North Carolina Z7330, hereinafter called Principal, and National Fire Insurance Company a corporation organ zed and e=tmg under the laws of the State of Conne fully of Hartford authorized to transact business in the State of Texas, as Surety, are bold and�y bound unto the City of Denton, a tmi umpal corporation organized and existing under the laws of the State of Texas, hereinafter called Owner, and unto all persons, firms, and corporations who may furnish materials for, or perform labor upon, the building or improvements hereinafter referred to, in the penal sum of FOUR HUNDRED TWENTY SEVEN THOUSAND FOUR nunYKCLr Mill r rally, 14V/1W WLLAYb (34L/,4aV) in lawnil money or ice Vmten States, to be paid in Demon, County, Texas, for the payment of which sum well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents This Bond shall automatically be increased by the amount of any Change Order or Supplemental Agreement which increases the Contract price, but in do evect shall a Change Order or Supplemental Agreement which reduces the Contract price decrease the penal stun of this Bond THE OBLIGATION TO PAY SAME is conditioned as follows Whereas, the Principal entered into a certain Contract, ideutified by Ordinance Number 2000-107, with the City of Denton, the Owner, dated the 21 day of MARCH A D 2000 , a copy of which is hereto attached and made a part hereof, for BID # 2408 - POWER TRANSFORMER NOW, THEREFORE, if the Principal shall well, truly and faithfully perform its duties and make prompt payment to all persons, firms, subcontractors, corporations and claimants supplying labor and/or material to the prosecution of the Work provided for in said Contract and any and all duly authorized modifications of said Contract that may hereafter be made, notice of which modifications to the Surety being hereby expressly waived, then this obligation shall be void, otherwise it shall remain in full force and effect. PROVIDED FURTHER, that if any legal action be Plied on this Bond, exclusive venue shall lie in Denton County, Texas. AND PROVIDED FURTHER, that the said Surety for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the Work to be performed thereunder, or to the Plans, Specifications, Drawings, etc., accompanying the same, shall in anywise affect its obligation on this Bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract, or to the Work to be performed thereunder, or to the Plans, Specifications, Drawings, etc PB-3 This Bond is given pursuant to the provisions of Chapter 2233 of the Texas t3ovognment Code, as amended, ad any other applicable statutes of the State of Texas. 7110 Undersigned ad Resident Agent Denton designated agent hereby designated by the Sttrety herein as the Cooly to whom any requisite notices may be delivered and on whom service of process may be had in matters artstag out of such suretyship, as provided by Article 7.19-1 of the Insurance Code, Vernon's Annotated Civil Statutes of the State of Texas IN WITNESS WHEREOF, this instrument is executed in 4 copies, each one of whieb shall be deemed an original, this the 21 day of MARCH , 2000 ATTEST: i BY. PRINCIPAL Waukesha Electric Systems Division of General Si nal Power Systems, Inc BY, y.c U c e. PRESIVU SURETY National Fire Insurance Company — �/ _�� of Hartford BY: i",�J � Q Lawrence W. Waldie BY, e-C-7�- c �' Texas Resident Agent A17ORNE ACT Ronda L Pekel The Resident Agent of the Sarety in Demon County, Texas for delivery of notice and service of the process is, NAME, Lawrence W. Waldie Marsh USA Inc. STREBTADDRESS: 1601 Elm St., Suite 2100, Dallas, TX 75201 (NOTE. Date of Payment Bond mast be dote of Contract. if Resident Agent is not a eorpomtion, give a personIstt m ) PB-4 POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That CONTINENTAL CASUALTY COMPANY, an Illinois corporation, NATIONAL FIRE INSURANCE COMPANY OF HARTFORD, a Connecticut corporation, AMERICAN CASUALTY COMPANY OF READING PENNSYLVANIA a Pennsylvania corporation (herein collectively called 'the CCC Surety Companies ), are duly organized and existing corporations having their principal offices in the City of Chicago, and State of Illinois and that they do by virtue of the signature and seals herein affixed hereby make constitute and appoint Drew Brach. Brian Cook Loretta A Peretti,H David Hoover, James A Dawdy, Ronda L Pekel, Individually their true and lawful Attorney(s)-in-Fact with full power and authority hereby conferred to sign seal and execute for and on tneir Dorian bonds undertakings and other obligatory instruments of similar nature In Unlimited Amounts - and to bind them thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of their corporations and all the acts of said Attorney, pursuant to the authority hereby given are hereby ratified and confirmed This Power of Attorney is made and executed pursuant to and by authority of the By -Laws and Resolutions, printed on the reverse hereof, duly adopted as indicated by the Boards of Directors of the corporations In Witness Whereof, the CCC Surety Companies have caused these presents to be signed by their Group Vice President and their corporate seals to be hereto affixed on this 17th day of March 2000 CONTINENTAL CASUALTY COMPANY OASU�<T 04SU9 m NATIONAL FIRE INSURANCE COMPANY OF HARTFORD 1� AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA pOPPOR�TP � \Mt'9Ar9AgtEG � OU SEAL t' i 7a t� ,p�� 1897 HA N �i • aP Marvin J Cashion Group Vice President State of Illinois County of Cook as On this 17th day of March 2000 before me personally came Marvin J Cashion tome known who being by me duly sworn, did depose and say that he resides in the City of Chicago State of Illinois that he is a Group Vice President of CONTINENTAL CASUALTY COMPANY NATIONAL FIRE INSURANCE COMPANY OF HARTFORD and AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA described in and which executed the above instrument that he knows the seals of said corporations, that the seals affixed to the said instrument are such corporate seals that they were so affixed pursuant to authority given by the Boards of Directors of said corporations and that he signed his name thereto pursuant to like authority and acknowledges same to be the act and deed of said corporations 2••••N.•N NN•N •N• ••H•� OFFICIAL SEAL' DIANE FAULKNER Mary pow futo of ISlnols My CamNoMat 8npira B/17ro1 • My Commission Expires September 17 2001 Diane Faulkner Notary Public CERTIFICATE I Mary A Ribikawskis Assistant Secretary of CONTINENTAL CASUALTY COMPANY NATIONAL FIRE INSURANCE COMPANY OF HARTFORD and AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA do hereby certify that the Power of Attorney herein above set forth is still in force, and further certify that the By -Law and Resolution of the Board of Directors of each corporation printed on the reverse hereof are still in force In testimony whereof I have hereunto subscribed my name and affixed the seals of the said corporations this 21st day of March 2000 CONTINENTAL CASUALTY COMPANY �GAsugtT tNSURq„_otio�'N NATIONAL FIRE INSURANCE COMPANY OF HARTFORD '0•*AMERICAN CASUALTY COMPANY OF READING PENNSYLVANIA ' pOPPOR�TE S��p,.p •41897 NA^" Mary A Ribikawskis Assistant Secretary (Rev 10/1/97) Authorizing By -Laws and Resolutions ADOPTED BY THE BOARD OF DIRECTORS OF CONTINENTAL CASUALTY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the Board of Directors of the Company "Article IX —Execution of Documents Section 3 Appointment of Attorney -in -fact The Chairman of the Board of Directors the President or any Executive Senior or Group Vice President may from time to time appoint by written certificates attorneys -in -fact to act in behalf of the Company in the execution of policies of insurance bonds undertakings and other obligatory instruments of like nature Such attorneys -in -fact subject to the limitations set forth in their respective certificates of authority shall have full power to bind the Company by their signature and execution of any such instruments and to attach the seal of the Company thereto The Chairman of the Board of Directors, the President or any Executive Senior or Group Vice President or the Board of Directors may, at any time revoke all power and authority previously given to any attorney -in fact This Power of Attorney is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of February 1993 Resolved that the signature of the President or any Executive, Senior or Group Vice President and the seal of the Company may be affixed by facsimile on any power of attorney granted pursuant to Section 3 of Article IX of the By Laws, and the signature of the Secretary or an Assistant Secretary and the seal of the Company may be affixed by facsimile to any certificate of any such power and any power or certificate bearing such facsimile signature and seal shall be valid and binding on the Company Any such power so executed and sealed and certified by certificate so executed and sealed shall with respect to any bond or undertaking to which it is attached continue to be valid and binding on the Company ADOPTED BY THE BOARD OF DIRECTORS OF AMERICAN CASUALTY COMPANY OF READING PENNSYLVANIA This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the Board of Directors of the Company "Article VF--Execution of Obligations and Appointment of Attorney -In -Fact Section 2 Appointment of Attorney-m-fact The Chairman of the Board of Directors the President or any Executive Senior or Group Vice President may from time to time appoint by written certificates attorneys -in -fact to act in behalf of the Company in the execution of policies of insurance bonds undertakings and other obligatory instruments of like nature Such attorneys -in -fact subject to the limitations set forth in their respective certificates of authority shall have full power to bind the Company by their signature and execution of any such instruments and to attach the seal of the Company thereto The President or any Executive Senior or Group Vice President may at any time revoke all power and authority previously given to any attorney -in -fact " This Power of Attorney is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of February 1993 Resolved that the signature of the President or any Executive Senior or Group Vice President and the seal of the Company may be affixed by facsimile on any power of attorney granted pursuant to Section 2 of Article VI of the By -Laws and the signature of the Secretary or an Assistant Secretary and the seal of the Company may be affixed by facsimile to any certificate of any such power and any power or certificate bearing such facsimile signature and seal shall be valid and binding on the Company Any such power so executed and sealed and certified by certificate so executed and sealed shall with respect to any bond or undertaking to which it is attached continue to be valid and binding on the Company ADOPTED BY THE BOARD OF DIRECTORS OF NATIONAL FIRE INSURANCE COMPANY OF HARTFORD This Power of Attorney is made and executed pursuant to and by authority of the following Resolution duly adopted on February 17 1993 by the Board of Directors of the Company RESOLVED That the President an Executive Vice President or any Senior or Group Vice President of the Corporation may from time to time appoint by written certificates Attorneys -in -Fact to act in behalf of the Corporation in the execution of policies of insurance bonds undertakings and other obligatory instruments of like nature Such Attomey-in-Fact subject to the limitations set forth in their respective certificates of authority shall have full power to bind the Corporation by their signature and execution of any such instrument and to attach the seal of the Corporation thereto The President an Executive Vice President any Senior or Group Vice President or the Board of Directors may at any time revoke all power and authority previously given to any Attorney -in -Fact This Power of Attorney is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of February 1993 RESOLVED That the signature of the President an Executive Vice President or any Senior or Group Vice President and the seal of the Corporation may be affixed by facsimile on any power of attorney granted pursuant to the Resolution adopted by this Board of Directors on February 17 1993 and the signature of a Secretary or an Assistant Secretary and the seal of the Corporation may be affixed by facsimile to any certificate of any such power and any power or certificate bearing such facsimile signature and seal shall be valid and binding on the Corporation Any such power so executed and sealed and certified by certificate so executed and sealed shall with respect to any bond or undertaking to which it is attached continue to be valid and binding on the Corporation CITY OF DENTON INSURANCE REQUIREMENTS FOR CONTRACTORS Bidder's attention is directed to the insurance requirements below It is highly recommended that bidders confer with their respective insurance carriers or brokers to determine in advance of Bid submission the availability of insurance certificates and endorsements as prescribed and provided herein If an apparent low bidder fails to comply strictly with the insurances requirements, that bidder may be disqualified from award of the contract Upon bid award, all insurance requirements shall become contractual obligations which the successful bidder shall have a duty to maintain throughout the course of this contract STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter As soon as practicable after notification of bid award, Contractor shall file with the Purchasing Department satisfactory certificates of insurance, containing the bid number and title of the project Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time, however, Contractors are strongly advised to make such requests prior to bid opening, since the insurance requirements may not be modified or waived after bid opening unless a written exception has been submitted with the bid Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted • Each policy shall be issued by a company authorized to do business in the State of Texas with an A M Best Company rating of at least A • Any deductibles or self -insured retentions shall be declared in the bid proposal If requested by the City, the insurer shall reduce or eliminate such deductibles or self -insured retentions with respect to the City, its officials, agents, employees and volunteers, or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses Liability policies shall be endorsed to provide the following •• Name as additional insured the City of Denton, its Officials, Agents, Employees and volunteers •• That such insurance is primary to any other insurance available to the additional insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought The inclusion of more than one insured shall not operate to increase the insurer's limit of liability • All policies shall be endorsed to read "SAID POLICY SHALL NOT BE CANCELLED, NONRENEWED OR MATERIALLY CHANGE WITHOUT 30 DAYS ADVANCED WRITTEN NOTICE BEING GIVEN TO THE OWNER (CITY) EXCEPT WHEN THE POLICY IS BEING CANCELLED FOR NONPAYMENT OF PREMIUM IN WHICH CASE 10 DAYS ADVANCE WRITTEN NOTICE IS REQUIRED" • Should any of the required insurance be provided under a claims -made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to clauns made after expiration of the contract shall be covered • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted [XI A General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000 shall be provided and maintained by the Contractor The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies [xl If the Commercial General Liability form (ISO Form CG 0001 current edition) is used Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage • Coverage B shall include personal injury Coverage C, medical payments, is not required If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least Bodily injury and Property Damage Liability for premises, operations, products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability Automobile Liability Insurance Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $1,000,000 either in a single policy or in a combination of basic and umbrella or excess policies The policy will include bodily minry and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract Satisfaction of the above requirement shall be in the form of a policy endorsement for any auto, or all owned, hired and non -owned autos [X] Workers Compensation Insurance Contractor shall purchase and maintain Worker's Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406 096 of the Texas Labor Code and rule 28TAC 110 110 of the Texas Worker's Compensation Commission (TWCC) [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract Coverage shall be on an "occurrence" basis, and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance Policy limits will be at least combined bodily injury and property damage per occurrence with a aggregate [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City budding Limits of not less than each occurrence are required [ ] Professional Liability Insurance Professional liability insurance with limits not less than per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement [ ] Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear [ ] Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications ATTACHMENT 1 [X] Worker's Compensation Coverage for Building or Construction Projects for Governmental Entities A Definitions Certificate of coverage ("certificate") -A copy of a certificate of insurance, a certificate of authority to self -insure issued by the commission, or a coverage agreement (TWCC-81, TWCC-82, TWCC-83, or TWCC-84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project Duration of the project - includes the time from the beginning of the work on the project until the contractor's/person's work on the project has been completed and accepted by the governmental entity Persons providing services on the project ("subcontractor" in §406 096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner -operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project "Services" does not include activities unrelated to the project, such as food/beverage vendors, office supply deliveries, and delivery of portable toilets B, The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401011(44) for all employees of the Contractor providing services on the project, for the duration of the project C The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract D� If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended E The contractor shall obtain from each person providing services on a project, and provide to the governmental entity (1) a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project, and (2) no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project F The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter G The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project H The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage I The contractor shall contractually require each person with whom it contracts to provide services on a project, to (1) provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401 011(44) for all of its employees providing services on the project, for the duration of the project, (2) provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project, (3) provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project, (4) obtain from each other person with whom it contracts, and provide to the contractor (a) a certificate of coverage, prior to the other person beginning work on the project, and (b) a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project, (5) retain all required certificates of coverage on file for the duration of the project and for one year thereafter, (6) notify the governmental entity in writing by certified marl or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project, and (7) contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services J By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self -insured, with the commission's Division of Self -Insurance Regulation Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions K The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity JUN-15-2000 13 34 AON OF GR G^!1 616 456 7451 P 01 Aon Risk Services Aon Risk Services, Inc of Michigan, 171 Monica NW, Suite 525, Grand Rapids, Michigan 49503 Telephone (616) 46a-5366 Facsimile (616) 456-7451 Direct Phone (616) 336-0416 TELEFAX TRANSMISSION Date 06/15/00 Pages Ind cover 5 To Denise Harpool From C Joy Teitsma Company City of Denton — Denton, TX Fax Number 940 349 7302 Re Certificate of Insurance wwra+•••wrr+++.•xwrwra+•*wwr++aa••wwrra+•••rrrr r+a••xrrr++•.xwrxra+•r Accompanying this memo please find Certificates of Insurance for Waukesha Electric Systems/SPX Corporation The onginal certificates are being mailed to you today Should you need anything further, please feel free to call me Regards, c)t cc Bob Baldus — Waukesha, Waukesha, WI (262) 521-0190 The matenals enclosed with this facsimile transmission are private and confidential and are the property of the sender The Information contained in the material is privileged and is intended only for the use of the individual(s) or entity(ies) named above If you are not the intended recipient, be advised that any unauthodzeri disclosure, copying, distribution or taking of any action in reliance on the contents of this telecopled information Is stncdy prohibited If you have received this facsimile transmission In error, please Immediately notify us by telephone to arrange for the return of the forwarded documents to us JUN-15-2000 13134 RON OF GR 616 456 4451 P 02 q rRDwIPPR a OATS IMMNDIYYI s THIS CERTIFICATE IS ISIEUSD AS A MATT INFORMATION Aon Risk Services, Ina ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER THIS CERTIFICATE DOES NOT AMEND 6XTPND OR 171 Munroe Avenue N N ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW COMPANIES AFFORDING COVERAGE Suits 523 Grand Rapzdo MI 49503 COMPANY 616-456-5366 A O S Fidelity & Gcaraaty C,p cDLnPANr _ INSURED — Waukesha Electric SystELme B O S F a 0 Soecialty Co COMPANY EPX Corporation 700 Terrace Point Drive C COMPANY Muskegon, MI 49443 D THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE I IRTFIO AIR OW HAVE BEEN ISSUED TO THE INSURED NAMED AOOVE TOP THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE IBBUED OR MAY PERTAIN THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN 16 SUBJECT TO ALL THE TERMS, FXOI IICIONS AND CONDITIONS OF SUCH POLICIES LIMITS BI IDWN MAY HAVE BEEN REDUCED BY PAID CLAIMS CO LTR TYPEOPINSURANCR POLICY NUMBER POUOY EFFECTIVE DAYC IMM/°°/YVI POLICY EXPIRATION °ATE WIMOD/YYI IILNrE GENERAL UABIUTY GENERAL AGGREGATE 8 5000000 PRODUCTS X GDMCLAIMSMADE OCCUR DREaa60600 1/01/00 1/07/01 ERONµSoADVINJURYAEG 9• 5000000 OWNER S A CONTRACTOR S PROT EACH OCCURRENCE A 2000000 FIRE DAMAGE [Any ON INN 2 20 000 0 25000 MED EXP IMY IF19 MIMI A AUTOL40OLE X UASIUTY ANY AUTO DE82213500 1/01/00 1/01/0, COMBINED SINGLE LIMIT 9 2000000 I ftr V9eaonl P9r nl F S ALL OWNED AUTOS SCHEDULED AUTOS DE92213400 1/01/00 1/01/01 Y SUUILY INJURY Per PCNd9ml 9 A HIRED AUTOS NON OWNED AUTOS XR0230044 1/01/00 1/01/01 x PROPERTY DAMAGE 0 GARAGE LIABILITY AV I U UNLY RA ACCIDENT 9 OTHER THAN AUTO ONLY ANY AUTO EACH ACCIDENT 0 AGGREGATE 0 N1CP96 WIPIUTY EACH OCCURRENCE a AGGREGATE S UMBRELLA FORM 9 OTI RR THAN WMDAMIA FORM WORMERS COMPENSATION AND MAY H 1 IT EMPLOYERS, LIABILITY EL EACH ACCIDENT s THE PROPRIETOR/ INCL PARTNERWEXECUTIVE a DISEASE POLICY UMIT 0 S OPPICERS ARE DLCL EL DISEASE EA EMPLOYEE OTHER DEEORIPr10N OF opERATioN6&ocAiianommeLesispEclu ITEMS RE City of Denton Hid #2409 - Power Transformer Bea attached a for additional information gg33, SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BS CANCELLED BEFORE THE CITY Of DMINTON EXPIRATION OA19 I"014!UF THE ISSUING COMPANY WILL ENDEAVOR TO MAIL ATTN DENISE KWOOL 30 DAYS WRITTEN NOTICE TO THE CERTIPIOATE HOLDER NAMED TO THE LEFT 901-R TNXAS B!"13INT MI FAILURE TO MAIL SUCH NOTICE SWILL IMPOSE NO OBLIGATION OR UAEAUTY DENTON TX 76201 OF ANY MIND UPON THE COMPANY ITS RAIDERS OR REPRESENTATIVES AITIN DRPPAWAT,v 045566017 ;x' W,J s f UKIGE JUN-15-2000 13 35 RON OF UR 616 456 7451 P 03 Attachment to ACORD Certificate for. Waukesha Electric Systems / SPX Corporation. The terms, conditions and provisions noted below are hereby attached to the captioned certificate as additional description of the coverage afforded by the Insurer(s) This attachment does not contain all terms conditions, coverages or exclusions contained In the policy li °t I'�i6°pi�atl'`i �i ,, CITY of DENTON ATTN DENISE HARPOOL 901-b TEXAS STREET DENTON TY 76201 lie DESCRIPTION of OPERATIONS/LOCATIONS/ VEHICLEr, ^�ont'd The cancellation provision on this Certificate of Insurance is amended as follows Said policy shall not be cancelled, nonrenewed or materially changed . without 00 days advant,ed written notice being given to the owner (city) except when the policy is being cancelled for nonpayment of premium Irt which case 10 days advance written notice is required 'Material Change means a s/gni flcant reduction m the provisions of the policy or the limit of coverage for the policy in place today. Additiondl Insured City of Denton, its Officials, Agents, Employees and Volunteers Authorized Representative Aon Risk Services 06/15/2000c JUN-15-2000 13 35 AON OF GR 616 456 7451 P 04 h O $ Tan V vlkf # g �$ r i L'�",,�I DATE IMNIDD/YYI � a, a \ 3 ! >K PRODUCER a 9' ^ # 6 15 DD THIS CERTIFICATE IS ISSUED ASIA MATTER OF INFORMATION Aoa Risk Service¢, Inc. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER THIS CERTIFICATE DOES NOT AMEND, EXTEND OR 171 Monroe Avenue N W ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW COMPANIES AFFORDING COVERAGE Suite 525 COMPANY Grand Rapids EEI 49503 616-456-5366 A U S Fidelity & Guaranty Co. INSURED COMPANY Waukesha Electric Systems a __ _ COMPANY SPX Corporation 700 Terrace Point Drive C COMPANY µ Muskegon, MI 49443 D ] THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS 00 LTR Typg OF WSURANCE POLICY NUMEER POMCY EPPECTIVS DATE IMMMDAYYI POLICY EXPIRATION DATE IMMMDMI LIMITS IRPIEM LIABILITY GENERAL AGGREGATE e PRODUCTS COMP/OP AGO e COMMERCIAL GENERAL LABILITY CLAIMS MADE u OCCUR PERSONAL E ROY INJURY e EACH OCCURRENCE e OWNER 6 • CONTRACTOR'S PROT FIRE OAMAGE Any one finl e MID EXP Any one Fefeanl F RUTOMOBRE LIABILITY ANY AUTO COMBINED SINGLE LIM B s BODILY INJURY IPW M,WN e ALL OWNED AUTOS SCHEDULED AUTOS BODILY INJURY IPe, eodoeno - , HIRED AUTOS NON OWNED AUTOS PROPERTY DAMAGE S GARAGE UAMLOY AUTO ONLY EA ACCIDENT s OTHER THAN AUTO ONLY ANY AUTO EACH ACCIDENT e j AGGREGATE e I E%OEBS LIABILITY EACH OCCURRENCE e AGGREGATE e UMBRELLA FORM - s OTHER THAN UMBRELLA FORM WORREM COMPENSATION AND X ATU O LIMTS A EMPLOYERS UABIUYV DRE2260200 1/01/00 1/01/01 EL EACH ACCIDENT 6 1000000 A THE PROPRIETOR/ INCL PAPITNERVID(ECUTIV6 DR32260400 1/01/00 1/01/01 ELDISEASE POUCYLIMIT S 1000000 EL DISEASE EA EMPLOYEE E 1000000 OFFICERS ARE EXCL OTHER DESCRIPTION OF OKRATIONSAAO TIONSAMNIOLEEIBPECIAL ITEMS RE: City of Denton Bid #2409 - Power Transformer Sae attached a for additional Workers, C eneatioa polio information s sue, SHOULD ANY OF THE ABOVE DESCRIBED POUOISE BE CANCELLE) BEFORE THE CITY Of DEMON EXPIRATION DATE THEREOF THE ISSUWO COMPANY WILL ENDEAVOR TO MAIL ATTIE DENISE HARPOOL 30 DAYS WNTTEN NOTICE TO THE IJER'TIFICATE HOLDER NAMED TO THE LEFT 901-8 TEXAS STREET AM FAILURE TO MAIL OUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY DENTON TX 76201 OF ANY BIND UPON THE COMPANY RSB AGENTS OR RERACH;NTATIm AUTH7 AE. T^M 045566017 I � x Itl61Ia � e"'� � iY /L I rytLe 1 I F'IdSL .;kAI i�'i'T+'y IF ly L I r�� JUN-15-2000 13 35 PON OF GR 616 456 7451 P 05 Attachment to ACORD Certificate for. Waukesha Electric Systems / SPX Corporation The terms, conditions end piuviolune noted below are hereby attached w the captioned certificate as additional description of the coverage afforded by the insurer(s) This attachment does not contain all terms ^„1diflons, coverages or exclusions contained in the Ilc ' IiL1r71J0EEt'1 i' t'1� r tWI�!/?�itW�SA2`�r-7•`a'�K�,�F.tIPtG '�Rt'i �'•A 1� 1 t� d i,}�iy ,n. �iii CITY of UhN I UN A U S Fidelity & Guaranty CO ATTN UhNlbt HARPOOL B uut•fi IEXASSTREET C DENTON TX 76201 D ADDmONAL POLICIES If a policy below does not Include limit Information, refer to the corresponding policy on the AUUM cerbribate roan Tar OIIC IIn11L9 Iht'i gu i tl { 15��N�HSiinl I Apt, ( 6X Jdl'I ^'I Fdlrx nlf'x�/'1 x x iI'VI FI h1Yi 'i a,1 1NA� i'n14�' roi,. 1 0 x' IAM�i''�'1�'��Y,�rlr.yL 1C7 li pn e J ,� '''a di'lii 4f Hi��", II bAv I fIY Iil� 4 J'n IW v IwN�4'fi i 4i 'S xrVL u �y'i ,4��1 ° I di pe 1' „tl gK v 4J IRIW %i�'il 'e' a'i 1 Ii �tiaI1V 1 , Ib'1"' �uNo'��it Aul'at.,^a A Workers Compensation & XM094UU45 1/1/00 111/01 $ Employers Liability A Workers' Compensation & IC12225419000 111/00 1/1101 $ Employees Liability A Workers' Compensation & DRE2200300 1/1/00 1/1/01 $ Employers' Liability A Workers'Co pensation& DRE2260500 111/00 1/1/01 S Employers' Liability All Workers' Compensation policies described on this Certificate of Insurance are subject to a Self Insured Ratantinn nP S350,000 — Each Claim — Workers' Compensation — Coverage A $300,000 — Each Claim — Employers Liability — (,overage B $350,000 — Disease - Each Employee — Employer's Liability — Coverage B Limits of Liability shown for all Workers' Compensation policies described on this Certificate of Insurance are in excess of the Self Insured Retention limits shown above The cancellation provision on this Certificate of insurance Is amended as follows Said policy shall not be cancelled, nonrenewed or materially changed` without 30 days advance written notice being given to the owner (city) except when Uiolpullcy lb being cancelled for nonpayment of premium in which case 10 days advance written notice is required 'Arafadal Change means a sleaMoant reduadon In the provlsiuna of Me policy or the limit of coverage for the polity in place today Waiver of Subrogation is Included in Workers' Compensation policies described hereon Authorized Representative Aon Risk Services 06/15/2000 TOTAL P 05