1987-2032088L
NO
AN ORDINANCE AUTHORIZING THE MAYOR OF THE CITY OF DENTON, TEXAS
TO EXECUTE AN AGREEMENT BETWEEN THE CITY OF DENTON AND TBAGUE
NALL AND PERKINS FOR PROFESSIONAL ENGINEERING SERVICES RELATING
TO DBNIA, EVERS AND NORTH LAKES PARKS, AUTHORIZING THE
EXPENDITURE OF FUNDS THEREFOR, AND PROVIDING AN EFFECTIVE DATE
THE COUNCIL OF THE CITY OF DENTON HEREBY ORDAINS
SECTION I That the Mayor is authorized to execute an
agreement between the City o£ Denton and Teague Nall and Perkins
for the purpose of providing engineering services relating to
Denla, Evers and North Lakes Parks, under the terms and
conditions contained in sa~d agreement, which ~s attached hereto
and made a part hereof
SECTION II That the City Council hereby authorizes the
expenditure of funds in the manner and amount as specified in the
agreement
SECTION III That this ordinance shall become effective
~mme~iatel¥ upon Its passage and approval
ATTEST
CITY
3EN~FER~L'TERS) ~ECRETAR?
APPROVED AS TO LEGAL FORM
DEBRA ADAMI DRAYOVITCH, CITY ATTORNEY
DanTE November 17, 1987
CIl~)F COUNCIL REPORT
TO Mayor and Members of the City Councd
FROM Lloyd V. HarreU, City Manager
SUB3ECT CONTRACT FOR RFP# 102 FOR PROFESSIONAL
ENGINEERING AND LANDSCAPE ARCHITECTURAL
PLANNING FOR CITY PARKS
SUMMARY The Cmty o! Denton sent out Request For Proposals for the above
servtces to some 25 professtonals We received seventeen Proposals including two
Denton ftrms These seventeen were revtewed according to the specified cmterta and
eight were selected for mtervtews We then scheduled further presentation and
mterwews wtth the etght professtonal firms and from these three were selected I then
scheduled negottatton sessmns w,th each of the three w~th fees and msurance being the
mare subjects At the ttme I was negotmtmg these ,terns, others wstted the three
firms, thetr offices and some projects that they had completed and/or had m progress
With these facts the Staff conststmg of Tom Shaw, Steve Brmkman, Bob Ttckner and
myself rev,ewed the tnformatmn The firm of Teague Nail & Perkms was selected to
prowde the reqmred servtces
The contract was then negotmted with Teague Na11 & Perkins It
was approved by Legal, the Staff and Teague Nail & Perkins
A11 professtonal firms or persons were given just and due
consideratton during the selectton process The estimated fee ts not to exceed
$73,500 00
BACKGROUND: The Request For Proposal was prepared and sent out for the
proposed pa~k zmprovements at Dema, Evers and North Lakes The Ctty of Denton staff
unammously selected the firm recommended
PROGRAMS~ DEPARTMENTS OR GROUPS AFFECTED This ts for Parks and
Recreatmn in the Capital-Bond Improvements Program
FISCAL IMPACT There is no addttmnal impact on the General Fund
lly submitted
C~ty Manager
J~61~ ~lx Ma)~all, C P M
~Pur~asmg Agent
~~mga~rSh'~ll, C P M Agent
1987, by and between the CITY OF DENTON h~ere-~e~after c~ OWNER,
acting by and through its Purchasing Agent, or duly appointed
representative authorized to act and TEAGUE NALL AND PERKINS, INC , a
corporation hereinafter called the ~GIN~
P~CITALS
--~ the furnishing of engineering/planning
This CONTRACT ~s applicable to planning, preparation and suhnlttal of
services by ENGINEER for master
grant applications, and preparation of construction documents for Denla
Park, Evers Park, and North Lakes Park as outlined in the proposal
suh~tted to OWNER by ~GINEER dated July 16, 1987, and as modified by
addendu~ to that same proposal dated September 15, 1987 These services
will be provided whether funded directly by OWNER, by private sources, and
implemented by OWNER, or by Grants or other sources, but only in specific
s~tuatlons and to the extent that such services frc~ time to t~me are
authorized in writing by OWNER, as provided in Section III following
CONTRACTUAL UNDERTAKINGS
SECTION I
~4PLOYMENT OF ~GINEER
The OWNER agrees to employ the ~GINEER and ~e ~GINEER agrees to furnish
engineering services as stated in the Sections to follow, and for having
rendered such services the OWNER agrees to pay to the ~GINEER compensation
as stated in Section VI following
SECTION II
CHARACTER AND EXTENT OF SERVICES
The engineering/planning services to be rendered by E~gineer shall be
performed as required during the following phases of each project
A pRELIMINARY
B DESIGN
C CONSTRUCTION
-1-
In addition %o these services, other services related to the project that
may be Included by specific authorization are identified hereIn as "D
SPECIAL SERVICES "
These various services are hereInafter more fully descrLbed as follows
A pRELIMINARY PHASE
1 Attend prel~u%ary conference with OWNER regardLng each of the
three (3) projects
2 Prepare a master plan for each park In sufficient detail to
Indicate clearly all proposed lmprov~nents and necessary
reconstruction Same shall Include layouts and cost estimates
for each park, and shall set ~forth clearly the ENGINeeR'S
recc~mendations
3 Furnish the OWNER all necessary copies of each master plan,
includIng layouts and cost estimates All reports in excess of 5
copies are to be paid for separately as provided hereInafter
(See paragraph II D 9 )
B DESIGN PHASE
1 Establish the scope and advise the OWNER, of any soil,
foundation, or other subsurface Lnvestlgatlons or any special
surveys or special testing which, in the opinion of the ENGINEER,
may be required for the proper execution of the project assist
the OWNER In arranging for the conduct of such investigations and
tests (The performance of these investigations and tests is not
- a par% of the ENGIN~ER'S services and will not be included unless
specifically authorized In writing under "D SPECIAL SERVICES"
following)
2 Furnish to the OWNER, where required by the circumstances of the
assignment, the engineer lng/planning data necessary for
appllcatlons for routine permits by local, state, and federal
authorities (as dIstinguished from detailed applications and
supportIng documents for state/federal government grants-In-aid,
or for planning advances not Included in these services)
3 OWNER shall provide all field surveys (1 e topog~_a~hlc design
surveys to Include existing facilities and utilities) to collect
information on surflclal topographic features, which in the
opinion of the ENGINe, ~s required in the design of the
project, (as distlngulshed from land surveys for boundary
descriptions of sites, easements, rights-of-way, etc )
4 D~velop the project design combInIng the applicatIon of sound
engineering/plannIng principles and economy which shall be
manifested by completed Construction Contract Doc~nents, (Plans,
Speclflcatlons, etc ) and assist OWNER with s~ta~lttal of such
Documents to local, state and federal agencies for approval as
may be appllcable
-2-
5 Prepare detaaled cost est/mates identifiable with the proposals
of authorized construction, whach shall ~nclude sumnarles of bid
items and quantities on the unit price system of bidding wherever
practacal The _~GINEER shall not ~ r ~e~lllred to guarantee the
accuracy of these estimates
6 Furnlsh to the OWNER all necessary cop~es of approved
Construction Contract Documents (plans, specifications, notice to
b~dders, proposals, etc ) All copies are to be paad for
separately as provided hereinafter (See Paragraph II D 9 )
C CONSTRUCTION pHASE
1 Assist the OWNER ~n the advertisement of the project for bads
2 Assist the OWNER ~n the opening and tabulation of bads for
constructaon of project and recc~mend to the OWNER as to the
proper action on all proposals received
3 Assist in the preparatlon of formal Contract Documents and in
coordinating their execution by the respective pa~t~es
4 Represent the OWNER ~n the Non-Resadent adminlstratlon of the
project In thls capacity, the ENGINEER shall have the authoraty
to exercise whatever raghts the OWNER may have to disapprove work
and materials that fall to conform to the Contract Docu~nents when
such failures are brought to the ENGINEER'S attention (Th~s
function of ENGINEER shall not be construed as supervlslon of the
project and 'does not include on-s~te aotlvltles other than
occasional s~te v~s~ts to observe overall project conditions or
when speolflcally requested by OWNER to-vls~t on-s~te for a
particular matter It particularly does not anvolve exhaustive
or continuous on-slte inspections to check the quality or
quantity of the work or material, nor does it place any
responslblllty on ENGINEER for the techniques and sequences of
constructlon or the safety precautaons lncadent thereto, and he
w~ll not be responsLble, or laable, in anY degree for the
Contractor ' s failure to perform the construction work ~n
accordance with the Contract Documents)
5 Consult and advise the f~NER, ~ssue such instructions to the
Contractor as ~n the judgment of the ENGINEER a~e necessary, and
prepare routine change orders as required
6 Review samples, catalog data, ~chedules, shop drawings,
laboratory, shop and m~ll tests of material and equl~x~ent and
- other data which the Contractor ~s required to sunnet, only for
conformance with the deslgn concept of the pro]ect and cc~pl~ance
with the informatlon glven by the Contract Documents, and
assemble written guarantees whlch are requlred by the Contract
Documents
-3-
7 Prepare or review monthly and f~nal est/mates for payments to
Contractors, and furnish to the OWNER any necessary
-- certifications as to payments to Contractors and Soppl~ers
8 Conduct, ~n company wlth OWNER, a flnal lnspectlon of the project
for conformance with the design concept of the project and
compliance w~th the Contract Documents, and approve ~n wrltlng
final payment to the Contractors
9 Revlse contract drawings, wlth the assistance of the Resldent
Pro3ect Representative to reflect avallable information as to how
the work was constructed Furnish a set of prints of these
revised drawings to the ~
D SPECIAL SERVICES
Various services incidental to the project, but not w~thln the scope
of the engineering/planning services covered by A B & C preceding,
whlch may be performed or arranged for separately by OWNER, or may be
added ~o the ~GIN~'S respons~bll~t~es by mutual agreement and
written authorization, ~nclude but are not necessarily l~m~ted to the
followLng
1 Furnish the services of a Field Representatlve for frequent (to
be defined by Owner) on-the-site observations of construction
The authorlty, responsLb~lltles and duties of such Field
Representative w~ll be as negotiated and agreed to by written
agreement of the part~es
2 Perform right-of-way determination surveys and/or land surveys,
perform construction surveys, establlsh boundaries and monuments,
furnlsh constructlon layout, and provlde other special field
surveys not provided for elsewhere ~n th~s CONTRACT Furnish
descrlptlve ~nstrtm~ents related to the various surveys
[Thls Space Left Blank Intentionally]
-4-
3 Appearances be~fore regulatory agencies
4 AssIstance to th~ OWNER as an ex~ert witness in any litigatIon
with third parties, arising from the develo~nent or construction
of the project
5 Special investigations involving detailed consideration of
operation, maintenance and overhead expenses, preparation of rate
schedules, earnlngs and expense statements, speclal feasLblllty
studies, appraisals, valuations, and material audits or
lnventorles required for certification of any force account
construction performed by the OWNER
6 Detailed mill, shop and/or laboratory inspection of materials or
equlr/~ent
7 Soil and foundation investigations, including test borings, soil
tests and analyses of test results
8 Extra travel required of the ENGINEER in connection with the
project, other than trips between ENGINEER'S offlc~ and the
project, or between ENGINEER'S office and any of ENGINEER'S
associates ' or subcontractor' s offices
9 Ail printing and reproduction costs except as provided
hereinbefore in Paragraphs II A 3 and II B 6 9egardlng
paragraph II B 6, it is recc~nended that the OWNER provide
construction plans and specificatIons to all prospective bidders,
subcontractors, and suppliers on the basis of a non-refundable
deposit E~GINEER w~ll assist OWNER in deterzu3%g _amount of
deposit required to offset the printing costs for the
construction plans and specifIcations
10 Preparation of applications and supporting documents for
government grants or planning advances for park projects (See
paragraph VI E )-
11 Revision of reports and Contract Doc~nents after specific
approval by OWNER, as provided In Section VII following
12 Media publication costs (e g ,,Notlce-to-B~dders," etc )
SECTION III
AUTHOP~IZATION OF SERVICES
No professional services of any nature (1 e master plans, grant
preparation and su~xalttal, or construction doc~nents) shall be undertaken
by the ENGINEER under this CONTRACT until he has received written
authorization from the OWNER
-5-
SECTION IV
PERIOD OF SERVICE
This CONTRACT shall be effective upon execution by the OWNER and ENGINEER,
and shall remazn zn force until terr0znated under the provlslons hereinafter
provlded in Section IX
SECTION V
COORDINATION WITH THE OWNER
The ENGINEER shall hold perlodlc conferences with the OWNER, or ~ts
representatives, to the end that the projects, as perfected, shall have
benefit of the OWNER'S experience and knowledge of exlstlng needs and
~ac~l~t~es, and be consistent with ~ts current policies and const_ruct~on
standards To l~pls~aen~ this coordznatzon, the OWNER shall make avazlable
to the ENGINRRR for use in planning the project, all exzstlng plans, maps,
field notes, Statistics, ~c~putatzons and~othe~ d~ta zn hzs possession
relatzve to exzstzng facllztzes and to the project
SECTION VI
THE ENGINEER'S COMPENSATION
For, and zn conszderatzon of, the services to be rendered by the ENGINEER,
the OWNER shall pay, and the ENGINEER shall receive the compensatzon
hereinafter set forth for the PRELIMINARY, DESIGN and CONSTRUCTION Phases
of the work and addztzonally for SPECIAL SERVICES that are in addztlon to
the basic engzneerzng/plannzng services All r~ttances by OWNER of such
cc~pensatzon shall ezther be mazled or delzvered to the ENGINEER'S offzce
as zdentzfled zn the work authorzzatzon
"Constructzon Cost" as used herezn is defzned as the total cost to the
OWNER for the executzon of the work authorzzed at one tzme and handled zn
each separate phase of eng3_neerzng servzces, excluding fees or other cost
for englneerzng and legal servzces, the cost of land, rights-of-way, legal
and admznzstratlve expenses, but 3_ncludzng the dzrect cost to the OWNER of
all constructzon contracts, ztems of construction, lncludzng labor,
materzals and equl~ment required for the cc~pleted work (zncludlng extras)
and the total value at szte of project of all labor, materzals, and
equzpment purchased or furnzshed dzrectly by the OWNER for the project
"Salary costs" as used herezn zs defzned as the cost of wages of engzneers,
draftsmen, stenographers, surveymen, clerks, laborers, etc for tzme
dzrectly chargeabl~e to the project plus employer funded fr~ge benefzts
zncludzng, but not lznttted to, social securzty contrzbutzons, unemployment,
exczse and payroll taxes, employment compensatzon znsurance, retzr~nent
benefzts, medzcal and inst~rance benefzts, sick leave, vacation, parkzng,
and holiday pay applicable thereto
-6-
The salary costs shall be based on the salary schedule attache~l ~reto as
Addend~ No 1 to th~s agreement Any revlslon of said schedule shall
constitute an amendment to th~s agreement requiring the prior approval of
the OWNER, which shall not be unreasonably w~thheld, provided, however,
said schedule shall not be revised more often than once annually during the
term hereof
A MASTF2q PLANS The preparation of the Master Plan for each of the
~hree (3) p~ks shall be considered as the PRELIM/NARY phase port~on
of the englneering/plann~ng services, and compensation for preparatlon
of same shall be as follows
Denia Park $ 2,750
Evers Park $ 2,750
North Lakes Park $ 6,000
Payment for the Master Plans (pRELIMINARY) shall be due w~th~n 30 days
after s~sslon and acceptance by the OWNER of the master plan/report
and cost estimates for each park
B DESIGN pHASE The preparation of construction documents (~ e
construction plan and specifications) shall constitute the DESIGN
phase of the englneer~ng/plannlng services to be provided under the
terms of this Contract
The preparation of constructlon plans and speclflcatlons for each park
shall be authorized by the OWNER upon acceptance by the OWNER of the
master plan for each respective park The authorization shall be made
on the basks of
1 An estimated $1 3 m~lllon of ~mprovements for all three (3)
parks combined
2 All design work assigned under one authorlzatlon (1 e
construction plans and speclf~catlons shall be prepared at
the same time for all three (3) parks)
Compensatlon for the DESIGN phase of the engineering/planning services
shall be based on a percentage of the construction cost of the
nmprovsments for each park The fee percentages for each park are as
shown below
Denla Park 5%
Evers Park 5%
North Lakes Park 4 5%
Should the OWNER be successful an obtaining matching grant funds
(total proposed Lmprov~aents = $2 6 m~ll~on) for the parks, the
following fee percentages shall be utilized
Denla Park 5%
Evers Park 5%
North Lakes Park 4%
-7-
The above fee percentages represent the total fee to be charged for
both the DESIGN and CONSTRUCTION phases of each park project The
DESIGN phase portion of the engineering/planning services shall be
cc~puted at 90% of the percentage fee, and the CONSTRUCTION phase
portion of the engineering/planning services shall be ccmputed at 10%
of the percentage fee
Should any lesser amount of grant funding be allocated to North Lakes
Park, ENGINEER agrees to negotiate with OWNER on a fee percentage to
be utilized for North Lakes Park bet%~en 4 0 and 4 5%
the DESIGN phase portion of the engineering/planning
Payment for ......... s ~n ~ro~rtlon to that
services shall be due in monthly instance=n= ~ ~v
part of the services in the DESIGN phase which has been accc~pllshed
Such payments shall be based on ENGINEER'S estnnate of "Construction
Cost", as evidenced by monthly statements sutx~tted by the ENGINEER to
the OWNER Final payment for services authorized Ln the DESIGN phase
shall be due at the completion of these services
In the event that proposals for construction of any of the work
authorized in the DESIGN phase are received within 60 days after
submlss~C~ of ccmpleted contract drawings and specifications to the
OWNER by the ENGINe, the charge for the corresponding services in
the DESIGN phase shall be adjusted to the "Construction Cost", as
reflected by the lowest acceptable proposal, or lowest bona fide bid
if no contract is awarded Where no proposal or bona fide bids are
received, the ENGINEER'S estimates shall be the basis for final
payment of the DESIGN phase No reduction shall be made frc~ the
DESIGN phase fee on account of penalties or liquidated damages or
other s~s withheld frc~ Contractor's payments
CONSTRUCTION PHASE This phase of the engineering/planning services
~as defined hereLnbefore in Section II C
Payment for the CONSTRUCTION phase of the engineering/planning
services shall be due in monthly installments in proportion to the
construction work cc~pleted on the basis of the Contractor's n~nthly
payment estimates plus the actual value of all materIals and equipment
purchased or furnished directly by the OWNER for the pro]ect Upon
cc~mpletion of all work authorized in the CONSTRUCTION phase, the
ENGINEER will be paid the rs~aainder of the charge for this phase
Compensation for the services covered by anY given written
authorization issued pursuant to Section III may be fixed by mutual
agreement of ENG/NEER and OWNER and supercede other provisions herein
when so stated .in said written authorization and endorsed by
authorized representatives of both parties In the absence of such
endorsed stat~nent of mutual agreement to the contrary, the provisions
herein for compensation shall govern f~or all services furnished under
this agreement
Compensation for SPECIAL SERVICES not covered by the PRELIMINARY,
DESIGN and CONSTRUCTION phases of the basic engineering/planning
services provided hereinabove shall be as follows
For all of ENGINEER'S personnel tnne applied to the SPECIAL SERVICES,
"Salary cost" times a multiplier of 2 50
For all direct non-labor and/or subcontract expense, ~nclud~ng, but
not llntzted to surveying (per SP~ECIAL SERVICES) , geotechnical
servaces, mileage, travel and l~vzng expense~, all at znvoace or
znternal office cost
Payments to the ENGINEER for authorazed SPECIAL SERVICES wall be made
monthly, upon presentation of monthly statements by the ENGINEER for
such services
Should the OWNE~ authoraze the ENGINEER to prepare grant
applacataons/sUtxazttals for any or all of the three (3) perks
addressed zn the RECITALS of thas Contract, ccmpensataon to the
,ENGINEER sbmll be based on the followzng lump stun schedule for each
park
Denaa Park $ 1,750
Evers Park $ 1,750
- North,Lakes Park $ 2,000
Payments to the ENGINEER for these servlces shall be made ina lun~p
stun amount upon completion of each authorazed applacat~on and ats
respectave sutm~ttal by the ENGINEER to the Texas Parks & Wlldlafe
Department
SECTION VII
REVISIONS OF REPORTS, PLANS, SPECIFICATIONS
AND OTHER DOCUMENTS
ENGINV. RR sbmll exe~case the same degree of care, skill and dll~ence ~n the
performance of the servaces descrzbed hereLn as as ordlnaraly provaded by a
pro~ess~onal engineer under sunzlar carct~nstances and ENGINEER shall, at no
cos% to OWNER, re-perforn% servaces whach faal to satasfy the foregoLng
standard of performance
The revas~ons and re-wor~ of reports, plan~, ~pecaf~cataons and other
documents durzng the formulatave stages as an orderly process Ln the
development of the project to meet the needs of the OWNER shall be
conBadered as part of t_he baszc engzne~er, zng./.plan~.~ln~g~ se~z~cesm,~h=°~verz~
after a aezznl~e ~, ,.~o ~'~' rr ~ ~ .............. ~n involves
subsequently ma~andbYex~ses~o~ cWhh~hg~s~,atoSr Pard°dI~ltrlo~Ut~o~the master
extra servaces ~
plans, drawings, specafacataons or other document_s, or if the.ENG~NEER_as
put to labor or expense by delays imposed on him ~rom causes not wltnln nas
control, such as by (but not llnttted to) the readvertasement of bads or by
the delLnquency or ansolvency of Contractors, the ENGINEER shall be
compensated for such extra expense whzch shall be consadered as SPECIAL
SERVICES
-9-
S~CTION VIII
OWNERSHIP OF DOCUMENTS
All documents Including Master Plans, Drawings, and Specifications prepared
or f~rnlshed by ENGINR. ~RR (and ENGINEER' S independent professional
assoclates and consultants) pursuant to this CONTRACT are instruments of
service ~n respect of the Project, and ENGINEER shall retain an ownership
and property anterest therein whether or not the Project ~s completed
OWNER may make and retain copaes for ~nformatlon and reference
connectlon w~th the use and occupancy of the Project by OWNER and others,
however, such doc~nents are not 3_ntended or represented to be suatable for
reuse by OWNER O~f others on extensions of the Project or on any other
project Any reuse wathout written ver~f~cataon or adaptataon by ENGINEER
for the spec~flc purpose ~_ntended w~ll be at OWNER'S sole r~sk and wathout
liability or legal exposure to ENGINEER, or to ENGINEER'S ~ndependent
professlonal assoclates or consultants, and OWNER shall lnden~lfy and hold
harmless ENGINEER and ENGINEER'S ~ndependent professional associates and
consultants frcm all claims, damages, losses and expenses Including
attorney' s fees arising out of or resulting therefrom Any such
~erafacataon or adaptatAon wall entatle ENGINEER to further compensatlon at
rates to be agreed upon by OWNER and ENGINEER
SECTION IX
TEI~MINATION
Either party to th~s CONTRACT may terminate the CONTRACT by g~ving to other
30 days notlce in wratang Upon delavery of such notace by the OWNER to
the ENGINEER, the ENGINEER shall dascontinue all servace~ an connectaon
wath the performance of th~s CONTRACT and shall proceed to cancel prc~ptly
all exlsting orders and contracts ansofar as such orders or contracts are
chargeable to thls CONTRACT As soon as practacal after receipt of not~ce
of termlnatlon, the ENGINEER shall submit a statement, showing in detail
the servaces performed under this CONTRACT to the date of termination The
OWNER shall then pay the ENGINEER promptly that proportlon of the
prescribed charges which the servaces actually performed under this
CONTRACT bear to the total services actually performed under th~s CONTRACT
less such payments on account of the charges as have been previously made
Copies of all completed or partially completed planning, desagns, plans and
speclflcataons prepared under thas CONTRACT shall be prc~ptly delavered to
the OWNER when and af th~s CONTRACT IS TERMINATe3
S~CTION X
SUCCESSORS AND ASSIGNMenTS
The OWNER and the ENGINEER each b3_nds h3/~self and has successors,
executors, adminastrators and asslgns to any other party of this CONTRACT
and to the successors, executors, adm~nlstrators and assigns ~f-such other
party, in respect to all covenants of thas CONTRACT Except as above,
neither the OWNER nor the ENGINEER shall assign, sublet or transfer has
interest in thls CONTRACT w~thout the written consent of the other
Noth3_ng herein shall be constltuted as creating any personal l~abalaty on
the part of any officer o~ agent of any public b~dy which may be a party
thereto
- 10 -
SECTION XI
OTHER iND~IFICATIONS
A INDE~qIFICATION
ENGINEER shal~ and doe~ hereby agree to indemnify and hold harmless
the City of Denton frcm any and all damages, loss or liab~il-ty of any
kind wbmtsoever, by reason of ln]ury to property or third persons
occasioned by any error, cmlsslon or negligent act of ENGINEER, 1ts
officers, agents, employees, Lnvltes, and other persons for whcm zt Ks
legally liable, with regard to the performance of this Agreement, and
ENGINEER wall, at its ~ost and expense, defen~l and protect the City of
Denton against any and all such claims and de~ands
EXECUTED IN 3 counterparts (each of which Ks an original) on behalf of
~qGINEER b~ lts~ PRINCIPAL shown below, and on behalf of the O~R.by its
-~/Y~9~ (thereunto duly authorlzed) this /7~'~--'day of
-~~, -1987
CITY OF DENTON TEAGUE NALL AND PERKINS, INC
OWNER ENGINEER
- 11 -
.~nnRNDUM NO 1 "Sa] ary and ~nsatlon Schedule"
(for use in Special Services asslg~.~nts balled "HOURLY")
Date October 7, 1987
OWNER City of Denton
ENGINEER Teague Nall and Perkzns, Inc
CONTRACT '~'Contract for Eng~neerzng Services"
I "PRINCIPALS" COMPENSATION (Billed wlth No Multlpl~ers) $84 per hour
II "EMPLOYEES" Salary Schedule which are wage rates used Ln hourly
b~llzngs; "salary cost" = wage rate plus Frznge Beneflt Factor (see
part III below), "HOURLY" b~llzngs = (hours charged to project by
particular e~ployee) x ("salary cost") x 2 5, all as further defzned
Ln Section VI ("The Engineer's Ccmpensatlon") of CONTRACT
Employee £ate~ory Wage Rate. _ __
Sen~or Engineers $ 20 - $ 30 per hour
$ 11 - $ 20 per hour
Engzneers
Senzor Planners $ 25 - $ 27 per hour
Planners $ 15 - $ 20 per hour
- $- 9 ~ $ 20 per hour
D~szgners
Draftzng Technicians $ 9 - $ 14 per hour
Drafts~uen $ 6 - $ 12 per hour
Field Representative $ 9 - $ 15 per hour
Clerlcal $ 5 - $ 11 per hour
III Fringe benefzt factor 32 4%
- 12 -
ISSUE DATE (MM/DD~
PRODUCER THIS CERTIFICATE I$ ISSUED AEA MATTER OF INFORMATION ONLV AND CONFERS
~ X NO RIGHTS UPON THE CERTIFICATE HOLDER THIE CERTIFICATE DOES NOT AMEND
EXTEND OR ALTER THE COVERAGE AFFORDED DY THE POLICIES BELOW
[6~ NOR IFINE(~q H[GI INt~Y COMPANIES AFFORDING COVERAGE
G~I{~ ~NI)~ rl_X~) 7~OZl~
COMPANY ~
COMPANY ~
INSURED
COMPANY
D
FOR1 NOR I H, [~ X~ 7~)~ O~ LE~ER
COMPANY ~
~ COMPREHENSIVE FORM INJURY $
PREMISE~OPE~TIONS PROPER~
~ UNDERGROUND DAMAGE $
i PRODUCT~OOMPLETEO OPE~TIONS
i CONT~CTUAL COa~INEO $
~ PERSONAL INJURY PERSONAL INJURY
i ANY AUTO {E~I $
HIRE0 AUTOS PROPER~
NON OWNED AUTOS DAMAGE
EXCESS LIABILITY
WORKERS COMPENSATION ;$ (EACH ACCIDEN~
EMPLOYERS LIABILITY $ (DISEASE POLICY LIMt~
, $ (DISEASE [ACH EMPLOYEE)
OTHER ,~)1~0 ~000 POI
I_]fAB[I ElY "( LfhZFIS I~DF" t)EI) PER (L~[FI
DESCRIPTION OF OPERATIONSILOCATIONS~EHICLES/SPECIAL ITEM8
~N~tlR~hl([ ~V~ZI fARIE FOR CI ~[H[~ I~RI ~I:NIEI) HE FFITN IIIF POI I(Y PFR]OD FOR
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EX
PIRATIpN DATE THEREOF THE ISEUING COMPANY WILL ENDEAVOR TO
MAIL ,t~ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE
LEFT BUT FAILURE TO . SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY
~ KIND UPON