Loading...
Development_Contract_Template_Revised 07_13_2020PROJECT NO. CONTRACT TYPE DEVELOPMENT CONTRACT FOR PUBLIC IMPROVEMENTS WHEREAS, , (the “Developer”), whose business address is , is the owner and developer of real property located in the corporate limits of the City of Denton being described as , (the “Development”), an addition to the City of Denton, Texas; and WHEREAS, Developer wishes to enter into this agreement with the City of Denton, Texas (the “City) to provide for the construction of certain public improvements generally described as the , (the “Public Improvements”), as further described in Exhibit A attached hereto and made a part hereof by reference, which, among other things, are necessitated by and will serve the Development; and WHEREAS, this agreement is entered into pursuant to Subchapter C of Chapter 212 of the Texas Local Government Code as a condition of plat approval and the Public Improvements are roughly proportional to the benefits received and burdens imposed by the Development; and WHEREAS, this agreement is required to ensure that the Public Improvements are constructed in accordance with the City’s standard specifications for public works projects, applicable ordinances and design criteria manuals (“Standard Specifications”), and the plans and specifications prepared by Developer’s engineer, (“Developer’s Engineer”) dated , which were approved by the City and are on file in the office of the City Engineer, which may be amended with the written approval of the City Engineer or their designee (the “Project Page 1 of 9 C:\Users\2421001\Desktop\DC CONTRACTS\Contracts for Applicant\word documents\Development Contract.docx DEVELOPMENT CONTRACT Page 2 of 9 Specifications”), such Standard Specifications and Project Specifications being incorporated herein by reference and herein called the “Plans and Specifications”; and WHEREAS, the Developer understands and agrees that it is responsible for and has retained at its sole expense, the Developer’s Engineer to design the Public Improvements in accordance with the Standard Specifications, taking into consideration the specific site conditions that may impact the Public Improvements; and WHEREAS, the Developer shall provide for the construction of the Public Improvements by and through , (the “Contractor”), whose address is , a construction contractor experienced in the construction of improvements similar to the Public Improvements, and WHEREAS, Developer and Contractor recognize that the City has an interest in ensuring that the Public Improvements, which will, upon completion and acceptance by the City, become public property, are properly constructed in accordance with the Plans and Specifications and that payment by Developer is provided therefor; NOW, THEREFORE, The Developer, Contractor, and City (the “Parties”) in consideration of their mutual promises and covenants contained herein agree as follows: 1. Covenants of Developer and Contractor. (a) Construction. Contractor shall construct the Public Improvements in accordance with the Plans and Specifications and complete the Public Improvements on or before . Developer shall be responsible for all monies due to the Contractor for construction of the Public Improvements. In no event shall the City be responsible for payment of any of the expenses or costs to construct the Public Improvements. The City Engineer DEVELOPMENT CONTRACT Page 3 of 9 in their discretion may require the Developer to provide security for payments to the Contractor, which may be in the form of a cash deposit with the City, a letter of credit, a dedicated construction account with a lending institution approved by the City Engineer, or other security that the City Engineer in their discretion deems adequate to ensure that the Developer does not default in its payment obligations to the Contractor. (b) Authority of City Engineer, Inspections, Tests and Orders, Developer and Contractor Warranty. All work on the Public Improvements shall be performed in a good and workmanlike manner and to the satisfaction of the City Engineer or their representative. The City Engineer shall decide all questions, which arise as to the quality and acceptability of materials furnished, work performed, and the interpretation of the Plans and Specifications and may reject any work not performed in accordance with the Plans and Specifications. The Contractor, its surety on the performance bond required herein and the Developer, warrant that the Public Improvements will be free from defects in materials and workmanship and that they will pay to remedy same for a period of two years after the completion of the Public Improvements and final acceptance by the City. This warranty shall not constitute a limitation on the duty to remedy latent defects in construction that were not known at the time of final acceptance or within said two year warranty period. The Contractor shall furnish the City Engineer or their representative with every reasonable facility for ascertaining whether or not the work performed was in accordance with the Plans and Specifications applicable thereto. DEVELOPMENT CONTRACT Page 4 of 9 Any work done, or materials used without suitable inspection by the City may be ordered removed and replaced at Contractor’s expense. The City Engineer or their designee shall perform periodic inspections of the work and shall perform a final inspection prior to final acceptance by the City and an inspection 30 days prior to the expiration of two years from the date of final completion and acceptance of the work by the City. Upon failure of the Contractor to allow for inspection, to test materials furnished, to satisfactorily repair, remove or replace, if so directed, rejected, unauthorized or condemned work or materials, or to follow any other request or order of the City Engineer or their representative, the City Engineer shall notify the Developer of such failure and may suspend inspections of such work until such failure is remedied. If such failure is not remedied to the satisfaction of the City Engineer, the City shall have no obligation under this agreement to approve or accept the Public Improvements and the City may withhold, suspend or revoke any permits or other approvals for the Development until such matter is remedied to the satisfaction of the City Engineer. (c) Insurance. Contractor shall provide for insurance in form and in substance in accordance with the City’s standard insurance requirements for public works projects, which are on file in the Office of the City Engineer and which are incorporated herein by reference. (d) Means and Methods of Construction. The means and methods of construction shall be such as Contractor may choose; subject, however, to the City’s right to reject the Public Improvements for which the means or method DEVELOPMENT CONTRACT Page 5 of 9 of construction does not, in the judgment of the City Engineer, assure that the Public Improvements are constructed in accordance with Plans and Specifications. (e) Books and Records. All of the Developer’s and the Contractor’s books and other records related to the construction of the Public Improvements shall be available for inspection by the City. (f) Performance Bonds. The Contractor shall execute a performance bond in the full amount of the cost to construct the Public Improvements in favor of the City ensuring completion of the Public Improvements in accordance with the Plans and Specifications and warranting against defects in materials and workmanship for a period of two years from the date of final acceptance by the City as provided in 1(b) herein. The performance bond shall be executed by a corporate surety authorized to do business in Texas in accordance with Chapter 2253 of the Texas Government Code, shall be on the City’s standard form, and shall contain a local resident agent for service of process. The Developer may be a co-obligee on the performance bond with regard to the Contractor’s obligations. (g) Payment Bonds. The Contractor shall execute a payment bond in the full amount of the cost to construct the Improvements in favor of the City insuring against claims from suppliers and subcontractors. The payment bond shall be executed by a corporate surety authorized to do business in Texas in accordance with Chapter 2253 of the Texas Government Code, shall be on the City’s standard form, and shall contain a local resident agent for service of process. Owner and Developer may be co-obligees on the payment bond. DEVELOPMENT CONTRACT Page 6 of 9 (h) Retainage: Final Payments. As security for the faithful completion of the Public Improvements, Contractor and Developer agree that the Developer shall retain ten (10) percent of the total dollar amount of the contract price until after final approval or acceptance of the Public Improvements by the City. The Developer shall thereafter pay the Contractor the retainage, only after Contractor has furnished to the Developer satisfactory evidence including an affidavit that all indebtedness has been paid, that all indebtedness connected with the work and all sums of money due for labor, materials, apparatus, fixtures or machinery furnished for and used in the performance of the work have been paid or otherwise satisfied. In addition, Contractor shall provide Developer with a consent to final payment from the payment bond surety. (i) Encumbrances. Upon completion and final acceptance of the Public Improvements by the City, the Public Improvements shall become the property of the City free and clear of all liens, claims, charges or encumbrances of any kind. If, after acceptance of the Public Improvements, any claim, lien, charge or encumbrance is made, or found to exist, against the Public Improvements, or land dedicated to the City, to which they are affixed, the Developer and Contractor shall upon notice by the City promptly cause such claim lien, charge or encumbrance to be satisfied and released or promptly post a bond with the City in the amount of such claim, lien, charge or encumbrance, in favor of the City, to ensure payment of such claim, lien, charge or encumbrance. (j) INDEMNIFICATION. THE DEVELOPER AND CONTRACTOR SHALL AND HEREBY DO INDEMNIFY, DEFEND AND SAVE DEVELOPMENT CONTRACT Page 7 of 9 HARMLESS, THE CITY, ITS OFFICERS, AGENTS AND EMPLOYEES FROM ALL SUITS, ACTIONS OR CLAIMS OF ANY CHARACTER, NAME AND DESCRIPTION BROUGHT FOR OR ON ACCOUNT OF ANY INJURIES OR DAMAGES RECEIVED AS SUSTAINED BY ANY PERSON, PERSONS OR PROPERTY ON ACCOUNT OF THE OPERATIONS OF THE CONTRACTOR, THEIR AGENTS, EMPLOYEES OR SUBCONTRACTORS; OR ON ACCOUNT OF ANY NEGLIGENT ACT OF FAULT OF THE CONTRACTOR, THEIR AGENTS, EMPLOYEES OR SUBCONTRACTORS IN CONSTRUCTION OF THE IMPROVEMENTS; AND SHALL PAY ANY JUDGMENT, WITH COSTS, WHICH MAY BE OBTAINED AGAINST THE CITY GROWING OUT OF SUCH INJURY OR DAMAGE. (k) Agreement Controlling. The provisions of this agreement shall control over any conflicting provision of any contract between the Developer and Contractor as to the construction of the Public Improvements. 2. Covenants of City of Denton. Upon proper completion of the Public Improvements in accordance with this agreement, the City agrees to accept the Public Improvements. 3. Nexus and Rough Proportionality. The Developer acknowledges and agrees that there is a reasonable nexus between the demands created by the Development and the Public Improvements, and that the costs associated with the construction and dedication of land for the Public Improvements is roughly proportional to the benefits received and DEVELOPMENT CONTRACT Page 8 of 9 the burdens imposed by the Development. The Developer shall indemnify and hold the City harmless against any claim by it or others claiming through it, that the required Public Improvements and associated dedication of land are unlawful exactions. 4. Venue and Governing Law. The Parties herein agree that this agreement shall be enforceable in Denton County, Texas, and if legal action is necessary in connection therewith, exclusive venue shall lie in Denton County, Texas. The terms and provisions of this agreement shall be construed in accordance with the laws and court decisions of the State of Texas. 5. Successor and Assigns. This contract shall be binding upon and inure to the benefit of the parties hereto, their respective successors and assigns. Executed this, day of , 20 . DEVELOPER Name: By: Name: Title: Address: CONTRACTOR Name: By: Name: Title: Address: DEVELOPMENT CONTRACT Page 9 of 9 CITY OF DENTONTODD HILEMAN, CITY MANAGER BY: ATTEST: ROSA RIOS, CITY SECRETARY BY: APPROVED AS TO LEGAL FORM: AARON LEAL, CITY ATTORNEY BY: THIS AGREEMENT HAS BEEN BOTH REVIEWED AND APPROVED As to financial and operational obligations and business terms. SIGNATURE PRINTED NAME TITLE Page 1 of 3 Effective December 1st, 2003 PROJECT NO. CONTRACT TYPE PERFORMANCE BOND THE STATE OF TEXAS § COUNTY OF DENTON § KNOW ALL MEN BY THESE PRESENTS: That , , of County, Texas, hereinafter called Principal and a Corporation organized under the laws of the State of and authorized to do business in the State of Texas, hereinafter called “Surety”, are held and firmly bound unto the City of Denton, Texas, a Municipal Corporation, in Denton County, Texas, hereinafter called “City” in the penal sum of ($ _) dollars, lawful money of the United States, for the payment of which sum well and truly to be made we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, and firmly by these presents: THE Condition of this Obligation is such that: WHEREAS, the Principal entered into a certain contract with Owner, dated the day of , 20 , in the proper performance of which the City of Denton has an interest, a copy of which is hereto attached and made a partKHUHRI for the construction of: Page 2 of 3 PERFORMANCE BOND NOW, THEREFORE, if the Principal shall well, truly, and faithfully cause to be performed and fulfilled all of the undertakings, covenants, terms, conditions, and agreements of said Contract in accordance with the Plans, Specifications, and Contract Documents during the original term thereof, and any extension thereof which may be granted, with or without notice to the surety, and during the life of any guaranty required under the Contract, which is incorporated, as if written word for word herein, and shall also well and truly cause to be performed and fulfilled all the covenants, terms and conditions and agreements of any and all authorized modifications of said Contract that may hereafter be made including, without limitation, to remedy and pay for any defects in material and workmanship or damage to other work or facilities which shall appear within two years from the date of final completion notice of which modifications to the surety being hereby waived; then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, further, that if any legal action be filed on this bond, venue shall lie in Denton County. AND, that said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract, or to the work performed thereunder, or the Plans, Specifications, Drawings, etc., accompanying the same shall in any wise affect its obligation on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed thereunder. Page 3 of 3 PERFORMANCE BOND IN WITNESS WHEREOF, this instrument is executed in triplicate, each one of which shall be deemed an original, this the day of , 20 . PRINCIPAL SURETY BY: BY: ATTORNEY-IN-FACT ATTEST: SECRETARY NOTE: POWER OF ATTORNEY OF SURETY MUST BE ATTACHED. DATE OF BOND MUST NOT BE PRIOR TO DATE OF CONTRACT DATE OF POWER OF ATTORNEY. CERTIFICATION MUST NOT BE PRIOR TO DATE OF CONTRACTOR BOND. Effective December 1st, 2003 PROJECT NO. CONTRACT TYPE PAYMENT BOND THE STATE OF TEXAS § COUNTY OF DENTON § KNOW ALL MEN BY THESE PRESENTS: That of the City of County of , and the State of , as principal, and authorized under the laws of the State of Texas to act as surety on bonds for principals, are held and firmly bound unto The City of Denton, OWNER, in the penal sum of dollars ($ ) for the payment whereof, the said Principal and Surety bind themselves and their heirs, administrators, executors, successors and assigns, jointly and severally, by these presents: WHEREAS, the Principal has entered into a certain written contract with the Owner, dated the day of 20 . to which contract is hereby referred to and made a part hereof as fully and to the same extent as if copied at length herein. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal shall pay all claimants supplying labor and material to him or a subcontractor PAYMENT BOND Page 2 of 3 in the prosecution of the work provided for in said contract, then this obligation shall be void, otherwise to remain in full force and effect; PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of the Texas Government Code, Chapter 2253 (Vernon, as currently amended), and all liabilities on this bond shall be determined in accordance with said provisions to the same extent as if they were copied at length herein. Surety, for value received, stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract, or to the work performed thereunder, or the plans, specifications, or drawings accompanying the same, shall in any way affect its obligation on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract, or to the work to be performed thereunder. PAYMENT BOND Page 3 of 3 IN WITNESS WHEREOF, the said Principal and Surety have signed and sealed this instrument this day of 20 . PRINCIPAL SURETY BY: BY: TITLE: TITLE: ADDRESS: ADDRESS: The name and address of the Resident Agent of Surety is: