The URL can be used to link to this page

2014-089/ � � �. � . � � �• � ,. • R ,, : � � . � . � ' ..• � � �� •. � , .... i ♦. ' , � � '. � �� .R' � ��. � �. : ,: � :. • �� '�. : � � � ' �� '� : � �' : � �. ,. :, . �: • : � �... �. .•: . ..... � � �. ��: •�: ' � , � � . ��: �� • •� �� , . . : •� • ..... , �� •� •� � . . ,� ��... ' � :•; � � '� . .� � �� •�. ,; : , . �. ,. , �. '�. � �� I I. � [ '� ♦ � � �� ,� � � �: . �' . , [. ' ', �' . �. ♦. l. �� ,�. . .. . • , : �: ♦ ' •: . . • ��. I:.. . �� . �� WHEREAS, the City has solicited, received and tabulated competitive proposals for the construction of public works ar improvements in accordance with the procedures af State law and City ordinances; and WHEREAS, the City Manager or a designated employee has received and recommended that the herein described proposal is the highest scored proposal for the construction of the public works or improvements described in the Request for Proposal (RFP) document and plans and specificatians therein; NOW, THEREFORE, • , • •' � ' • ' � •'' �' SECTION 1. The fallowing competitive proposal for the construction of public works ar improvements, as described in the '°Request for Proposals" or plans and specifications on file in the Office of the City's Purchasing Agent f11ed according to the RFP number assigned hereto, are hereby accepted and appraved: RFP NUMBER CONTRACTOR AMOUNT 5442 Durable Specialties, Inc. $4,500,000 SECTION 2. The acceptance and approval of the above competitive propasals shall not canstitute a contract between the City and the person submitting the proposal for construction af such public works or improvements herein accepted and approved, until such person shall comply with all requirements specified in the Notice to Proposers including the timely executian of a written contract and furnishing of performance and payment bonds, and insurance certificate after natification of the award. SECTION 3. The City Manager is hereby authorized to execute all necessary written contracts for the performance af the construction of the public works or improvements in accordance with the propasals accepted and approved herein, provided that such contracts are made in accardance with the Natice to Praposers and Request for Propasals, and documents relating thereto specifying the terms, conditions, plans and specifications, standards, quantities and specified sums contained therein. SECTION 4. The City Cauncil of the City of Dentan, Texas hereby expressly delegates the authority ta take any actions that may be required or permitted ta be performed by the City of Denton under RFP 5442 to the City Manager af the City of Dentan, Texas, or his designee. SECTION 5. Upan acceptance and appraval of the abave campetitive prapasals and the execution af contracts for the public works and improvements as authorized herein, the City Council hereby authorizes the expenditure af funds in the manner and in the amount as specified in such appraved propasals and authorized contracts executed pursuant thereto. SECTION 6. This ordinance shall became effective immediately upon its passage and _ approval, PASSED AND APPROVED this the ��` day of ;� g i , 2014. �� r� -� �� Jf f �. � ( � � ,.n- t � f` �,. � i x �� £ f f,... 1VC��1� �� Bt��l� ��t..,�i�I-�S, MAYOR ATTEST: JENNIFER WALTERS, CITY SECRETARY BY: r .��-��m ,.� , � � APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY � � ��. BY: ;; `� �� .� �� ,* CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND DURABLE SPECIALTIES, INC. (RFP 5442) THIS CONTRACT is made and entered into this 1 day of April, 2014, by and between Durable Specialties, Inc. a corporation, whose address is 2302 Paddock Way Dr., Grand Prairie, TX 75050, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a Texas Municipal Corporation and Home-Rule City, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and the subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Contractor shall provide construction services in accordance with the City's RFP # 5442, for Construction of Traffic Intersections, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes as "Exhibit A". The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) City of Denton Reyuest for Proposal #5442 in the office of the Purchasing Manager (Exhibit "A"); (b) City of Denton Standard Terms and Conditions (Exhibit "B"); (c) Insurance Requirements (Exhibit "C"); (d) Payment and Performance Bond (Exhibit "D"); (e) Contractor's Pricing and Information (Exhibit "F"); (� Conflict of Interest (Exhibit "G"); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to this written Contract, and then to the contract documents in the sequential order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written. ATTEST: . � � . a �� r� a �. � ATTEST: JENNIFER WALTERS, CITY SECRETARY � .a ,� �`� � � , � r��p �� ,i �t �` �� B'Y: � .��a� � ��•u � if .,'t � �.��`, [� �t�� _ APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY m� ,�`` �� ,�-�� -� ��, y �� ,.�. ,.�.,�u:_�.� ��,�_u� � �.....� "��. � � ._...., � �� .,, �► ;s •. Durable Snecialties. Inc. By: " ��A4 �I��RJ �'.A� �I,�.i ,�,6 ��.SL, �. TYPED r��i��: �� c� .��_ � � � ,r a � ��t�r��: r � �' � � � . , ; . � �� LL,�� f � �� E-MAIL AD�I�I:� ' CITY OF DENTON, TEXAS A Texas Municipal Corporation �.�" "� "`� � p �� ,� , � �� t �� y �. . � �-�-�-�,� ,,, � �,�. � a , ��- � �. t�i ;(�T�Cr� C. �:'�1'�'��'I��.�I... . . CITY MANAGER EXII�Ur� GLB99 CITY OF DENTON GENERAL CONDITIONS FOR BUILDING CONSTRUCTION ARTICLE 1 GENERAL PROVISIONS GENERAL DEFINITIONS 1.1 The following definitions apply throughout these General Conditions and to the other Contract Documents: a) THE CONTRACT DOCUMENTS The Contract Documents consist of the formal Building Construction Services Agreement between the Owner and the Contractor', these General Conditions and other supplementary conditions included by special provisions or addenda, drawings, specifications, addenda issued prior to execution of the Contract, other documents listed in the Contract, and Amendments issued after execution of the Contract. For purposes of these General Conditions, an Amendment is: (1) a written Supplemental Agreement to the Contract signed by authorized representatives of both parties; (2) a Change Order, including Change Orders signed only by the Owner as described in Subparagraph 7.l (b) and Subparagraph 7.1(e); or (3) a written order for a minor change in the Work issued by the Engineer as described in Paragraph 7.3. The Contract Documents also include bid documents such as the Owner's Instructions to Bidders, sample forms, the Contractor's Bid Proposal and portions of addenda relating to any of these documents, and any other documents, exhibits or attachments specifically enumerated in the Building Construction Services Agreement, but specifically exclude geotechnical and subsurface reports that the Owner may have provided to the Contractor. b) THE CONTRACT The Contract Documents, as defined in Paragraph 1.1, are expressly incorporated into and made a part of the formal Building Construction Services Agreement between the Owner and the Contractor by reference in this Paragraph and Paragraph l.l (which documents are sometimes also referred to collectively in these General Conditions as the "Contract"). The Contract Documents represent the entire and integrated agreement between the Owner and the Contractor and supersede all prior negotiations, representations or agreements, either written or oral. The terms and conditions of the Contract Documents may be changed only by an Amendment. The Contract Documents shall not be construed to create a contractual relationship of any kind: (1) between the Engineer and Contractor; (2) between the Owner and a Subcontractor or Sub-subcontractor; or (3) between any persons or entities other than the Owner and Contractor. The Engineer shall, however, be entitled to performance and enforcement of obligations under the Contract Documents intended to facilitate performance of the Engineer's duties. c) THE WORK The term "Work" means the construction and services reyuired by the Contract Documents, whether completed or partially completed, and includes all labor, materials, equipment, and services provided or to be provided by the Contractor, or any Subcontractors, Sub- subcontractors, material suppliers, or any other entity for whom the Contractor is responsible, to fulfill the Contractor's obligations. The Work may constitute the whole or a part of the Project. d) THE PROJECT The Project is the total construction more particularly described in the Building Construction Services Agreement, of which the Work performed under the Contract Documents may be the whole or a part of the Project and which may include construction by the Owner or by separate contractors. All references in these General Conditions to or concerning the Work or the site of the Work will use the term "Project," notwithstanding that the Work may only be a part of the Proj ect. e) THE DRAWINGS The Drawings (also known as the "Plans") are the graphic and pictorial portions of the Contract Documents, wherever located and whenever issued, showing the design, location and dimensions of the Work, generally including plans, elevations, sections, details, schedules, and diagrams. f� THE SPECIFICATIONS The Specifcations are that portion of the Contract Documents consisting of the written requirements for materials, equipment, construction systems, standards, and workmanship for the Work, performance of related services, and other technical requirements. g) THE PROJECT MANUAL The Project Manual is the volume or volumes which contain the bidding requirements, sample forms, General Conditions for Building Construction, special provisions, and Specifcations. The Project Manual may be modified by written addendums issued by the Owner during bidding, in which case the written addendums become a part of the Project Manual upon their issuance, unless otherwise indicated by the Owner in writing. h) ALTERNATE An Alternate is a variation in the Work on which the Owner requires a price separate from the City Building General Conditions Base Bid. If an Alternate is accepted by the Owner, the variation will become a part of the Contract through the execution of a change order or amendment to the Contract and the Base Bid will be adjusted to include the amount quoted. If an alternate is accepted by the Owner, and later deleted prior to any Work under the alternate being performed or materials delivered to the Project site, the Owner will be entitled to a credit in the full value of the alternate as priced in the Contractor's Bid. i) BASE BID The Base Bid is the price quoted for the Work before Alternates are considered. j) HAZARDOUS SUBSTANCE The term Hazardous Substance is defned to include the following: (1) any asbestos or any material which contains any hydrated mineral silicate, including chrysolite, amosite, crocidolite, tremolite, anthophylite or actinolite, whether friable or non- friable; (2) any polychlorinated biphenyls ("PCBs"), or PCB-containing materials, or fluids; (3) radon; (4) any other hazardous, radioactive, toxic or noxious substance, material, pollutant, or solid, liquid or gaseous waste; (5) any pollutant or contaminant (including but not limited to petroleum, petroleum hydrocarbons, petroleum products, crude oil or any fractions thereof, any oil or gas exploration or production waste, any natural gas, synthetic gas or any mixture thereof, lead, or other toxic metals) which in its condition, concentration or area of release could have a significant effect on human health, the environment, or natural resources; (6) any substance that, whether by its nature or its use, is subject to regulation or requires environmental investigation, monitoring, or remediation under any federal, state, or local environmental laws, rules, or regulations; (7) any underground storage tanks, as defined in 42 U.S.C. Section 6991(1)(A)(I) (including those defined by Section 9001(1) of the 1984 Hazardous and Solid Waste Amendments to the Resource Conservation and Recovery Act, 42 U.S.C. Section 6901 et seq.; the Texas Water Code Annotated Section 26344; and Title 30 of the Texas Administrative Code Sections 334.3 and 334.4), whether empty, filled or partially filled with any substance; and (8) any other hazardous material, hazardous waste, hazardous substance, solid waste, and toxic substance as those or similar terms are defined under any federal, state, or local environmental laws, rules, or regulations. k) OTHER DEFINITIONS As used in the Contract Documents, the following additional terms have the following meanings: (1) "provide" means to furnish, install, fabricate, deliver and erect, including all services, materials, appurtenances and other expenses to complete in place, ready for operation or use; (2) "shall" means the action of the party to which reference is being made is mandatory; (3) "as required" means as prescribed in the Contract Documents; and (4) "as necessary" means all action essential or needed to complete the work in accordance with the Contract Documents and applicable laws, ordinances, construction codes, and regulations. 1.2 EXECUTION, CORRELATION AND INTENT 5 (a) The Building Construction Services Agreement shall be signed by duly authorized representatives of the Owner and Contractor as provided in the Agreement. (b) Execution of the Building Construction Services Agreement by the Contractor is a representation that the Contractor has visited the site, become familiar with local conditions, including but not limited to subsurface conditions, under which the Work is to be performed and correlated personal observations with requirements of the Contract Documents. (c) The intent of the Contract Documents is to include all items necessary for the proper execution and completion of the Work by the Contractor. The Contract Documents are complementary, and what is required by one shall be as binding as if required by all; performance by the Contractor shall be required only to the extent consistent with the Contract Documents and reasonably inferable from them as being necessary to produce the intended results. (d) Organization of the Specifications into divisions, sections, and articles, and arrangement of Drawings shall not control the Contractor in dividing the Work among Subcontractors or in establishing the extealt of Work to be performed by any trade. (e) Unless otherwise stated in the Contract Documents, words which have well-known technical or construction industry meanings are used in the Contract Documents in accordance with such recognized meanings. (� The Drawings and Specifications are intended to agree with one another, and Work called for by Drawings and not mentioned in Specifications, or vice versa, shall be furnished as if set forth by both. Specifications shall govern materials, methods and quality of work. In the event of a conflict on the Drawings between scale and dimension, figured dimensions shall govern over scale dimensions and large scale drawings shall govern over small scale drawings. Conflict between two or more dimensions applying to a common point shall be referred to the Engineer for final adjustment. If discrepancies or conflicts occur within or between the Drawings and Specifications regarding the Work, or within or between other Contract Documents, the Contractor shall not perform such Work without having obtained a clarification from the Engineer and resolution by the Owner. The Owner's decision as to the appropriate resolution of a conflict or discrepancy shall be final. Should the Drawings or the Specifications disagree within themselves or with each other; the Base Bid will be based on the most expensive combination of quality and quantity of Work indicated. (g) Deviations from Contract Documents shall be made only after written approval is obtained from Engineer and Owner, as provided in Article 7. (h) The intention of the Contract Documents is to include all materials, labor, tools, equipment, utilities, appliances, accessories, services, transportation, and supervision required to completely perform the fabrication, erection and execution of the Work in its final position. (i) The most recently issued Drawing or Specification takes precedence over previous issues of the same Drawing or Specification. In the event of a conflict, the order of precedence of interpretation of the Contract Documents is as follows: (1) Amendments (see Paragraph 7.2 for order of precedence between Amendments); (2) the Building Construction Services Agreement; (3) addenda, with those addenda of later date having precedence over those of an earlier date; (4) the Supplementary General Conditions and Special Provisions, if any; (5) the General Conditions for Building Construction; (6) the Specifications and Drawings. 1.3 OWNERSHIP AND USE OF ENGINEER'S DRAWINGS, SPECIFICATIONS AND OTHER DOCUMENTS All Drawings, Specifications, and copies thereof furnished by the Engineer are and shall remain the property of the Owner and are, with the exception of the Contract set for each party, to be returned to the Owner upon request at the completion of the Work. 1.4 CAPITALIZATION Terms capitalized in these General Conditions include those which are: (1) specifically defined in these General Conditions (except the terms defined in Subparagraph 1.1(j), which terms are of common grammatical usage and are not normally capitalized); (2) the titles of numbered articles and identified references to Paragraphs, Subparagraphs, and Clauses; (3) the titles of other documents published or used by the Owner as manuals or official policy statements; or (4) proper nouns or other words required under standard grammatical rules to be capitalized. ARTICLE 2 THE OWNER 2.1 DEFINITION OF OWNER The Owner is the City of Denton, a Texas municipal corporation, and is identified as such in the Building Construction Services Agreement, and is referred to throughout the Contract Documents as if singular in number. The term "Owner" means the Owner or the Owner's authorized representatives. 2.2 INFORMATION AND SERVICES REQUIRED OF THE OWNER (a) The Owner shall furnish the most recent survey describing the physical characteristics, legal limits, utility locations, and a permanent benchmark for the site of the Project. The Owner shall also furnish any environmental site assessments that may have been given to the Owner or conducted for the property upon which the Project is to be constructed. THIS INFORMATION IS FURNISHED TO THE CONTRACTOR ONLY IN ORDER TO MAKE DISCLOSURE OF THIS MATERIAL AND FOR NO OTHER PURPOSE. BY FURNISHING THIS MATERIAL, THE OWNER DOES NOT REPRESENT, WARRANT, OR GUARANTEE ITS ACCURACY EITHER IN WHOLE, IN PART, IMPLICITLY OR EXPLICITLY, OR IN ANY OTHER WAY, AND THE OWNER SHALL HAVE NO LIABILITY FOR THIS MATERIAL. (b) Except for permits and fees which are provided for in Subparagraph 3.7(a), the Owner shall secure and pay for necessary approvals, easements, assessments, and charges required for construction, use, or occupancy of permanent structures or for permanent changes in existing facilities. (c) Information or services under the Owner's control shall be furnished by the Owner with reasonable promptness to avoid delay in the orderly progress of the Work. It is incumbent upon the Contractor to identify, establish, and maintain a current schedule of latest dates for submittal and approval, as required in Paragraph 3.10, including when such information or services must be delivered. If Owner delivers the information or services to the Contractor as scheduled and Contractor is not prepared to accept or act on such information or services, then Contractor shall reimburse Owner for all extra costs incurred of holding, storage, or retention, including redeliveries by the Owner to comply with the current schedule. (d) Unless otherwise provided in the Contract Documents, the Contractor will be furnished electronic copies of the Drawings and Specifications for bid purposes and one hard copy approved by Building Inspections upon execution of the Contract. Contractor may obtain additional copies by paying the cost of additional printing or reproduction. (e) The obligations described above are in addition to other duties and responsibilities of the Owner enumerated in the Contract Documents and especially those in respect to Article 6(Construction by Owner or by Separate Contractors), Article 9(Payments and Completion), and Article 11 (Insurance and Bonds). (fl The Owner shall forward all instructions to the Contractor through the Engineer, except for the Owner's Notice to Proceed and the Owner's decision to carry out Work as described in Paragraph 2.4. (g) The Owner's employees, agents, and consultants may be present at the Project site during performance of the Work to assist the Engineer in the performance of the Engineer's duties and to verify the Contractor's record of the number of workmen employed on the Work, their occupational classification, the time each is engaged in the Work, the equipment used in the performance of the Work, and for purpose of verifcation of Contractor's Applications for Payment. 2.3 OWNER'S RIGHT TO STOP THE WORK If the Contractor fails to correct any portion of the Work which is not in accordance with the requirements of the Contract Documents as required by Paragraph 12.2 or refuses or fails to carry out all or any part of the Work in accordance with the Contract Documents, the Owner, by written order, may order the Contractor to stop the Work, or any portion of the Work, until the cause for the order has been eliminated. The right of the Owner however, to stop the Work shall not create or imply a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity. The rights of the Owner under this Paragraph 2.3 shall be in addition to, and not in restriction of, the Owner's rights under Paragraph 12.2. 2.4 OWNER'S RIGHT TO CARRY OUT THE WORK If the Contractor fails or refuses to carry out the Work or perform any of the terms, covenants, or obligations of the Contract Documents, and fails or refuses to correct any failure or refusal with diligence and promptness within fourteen (14) days after receipt of notice from the Owner, the Owner may correct the Contractor's failure or refusal or cause such failure or refusal to be corrected, without affecting, superseding, or waiving any other contractual, legal, or equitable remedies the Owner has, including but not limited to the Owner's termination rights under Article 13. In that case, an appropriate Change Order will be issued deducting the Owner's cost of correction, including Engineer's compensation for additional services and expenses made necessary by the failure or refusal of the Contractor from payments then or thereafter due to the Contractor. The cost of correction is subject to verification (but not approval) by the Engineer. If payments then or thereafter s due the Contractor are not sufficient to cover the cost of correction, the Contractor shall pay the difference to the Owner. 2.5 NOTICE TO PROCEED After final execution of the Contract and receipt and approval of the required performance and payment bonds and evidence of required insurance, the Owner will issue a written notice to proceed with the Work, including the designated Contract Time within which Substantial Completion of the Work must be achieved. If the Owner unreasonably delays issuance of a written notice to proceed through no fault of the Contractor, the Contractor shall be entitled only to an equitable adjustment of the Contract Time, if properly claimed pursuant to the requirements of Paragraph 4.3; but the Contractor shall not be entitled to any increase to the Contract Sum whatsoever for this reason. ARTICLE 3 THE CONTRACTOR 3.1 DEFINITION OF CONTRACTOR The Contractor is the person or business entity identified as such in the Building Construction Services Agreement, and is referred to throughout the Contract Documents as if singular in number. The term "Contractor" means the Contractor or the Contractor's authorized employees or representatives. 3.2 REVIEW OF CONTRACT DOCUMENTS AND FIELD CONDITIONS BY CONTRACTOR (a) The Contractor shall carefully check, study, and compare the Contract Documents with each other and shall at once report to the Engineer in writing any inconsistency, ambiguity, error, omission, conflict, or discrepancy the Contractor may discover. The Contractor shall also verify all dimensions, field measurements, and field conditions before laying out the Work. The Contractor will be held responsible for any subsequent error, omission, conflict, or discrepancy which might have been avoided by the above-described check, study, comparison, and reporting. In the event the Contractor continues to work on an item where an inconsistency, ambiguity, error, omission, conflict, or discrepancy exists without obtaining such clarification or resolution or commences an item of the Work without giving written notice of an error, omission, conflict, or discrepancy that might have been avoided by the check, study, and comparison required above, it shall be deemed that the Contractor bid and intended to execute the more stringent, higher quality, or state of the art requirement, or accepted the condition as is in the Contract Documents, without any increase to the Contract Sum or Contract Time. The Contractor shall also be responsible to correct any failure of component parts to coordinate or ft properly into final position as a result of Contractor's failure to give notice of and obtain a clarification or resolution of any error, omission, conflict, or discrepancy, without any right to any increase to the Contract Sum or Contract Time. (b) The Contractor shall perform the Work in accordance with the Contract Documents and submittals approved pursuant to Paragraph 3.12. 3.3 SUPERVISION AND CONSTRUCTION PROCEDURES (a) The Contractor shall supervise and direct the Work, using the Contractor's best skill and attention. The Contractor shall be solely responsible for and have control over construction means, methods, techniques, sequences, and procedures and for coordinating all portions of the Work, unless the Contract Documents set forth specific instructions concerning these matters. (b) The Contractor shall be responsible to the Owner for the acts and omissions of the Contractor's employees, Subcontractors, Sub-subcontractors, and their respective agents and employees, and any other persons performing portions of the Work under a subcontract with the Contractor or with any Subcontractor, and all other persons or entities for which the Contractor is legally responsible. All labor shall be performed by mechanics that are trained and skilled in their respective trades. Standards of work required throughout shall be of a quality that will bring only first class results. Mechanics whose work is unsatisfactory, or who are considered careless, incompetent, unskilled, or otherwise objectionable shall be dismissed promptly from the Work and immediately replaced with competent, skilled personnel. Any part of the Work adversely affected by the acts or omissions of incompetent, unskilled, careless, or objectionable personnel shall be immediately corrected by the Contractor. (c) The Contractor shall not be relieved of its obligation to perform the Work in accordance with the Contract Documents either by activities or duties of the Engineer in the Engineer's administration of the Contract, or by tests, inspections, or approvals required or performed by persons other than the Contractor. (d) The Contractor shall be responsible for inspection of portions of Work already performed under this Contract to determine that such portions are in proper condition to receive subsequent Work. The Contractor's responsibility under this paragraph will not in any way eliminate the Engineer's responsibility to the Owner under the Engineer/Owner Agreement. (e) Any Contractor, Subcontractor, Sub-subcontractor, or separate contractor who commences Work over, in, or under any surface prepared by the Owner or by any other contractor, subcontractor, sub-subcontractor or separate contractor without the Contractor having given written notice to the Engineer of the existence of any faulty surface or condition in the surface that prevents achieving the quality of workmanship specified by the Contract Documents and without having obtained the prior approval of the Engineer and the Owner to proceed is deemed to have accepted the surface or condition in the surface as satisfactory at the commencement of such Work. Any unsatisfactory Work subsequently resulting from such a faulty surface or condition in the surface that was not pre-approved by the Engineer or the Owner after notice as provided above may be rejected and replacement required, without any increase to the Contract Sum or Contract Time. (� All grades, lines, levels, and benchmarks shall be established and maintained on an ongoing basis by the Contractor. The Contractor is solely responsible for any errors made in establishing or maintaining proper grades, lines, levels, or benchmarks. Each Contractor for his own Work shall verify all grades, lines, levels, and dimensions as indicated on Drawings. He shall report any errors, omissions, conflicts, or inconsistencies to Engineer before commencing any Work affected by these conditions. Contractor shall establish and safeguard benchmarks in at least two widely separated places and, as Work progresses, establish benchmarks at each level and lay out partitions on rough floor in exact locations as guides to all trades. The Contractor shall, from the permanent benchmark provided by the Owner, establish and maintain adequate horizontal and vertical control. 3.4 LABOR AND MATERIALS (a) Except as is otherwise specifically provided in the Contract Documents as being the responsibility of the Owner, the Contractor shall provide and pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other 10 facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. (b) The Contractor shall enforce strict discipline and good order among the Contractor's employees and other persons carrying out the Contract. The Contractor shall not permit employment of unfit persons or persons not skilled in tasks assigned to them. (c) The Contractor shall give preference, when qualified labor is available to perform the Work to which the employment relates, to all labor hired for the Project in the following order: (1) to bona fide residents of the City of Denton, Texas; (2) to bona fide residents of the County of Denton, Texas; (3) to bona fide residents of the State of Texas; (4) to bona fide residents of the United States. 3.5 WARRANTY (a) General Warranty. The Contractor warrants to the Owner that all Work shall be accomplished in a good and workmanlike manner and that all materials and equipment furnished under the Contract will be of good quality, new (unless otherwise specified), and free from faults or defects, and that the Work will otherwise conform to the Contract Documents. Work not conforming to these reyuirements, including substitutions not properly approved and authorized, will be considered defective or nonconforming. The Contractor's warranty excludes any remedy for damage or defect caused by abuse, modifications not executed by the Contractor, improper or insufficient maintenance, improper operation, or normal wear and tear under normal usage. If required by the Engineer, the Contractor shall furnish satisfactory evidence as to the kind and auality of materials and equipment. The commencement date, duration, and other conditions related to the scope of this general warranty are established in Subparagraphs 9.9 (a) and 12.2(b) of these General Conditions. THE GENERAL WARRANTY PROVIDED IN THIS SUBPARAGRAPH IS IN ADDITION TO AND DOES NOT LIMIT OR DISCLAIM ANY OTHER WARRANTY OR REMEDY REQUIRED OR PROVIDED BY LAW OR THE CONTRACT DOCUMENTS AND SUCH WARRANTY SHALL REQUIRE THE CONTRACTOR TO REPLACE DEFECTIVE MATERIALS AND RE-EXECUTE DEFECTIVE WORK THAT IS DISCLOSED BY THE OWNER TO THE CONTRACTOR WITHIN A PERIOD OF ONE (1) YEAR AFTER SUBSTANTIAL COMPLETION OF THE ENTIRE WORK OR, IF A LATENT DEFECT, WITHIN ONE (1) YEAR AFTER DISCOVERY BY THE OWNER OF THE LATENT DEFECT. (b) Special Warranties. The Contractor shall assign to the Owner in writing, as a condition precedent to final payment, the terms and conditions of all special warranties required under the Contract Documents. 3.6 TAXES The Owner qualifes for exemption from state and local sales and use taxes, pursuant to the provisions of Section 151.309 of the Texas Tax Code, as amended. Therefore, the Owner shall not be liable for, or pay the Contractor's cost of, such sales and use taxes which would otherwise be payable in connection with the purchase of tangible personal property furnished and incorporated into the real property being improved under the Contract Documents or the purchase of materials, supplies and other tangible personal property, other than machinery or equipment and its accessories � and repair and replacement parts, necessary and essential for performance of the Contract which is to be completely consumed at the job site. The Contractor shall issue an exemption cer�ificate in lieu of the tax on such purchases. 3.7 PERMITS, FEES AND NOTICES (a) The Contractor shall comply with and give notices required by laws, ordinances, rules, regulations, and lawful orders of governmental entities or agencies applying to performance of the Work. (b) Except as provided in Subparagraph (d) below, it is not the Contractor's responsibility to ascertain that the Contract Documents are in accordance with applicable laws, ordinances, construction codes, and rules and regulations. However, if the Contractor observes that portions of the Contract Documents are at variance with applicable laws, ordinances, construction codes, rules or regulations, the Contractor shall promptly notify the Engineer and the Owner in writing, and necessary changes shall be accomplished by appropriate Amendment. (c) If the Contractor performs Work knowing it to be contrary to laws, ordinances, construction codes, or rules and regulations without notifying the Engineer and the Owner, the Contractor shall assume full responsibility for the Work and shall bear the attributable costs of the correction of the Work and any other Work in place that may be adversely affected by the corrective work. 3.8 ALLOWANCES (a) The Contractor shall include in the Contract Sum all allowances stated in the Contract Documents. Items covered by allowances shall be supplied for the amounts identified in the Contract and by persons or entities as the Owner may direct, but the Contractor shall not be required to employ persons or entities against which the Contractor makes reasonable objection. (b) Unless otherwise provided in the Contract Documents: (1) materials and equipment under an allowance shall be selected promptly by the Owner to avoid delay in the Work; (2) the amount of each allowance shall cover the cost to the Contractor of materials and equipment delivered at the site less all exempted taxes and applicable trade discounts; (3) the amount of each allowance includes the Contractor's costs for unloading and handling at the site, labor, installation costs, overhead, profit, and other expenses contemplated for stated allowance Work; (4) whenever costs are more than or less than allowances, the Contract Sum shall be adjusted accordingly by Change Order. The amount of the Change Order shall reflect: (i) the difference between actual costs and the allowances under Clause (b) (2); and (ii) changes in Contractor's costs under Clause (b) (3); (5) the Owner retains the right to review and approve Subcontractors selected by the Contractor to perform work activities covered by allowances. 3.9 SUPERINTENDENT (PROJECT MANAGER-ONSITE SUPERVISOR) 12 The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during performance of the Work. The superintendent shall represent the Contractor, and communications given to the superintendent shall be as binding as if given to the Contractor. Important communications shall be confirmed in writing. Other communications shall be similarly confirmed on written reyuest in each case. The Owner reserves the right to request that the Contractor replace its superintendent at any time and the Contractor will replace said superintendent at the Owner's direction. 3.10 CONTRACTOR'S CONSTRUCTION SCHEDULES (a) The Contractor shall, immediately after award of the Contract and before submittal of the first Application for Payment, prepare and submit the construction schedule for the Engineer's and Owner's information, review, and approval in accordance with the following provisions: (1) Unless otherwise approved in writing by the Owner, the construction schedule shall not exceed the Contract Time limits currently in effect under the Contract Documents and shall provide for expeditious and practicable execution of the Work. (2) The construction schedule shall include all shop drawing and submittal data requirements, indicating for each: (i) the latest date to be submitted by the Contractor; and (ii) the latest date for approval by the Engineer. (3) The construction schedule shall be in the form of a critical path management schedule, and shall indicate each critical task (the "predecessor") of all the major construction activities of the Work in a logical and sequential order (the "project network") which requires completion prior to commencement of the task next following (the "successor"). Each task shall be identified with: (i) actual work time, exclusive of slack time, for accomplishment; (ii) the latest start date; (iii) the latest fnish date; (iv) the amount of float associated with each task; (v) the amount of labor, material, and equipment associated with each task; and (vi) the percentage of completion as of the date of the current schedule. (4) The construction schedule shall be revised and updated monthly to reflect the actual status of the Work and shall be submitted with each Application for Payment. (5) On or before the first day of each month, following the date of commencement of the Work as stated in the notice to proceed, the Contractor shall prepare and submit to the Engineer and the Owner an up-to-date status report of the progress of the various construction phases of the Work in the form of an updated construction schedule. This status report shall consist of a time scale drawing indicating actual progress of the various phases of the Work and the percentage of completion of the entire Work. The original construction schedule shall be updated or changed to indicate any adjustments to the Contract Time granted by the Owner. 13 The updated schedule must be submitted with the Contractor's Application for Payment. No application will be certifed without a satisfactory update to the construction schedule. (6) The construction schedule will also be revised to show the effect of change orders and other events on Contract Time. No request for an increase in Contract Time will be considered unless it is accompanied by a schedule revision demonstrating the amount of time related to the cause of the request. If the Contractor's status schedules reflect that the Contractor has fallen behind the pace required to complete the Work within the Contract Time, through no fault of the Owner, the Contractor shall prepare a recovery schedule demonstrating how it intends to bring its progress back within the Contract Time. This recovery schedule shall be in a form acceptable to the Owner. (7) Costs incurred by the Contractor in preparing and maintaining the required construction schedule, any updated schedule, and any recovery schedule required by the Owner will not be paid as an additional or extra cost and shall be included in the Contract Sum. (8) The Contract Sum is deemed to be based upon a construction schedule requiring the full Contract Time. NO CLAIM FOR ADDITIONAL COMPENSATION SHALL BE ALLOWED AS A RESULT OF THE CONTRACTOR BASING HIS BID ON AN EARLY COMPLETION SCHEDULE, OR AS A RESULT OF DELAYS AND COSTS ATTRIBUTABLE TO COMPLETION LATER THAN THE PLANNED EARLY COMPLETION DATE. (b) The Contractor shall also prepare and keep current, for the Engineer's approval, a schedule of submittals which is coordinated with the Contractor's construction schedule and allows the Engineer reasonable time to review submittals. (c) The Contractor shall conform to the most recent schedules approved as to form by the Engineer and the Owner. Any subsequent revisions made by the Contractor to schedules in effect shall conform to the provisions of Subparagraph 3.10(a) (d) If the Work falls behind the approved construction schedule, the Contractor shall take such steps as may be necessary to improve his progress, and the Engineer and the Owner may require him to increase the number of shifts, overtime operations, days of work, or the amount of construction plant, and to submit for approval revised schedules in the form required above in order to demonstrate the manner in which the agreed rate of progress will be regained, all without additional cost to the Owner. 3.11 DOCUMENTS AND SAMPLES AT THE PROJECT SITE The Contractor shall maintain at the Project site for the Owner one record copy of the Drawings, Specifications, addenda, and Amendments in good order and marked currently to record changes and selections made during construction, and in addition shall maintain at the Project site approved Shop Drawings, Product Data, Samples, and similar required submittals. These shall be available to the Engineer and shall be delivered to the Engineer for submittal to the Owner upon completion of the Work. 3.12 SHOP DRAWINGS, PRODUCT DATA AND SAMPLES (a) Shop Drawings are drawings, diagrams, schedules, and other data specially prepared for the Work by the Contractor or a Subcontractor, Sub-subcontractor, manufacturer, supplier, or distributor to illustrate some portion of the Work. 14 (b) Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by the Contractor to illustrate materials or equipment for some portion of the Work. (c) Samples are physical examples which illustrate materials, equipment, or workmanship and establish standards by which the Work will be judged. (d) Shop Drawings, Product Data, Samples, and similar submittals are not Contract Documents. The purpose of their submittal is to demonstrate for those portions of the Work for which submittals are required the way the Contractor proposes to conform to the information given and the design concept expressed in the Contract Documents. Review by the Engineer is subject to the limitations of Paragraph 4.2. (e) The Contractor shall review, approve and submit to the Engineer Shop Drawings, Product Data, Samples, and similar submittals required by the Contract Documents with reasonable promptness and in such sequence as to cause no delay in the Work or in the activities of the Owner or of separate contractors. Submittals made by the Contractor which are not required by the Contract Documents may be returned without action. ( fl The Contractor shall perform no portion of the Work requiring submittal and review of Shop Drawings, Product Data, Samples, or similar submittals until the respective submittal has been approved by the Engineer. Work requiring this submittal and review shall be in accordance with approved submittals and any identified exceptions noted by the Engineer. (g) By approving and submitting Shop Drawings, Product Data, Samples and similar submittals, the Contractor represents that the Contractor has determined and verified materials, field measurements, and related field construction criteria, or will do so, and has checked and coordinated the information contained within submittals with the requirements of the Work and of the Contract Documents. The Contractor's attention is directed to Paragraph 3.2 of these General Conditions and the requirements stated in that Paragraph. (h) The Contractor shall not be relieved of responsibility for deviations, substitutions, changes, additions, deletions or omissions from requirements of the Contract Documents by the Engineer's approval of Shop Drawings, Product Data, Samples, or similar submittals unless the Contractor has specifically informed the Engineer in writing of such substitutions, changes, additions, deletions, omissions, or deviations involved in the submittal at the time of submittal and the Engineer, subject to a formal Change Order signed by the Owner, Engineer and Contractor, has given written approval to the specific substitutions, changes, additions, deletions, omissions, or deviations. The Contractor shall not be relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples, or similar submittals by the Engineer's approval thereof. Further, notwithstanding any approval of a submittal by the Engineer, the Contractor shall be responsible for all associated Project costs, including costs of coordination's, modifications, or impacts, direct or indirect, resulting from any and all substitutions, changes, additions, deletions, omissions, or deviations, whether or not specifically identified by the Contractor to the Engineer at the time of the above-mentioned submittals, including additional consulting fees, if any, in any and all accommodations associated with such substitutions, changes, additions, deletions, omissions, or deviations to the requirements of the Contract Documents. (i) The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data, Samples, or similar submittals, to additional revisions other than those requested by the Engineer on previous submittals. In the absence of such written notice, the Engineer's approval of a resubmission shall not apply to the additional revisions not requested. (j) Informational submittals upon which the Engineer is not expected to take responsive action may be so identifled in the Contract Documents. 15 (k) When professional certifcation of performance criteria of materials, systems, or equipment is required by the Contract Documents, the Engineer shall be entitled to rely upon the accuracy and completeness of such calculations and certifications. 3.13 USE OF THE PROJECT SITE The Contractor shall confine operations at the Project site to areas perrriitted by law, ordinances, permits, and the Contract Documents and shall not unreasonably encumber the Project site with materials or equipment. 3.14 CLEANING UP (a) The Contractor shall keep the Project site and surrounding area free from accumulation of waste materials or rubbish caused by operations under the Contract. Upon the completion of the Work the Contractor shall remove from and about the Project site all waste materials, and rubbish, and all of the Contractor's tools, construction equipment, machinery, and surplus materials. (b) If the Contractor fails to clean up as provided in the Contract Documents, the Owner may clean up and the Owner's cost of cleaning up shall be charged to the Contractor. 3.15 ACCESS TO WORK The Contractor shall provide the Owner and the Engineer access to the Work in preparation and progress wherever located during the course of construction. 3.16 TESTS AND INSPECTIONS (a) Tests, inspections, and approvals of portions of the Work required by the Contract Documents or by laws, ordinances, rules, regulations, or orders of governmental entities or agencies having jurisdiction over the Work shall be made at appropriate times. Unless otherwise provided, the Contractor shall make arrangements for such tests, inspections, and approvals with an independent testing laboratory or entity acceptable to the Owner or with the appropriate governmental entity or agency, and the Contractor shall bear all related costs of tests, inspections, and approvals. The Contractor shall give the Engineer timely notice of when and where tests and inspections are to be made so the Engineer may observe such procedures. The Owner shall bear costs of tests, inspections, or approvals which become requirements after bids or proposals are received. (b) If the Engineer, the Owner or other public authorities having jurisdiction over the Work determine that portions of the Work require additional testing, inspection or approval not included under Subparagraph 3.17(a), the Engineer will, upon written authorization from the Owner, instruct the Contractor to make arrangements for such additional testing, inspection or approval by an entity acceptable to the Owner, and the Contractor shall give timely notice to the Engineer of when and where tests and inspections are to be made so that the Engineer may observe such procedures. The Owner shall bear such costs except as provided in Subparagraph 3.17(c). (c) If procedures for testing, inspection, or approval under Subparagraphs 3.17(a) and 3.17(b) reveal deficiencies or nonconformities in the Work, the Contractor shall bear all costs made necessary to correct the deficiencies or nonconformities, including those of repeated procedures and compensation for the Engineer's services and expenses, if any. The Contractor shall bear the costs of any subsequent testing, inspection, or approval of the corrected Work. 16 (d) Tests or inspections conducted pursu.ant to the Contract Documents shall be made promptly to avoid unreasonable delay in the Work. 3.17 ROYALTIES AND PATENTS The Contractor shall pay all royalties and license fees. CONTRACTOR SHALL COMPLETELY DEFEND, INDEMNIFY AND HOLD OWNER AND ENGINEER HARMLESS FROM ANY AND ALL SUITS OR CLAIMS FOR INFRINGEMENT OF PATENT RIGHTS, REGARDLESS OF WHETHER OR NOT THE OWNER OR THE ENGINEER SPECIFIED A PARTICULAR DESIGN, PROCESS OR PRODUCT IN THE CONTRACT DOCUMENTS THAT MAY BE THE SUBJECT OF A PATENT INFRINGEMENT OR OTHERWISE ACTIVELY INDUCED OR CONTRIBUTED TO THE INFRINGEMENT. In the event the Contractor has reason to believe that a particular design, process or product specified infringes a patent, the Contractor shall immediately notify the Owner and the Engineer of same. 3.18 INDEMNIFICATION (a) THE CONTRACTOR AGREES TO DEFEND, INDEMNIFY AND HOLD THE OWNER, ITS OFFICERS, AGENTS AND EMPLOYEES, AND THE ENGINEER, HARMLESS AGAINST ANY AND ALL CLAIMS, LAWSUITS, JUDGMENTS, FINES, PENALTIES, COSTS AND EXPENSES FOR PERSONAL INJURY (INCLUDING DEATH), PROPERTY DAMAGE OR OTHER HARM OR VIOLATIONS FOR WHICH RECOVERY OF DAMAGES, FINES, OR PENALTIES IS SOUGHT, SUFFERED BY ANY PERSON OR PERSONS, THAT MAY ARISE OUT OF OR BE OCCASIONED BY CONTRACTOR'S BREACH OF ANY OF THE TERMS OR PROVISIONS OF THIS CONTRACT, VIOLATIONS OF LAW, OR BY ANY NEGLIGENT, GROSSLY NEGLIGENT, INTENTIONAL, OR STRICTLY LIABLE ACT OR OMISSION OF THE CONTRACTOR, ITS OFFICERS, AGENTS, EMPLOYEES, SUBCONTRACTORS, OR SUB-SUBCONTRACTORS AND THEIR RESPECTIVE OFFICERS, AGENTS, OR REPRESENTATIVES, OR ANY OTHER PERSONS OR ENTITIES FOR WHICH THE CONTRACTOR IS LEGALLY RESPONSIBLE IN THE PERFORMANCE OF THIS CONTRACT; EXCEPT THAT THE INDEMNITY PROVIDED FOR IN THIS PARAGRAPH SHALL NOT APPLY TO ANY LIABILITY RESULTING FROM THE SOLE NEGLIGENCE OR FAULT OF THE OWNER, ITS OFFICERS, AGENTS, EMPLOYEES OR SEPARATE CONTRACTORS, OR OF THE ENGINEER, AND IN THE EVENT OF JOINT AND CONCURRENT NEGLIGENCE OR FAULT OF THE CONTRACTOR, THE OWNER, AND THE ENGINEER, RESPONSIBILITY AND INDEMNITY, IF ANY, SHALL BE APPORTIONED IN ACCORDANCE WITH THE LAW OF THE STATE OF TEXAS, WITHOUT, HOWEVER, WAIVING ANY GOVERNMENTAL IMMUNITY AVAILABLE TO THE OWNER UNDER TEXAS LAW AND WITHOUT WAIVING ANY DEFENSES OF THE PARTIES UNDER TEXAS LAW. THE PROVISIONS OF THIS PARAGRAPH ARE SOLELY FOR THE BENEFIT OF THE PARTIES HERETO AND ARE NOT INTENDED TO CREATE OR GRANT ANY RIGHTS, CONTRACTUAL OR OTHERWISE, TO ANY OTHER PERSON OR ENTITY. (b) In claims against any person or entity indemnified under this Paragraph 3.19 by an employee of the Contractor, a Subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable, the indemnification obligation under this Paragraph 3.19 shall not be limited by a limitation on amount or type of damages, compensation or benefits payable by or for the Contractor or a Subcontractor under workers compensation acts, disability benefit acts or other employee benefit acts. 17 (c) Indemnifcation under this Paragraph 3.19 shall include, but is not limited to, liability which could result to or be created for the Owner, its officers, agents, or employees, or the Engineer pursuant to State or Federal laws or regulations relating to pollution of the environment and State or Federal laws or regulations relating to the occupational safety and health of workers. The Contractor specifically agrees to comply with the above-mentioned laws and regulations in the performance of the Work by the Contractor and that the obligations of the Owner, its officers, agents, and employees, and the Engineer under the above-mentioned laws and regulations are secondary to those of the Contractor. ARTICLE 4 CONTRACT ADMINISTRATION 4.1 THE DESIGN PROFESSIONAL (ENGINEER) (a) The design professional is the person lawfully licensed to practice architecture or engineering or a firm or other business entity lawfully practicing architecture/engineering identified as such in the formal Building Construction Services Agreement and is referred to throughout the Contract Documents as if singular in number. The term "Engineer" means the Engineer or the Engineer's authorized representative. The Owner may, at its option, designate a qualified Owner representative to serve as the Engineer on the Project instead of an outside firm or person. In such event, the references in these General Conditions that refer to the Engineer shall apply to the Owner-designated Engineer representative and the Owner-designated Engineer representative shall be accorded that same status by the Contractor. (b) In the event the Engineer is an outside person or firm and the Engineer's employment is terminated, the Owner may, at its option, contract with a new outside Engineer to replace the former, or may designate a yualified Owner representative to serve as the Engineer. The replacement Engineer, whether an Owner representative, an independent Engineer or any other yualified person or entity, shall be regarded as the Engineer for all purposes under the Contract Documents and shall be accorded that same status by the Contractor. Any dispute in connection with such appointment shall be reviewed and settled by the Owner, whose decision shall be final and binding. • (c) Owner reserves the right to appoint a representative empowered to act for the Owner during the Construction Phase and to supersede the Engineer's Construction Phase responsibility. Similarly, from time to time the Owner may expand or reduce the Owner's delegation of powers to the Engineer, with the Owner notifying the Contractor of any such changes. The Engineer shall not be construed as a third party beneficiary to the Contract and can in no way object to any expansion or reduction of powers as set forth in this Subparagraph (c). In no event, however, shall the Owner have control over charge of, or be responsible for, construction means, methods, techniques, sequences, or procedures, or for safety precautions or programs in connection with the Work since these are solely the Contractor's responsibility. The Owner will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Owner will not have control over or charge of and will not be responsible for acts or omissions of Contractor, Subcontractors, or their agents or employees, or of any other persons performing portions of the Work. 4.2 CLAIMS AND DISPUTES (a) Definition; General Notice of Claim Procedure. As used in these General Conditions, a"Claim" means a demand or assertion by one of the parties to the Contract seeking an adjustment of the terms of the Contract Documents, of the Contract Sum, of the Contract Time, or some other relief in respect to the terms of the Contract Documents. The term also includes all other disputes 18 between the Owner and the Contractor arising out of or relating to the Project or the Contract Documents, including but not limited to claims that work was outside the scope of the Contract Documents. The responsibility to substantiate the Claim and the burden of demonstrating compliance with this provision shall rest with the party making the Claim. Except where otherwise provided in the Contract Documents, a Claim by the Contractor, whether for additional compensation, additional time, or other relief, including but not limited to claims arising from concealed conditions, MUST BE MADE BY WRITTEN NOTICE TO THE ENGINEER AND THE OWNER WITHIN FOURTEEN (14) DAYS AFTER OCCURRENCE OF THE EVENT OR EVENTS GIVING RISE TO THE PARTICULAR CLAIM. Every Claim of the Contractor, whether for additional compensation, additional time, or other relief, including but not limited to claims arising from concealed conditions, shall be signed and sworn to by an authorized corporate officer (if not a corporation, then an official of the company authorized to bind the Contractor by his signature) of the Contractor, verifying the truth and accuracy of the Claim. THE CONTRACTOR SHALL BE DEEMED TO HAVE WAIVED ANY CLAIM NOT MADE STRICTLY IN ACCORDANCE WITH THE PROCEDURE AND TIME LIMITS SET OUT IN THIS PARAGRAPH. (b) Referral to the Engineer. Claims, disputes, and other matters in question between the Contractor and the Owner relating to the progress or execution of the Work or the interpretation of the Contract Documents shall be referred to the Engineer for recommendation to the Owner, which recommendation the Engineer will furnish in writing within a reasonable time, provided proper and adeyuate substantiation has been received. Failure of the Contractor to submit the Claim to the Engineer for rendering of a recommendation to the Owner shall constitute a waiver of the Claim. (c) Continuing Contract Performance. Pending final resolution of a claim the Contractor shall proceed diligently with performance of the Work and the Owner shall continue to make payments in accordance with the Contract Documents. (d) Claims for Concealed or Unknown Conditions. No adjustment in the Contract Sum or Time associated with concealed or unknown conditions will normally be considered or allowed; provided, however, that the Contract Sum or Time may be adjusted by the Owner in such circumstances only if: (1) a concealed subsurface condition is encountered in the course of performance of the Work; (2) a concealed or unknown condition in an existing structure is at variance with conditions indicated by the Contract Documents; or (3) an unknown physical condition is encountered below the surface of the ground or in an existing structure which is of an unusual nature and materially different from those ordinarily encountered and generally recognized as inherent in the character of the Work; and (4) a notice of claim with proper and adequate substantiation is presented pursuant to Subparagraph 4.3(a) of these General Conditions; and (5) the Owner and the Engineer determine that: (i) prior to submitting its bid for the Work, the Contractor used reasonable diligence to fully inspect the portion of the Project site where the condition was discovered; and (ii) the work caused or required by the concealed or unknown condition at issue can be considered extra work to the extent that additional new Drawings must be prepared and issued and new construction beyond the scope of the Contract Documents is required. 19 (e) Disclaimer of Warranties as to Reports, Drawings, and Specifications. PROJECT SITE INFORMATION AND REPORTS (INCLUDING BUT NOT LIMITED TO SOILS TESTING REPORTS, GEOTECHNICAL REPORTS, OR ENVIRONMENTAL SITE ASSESSMENTS) PROVIDED BY THE OWNER AND THE ENGINEER IN THE PROJECT MANUAL OR BY OTHER MEANS SHALL BE UTILIZED BY THE CONTRACTOR AT THE CONTRACTOR'S OWN RISK. THE OWNER AND THE ENGINEER DO NOT GUARANTEE OR WARRANT ANY INFORMATION SHOWN IN THE PROJECT SITE INFORMATION AND REPORTS. (� Claims for Additional Cost. If the Contractor wishes to make a claim for an increase in the Contract Sum, written notice as provided in this Paragraph 4.3 shall be given before proceeding to execute the Work. Prior notice is not required for claims relating to an emergency endangering life or property arising under Paragraph 10.3. In addition, the Contractor's request for an increase in the Contract Sum for any reason (other than work performed under emergency conditions) shall be made far enough in advance of required work to allow the Owner and the Engineer a sufficient amount of time, without adversely affecting the construction schedule, to review the request, prepare and distribute such additional documents as may be necessary to obtain suitable estimates or proposals and to negotiate, execute and distribute a Change Order for the required work if the Contractor believes that additional cost is involved for reasons including but not limited to: (1) a written interpretation from the Engineer; (2) a written order for a minor change in the Work issued by the Engineer; (3) failure of payment by the Owner; (4) termination of the Contract by the Owner; (5) the Owner's temporary suspension of all or any portion of the Work where the Contractor was not at fault; or (6) other reasonable grounds. (g) Injury or Damage to Person or Property. If the Contractor suffers injury or damages to person or property because of an act or omission of the Owner, or of any of the Owner's officers, employees or agents, written, sworn-to notice of any claim for damages or injury shall be given as provided in Subparagraph 4.3(a). The notice shall provide sufficient detail to enable the Engineer and the Owner to investigate the matter. (h) Subcontractor Pass-Through Claims. In the event that any Subcontractor of the Contractor asserts a claim to the Contractor that the Contractor seeks to pass through to the Owner under the Contract Documents, any entitlement of the Contractor to submit and assert the claim against the Owner shall be subject to: (1) the requirements of Paragraph 4.3 of these General Conditions; and 20 (2) the following additional three requirements listed below, all three of which additional requirements shall be conditions precedent to the entitlement of the Contractor to seek and assert such claim against the Owner: (ii) The Contractor shall either (A) have direct legal liability as a matter of contract, common law, or statutory law to the Subcontractor for the claim that the Subcontractor is asserting or (B) the Contractor shall have entered into a written liquidating agreement with the Subcontractor, under which agreement the Contractor has agreed to be legally responsible to the Subcontractor for pursing the assertion of such claim against the Owner under the Contract and for paying to the Subcontractor any amount that may be recovered, less Contractor's included markup (subject to the limits in the Contract Documents for any markup). The liability or responsibilities shall be identified in writing by the Contractor to the Owner at the time such claim is submitted to Owner, and a copy of any liquidating agreement shall be included by the Contractor in the claim submittal materials. (ii) The Contractor shall have reviewed the claim of the Subcontractor prior to its submittal to Owner and shall have independently evaluated such claim in good faith to determine the extent to which the claim is believed in good faith to be valid. The Contractor shall also certify, in writing and under oath to the Owner, at the time of the submittal of such claim, that the Contractor has made a review, evaluation, and determination that the claim is made in good faith and is believed to be valid. (iii) The Subcontractor making the claim to the Contractor shall certify in writing and under oath that it has compiled, reviewed and evaluated the merits of such claim and that the claim is believed in good faith by the Subcontractor to be valid. A copy of the certification by the Subcontractor shall be included by Contractor in the claim submittal materials. (3) Any failure of the Contractor to comply with any of the foregoing requirements and conditions precedent with regard to any such claim shall constitute a waiver of any entitlement to submit or pursue such claim. (4) Receipt and review of a claim by the Owner under this Subparagraph shall not be construed as a waiver of any defenses to the claim available to the Owner under the Contract Documents or law. (i) Owner's Right to Order Acceleration and to Deny Claimed and Appropriate Time Extensions, in Whole or in Part. The Contractor acknowledges and agrees that Substantial Completion of the Work by or before the Scheduled Completion Date is of substantial importance to Owner. The following provisions, therefore, will apply: (1) If the Contractor falls behind the approved construction schedule for whatever reason, the Owner shall have the right, in the Owner's sole discretion, to order the Contractor to develop a recovery schedule as described in Paragraph 3.10 or to accelerate its progress in such a manner as to achieve Substantial Completion on or before the Contract Time completion date or such other date as the Owner may reasonably direct and, upon receipt, the Contractor shall take all action necessary to comply with the order. In such event, any possible right, if any, of the Contractor to additional compensation for any acceleration shall be subject to the terms of this Subparagraph (i). 21 (2) In the event that the Contractor is otherwise entitled to an extension of Contract Time and has properly initiated a Claim for a time extension in accordance with Subparagraph 4.3(a) above, the Owner shall have the right, in the Owner's sole discretion, to deny all, or any part, of the Claim for extension of Contract Time by giving written notice to the Contractor provided within fourteen (14) days after receipt of the Contractor's Claim. If the Owner denies the Contractor's claim for an extension of Contract Time under this Clause (i)(2), either in whole or in part, the Contractor shall proceed to prosecute the Work in such a manner as to achieve Substantial Completion on or before the then existing Scheduled Completion Date. (3) If the Contractor would have been entitled to a time extension for a reason specifically allowed under the Contract Documents, for an amount of time that would have justified approval by the Owner if not for the need and right to accelerate, the Contractor may initiate a Claim for acceleration costs pursuant to Subparagraph 4.3(a). Any resulting Claim for acceleration costs properly initiated by the Contractor under Subparagraph 4.3(a) above shall be limited to those reasonable and documented direct costs of labor, materials, equipment, and supervision solely and directly attributable to the actual acceleration activity necessary to bring the Work back within the then existing approved construction schedule. These direct costs include the premium portion of overtime pay, additional crew, shift, or equipment costs if requested in advance by the Contractor and approved in writing by the Owner. A percentage markup for the prorated cost of premium on the existing performance and payment bonds and required insurance, not to exceed 5%, will be allowed on the claimed acceleration costs. NO OTHER MARKUP FOR PROFIT, OVERHEAD (INCLUDING BUT NOT LIMITED TO HOME OFFICE OVERHEAD) OR ANY OTHER COSTS WILL BE ALLOWED ON ANY ACCELERATION CLAIM. The Owner shall not be liable for any costs related to an acceleration claim other than those described in this Clause (i) (3). (i) Waiver of Claims; Final Payment. The making of final payment shall constitute a waiver of claims by the Owner except those arising from: (1) claims, security interests, purported liens, or other attempted encumbrances arising out ofthe Contract and remaining unsettled; (2) defective or nonconforming Work appearing after Substantial Completion; (3) latent defects, as defined in Subparagraph 12.2(d), appearing after Final Completion; or (4) the terms of general and special warranties required by the Contract Documents or allowed or implied by law. (k) THE CONTRACTOR SHALL NOT BE ENTITLED TO RECOVER ATTORNEY'S FEES AS A PART OF ANY CLAIM MADE UNDER THE CONTRACT DOCUMENTS OR IN ANY SUBSEQUENT LAWSUIT OR ALTERNATIVE DISPUTE RESOLUTION PROCEEDING. (1) No Waiver of Governmental Immunity. NOTHING IN THE CONTRACT DOCUMENTS SHALL BE CONSTRUED TO WANE THE OWNER'S GOVERNMENTAL IMMUNITY FROM LAWSUIT, WHICH IMMUNITY IS EXPRESSLY RETAINED TO THE EXTENT IT IS NOT CLEARLY AND UNAMBIGUOUSLY WAIVED BY STATE LAW. 22 ARTICLE 5 SUBCONTRACTORS 5.1 DEFINITIONS OF SUBCONTRACTOR (a) A Subcontractor is person or entity who has a direct contract with the Contractor to perform a portion of the Work at the Project site or to supply materials or equipment to the Contractor by purchase or lease for use in performance of or incorporation into the Work. The term "Subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Subcontractor or an authorized representative of the Subcontractor. The term "Subcontractor" does not include a separate contractor or subcontractors of a separate contractor. (b) A Sub-subcontractor is a person or entity who has a direct or indirect contract with a Subcontractor to perform a portion of the Work at the Project site or to supply materials or equipment to the Subcontractor or another Sub-subcontractor by purchase or lease for use in performance of or incorporation into the Work. The term "Sub-subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Sub-subcontractor or an authorized representative of the Sub-subcontractor. 5.2 AWARD OF SUBCONTRACTS AND OTHER CONTRACTS FOR PORTIONS OF THE WORK (a) Immediately after the award of the Contract by the Owner, and before the Building Construction Services Agreement is signed by the Contractor and the Owner, the Contractor shall furnish to the �ngineer in writing, for acceptance by the Owner and the Engineer, a list of the names, addresses, telephone numbers, M/WBE certifcation numbers (where applicable), and type of work of the Subcontractors (including those who are to furnish materials or equipment fabricated to a special design), proposed for the principal portions of the Work, including furnishings when made a part of the Contract. The Contractor shall immediately notify the Owner in writing of any changes in the list as they occur. The Engineer will promptly reply to the Contractor in writing stating whether or not the Owner or the Engineer, after due investigation, has reasonable objection to any such proposed person or entity. Failure of the Owner or Engineer to reply promptly shall constitute notice of no reasonable objection. (b) The Contractor shall not contract with a proposed person or entity to whom the Owner or Engineer has made reasonable and timely objection. (c) Engineer's and Owner's approval of or objection to any Subcontractor or of a particular process or material will not relieve the Contractor of his responsibility for performance of Work as called for under the Contract Documents, and shall not provide a basis for any claim for additional time or money on the part of the Contractor. Approval shall not be construed to create any contractual relationship between the Subcontractor and either the Owner or Engineer. In no event shall the Contract Sum be increased as a result of the rejection of any Subcontractor. (d) The Contractor shall not change a Subcontractor previously selected if the Owner or Engineer makes reasonable objection to such change. 5.3 SUBCONTRACTUAL RELATIONS (a) By appropriate agreement, written where legally required for validity, the Contractor shall require each Subcontractor, to the extent of the Work to be performed by the Subcontractor, to be bound to the Contractor by the terms of the Contract Documents (including but not limited to 23 these General Conditions), and to assume toward the Contractor all the obligations and responsibilities which the Contractor, by the Contract Documents, assumes toward the Owner and the Engineer. Each subcontract agreement shall preserve and protect the rights of the Owner and the Engineer under the Contract Documents (including but not limited to these General Conditions) with respect to the Work to be performed by the Subcontractor so that subcontracting will not prejudice the rights of the Owner and the Engineer. Where appropriate, the Contractor shall require each Subcontractor to enter into similar agreements with Sub- subcontractors. The Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract agreement, copies of the Contract Documents to which the Subcontractor is to be bound. Subcontractors shall similarly make copies of applicable portions of such Documents available to their respective proposed Sub-subcontractors. (b) The Contractor is solely responsible for making payments properly to the Contractor's Subcontractors on the Project. During performance of the Work, the Contractor shall comply with the following additional rules regarding Subcontractor payments: (1) The Contractor shall submit, beginning with the Second Application and Certificate for Payment, a Subcontractor Payment Report (the "Report") with each Application and Certificate for Payment. The Report shall show all payments made to date by the Contractor (plus existing retainage) to each Subcontractor involved in the Project. The Report shall be made on a form approved and supplied by the Owner. As an alternative to the Report, the Contractor may furnish Affidavits of Payment Received with the Application and Certificate for Payment, which affidavits shall be executed by each Subcontractor owed money and paid during the previous progress payment period for work or materials furnished on the Project. RECEIP'T BY THE OWNER OF THE REPORT OR AFFIDAVITS OF PAYMENT RECEIVED SHALL BE A CONDITION PRECEDENT TO PAYMENT ON ANY APPLICATION. (2) If, for any reason, the Contractor is withholding payment to a Subcontractor due to a dispute or other problem with performance, the Contractor shall note the amount withheld and that payment is in dispute. The Owner may require the Contractor to document and verify the dispute or other problem in question. (3) The Owner reserves the right in its sole discretion, to withhold payment to the Contractor pursuant to Paragraph 9.5(a) of the General Conditions, should it appear from the Report, statements of payment received or other information furnished to the Owner that: (i) the Report has not been properly completed; (ii) the Contractor has knowingly provided false information regarding payment of any Subcontractor; or (iii) the Contractor has otherwise failed to make payments properly to any Subcontractor. (4) THE CONTRACTOR SHALL NOT HAVE ANY RIGHT TO MAKE A CLAIM FOR ADDITIONAL TIME OR ADDITIONAL COMPENSATION AS A RESULT OF THE OWNER'S OR ENGINEER'S ENFORCEMENT OF THIS SUBPARAGRAPH 5.3(b). NO PROVISION OF THIS SUBPARAGRAPH OR ANY OF THE CONTRACT DOCUMENTS SHALL BE CONSTRUED TO CREATE A CONTRACTUAL RELATIONSHIP, EXPRESS OR IMPLIED, BETWEEN ANY SUBCONTRACTOR AND EITHER THE 24 OWNER OR THE ENGINEER AND SHALL NOT BE CONSTRUED TO MAKE ANY SUBCONTRACTOR OR ANY OTHER PERSON OR ENTITY A THIRD PARTY BENEFICIARY OF THE CONTRACT BETWEEN THE OWNER AND THE CONTRACTOR. 5.4 CONTINGENT ASSIGNMENT OF SUBCONTRACTS In the event of a termination of this Contract by the Owner under Article 14, the Contractor shall, if requested in writing by the Owner, within fifteen (15) days after the date notice of termination is sent, deliver and assign to Owner, or any person or entity acting on the Owner's behalf, any or all subcontracts made by Contractor in the performance of the Work, and deliver to the Owner true and correct originals and copies of the subcontract documents. In the event assignment is not requested by the Owner, Contractor shall terminate all subcontracts to the extent that Owner has not directed assignment of same and to the extent that they relate to the performance of Work terminated by the notice of termination. ARTICLE 6 CONSTRUCTION BY THE OWNER/ SEPARATE CONTRACTORS 6.1 OWNER'S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS (a) The Owner reserves the right to perform construction or operations related to the Project with the Owner's own forces, and to award separate contracts in connection with other portions of the Project or other construction or operations on the Project site under Conditions of the Contract identical or substantially similar to these General Conditions, including those portions related to insurance and waiver of subrogation. If the Contractor claims that delay or additional cost is involved because of such action by the Owner, the Contractor shall make a claim as provided elsewhere in and in accordance with the Contract Documents. (b) When separate contracts are awarded for different portions of the Project or other construction or operations on the Project site, the term "Contractor" in the Contract Documents in each case shall mean the Contractor who executes each separate Building Construction Services Agreement with the Owner. (c) The Owner shall provide for coordination of the activities of the Owner's own forces and of each separate contractor with the Work of the Contractor, who shall cooperate with them. The Contractor shall participate with other separate contractors and the Owner in reviewing their construction schedules when directed to do so. The Contractor shall, with the approval of the Owner, make any revisions to the construction schedule deemed necessary after a joint review and mutual agreement. The construction schedules shall then constitute the schedules to be used by the Contractor, separate contractors, and the Owner until subsequently revised by mutual agreement or by written Change Order. If the Contractor believes it is entitled to an adjustment of the Contract Sum under the circumstances, the Contractor shall submit a written proposal for a Change Order pursuant to Article 7 of the General Conditions. In the event the Contractor's Change Order proposal is denied by the Owner, the Contractor must submit any Claim pursuant to Paragraph 4.3 of the General Conditions. (d) Unless otherwise provided in the Contract Documents, when the Owner performs construction or operations related to the Project with the Owner's own forces, the Owner shall be deemed to be subject to the same obligations and to have the same rights which apply to the Contractor under these General Conditions, including, without excluding others, those stated in Article 3, this Article 6, and Articles 10, 11 and 12. 25 6.2 MUTUAL RESPONSIBILITY (a) The Contractor shall afford the Owner and separate contractors' reasonable opportunity for access to and storage of their materials and equipment and the performance of their activities and shall coordinate the Contractor's construction and operations with the separate contractors as required by the Contract Documents. (b) If part of the Contractor's Work depends for proper execution or results upon construction or operations by the Owner or a separate contractor, the Contractor shall, prior to proceeding with that portion of the Work, promptly report to the Engineer apparent discrepancies or defects in the other construction that would render it unsuitable for proper execution and results. Failure of the Contractor to so report shall constitute an acknowledgment that the Owner's or separate contractors completed or partially completed construction is fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable. (c) The Owner shall not be liable to the Contractor for damages suffered by the Contractor due to the fault or negligence of a separate contractor or through failure of a separate contractor to carry out the directions of the Owner or the Engineer. Should any interference occur between the Contractor and a separate contractor, the Engineer or the Owner may furnish the Contractor with written instructions designating priority of effort or change in methods, whereupon the Contractor shall immediately comply with such direction. In such event, the Contractor shall be entitled to an extension of the Contract Time only for unavoidable delays verified by the Engineer; no increase in the Contract Sum, however, shall be due to the Contractor. (d) The Contractor shall promptly remedy damage wrongfully caused by the Contractor to completed or partially completed construction or to property of the Owner or separate contractors as provided in Subparagraph 10.2(e). (e) Should the Contractor cause damage to the work or property of any separate contractor on the Project, the Contractor shall, upon due notice, settle with the separate contractor by agreement, if the separate contractor will so settle. If the separate contractor sues the Owner or submits a claim on account of any damage alleged to have been so sustained, the Owner shall notify the Contractor who shall defend such proceedings, at the Contractor's expense, and if any judgment or award against the Owner arises from the separate contractor's claim, the Contractor shall pay or satisfy it and shall reimburse the Owner for all attorney's fees and costs which the Owner has incurred. (� The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are described for the Contractor in Paragraph 3.14. 6.3 OWNER'S RIGHT TO CLEAN UP If a dispute arises among the Contractor, separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the Project site and surrounding area free from waste materials and rubbish as described in Paragraph 3.15, the Owner may clean up and allocate the cost among those responsible as the Engineer recommends to be just. �� ARTICLE 7 AMENDMENTS 7.1 CHANGE ORDERS (a) A Change Order is a written order to the Contractor, signed by the Owner and the Engineer, issued after execution of the Contract, authorizing a change in the Work, an adjustment in the Contract Sum, or an adjustment to the Contract Time, consistent with other applicable provisions of this Contract. The Owner, without invalidating the Contract and without reyuiring notice of any kind to the sureties, may order changes to the scope of Work under the Contract by additions, deletions, or other revisions, the Contract Sum and Contract Time to be adjusted consistent with other applicable provisions of this Contract. All Change Orders shall be executed on a Change Order form approved by the Owner and the Owner's City Attorney. (b) In addition to the Owner and the Engineer, the Contractor shall sign all Change Orders to verify and confirm the terms and conditions established by Change Order; however, should the Contractor refuse to sign a Change Order, this shall not relieve him of his obligation to perform the change directed by the Owner and the Engineer to the best of his ability in accordance with the provisions of this Article 7. A Change Order signed by the Contractor indicates his agreement with all of the changes approved, including the adjustment in the Contract Sum or the Contract Time. EACH CHANGE ORDER SHALL BE SPECIFIC AND FINAL AS TO PRICES AND EXTENSIONS OF TIME, WITH NO RESERVATIONS OR OTHER PROVISIONS ALLOWING FOR FUTURE ADDITIONAL MONEY OR TIME AS A RESULT OF THE PARTICULAR CHANGES IDENTIFIED AND FULLY COMPENSATED IN THE CHANGE ORDER. The execution of a Change Order by the Contractor shall constitute conclusive evidence of the Contractor's agreement to the ordered changes in the Work. The Contractor forever releases any claim against the Owner for additional time or compensation for matters relating to or arising out of or resulting from the Work included within or affected by the executed Change Order. This release applies to claims related to the cumulative impact of all Change Orders and to any claim related to the effect of a change on other Work. (c) No extra work (except under emergency conditions) or changes shall be made nor shall any substitutions, changes or additions to or omissions or deviations from the requirements of the Drawings and Specifications be made unless pursuant to a written Change Order signed by the Owner and the Engineer, it being expressly understood that the Owner shall not be liable for the cost of extra work or any substitution, change, addition, omission or deviation from the requirements of the Drawings or Specifications unless the same shall have been authorized in writing by the Owner and the Engineer in a written change order or other Amendment. The provisions of this Paragraph 7.1 shall control in the event of any inconsistency between such provisions and the other provisions of this Article 7. See Subparagraph 10.3(a) of the General Conditions for Change Orders under emergency conditions. (d) The method of determining the cost or credit to the Owner for any change in the Work shall be one of the following: (1) mutual acceptance of a not-to-exceed lump sum amount properly itemized and supported by sufficient substantiating data to permit evaluation; (2) unit prices stated in the Contract Documents or subsequently agreed upon; 2� (3) cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee; or (4) the force account method provided in Subparagraph 7.1(e) (e) If the parties cannot agree to one of the methods of calculating cost provided in Clauses (d) (1), (d) (2), or (d) (3), or if the parties agree to a method but cannot agree to a fnal dollar fgure, or if the Contractor for whatever reason refuses to sign the Change Order in question, the Contractor, provided he receives a written order signed by the Owner, shall promptly proceed with the Work involved. The cost of the Work involved shall then be calculated on the basis of the reasonable jobsite expenditures and savings of those performing the Work attributable to the changes, including a reasonable allowance for overhead and profit, such allowance in any case never to exceed 15%. In such case, the Contractor shall keep an itemized accounting of the Work involved, on a daily basis, in such form and with the appropriate supporting data as the Engineer and Owner may prescribe. Sworn copies of the itemized accounting shall be delivered to the Engineer each day during the performance of force account work, with copies to the Owner. FAILURE OF THE CONTRACTOR TO SUBMIT THE SWORN-TO ITEMIZED ACCOUNTING DAILY AS REQUIRED HEREIN SHALL CONSTITUTE A WAIVER BY THE CONTRACTOR OF ANY RIGHT TO DISPUTE THE OWNER'S DETERMINATION OF THE AMOiJNT DUE THE CONTRACTOR FOR FORCE ACCOLINT WORK. Costs to be charged under this Subparagraph for force account work are limited to the following: (1) costs of labor, including social security, old age and unemployment insurance, fringe benefits required by agreement or custom, and workers compensation insurance; (2) costs of materials, supplies and equipment (but not to include off-site storage unless approved in writing by the Owner), whether incorporated or consumed; (3) rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor or others; (4) costs of premiums for all bonds and insurance related to the Work; and (5) additional costs of supervision and field office personnel directly attributable to the changed Work. Pending final determination of cost to the Owner, payment of undisputed amounts on force account shall be included on the Engineer's Certificate of Payment as work is completed. (� The amount of credit to be allowed to the Owner for any deletion of Work or any other change which results in a net decrease of the Contract Sum shall be the amount of actual net cost confirmed by the Engineer plus the stated percentage for overhead and profit. When both additions and deletions or credits covering related Work or substitutions are involved in any one change, the allowance for overhead and profit shall be fgured on the basis of the net increase or decrease with respect to that change. 7.2 SUPPLEMENTAL AGREEMENTS A written Supplemental Agreement can also be used to implement changes in the Work instead of a Change Order form, including but not limited to situations involving partial occupancy of the Work under Paragraph 9.8, a change made to the Drawings or the Specifications without an increase in the zs Contract Sum, or special circumstances where it is necessary or more appropriate for the Owner to use a Supplemental Agreement. Written Supplemental Agreements shall have a status equal to that of Change Orders for purposes of priority of Contract Documents interpretation, except that to the extent of a conflict, later Supplemental Agreements in time control over earlier Supplemental Agreements, and the latest Change Order or Supplemental Agreement in time controls over earlier dated Change Orders and Supplemental Agreements. The rules of Subparagraphs 7.1(b) through (fl shall also apply to the negotiation and execution of Supplemental Agreements. 7.3 MINOR CHANGES IN THE WORK The Engineer, after notifying the Owner, shall be authorized to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Minor changes shall be effected by written order, and shall be binding on the Owner and the Contractor. The Contractor shall carry out such written orders promptly. These written orders shall not be deemed to change or impact the Contract Sum or the Contract Time. Contractor shall have no Claim for any minor change ordered to the Work under this Paragraph 7.3 unless the Contractor submits its change proposal, prior to complying with the minor change ordered and in no event later than ten (10) working days from the date the minor change was ordered, to the Owner for approval. 7.4 TIME REQUIRED TO PROCESS AMENDMENTS (a) All of the Contractor's responses to proposal requests shall be accompanied by a complete, itemized breakdown of costs. Responses to proposal requests shall be submitted sufficiently in advance of the required work to allow the Owner and the Engineer a minimum of thirty (30) calendar days after receipt by the Engineer to review the itemized breakdown and to prepare or distribute additional documents as may be necessary. All of the Contractor's responses to proposal requests shall include a statement that the cost described in the response represents the complete, total and final cost and additional Contract Time associated with the extra work, change, addition to, omission, deviation, substitution, or other grounds for seeking extra compensation under the Contract Documents, without reservation or further recourse. (b) All Amendments require approval by either the City Council or, where authorized by the state law and City ordinance, by the City Manager pursuant to Administrative Action. The approval process requires a minimum of forty-five (45) calendar days after submission to the Owner in final form with all supporting data. Receipt of a submission by Owner does not constitute acceptance or approval of a proposal, nor does it constitute a warranty that the proposal will be authorized by City Council Resolution or Administrative Action. THE TIME REQUIRED FOR THE APPROVAL PROCESS SHALL NOT BE CONSIDERED A DELAY AND NO EXTENSIONS TO THE CONTRACT TIME OR INCREASE IN THE CONTRACT SUM WILL BE CONSIDERED OR GRANTED AS A RESULT OF THIS PROCESS. Pending the approval described above, the Contractor will proceed with the work under a pending Amendment only if directed in writing by the Owner. ARTICLE 8 CONTRACT TIME 8.1 DEFINITIONS (a) Unless otherwise provided, the Contract Time is the period of time, including authorized adjustments, allotted in the Contract Documents for Substantial Completion of the Work. (b) The date of commencement of the Work is the date established in the notice to proceed from the Owner. The date of commencement shall not be postponed by the failure of the Contractor, or of zs persons or entities for whom the Contractor is responsible to act promptly to commence the Work. If the Owner unreasonably delays the issuance of the notice to proceed through no fault of the Contractor, the Contractor shall be entitled only to an equitable extension of the Contract Time; the Contract Sum shall remain unchanged. (c) The date of Substantial Completion is the date certified by the Engineer in accordance with Paragraph 9.7. (d) The term "day" as used in the Contract Documents shall mean a calendar day, beginning and ending at 12:00 midnight, unless otherwise specifically defined by special provision. 8.2 PROGRESS AND COMPLETION (a) Time limits stated in the Contract Documents are of the essence of the Contract. By executing 'the Building Construction Services Agreement, the Contractor confirms that the Contract Time is a reasonable period for performing the Work. (b) The Contractor shall not knowingly, except by agreement with or instruction of the Owner in writing, prematurely commence operations on the Project site or elsewhere prior to the effective date of insurance to be furnished by the Contractor as required by Article 11. The date of commencement of the Work shall not be changed by the effective date of insurance required by Article 11. (c) Liquidated Damages. The Contractor shall proceed expeditiously with adequate forces, materials, and equipment, and shall achieve Substantial Completion within the Contract Time. If the Contractor fails or refuses to complete the Work within the Contract Time as specified in the Bid Proposal form, the Building Construction Services Agreement, or in any proper extension of the Contract Time granted by the Owner, then the Contractor agrees, as a part of the consideration for the awarding of the Contract, to pay to the Owner the amount of liquidated damages (hereinafter called the "Stipulated Amount") as stipulated in the Bid Proposal form and the Building Construction Services Agreement for each calendar day that the Contractor has not Substantially Completed the Work after the expiration of the Contract Time provided. The Stipulated Amount is not to be considered as a penalty, but shall be deemed, taken, or treated as reasonable liquidated damages, fixed and agreed upon by and between the Contractor and the Owner because of the impracticality and extreme difficulty of fixing and ascertaining the actual damages the Owner would sustain in the event of the Contractor's late completion of the Project, and the stipulated amount is agreed to be the daily amount of damages that the Owner would sustain. The Stipulated Amount, as it accrues, will be retained from any portion of the Contract Sum due or that may become due to the Contractor. In the event the portion of the Contract Sum retained by the Owner is insufficient to recover the Stipulated Amount, then the Contractor or the Contractor's Surety shall pay to the Owner any additional liquidated damages due that are in excess of the funds remaining unpaid in the Contract Sum. The Owner shall be the sole judge as to whether or not the Work has been Substantially Completed within the calendar days allotted, which shall include the original Contract Time and any proper extension of the Contract Time granted in writing by the Owner. Should the Contractor dispute the Owner's determination of liquidated damages due, however, or should the Contractor, or the Contractor's agents or assigns, institute any legal action against the Owner to enforce rights under the Contract Documents, then this Subparagraph 8.2(c) shall not be construed to prevent the Owner from seeking full recovery for any and all actual damages suffered by the Owner and attributable to the Contractor, as an alternative to all liquidated damages due. 30 8.3 DELAYS AND EXTENSIONS OF TIME (a) If the Contractor is delayed at any time in the progress of the Work by an act or neglect of the Owner or Engineer, or of an employee of either, or of a separate contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's control, or by delay authorized by the Owner pending a claim, or by other causes which the Engineer determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Engineer and Owner may determine. (b) Claims relating to Contract Time and time extensions shall be made in accordance with the applicable provisions of Paragraph 4.3. (c) No Damages for Delay. NOTWITHSTANDING ANY OTHER PROVISIONS OF THE CONTRACT DOCUMENTS, INCLUDING THE GENERAL CONDITIONS, NO ADJUSTMENT SHALL BE MADE TO THE CONTRACT SUM AND THE CONTRACTOR SHALL NOT BE ENTITLED TO CLAIM OR RECEIVE ANY ADDITIONAL COMPENSATION AS A RESULT OF OR ARISING OUT OF ANY DELAY, HINDRANCE, DISRUPTION, FORCE MAJEURE, IMPACT, OR INTERFERENCE, INTENTIONAL OR UNINTENTIONAL, FORESEEN OR UNFORESEEN, WHICH INCREASES THE TIME TO COMPLETE THE WORK, INCLUDING BUT NOT LIMITED TO ANY DELAYS CAUSED IN WHOLE OR IN PART BY THE ACTS, OMISSIONS, FAILURES, NEGLIGENCE, OR FAULT OF THE OWNER, THE ENGINEER, OR THE OWNER'S REPRESENTATIVE, AN EXTENSION OF THE CONTRACT TIME UNDER SUBPARAGRAPH 8.3(a) BEING THE CONTRACTOR' S SOLE REMEDY. (d) The Owner shall have the right to occupy, without prejudice to the right of either party, any completed or largely completed portions of the structure or Work, notwithstanding the fact that the Contract Time for completing all or a portion of the Work may not have expired. Partial occupancy and use shall not be deemed as an acceptance of the Work taken or used. (e) The Contractor shall promptly suspend the Work when either the Contractor or the Owner is ordered to do so by a court order from a court having lawful jurisdiction, and the Contractor will not be entitled to additional compensation by virtue of any delays resulting from the court order. The Contractor will also not be liable to the Owner for a delay caused in fact by the Work being suspended by a court order. (� The Engineer, with the consent of the Owner, shall have the authority to suspend the Work, in whole or in part, for such period or periods as the Engineer deems necessary due to unusual or severe weather conditions as are considered unfavorable for the suitable prosecution of the Work, or due to failure on the part of the Contractor to correct conditions considered unsafe for workmen or the general public. If it should become necessary to stop the Work for an indefinite period, the Contractor shall store all materials in such a manner that they will not obstruct or impede the public unnecessarily or become damaged in any way, and shall take every precaution to prevent damage or deterioration of the Work performed. In cases of suspension of the Work under this Subparagraph, the Contractor shall also provide suitable drainage about the Work and erect temporary structures where necessary. The Contractor shall not suspend the Work in whole or in part without written authority from the Engineer or the Owner, and shall resume the Work promptly when notified by the Engineer or the Owner to resume operations. K�i (g) In the event of a delay that is the responsibility of the Contractor or any of the Subcontractors, for which the Contractor is not entitled to a time extension under the provisions of this Contract, the Owner may direct that the Work be accelerated by means of overtime, additional crews or additional shifts, or resequencing. This acceleration shall be at no cost to the Owner and will continue until the Contract Time is restored. In the event of a delay for which the Contractor is entitled to a time extension, as determined by the Engineer, Owner may similarly direct acceleration and the Contractor agrees to perform same on the basis that the Contractor will be reimbursed only to the extent described in Subparagraph 4.3(i). THE CONTRACTOR EXPRESSLY WAIVES ANY OTHER COMPENSATION RESULTING FROM ACCELERATION, SUCH AS LOSS OF LABOR PRODUCTIVITY OR EFFICIENCY. ARTICLE 9 PAYMENTS AND COMPLETION 9.1 CONTRACT SUM The Contract Sum is stated in the Building Construction Services Agreement and, including authorized adjustments, is the total amount of compensation payable by the Owner to the Contractor for the performance of the Work under the Contract Documents. 9.2 SCHEDULE OF VALUES Before the first Application for Payment, the Contractor shall submit to the Engineer a schedule of values allocated to various portions of the Work, prepared in such form and supported by such data to substantiate its accuracy as the Engineer may require. This schedule, when approved by the Engineer and the Owner, shall be used as a basis for the Contractor's Application for Payment. The schedule of values shall follow the trade division of the Specifications. Contractor's Application for Payment shall be filed on the current version of AIA Form G702 (Application and Certificate for Payment), as approved by the Owner. 9.3 APPLICATIONS FOR PAYMENT (a) At least ten (10) days before the date established for each progress payment, the Contractor shall submit to the Engineer an itemized Application for Payment for Work completed in accordance with the schedule of values. The Application shall be notarized, if required, and supported by data substantiating the Contractor's right to payment as the Owner or Engineer may require, including but not limited to copies of requisitions from Subcontractors and material suppliers, and reflecting the applicable retainage as required in the Contract Documents. Contractor's Application for Payment shall also provide other supporting documentation as the Owner or the other applicable provisions of the Contract Documents may require. (b) Applications for Payment may not include requests for payment of amounts the Contractor does not intend to pay to a Subcontractor because of a good faith dispute, unless the Contractor complies with Clause 53(b) (2) of these General Conditions and the Contractor's Payment Bond Surety consents in writing to payment to the Contractor of the funds deemed to be in dispute. (c) Unless otherwise provided in the Contract Documents, progress payments shall include payment for materials and equipment delivered and suitably stored at the Project site for subsequent incorporation into the Work within thirty (30) days after delivery to the Project site. If approved in advance by the Owner, payment may similarly be made for materials and equipment suitably stored away from the Project site at a location agreed upon in writing. Payment for costs incurred 32 in storage of materials or equipment away from the Project site will NOT be made by Owner unless: (1) the Owner has given prior approval of such off-site storage in writing; (2) the materials or equipment are stored in a bonded warehouse located in Denton County and identified with the Project for which they are stored, as evidenced by warehouse receipts and appropriate documents of title; and (3) the materials or equipment stored off-site will be incorporated into the Work within thirty (30) days after delivery. STORAGE IN FACILITIES OF THE MANUFACTURER OR THE CONTRACTOR WILL NOT BE PERMITTED OR PAID FOR, UNLESS THE OWNER HAS EXPRESSLY GIVEN PRIOR APPROVAL OF SUCH STORAGE IN WRITING. (d) The Contractor warrants that title to all Work covered by an Application for Payment will pass to the Owner no later than the time of payment. The Contractor further warrants that upon submittal of an Application for Payment all Work for which Certificates for Payment have been previously issued and payments received from the Owner shall be free and clear of liens, claims, security interests or encumbrances in favor of the Contractor, Subcontractors, material suppliers, or other persons or entities making a claim by reason of having provided labor, materials, and equipment relating to the Work. (e) All materials or equipment delivered to the Project site earlier than thirty (30) days prior to an approved schedule for delivery to the Project site shall be classified as an "early delivery." All early delivery materials or equipment must have the express written permission of the Owner to be stored on the Project site. If any unauthorized early delivery occurs, Contractor shall, at Contractor's expense or at the expense of the responsible Subcontractor or Supplier, cause such early delivery to be removed from the Project site and stored off-site until required at the Project site. All costs of labor, transportation and storage will be included as part of the expense. If the Contractor fails or refuses to remove unauthorized early delivery materials, the Owner may cause such materials to be removed at the Contractor's sole expense, and amounts may be withheld from the Contractor's Application for Payment to reimburse the Owner for any costs incurred in removing unauthorized early delivery materials. OWNER WILL NOT BE RESPONSIBLE FOR THE PROTECTION OF OR RISK OF LOSS ON ANY EARLY DELIVERY MATERIALS OR EQUIPMENT, NOR WILL OWNER BE LIABLE FOR ANY PAYMENT FOR THE EARLY DELIVERY MATERIALS OR EQUIPMENT. Any materials or equipment classified as early delivery will not be approved for payment as stored materials prior to thirty (30) days before the incorporation of the materials or equipment into the Work, unless storage and payment at an earlier date is expressly approved in writing by the Owner. ( fl If the Contract Sum is equal to or less than $25,000.00 and performance and payment bonds are not furnished by the Contractor, no payment applied for will be payable under the Contract until the Work has been Finally Completed and accepted. 9.4 CERTIFICATES FOR PAYMENT (a) The Engineer will, within ten (10) days after receipt of the Contractor's Application for Payment, either issue to the Owner a Certificate for Payment, with a copy to the Contractor, for such amount as the Engineer determines is properly due, or notify the Contractor and Owner in writing of the Engineer's reasons for withholding certification in whole or in part as provided in (a) Subparagraph 9.5(a). The Certificate for Payment shall be issued on the current version of AIA Form G702 (Application and Certificate for Payment) as approved by the Owner. 33 (b) The issuance of a Certificate for Payment will constitute a representation by the Engineer to the Owner, based on the Engineer's observations at the site and the data comprising the Application for Payment, that the Work has progressed to the point indicated and that, to the best of the Engineer's knowledge, information and belief, quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial and Final Completion, to results of subsequent tests and inspections, to minor deviations from the Contract Documents correctable prior to Final Completion and to specific qualifications expressed by the Engineer. The issuance of a Certificate for Payment will further constitute a representation that the Contractor is entitled to payment in the amount certified, subject to the Owner's approval. The issuance of a Certificate for Payment is not a representation that the Engineer has: (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work; (2) reviewed construction means, methods, techniques, sequences or procedures; (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the Owner to substantiate the Contractor's right to payment; or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. (c) Whenever the Application for Payment for Work done since the last previous Application for Payment exceeds one hundred dollars ($100.00) in amount, Owner will pay a percentage of the Application, less applicable retainage, to the Contractor within thirty (30) days following Owner's receipt and approval of the Certificate for Payment certified by the Engineer. The Application may include acceptable nonperishable materials delivered to the Work or stored as provided for in Paragraph 9.3(c) and the payment will be allowed on the net invoice value, less taxes and applicable retainage. (d) The City is required to withhold retainage for public works contracts in which the total contract price estimate at the time of execution is more than $400,000; however, this requirement is typically applied by the City for all public works contracts in excess of $50,000. The City may require varying percentage withholding amounts; however, the City typically requires five percent. For retainage percentages in excess of five percent, the City must deposit the retainage into an interest-bearing account and pay the interest earned to the contractor on completion of the contract. The retainage will be withheld by the Owner from each progress payment until final completion of the Work by the Contractor, approval of final completion by the Engineer, and final acceptance of the Work by the Owner. Unless otherwise required by state law, the retainage percentage as specifed above is based upon the original Contract Sum, and will not be affected in the event the original Contract Sum is subsequently increased or decreased by Change Order. (e) No progress payments shall be made on contracts where performance and payment bonds are not required or furnished. In such instances, payment for the Work performed will be made upon final completion and acceptance by the Owner of all Work. 9.5 DECISIONS TO WITHHOLD CERTIFICATION (a) The Engineer or the Owner may decide not to certify payment and may withhold a Certificate for Payment in whole or in part, to the extent reasonably necessary to protect the Owner's interest, if 34 in the Engineer's or Owner's opinion the representations to the Owner required by Subparagraph 9.4(b) cannot be made. If the Engineer or the Owner is unable to certify payment in the amount of the Application, the Engineer or the Owner will notify the Contractor as provided in Subparagraph 9.4(a). If the Contractor and Engineer or the Owner cannot agree on a revised amount, the Engineer will promptly issue a Certificate for Payment for the amount for which the Engineer is able to make the required representations to the Owner. The Engineer or the Owner may also decide not to certify payment or, because of subsequently discovered evidence or subsequent observations, may nullify the whole or a part of a Certificate for Payment previously issued to such extent as may be necessary, in the Engineer's or Owner's opinion, to protect the Owner from loss because o£ (1) defective or nonconforming Work not remedied; (2) third party claims filed or reasonable evidence indicating probable filing of such claims; (3) failure of the Contractor to make payments properly to Subcontractors or for labor, materials, or equipment; (4) reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum; (5) damage to the Owner or another contractor; (6) reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; (7) persistent failure to carry out the Work in accordance with the Contract Documents; or (8) mathematical or other errors that are discovered in the Application for Payment. (b) When each of the above reasons that existed for withholding certifcation are removed or remedied, certification will be made for amounts previously withheld. (c) The Owner may, at its option, offset any progress payment or final payment under the Contract Documents against any debt (including taxes) lawfully due to the Owner from the Contractor, regardless of whether the amount due arises pursuant to the terms of the Contract Documents or otherwise and regardless of whether or not the debt due to the Owner has been reduced to judgment by a court. 9.6 PROGRESS PAYMENTS (a) After the Engineer has issued a Certificate for Payment, the Owner shall make payment in the manner and within the time provided in the Contract Documents, and shall so notify the Engineer. The Owner shall not be liable for interest on any late or delayed progress payment or final payment caused by any claim or dispute, any discrepancy in quantities, any failure to provide supporting documentation or other information required with the Application for Payment or as a precondition to payment under the Contract Documents, or due to any payment the Owner or the Engineer has a right to withhold or not certify under the Contract Documents. Notwithstanding the foregoing, the Owner may refuse to make payment on any Certificate for c�.7 Payment (including, without limitation, the fnal Certificate for Payment) for any'default under the Contract Documents, including but not limited to those defaults set forth in Subparagraph 9.5(a), Clauses (1) through (7). The Owner shall not be deemed in default by reason of withholding payment while any Contractor default remains uncured. (b) The Contractor shall promptly pay each Subcontractor, upon receipt of payment from the Owner, out of the amount paid to the Contractor on account of each Subcontractor's portion of the Work, the amount to which said Subcontractor is entitled, reflecting percentages actually retained from payments to the Contractor on account of such Subcontractors portion of the Work. The Contractor shall, by appropriate agreement with each Subcontractor, require each Subcontractor to make payments to Sub-subcontractors in similar manner. (c) The Engineer will, on request, furnish to a Subcontractor, if practicable, information regarding percentages of completion or amounts applied for by the Contractor and action taken thereon by the Engineer and the Owner on account of portions of the Work done by such Subcontractor. (d) Neither the Owner nor the Engineer shall have an obligation to pay or to see to the payment of money to a Subcontractor except as may otherwise be required by law. That obligation belongs to the Contractor or, in the event of the Contractor's failure to pay a Subcontractor, to the Surety on the Payment Bond as required under Paragraph 11.3. (e) Payment to material suppliers shall be treated in a manner similar to that provided in Subparagraphs 9.6(b), (c), and (d). (fl A Certificate for Payment, a progress payment, or partial or entire use or occupancy of the Project by the Owner shall not constitute acceptance of Work not performed in accordance with the Contract Documents. 9.7 SUBSTANTIAL COMPLETION (a) The Date of Substantial Completion of the Work, or designated portion of the Work, is the date certified by the Engineer when construction is sufficiently completed in accordance with the City Of Denton General Conditions For Building Construction. (a) the Contract Documents such that the Owner may beneficially occupy and use the Work, or designated portions of the Work, for the purposes for which it is intended and only trivial and insignifcant items remain which do not affect the Work as a whole. (b) When the Contractor considers that the Work, or the portion of the Work which the Owner agrees to accept separately, is Substantially Complete, the Contractor shall prepare and submit to the Engineer a comprehensive list of remaining items to be completed or corrected. The Contractor shall proceed promptly to complete and correct items on the list (hereinafter called the "punch list"). Failure to include an item on the punch list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. Upon receipt of the punch list, the Engineer will make an inspection to determine whether the Work, or designated portion of the Work, is Substantially Complete. If the Engineer's inspection discloses any item, whether or not included on the punch list, which is not in accordance with the requirements of the Contract Documents and which renders the Work inspected not Substantially Complete the Contractor shall, before issuance of the Certificate of Substantial Completion, complete or correct the item upon notification by the Engineer. The Contractor shall then submit a request for another inspection by the Engineer to determine Substantial Completion. When the 36 Work or designated portion of the Work is Substantially Complete, the Engineer will prepare a Certificate of Substantial Completion which shall establish the date of Substantial Completion, shall establish responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work and insurance, and shall fix the time within which the Contractor shall finish all items on the punch list accompanying the Certificate. (c) The Certificate of Substantial Completion shall be submitted to the Owner and the Contractor for their written acceptance of responsibilities assigned to them in the Certificate. (d) Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Engineer, the Owner shall make payment, reflecting adjustment in retainage, if any, for the Work, or portion of the Work, as provided in the Contract Documents. 9.8 PARTIAL OCCUPANCY OR USE (a) The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate Supplemental Agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Subparagraph 11.2(e) and authorized by public authorities having jurisdiction over the Work. Such partial occupancy or use may commence whether or not the portion is Substantially Complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion Substantially Complete, the Contractor shall prepare and submit a list to the Engineer as provided under Subparagraph 9.7(b). Consent of the Contractor to partia] occupancy or use shall not be unreasonably withheld. The stage of the (a) progress of the Work shall be determined by written agreement between the Owner and Contractor or, if no agreement is reached, by decision of the Engineer. (b) Immediately prior to such partial occupancy or use, the Owner, Contractor, and Engineer shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. (c) Unless otherwise agreed upon, partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents. 9.9 FINAL COMPLETION AND FINAL PAYMENT (a) Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Engineer, accompanied by the Owner's representative, will promptly make final inspection and, when the Engineer finds the Work acceptable under the Contract Documents and the Contract Documents fully performed, the Engineer will promptly issue a final Certificate for Payment stating that to the best of the Engineer's knowledge, information and belief, and on the basis of the Engineer's observations and inspections, the Work has been completed in accordance with terms and conditions of the Contract Documents and that the entire balance found to be due the Contractor and noted in said final Certificate is due and payable. The Engineer's final Certificate for Payment will constitute a further representation that conditions listed in Subparagraph 9.9(b) as a condition precedent to the Contractor's being entitled to final payment have been fulfilled. Owner will normally make 37 final payment within thirty (30) days after Owner's receipt and approval of the final Certificate for Payment. Warranties required by the Contract Documents shall commence on the date of Substantial Completion of the Work, unless otherwise provided by separate agreement between the Owner and the Contractor. (b) Neither final payment nor any remaining retained percentage shall become due until the Contractor submits to the Engineer: (1) an affdavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner's property might be responsible or encumbered (less amounts withheld by Owner) have been paid or otherwise satisfied; (2) a certificate evidencing that insurance required by the Contract Documents to remain in force after final payment is currently in effect and will not be cancelled or allowed to expire until at least thirty (30) days prior written notice has been given to the Owner; (3) a written statement that the Contractor knows of no substantial reason that the insurance will not be renewable to cover the period required by the Contract Documents; (4) a consent of surety to final payment; and (5) if required by the Owner, other data establishing payment or satisfaction of obligations, such as receipts, releases and waivers of liens, claims, security interests or encumbrances arising out of the Contract, to the extent and in such form as may be designated by the Owner. (c) As a precondition to final payment by the Owner under this Contract, the Contractor's affidavit under Clause (b)(1) shall state that the Contractor has paid each of his subcontractors, laborers or materialmen in full for all labor and materials provided to him for the Work under this Contract. In the event the Contractor has not paid each of his subcontractors, laborers or materialmen in full, the Contractor shall state in the affidavit the amount owed and the name of each subcontractor, laborer or materialmen to whom such payment is owed. IN ANY EVENT, THE CONTRACTOR SHALL BE REQUIRED TO EXECUTE THE OWNER'S STANDARD AFFIDAVIT OF FINAL PAYMENT AND RELEASE AS A PRECONDITION TO RECEIPT OF FINAL PAYMENT. (d) If, after Substantial Completion of the Work, final completion of the Work is materially delayed through no fault of the Contractor or by issuance of Change Orders affecting final completion and the Engineer confirms the delay, the Owner shall, upon application by the Contractor and certification by the Engineer, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than retainage stipulated in the Contract Documents, and if bonds have been furnished, the written consent of surety to payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Engineer prior to certification of payment. Payment shall be made under terms and conditions governing final payment, except that it shall not constitute a waiver of claims. (e) The acceptance by the Contractor of the final payment shall operate as and shall be a complete release of the Owner from all claims or liabilities under the Contract, for anything done or furnished or relating to the Work or the Project, or for any act or neglect of the Owner relating to or connected with the Work or the Project. ARTICLE 10 SAFETY, SECURITY AND UTILITY PROVISIONS; ENVIRONMENTAL COMPLIANCE 38 10.1 SAFETY PRECAUTIONS AND PROGRAMS The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the performance of the Contract, and will comply with all applicable City, County, State and Federal health and safety regulations. 10.2 SAFETY OF PERSONS AND PROPERTY (a) The Contractor shall take reasonable precautions for safety of, and shall provide reasonable protection to prevent damage, injury or loss to: (1) employees on the Work and other persons who may be affected thereby; (2) the Work and materials and equipment to be incorporated therein, whether in storage on or off the site, under care, custody or control of the Contractor or the Contractor's Subcontractors or Sub-subcontractors; and (3) other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction. (b) The Contractor shall give notices and comply with applicable laws, ordinances, rules, regulations and lawful orders of public authorities bearing on safety of persons or property or their protection from damage, injury or loss. (c) The Contractor shall erect and maintain, as required by existing conditions and performance of the Contract, reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards, promulgating safety regulations and notifying owners and users of adjacent sites and utilities. (d) USE OF EXPLOSIVES IS PROHIBITED - CLAIMS AND TOTAL INDEMNIFICATION. The Owner shall have the right to pre-approve the use of any explosives on the Project; the Contractor shall not assume in its bid that permission to use explosives will be granted. The Owner shall NOT be liable for any claim for additional time or compensation as a result of the Owner's denial of permission to use explosives. Where use of explosives is permitted by the Owner, the Contractor EXPRESSLY AGREES TO BE SOLELY RESPONSIBLE for the determination as to whether explosives shall actually be used, and for any result from the use, handling or storage of explosives, and shall INDEMNIFY, DEFEND AND HOLD COMPLETELY HARMLESS the Owner, its officers, agents and employees, and the Engineer against any and all claims, lawsuits, judgments, costs or expenses for personal injury (including death), property damage or other harm for which recovery of damages is sought, suffered by any person or persons, as the result of the use, handling or storage of the explosives by the Contractor or any Subcontractor, REGARDLESS OF WHETHER SAID USE, HANDLING OR STORAGE WAS NEGLIGENT OR NOT, AND REGARDLESS OF WHETHER THE DAMAGE OR INJURY WAS CONTRIBUTED TO IN ANY WAY BY THE NEGLIGENCE OR FAULT OF THE OWNER, ITS OFFICERS, AGENTS, EMPLOYEES, OR REPRESENTATIVES, OR THE ENGINEER AND ITS OFFICERS, AGENTS, EMPLOYEES, OR REPRESENTATIVES. In the event of conflict with any other indemnity paragraph in this Contract, this paragraph controls. This indemnity paragraph is intended solely for the benefit of the parties to this Contract and is not intended to create or grant any rights, contractual or otherwise, to or for any other person or entity. The Contractor shall furnish the Owner and the Engineer with evidence of insurance sufficient to cover possible damage or injury, which insurance shall either include the 39 Owner and the Engineer as additional insureds or be sufficiently broad in coverage as to fully protect the Owner and the Engineer. (e) The Contractor shall promptly remedy damage and loss (other than damage or loss insured under property insurance required by the Contract Documents) to property referred to in Clauses 10.2(a)(2) and 10.2(a)(3) caused in whole or in part by the Contractor, a Subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible under Clauses 10.2(a)(2) and 10.2(a)(3), except damage or loss attributable to acts or omissions of the Owner or Engineer or anyone directly or indirectly employed by either of them, or by anyone for whose acts either of them may be liable, and not attributable to the fault or negligence of the Contractor or any of its Subcontractors. The foregoing obligations of the Contractor are in addition to the Contractor's obligations under Paragraph 3.19. To the extent that any such damage or loss may be covered by property insurance or other insurance required by the Contract Documents, the Owner and the Contractor shall exercise their best efforts to make a claim and obtain recovery from the insurers to provide for the cost, in whole or in part, of the repair work or to provide for reimbursement for such damage or loss. (� The Contractor shall designate a responsible member of the Contractor's organization at the site whose duty shall be the prevention of accidents. This person shall be the Contractor's , superintendent unless otherwise designated by the Contractor in writing to the Owner and Engineer. (g) The Contractor shall not load or permit any part of the Work or the Project site to be loaded so as to endanger its safety. 10.3 EMERGENCIES In an emergency affecting safety, health, or security of persons or property, the Contractor shall act, at the Contractor's discretion, to prevent threatened damage, injury, or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Paragraph 4.3 and Article 7. 10.4 PUBLIC CONVENIENCE AND SAFETY (a) The Contractor shall place materials stored about the Work and shall conduct the Work at all times in a manner that causes no greater obstruction to the public than is considered necessary by the Owner. Sidewalks or streets shall not be obstructed, except by special permission of the Owner. The materials excavated and the construction materials or plant used in the performance of the Work shall be placed in a manner that does not endanger the Work or prevent free access to all fire hydrants, water mains and appurtenances, water valves, gas valves, manholes for the telephone, telegraph signal or electric conduits, wastewater mains and appurtenances, and fire alarm or police call boxes in the vicinity. (b) The Owner reserves the right to remedy any neglect on the part of the Contractor in regard to public convenience and safety which may come to the Owner's attention, after twenty-four (24) hours notice in writing to the Contractor. In case of an emergency, the Owner shall have the right to immediately remedy any neglect without notice. In either case, the cost of any work done by the Owner to remedy the Contractor's neglect shall be deducted from the Contract Sum. The Contractor shall notify the City Traffic Contro) Department when any street is to be closed or obstructed. The notice shall, in the case of major thoroughfares or street upon which transit lines operate, be forty-eight (48) hours in advance. The Owner reserves the right to 40 postpone or prohibit any closure or obstruction of -any streets or thoroughfares to the extent necessary for the safety and benefit of the traveling public. The Contractor shall, when directed by the Engineer or the Owner, keep any street or streets in condition for unobstructed use by City departments. When the Contractor is required to construct temporary bridges or make other arrangements for crossing over ditches or around structures, the Contractor's responsibility for accidents shall include the roadway approaches as well as the crossing structures. 10.5 BARRICADES, LIGHTS AND WATCHMEN If the Work is carried on or adjacent to any street, alley or public place, the Contractor shall, at the Contractor's own cost and expense, furnish, erect and maintain sufficient barricades, fences, lights and danger signals, shall provide suff cient watchmen, and shall take such other precautionary measures as are necessary for the protection of persons or property and of the Work. All barricades shall be painted in a color that will be visible at night, shall indicate in bold letters thereon the Contractor's name and shall be illuminated by lights from sunset to sunrise. The term "lights," as used in this Paragraph, shall mean flares, flashers, or other illuminated devices. A sufficient number of barricades with adequate markings and directional devices shall also be erected to keep vehicles from being driven on or into any Work under construction. The Contractor will be held responsible for all damage to the Work due to failure of barricades, signs, lights and watchmen to protect the Work. Whenever evidence is found of such damage, the Engineer may order the damaged portion immediately removed and replaced by the Contractor at Contractor's cost and expense. The Contractor's responsibility for maintenance of barricades, signs, and lights, and for providing watchmen, shall not cease until the Project has been finally accepted by the Owner. 10.6 PUBLIC UTILITIES AND OTHER PROPERTIES TO BE CHANGED In case it is necessary to change or move the property of the Owner or of any telecommunications or public utility, such property shall not be removed or interfered with until ordered to do so by the Engineer. The right is reserved to the owner of any public or private utilities to enter upon the Project site for the purpose of making such changes or repairs of their property that may become necessary during the performance of the Work. The Owner reserves the right of entry upon the Project site for any purpose, including repairing or relaying sewer and water lines and appurtenances, repairing structures, and for making other repairs, changes, or extensions to any of the Owner's property. The Owner's actions shall conform to the Contractor's current and approved schedule for the performance of the Work, provided that proper notification of schedule requirements has been given to the Owner by the Contractor. 10.7 ARRANGEMENT AND CHARGE FOR WATER FURNISHED BY THE OWNER; ELECTRICITY FOR THE PROJECT (a) Traffic Department will supply contractor with Electricity through coordination with DME. 10.8 USE OF FIRE HYDRANTS The Contractor, Subcontractors, and any other person working on the Project shall not open, turn off, interfere with, attach any pipe or hose to, or connect anything with any fire hydrant, stop valve, or stop cock, or tap any water main belonging to the Owner, unless duly authorized to do so by the Denton Water Utilities Department in accordance with the Denton City Code. 10.9 ENVIRONMENTAL COMPLIANCE 41 (a) The Contractor and its Subcontractors are deemed to have made themselves familiar with and at all times shall comply with all applicable federal, state or local laws, rules, regulations, ordinances, and rules of common law now in effect (including any amendments now in effect), relating to the environment, Hazardous Substances or exposure to Hazardous Substances, including but not limited to the Comprehensive Environmental Response, Compensation and Liability Act of 1980, 42 U.S.C.A. §§ 9601, et seq.; the Hazardous Materials Transportation Act, 49 U.S.C.A. §§ 1801, et seq.; the Resource Conservation and Recovery Act of 1976, 42 U.S.C.A. §§ 6901, et seq.; the Federal Water Pollution Control Act, 33 U.S.C.A §§ 1201, et seq.; the Toxic Substances Control Act, 15 U.S.C.A. §§ 2601, et seq.; the Clean Air Act, 42 U.S.C.A. §§ 7401, et seq.; the Safe Drinking Water Act, 42 U.S.C.A. §§ 3808, et seq., and any current judicial or administrative interpretation of these laws, rules, regulations, ordinances, or rules of common law, including but not limited to any judicial or administrative order, consent decree, or judgment affecting the Project. (b) In the event the Contractor encounters on the site materials reasonably believed to be a Hazardous Substance that have not been rendered harmless, and removal of such materials is not a part of the scope of Work required under the Contract Documents, the Contractor shall immediately stop Work in the affected area and report in writing the facts of such encounter to the Engineer and the Owner. Work in the affected area shall not thereafter be resumed except by written order of the Owner unless and until the material is determined not to be a Hazardous Substance or the Hazardous Substance is remediated. The Owner may choose to remediate the Hazardous Substance with a separate contractor or through a Change Order with the Contractor. If the Owner determines that the Hazardous Substance exists in the affected area due to the fault or negligence of the Contractor or any of its Subcontractors, the Contractor shall be responsible for remediating the condition at the sole expense of the Contractor in accordance with the Contractor's APPROVED Spill Remediation Plan. An extension of the Contract Time for any delay in the progress schedule caused as a result of the discovery and remediation of a Hazardous Substance may be granted by the Owner only if all remaining Work on the Project must be suspended and the delay cannot be made up elsewhere in the progress schedule. Any request for an extension of the Contract Time related to the discovery and remediation of a Hazardous Substance is subject to the provisions of Paragraph 4.3 and Article 8. (c) The Contractor shall be responsible for identification, abatement, cleanup, control, removal, remediation, and disposal of any Hazardous Substance brought into or upon the site by the Contractor or any Subcontractor or Supplier. The Contractor shall obtain any and all permits necessary for the legal and proper handling, transportation, and disposal of the Hazardous Substance and shall, prior to undertaking any abatement, cleanup, control, removal, remediation, and disposal, notify the Owner and the Engineer so that they may observe the activities; provided, however, that it shall be the Contractor's sole responsibility to comply with all applicable laws, rules, regulations, or ordinances governing the activities. (d) The Contractor shall deposit surplus or waste excavation or other materials removed as part of the Work at a legal disposal site in accordance with all applicable state, federal, and local laws, rules, regulations, and ordinances. The Contractor shall submit to the Owner for review and approval all planned disposal sites or proposed uses for the surplus or waste excavation or other materials prior to removal of any excavation or other material from the Project site. A copy of all transport manifests for surplus or waste excavation or other materials shall be obtained and retained in the Contractor's records for reference purposes, to be provided upon 42 request to the Engineer, the Owner, or any governmental regulatory agency with jurisdiction over the matter. (e) The Contractor shall not install any materials in the performance of the Work that contain asbestos or asbestos-related material such as hydrated mineral silicate, including chrysolite, amosite, crocidolite, tremolite, anthophylite or actinolite, whether friable or non-friable. (� The Owner reserves the right in its sole option to exercise the following remedies (without waiving the right to pursue the imposition of any civil or criminal fines or penalties that may be imposed under state, federal, or local laws or ordinances), at no additional cost to the Owner and without an extension of the Contract Time, in the event the Contractor fails or refuses after seven (7) days advance written notice from the Owner to comply with the provisions of this Paragraph 10.10, the terms of the SPRP, the terms of the Clean Air Management Plan, any storm water permit or other environmental permit issued in connection with the Work, or any applicable environmental law, rule, regulation, or ordinance: (1) suspend all or any portion of the Work until the noncompliance is corrected, or until a detailed plan to achieve compliance within a reasonably prompt period of time is prepared by the Contractor and approved by the Owner; (2) if the Contractor fails to properly address the noncompliance within the time stipulated by the Owner, perform the necessary remediation or correction work and backcharge the Contractor for the cost of the remediation or correction; or (3) terminate the Contract for cause as provided in Article 13. ARTICLE 11 INSURANCE AND BONDS 11.1 CONTRACTOR'S INSURANCE Contractors shall refer to Attachment A for all City of Denton insurance reyuirements. 11.2 PROPERTY INSURANCE Contractors shall refer to Attachment A for all City of Denton insurance requirements. 11.3 `UMBRELLA' LIABILITY INSURANCE Contractors shall refer to Attachment A for all City of Denton insurance requirements. 11.4 POLICY ENDORSEMENTS AND SPECIAL CONDITIONS Contractors shall refer to Attachment A for all City of Denton insurance requirements. 11.6 PERFORMANCE AND PAYMENT BONDS (a) Subject to the provisions of Subparagraph 11.3(b), the Contractor shall, with the execution and delivery of the Construction Services Agreement, furnish and file with the Owner in the amounts required in this Paragraph, the surety bonds described in Clauses (a)(1) and (a)(2) below, which surety bonds shall be in accordance with the Charter of the City of Denton and the provisions of Chapter 2253, Texas Government Code, as amended; each bond shall be signed by the Contractor, as Principal, and by an established bonding company, as surety, meeting the requirements of Subparagraph 11.3(c) and approved by the Owner. The surety bonds shall be 43 accompanied by an appropriate Power-of-Attorney clearly establishing the extent and limitations of the authority of each signer to so sign: (1) Performance Bond. A good and sufficient bond in an amount equal to 100% of the total Contract Sum, guaranteeing the full and faithful execution of the Work and performance of the Contract in accordance with Plans, Specifications and all other Contract Documents, including any Amendments thereof, for the protection of the Owner. This bond shall also provide for the repair and maintenance of all defects due to faulty materials and workmanship that appear within a period of two (2) year from the date of final completion and acceptance of the improvements by the Owner or lesser or longer periods as may be otherwise designated in the Contract Documents. (2) Payment Bond. A good and sufficient bond in an amount equal to 100% of the total Contract Sum, guaranteeing the full and prompt payment of all claimants supplying labor or materials in the prosecution of the Work provided for in the Contract Documents and any Amendments thereto, and for the use and protection of each claimant. (b) If the Contract Sum, including Owner-accepted alternates and allowances, if any, is greater than $ l 00,000, Performance in 100% of the Contract Sum are mandatory and shall be provided by the Contractor. If the Contract Sum is greater than $50,000 but less than or equal to $100,000, only a Payment Bond in 100% of the Contract amount is mandatory; provided, however, that the Contractor may elect to furnish a Performance Bond in the same amount if the Contractor so chooses. If the Contract Sum is less than or equal to $25,000, the Contractor may elect not to provide Performance and Payment Bonds; provided that in such event, no money will be paid to the Contractor until final completion and acceptance of all work by Owner. If the Contractor elects to provide Performance and Payment Bonds 100% of the total Contract Sum, progress payments in accordance with these General Conditions shall be disbursed. (c) No surety will be accepted by the Owner who is now in default or delinquent on any bonds or who is a party to any litigation against the Owner. All bonds shall be made and executed on the Owner's standard forms, shall be approved by the Owner, and shall be executed by not less than one corporate surety that is authorized and admitted to do business in the State of Texas, is licensed by the State of Texas to issue surety bonds, is listed in the most current United States Department of the Treasury List of Acceptable Sureties, and is otherwise acceptable to the Owner. Each bond shall be executed by the Contractor and the surety, and shall specify that legal venue for enforcement of each bond shall lie exclusively in Denton County, Texas. Each surety shall designate an agent resident in Denton County, Texas to whom any requisite statutory notices may be delivered and on whom service of process may be had in matters arising out of the suretyship. (d) The person or persons, partnership, company, frm, Limited Liability Company, association, corporation, or other business entity to whom the Contract is awarded shall, within ten (10) days after such award, sign the required Contract with the Owner and provide the necessary surety bonds and evidence of insurance as required under the Contract Documents. No Contract shall be binding on the Owner until it has been approved as to form by the City Attorney, executed for the Owner by the City Manager, the performance and payment bonds and evidence of insurance have been furnished as required by the Contract Documents, and the fully executed contract has been delivered to the Contractor. 44 (e) The failure of the Contractor to execute the Contract or deliver the required statutory bonds and evidence of insurance within ten (10) days after the Contract is awarded or as soon thereafter as the Owner can assemble and deliver the Contract shall constitute a material breach of the Contractor's bid proposal and the Owner may rescind the Contract award and collect or retain the proceeds of the bid security. By reason of the uncertainty of the market prices or materials and labor, and it being impracticable and difficult to determine accurately the amount of damages occurring to the Owner by reason of the Contractor's failure to execute and furnish the statutory bonds and to sign the Contract within ten (10) days, the fling of a bid proposal with the accompanying bid security will be considered as an acceptance of this Subparagraph 11.3(e). In the event the Owner should re-advertise for bids, the defaulting Contractor shall not be eligible to bid, and the lowest responsible bid obtained in the re-advertisement shall be the bid referred to in this Paragraph. ARTICLE 12 DEFECTIVE AND NONCONFORMING WORK 12.1 UNCOVERING OF WORK (a) If a portion of the Work is covered contrary to the Engineer's request or to requirements specifically expressed in the Contract Documents, the Work must, if required in writing by the Engineer, be uncovered for the Engineer's observation and be replaced at the Contractor's expense without change in the Contract Time. (b) If a portion of the Work has been covered which the Engineer has not specifically requested to observe prior to it being covered, the Engineer may request to see such Work and it shall be uncovered by the Contractor. If such Work is in accordance with the Contract Documents, costs of uncovering and replacement shall, by appropriate Change Order, be charged to the Owner. If any Work is not in accordance with the Contract Documents, the Contractor shall pay the costs of uncovering, repair, replacement unless the condition was caused by the Owner or a separate contractor in which event the Owner shall be responsible for payment of such costs. 12.2 CORRECTION OF WORK (a) The Contractor shall promptly correct Work rejected by the Engineer as failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear costs of correcting such rejected Work, including additional testing and inspections and compensation for the Engineer's services and expenses made necessary thereby. (b) If any of the Work is found to be defective or nonconforming with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of written notice from the Engineer or the Owner to do so unless the Owner has previously given the Contractor a written acceptance or waiver of the defect or nonconformity. The Contractor's obligation to correct defective or nonconforming Work remains in effect for: (1) one year after the date of Substantial Completion of-the Work or designated portion of the Work; (2) one year after the date for commencement of warranties established by agreement in connection with partial occupancy under Subparagraph 9.8(a); or 45 (3) the stipulated duration of any applicable special warranty required by the Contract Documents. (c) The one-year period described in Clauses (b)(1) and (b)(2) shall be extended with respect to portions of the Work performed, repaired, or corrected after Substantial Completion by the period of time between Substantial Completion and the actual completion of the Work. (d) The obligations of the Contractor under this Paragraph 12.2 shall survive final acceptance of the Work and termination of this Contract. The Owner shall give notice to the Contractor promptly after discovery of a defective or nonconforming condition in the Work. The one-year period stated in Clauses (b)(1) and (b)(2) does not limit the ability of the Owner to require the Contractor to correct latent defects or nonconformities in the Work, which defects or nonconformities could not have been discovered through reasonable diligence by the Owner or the Engineer at the time the Work was performed or at the time of inspection for certification of Substantial Completion or Final Completion. The one year period also does not relieve the Contractor from liability for any defects or deficiencies in the Work that may be discovered after the expiration of the one year correction period. (e) The Contractor shall remove from the Project site portions of the Work which are not in accordance with the requirements of the Contract Documents and are neither corrected by the Contractor nor accepted by the Owner. (fl If the Contractor fails to correct defective or nonconforming Work within a reasonable time after notice from the Owner or the Engineer, the Owner may correct it in accordance with Paragraph 2.4. If the Contractor does not proceed with correction of defective or nonconforming Work within a reasonable time fixed by written notice from the Engineer, the Owner may remove or replace the defective or nonconforming Work and store the salvageable materials or equipment at the Contractor's expense. If the Contractor does not pay costs of removal and storage within ten days after written notice, the Owner may, upon ten (10) additional days written notice, sell the materials and equipment at auction or at private sale and shall account for the proceeds after deducting costs and damages that should have been borne by the Contractor, including compensation for the Engineer's services and expenses made necessary as a result of the sale. If the proceeds of sale do not cover costs which the Contractor should have borne, the Contract Sum shall be reduced by the deficiency. If payments due to the Contractor then or thereafter are not sufficient to cover the deficiency, the Contractor shall pay the difference to the Owner. (g) The Contractor shall bear the cost of correcting destroyed or damaged construction of the Owner or separate contractors, whether the construction is completed or partially completed, that is caused by the Contractor's correction or removal of Work which is not in accordance with the requirements of the Contract Documents. (h) Nothing contained in this Paragraph 12.2 shall be construed to establish a period of limitation with respect to other obligations which the Contractor might have under the Contract Documents. Establishment of the one-year time period as described in Subparagraph 12.2(b) relates only to the specific obligation of the Contractor to correct the Work, and has no relationship to the time within which the obligation to comply with the Contract Documents may be sought to be enforced, nor to the time within which proceedings may be commenced to establish the Contractor's liability with respect to the Contractor's obligations other than specifically to correct the Work. 46 (i) Any Work repaired or replaced pursuant to this Article 12 shall be subject to the provisions of Article 12 to the same extent as Work originally performed or installed. 12.3 ACCEPTANCE OF NONCONFORMING WORK The Owner may, in the Owner's sole discretion, accept Work which is not in accordance with the requirements of the Contract Documents instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. The adjustment will be accomplished whether or not final payment has been made. ARTICLE 13 COMPLETION OF THE CONTRACT; TERMINATION; TEMPORARY SUSPENSION 13.1 FINAL COMPLETION OF CONTRACT The Contract will be considered completed, except as provided in any warranty or maintenance stipulations, bond, or by law, when all the Work has been finally completed, the final inspection is made by the Engineer, and final acceptance and final payment is made by the Owner. 13.2 WARRANTY FULFILLMENT Prior to the expiration of the specified warranty period provided for in the Contract Documents, the Engineer will make a detailed inspection of the Work and will advise the Contractor and the Contractor's Surety of the items that require correction. The Engineer will make a subsequent inspection and if the corrections have been properly performed, the Engineer will issue a letter of release on the maintenance stipulations to the Contractor and the Surety. If for any reason the Contractor has not made the required corrections before the expiration of the warranty period, the warranty provisions as provided for in the Contract Documents shall remain in effect until the corrections have been properly performed and a letter of release issued. 13.3 TERMINATION BY THE OWNER FOR CAUSE (a) Notwithstanding any other provision of these General Conditions, the Work or any portion of the Work may be terminated immediately by the Owner for any good cause after giving seven (7) days advance written notice and opportunity to cure to the Contractor, including but not limited to the following causes: (1) Failure or refusal of the Contractor to start the Work within ten (10) days after the date of written notice by the Owner to commence the Work. (2) A reasonable belief that the progress of the Work being made by the Contractor is insufficient to complete the Work within the specified time. (3) Failure or refusal of the Contractor to provide sufficient and proper equipment or construction forces to properly execute the Work in a timely manner. (4) A reasonable belief that the Contractor has abandoned the Work. (5) A reasonable belief that the Contractor has become insolvent, bankrupt, or otherwise financially unable to carry on the Work. 47 (6) Failure or refusal on the part of the Contractor to observe any requirements of the Contract Documents or to comply with any written orders given by the Engineer or the Owner as provided for in the Contract Documents. (7) Failure or refusal of the Contractor to promptly make good any defects in materials or workmanship, or any defects of any nature, the correction of which has been directed in writing by the Engineer. (8) A reasonable belief by the Owner that collusion exists or has occurred for the purpose of illegally procuring the Contract or a Subcontractor, or that a fraud is being perpetrated on the Owner in connection with the construction of Work under the Contract. (9) Repeated and flagrant violation of safe working procedures. (10) The filing by the Contractor of litigation against the Owner prior to completion of the Work. (b) When the Work or any portion of the Work is terminated for any of the causes itemized above or for any other cause except termination for convenience pursuant to Subparagraph 13.3(e), the Contractor shall, as of the date specified by the Owner, discontinue the Work or portion of the Work as the Owner shall designate, whereupon the surety shall, within fifteen (15) days after the written notice of termination for cause has been served upon the Contractor and the surety or its authorized agents, assume the obligations of the Contractor for the Work or that portion of the Work which the Owner has ordered the Contractor to discontinue and may: (1) perform the Work with forces employed by the surety; (2) with the written consent of the Owner, tender a replacement contractor to take over and perform the Work, in which event the surety shall be responsible for and pay the amount of any costs required to be incurred for the completion of the Work that are in excess of the amount of funds remaining under the Contract as of the time of the termination; or (3) with the written consent of the Owner, tender and pay to the Owner in settlement the amount of money necessary to finish the balance of uncompleted Work under the Contract, correct existing defective or nonconforming Work, and compensate the Owner for any other loss sustained as a result of Contractor's default. In the event of termination for cause involving Clause (b)(1) or (b)(2), the Surety shall assume the Contractor's place in all respects, and the amount of funds remaining unpaid under the Contract shall be paid by the Owner for all Work performed by the surety or the replacement contractor in accordance with the terms of the Contract Documents, subject to any rights of the Owner to deduct any costs, damages, or liquidated or actual damages that the Owner may have incurred, including but not limited to additional fees and expenses of the Engineer and attorneys fees, as a result of such termination. (c) The balance of the Contract Sum remaining at the time of the Contractor's default and of the termination shall become due and payable to the surety as the Work progresses, subject to all of the terms, covenants, and conditions of the Contract Documents. If the surety does not, within the time specified in Subparagraph 13.3(b), exercise its obligation to assume the obligations of the Contract, or that portion of the Contract which the Owner has ordered the 48 Contractor to discontinue, then the Owner shall have the power to complete the Work by contract or otherwise, as it may deem necessary. The Contractor agrees that the Owner shall have the right to take possession of or use any or all of the materials, plant, tools, eyuipment, supplies, and property of every kind provided by the Contractor for the purpose of the Work, and to procure other tools, equipment, labor, and materials for the completion of the Work, and to charge to the account of the Contractor the expenses of completion and labor, materials, tools, equipment, and incidental expenses. The expenses incurred by the Owner to complete the Work shall be deducted by the Owner out of the balance of the Contract Sum remaining unpaid to or unearned by the Contractor. The Contractor and the surety shall be liable to the Owner for any costs incurred in excess of the balance of the Contract Sum for the completion and correction of the Work, and for any other costs, damages, expenses (including but not limited to additional fees of the Engineer and attorney's fees), and liquidated or actual damages incurred as a result of the termination, (d) The Owner shall not be required to obtain the lowest bid for the Work of completing the Contract as described in Subparagraph 13.3(c), but the expenses to be deducted from the Contract Sum shall be the actual cost of such Work. In case the Owner's expense is less than the sum which would have been payable under the Contract, if the same had been completed by the Contractor, then the Owner may pay to the Contractor (or the Surety, in the event of a complete termination for cause) the difference in the cost, provided that the Contractor (or the Surety) shall not be entitled to any claim for damages or for loss of anticipated profits. In case such expenses for completion shall exceed the amount which would have been payable under the Contract if the same had been completed by the Contractor, then the Contractor and his Sureties shall pay the amount of the excess to the Owner on notice from the Owner for excess due. When only a particular part of the Work is being carried on by the Owner by contract or otherwise under the provisions of this Subparagraph, the Contractor shall continue the remainder of the Work in conformity with the terms of the Contract, and in such manner as not to hinder or interfere with the performance of workmen employed and provided by the Owner. (e) The right to terminate this Contract for the convenience of the Owner (including but not limited to nonappropriation of funding) is expressly retained by the Owner. In the event of termination for convenience, the Owner shall deliver at least ten (10) days advance written notice of termination for convenience to the Contractor. Upon the Contractor's receipt of such written notice, the Contractor shall cease the performance of the Work and shall take reasonable and appropriate action to secure and protect the Work in place. The Contractor shall then be reimbursed by the Owner in accordance with the terms and provisions of the Contract Documents, not to exceed actual labor costs incurred, materials stored at the Project site or away from the Project site as approved by the Owner but not yet paid for, plus actual, reasonable, and documented termination charges, if any, paid by the Contractor in connection with the Work in place which is completed and in conformance with the Contract Documents to the date of termination for convenience. No amount shall ever be due to the Contractor for lost or anticipated profits. 13.4 TEMPORARY SUSPENSION OF THE WORK (a) The Work or any portion of the Work may be temporarily suspended by the Owner immediately upon written notice to the Contractor for any reason, including but not limited to: (1) the causes described in Clauses 13.1(a)(1) through (a)(10) above; 49 (2) where other provisions in the Contract Documents require or permit temporary suspension of the Work; (3) situations where the Work is threatened by, contributes to, or causes an immediate threat to public health, safety, or security; or (4) other unforeseen conditions or circumstances. (b) The Contractor shall immediately resume the temporarily suspended Work when ordered in writing by the Owner to do so. The Owner shall not under any circumstances be liable for any claim of the Contractor arising from a temporary suspension due to a cause described in Clause (a)(1) above; provided, however, that in the case of a temporary suspension for any of the reasons described under Clauses (a)(2) through (a)(4), where the Contractor is not a contributing cause of the suspension under one of those Clauses or where the provision of the Contract Documents in question specifically provides that the suspension is at no cost to the Owner, the Owner will make an equitable adjustment for the following items, provided that a claim is properly made by the Contractor under Subparagraph 4.3 of these General Conditions: (1) an equitable extension of the Contract Time, not to exceed the actual delay caused by the temporary suspension as determined by the Engineer and the Owner; (2) an equitable adjustment to the Contract Sum for the actual, necessary, and reasonable costs of properly protecting any Work that is finished or partially finished during the period of the temporary suspension (no profit and overhead shall be allowed on top of these costs); and (3) if it becomes necessary to move equipment from the Project site and then return it to the Project site when the Work is ordered to be resumed, an equitable adjustment to the Contract Sum for the actual, necessary, and reasonable cost of these moves; provided, however, that no adjustment shall be due if the equipment is moved to another Project site of the Owner. ARTICLE 14 MISCELLANEOUS PROVISIONS 14.1 GOVERNING LAW; COMPLIANCE WITH LAWS AND REGULATIONS (a) This Contract shall be governed by the laws and case decisions of the State of Texas, without regard to conflict of law or choice of law principles of Texas or of any other state. (b) This Contract is entered into subject to and controlled by the Charter and ordinances of the City of Denton and all applicable laws, rules, and regulations of the State of Texas and the Government of the United States of America. The Contractor shall, during the performance of the Work, comply with all applicable City codes and ordinances, as amended, and all applicable State and Federal laws, rules and regulations, as amended. 50 14.2 SUCCESSORS AND ASSIGNS The Owner and the Contractor respectively bind themselves, their partners, successors, assigns, and legal representatives to the promises, covenants, terms, conditions, and obligations contained in the Contract Documents. The Contractor shall not assign, transfer, or convey its interest or rights in the Contract, in part or as a whole, without written consent of the Owner. If the Contractor attempts to make an assignment, transfer, or conveyance without the Owner's written consent, the Contractor shall nevertheless remain legally responsible for all obligations under the Contract Documents. The Owner shall not assign any portion of the Contract Sum due or to become due under this Contract without the written consent of the Contractor, except where assignment is compelled or allowed by court order, the terms of the Contract Documents, or other operation of law. 14.3 WRITTEN NOTICE Except as otherwise provided in Article 16, any notice, payment, statement, or demand required or permitted to be given under this Contract by either party to the other may be effected by personal delivery in writing or by mail, postage prepaid to the Project Manager or Superintendent of either party, or to an officer, partner, or other designated representative of either party. Mailed notices shall be addressed to the parties at an address designated by each party, but each party may change its address by written notice in accordance with this section. Mailed notices shall be deemed communicated as of three (3) days after mailing. 14.4 RIGHTS AND REMEDIES; NO WAIVER OF RIGHTS BY OWNER (a) The duties and obligations imposed on the Contractor by the Contract Documents and the rights and remedies available to the Owner under the Contract Documents shall be in addition to, and not a limitation of, any duties, obligations, rights, and remedies otherwise imposed or made available by law. (b) No action or failure to act by the Owner shall constitute a waiver of a right afforded the Owner under the Contract Documents, nor shall any action or failure to act by the Owner constitute approval of or acquiescence in a breach of the Contract by Contractor, except as may be specifcally agreed in writing by Change Order or Supplemental Agreement. 14.5 INTEREST The Owner shall not be liable for interest on any progress or final payment to be made under the Contract Documents, except as may be provided by the applicable provisions of the Prompt Payment Act, Chapter 2251, Texas Government Code, as amended, subject to Paragraph 9.6(a) of these General Conditions. 14.6 OFFICERS OR EMPLOYEES OF THE OWNER NOT TO HAVE FINANCIAL INTEREST IN ANY CONTRACT OF THE OWNER No officer or employee of the Owner shall have a financial interest, direct or indirect, in any Contract with the Owner, or be fnancially interested, directly or indirectly, in the sale to the Owner of any land, materials, supplies or services, except on behalf of the Owner as an officer or employee. Any violation of this article shall constitute malfeasance in office, and any officer or employee of Owner guilty thereof shall thereby forfeit his office or position. Any violation of this section, with the knowledge, express or implied, of the person, persons, partnership, company, firm, association or corporation contracting with the Owner shall render the Contract involved voidable by the Owner's City Manager or City Council. 51 14.7 VENUE This Contract is deemed to be performed in Denton County, Texas, and if legal action is necessary to enforce this Contract, exclusive venue shall lie in Denton County, Texas. 14.8 INDEPENDENT CONTRACTOR In performing the Work under this Contract, the relationship between the Owner and the Contractor is that of an independent contractor. The Contractor shall exercise independent judgment in performing the Work and is solely responsible for setting working hours, scheduling or prioritizing the Work flow and determining the means and methods of performing the Work, subject only to the requirements of the Contract Documents. No term or provision of this Contract shall be construed as making the Contractor an agent, servant, or employee of the Owner, or making the Contractor or any of the Contractor's employees, agents, or servants eligible for the fringe benefits, such as retirement, insurance and worker's compensation, which the Owner provides to its employees. 14.9 NONDISCRIMINATION As a condition of this Contract, the Contractor covenants that he will take all necessary actions to insure that, in connection with any work under this Contract, the Contractor and its Subcontractors will not discriminate in the treatment or employment of any individual or groups of individuals on the grounds of race, color, religion, national origin, age, sex, or handicap unrelated to job performance, either directly, indirectly or through contractual or other arrangements. The Contractor shall also comply with all applicable requirements of the Americans with Disabilities Act, 42 U.S.C.A. §§12101-12213, as amended. In this regard, the Contractor shall keep, retain and safeguard all records relating to his Contract or Work performed thereunder for a minimum period of three (3) years from final Contract completion, with full access allowed to authorized representatives of the Owner, upon request, for purposes of evaluating compliance with this and other provisions of the Contract. 14.10 GIFTS TO PUBLIC SERVANTS (a) The Owner may terminate this Contract immediately if the Contractor has offered, conferred, or agreed to confer any benefit on a City of Denton employee or official that the City of Denton employee or official is prohibited by law from accepting. (b) For purposes of this Article, "benefit" means anything reasonably regarded as pecuniary gain or pecuniary advantage, including benefit to any other person in whose welfare the beneficiary has a direct or substantial interest, but does not include a contribution or expenditure made and reported in accordance with law. (c) Notwithstanding any other legal remedies, the Owner may require the Contractor to remove any employee of the Contractor from the Project who has violated the restrictions of this Article or any similar State or Federal law, and obtain reimbursement for any expenditures made to the Contractor as a result of the improper offer, agreement to confer, or conferring of a benefit to a City of Denton employee or official. ARTICLE 15 RIGHT TO AUDIT CONTRACTOR'S RECORDS By execution of the Building Construction Services �Agreement, the Contractor grants the Owner the right to audit, at the Owner's election, all of the Contractor's records and billings relating to the performance of the Work under the Contract Documents. The Contractor agrees to retain its Project records for a minimum of five (5) years following completion of the Work. The Owner agrees that it will exercise the right to audit only at reasonable hours. City may review any and all of the services 52 performed by Contractor under this Contract. Any payment, settlement, satisfaction, or release made or provided during the course of performance of this Contract shall be subject to City's rights as may be disclosed by an audit under this section. ARTICLE 16 NOTICE OF CONTRACT CLAIM This Contract is subject to the provisions of the Denton City Code, as amended, relating to requirements for filing a notice of a breach of contract claim against City. Contractor shall comply with the requirements of this ordinance as a precondition of any litigation relating to this Contract, in addition to all other requirements in this Contract related to claims and notice of claims. �,ttt�t�l�� a��f�i�.i �t�°i�+� bcf�►wc�r� tl�c� �'�Cl FiT`�' sic��u��r��st su � lic�° te��na�< ��° +��tr�t�t• t�t� ic,z•r��s �ri€� conditions set forth in the negotiated contract shall prevail. 53 EXIIIU�I 66/"�99 \.. ,, „ �� •-� , �� . . � � � . � . Respondent's attention is directed to the insurance requirements below. It is highly recommended that respondents confer with their respective insurance carriers or brokers to determine in advance of Proposal/Bid submission the availabiliry of insurance certificates and endorsements as prescribed and provided herein. If an apparent low respondent fails to comply strictly with the insurance requirements, that respondent may be disqualified from award of the contract. Upon contract award, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: WithouP limiling any of Phe other obligations or liaBiliPies of the ConPractor, the Contractor shall provide and mainlain until the conPracted work has been coonplePed and accepPed by Phe City of DenPon, Owner, Phe minimum insurance coverage as indicated hereinafter. As soon as practicable after notification of contract award, Conlraclor shall file with the Purchasing Department satisfaceory cerPificates of insurance including any applicable addendum or endorsements, conPaining the conPrace number and Pitle of the project. Contractor may, upon wriPeen requesP to Phe Purchasing DeparPment, ask for clarification of any insurance requiremenPs at any li`ne; however, Contraceors are strongly advised to make such requesls prior Po proposaUbid opening, since the insurance requirements may noP be modified or waived afier proposaUbid opening unless a wriPten excepPion has 8een suBmiPted with the proposaUbid. ConlracPor shall noP coonntence any work or deliver any maPerial until he or she receives noPification PhaP the cortlract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirerrtents shall comply wiPh the following general specifications, and shall be mainPained in compliance wiPh these general specificaPions throughouf Phe duraPion of the ConPract, or longer, if so noted: • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. • Any deductibles or self-insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. a Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. � That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. • CancellaPion: City requires 30 day written notice should any of the policies described on the certificaPe be cancelled or malerially changed before the expiraeion date. 54 • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. . Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. . Concerning the insurance to be furnished by the Contractor, it is a condition precedent to acceptability that: �>> All policies must comply with the applicable requirements and special provisions of Attachment A. (2) Any policy evidenced by a certificate of insurance or submitted for review shall not be subject to limitations, conditions or resteictions deemed inconsistent with the intent of the insurance requirements set forth herein, and the Owner's decision regarding whether any policy contains such provisions, contrary to this requirement, shall be final. • The Contractor agrees to the following special provisions: (1) The Contractor hereby waives subrogation rights for loss or damage to the extent same are covered by insurance. Insurers shall have no right of recovery or subrogation against the Owner, it being the intention that the insurance policies shall protect all parties to the Contract and be primary coverage for all losses covered by the policies. This waiver of subrogation shall be included, by endorsement or otherwise, as a provision of all policies required under Attachment A. (2) Insurance companies issuing the insurance policies and the Contractor shall have no recourse against the Owner for payment of any premiums or assessments for any deductibles, as all such premiums and deductibles are the sole responsibility and risk of Contractor. (3) Approval, disapproval or failure to act by the Owner regarding any insurance supplied by the Contractor (or any Subcontractors) shall not relieve the Contractor of any responsibility or liability for damage or accidents as set forth in the Contract Documents. The bankruptcy, insolvency or denial of liability of or by the Contractor's insurance company shall likewise not exonerate or relieve the Contractor from liability. (4) The Owner reserves the right to review the insurance requirements of this Attachment A during the effective period of this Contract and to modify insurance coverage's and their limits when deemed necessary and prudent by the Owner's Risk Management Division, based upon economic conditions, the recommendation of professional insurance advisors, changes in statutory law, court decisions or other relevant factors. The Contractor agrees to make any reasonable request for deletion, revision or modification of particular policy terms, conditions, limitations or exclusions (except where policy provisions are established by law or regulation binding upon either party to this Contract or upon the underwriter of any such policy provisions). Upon request by the Owner, the Contractor shall exercise reasonable efforts to accomplish such changes in policy coverage's and shall pay the cost thereof. F�7 (5) No special payments shall be made for any insurance policies that the Contractor and Subcontractors are required to carry; all are included in the stated Contract value. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or oblained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be ►naintained in compliance with these additional specificaPions throughout the duration of the Contract, or longer, if so noted: [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability Form (ISO Form CG 0001 current edition) is used: • Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury, • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: Bodily injury and Property Damage Liability for premises, operations, products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non-owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a$500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named [nsured. For building or construction projects, the Contractor shall comply with the provisions of Attachment ] in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). 56 [] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at ]east $500,000.00 combined bodily injury and property damage per occurrence with a$1,000,000.00 aggregate. [] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than _ each occurrence are required. [ ] Professional Liability Insurance Professional liability insurance with limits not less than $1,000.000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. 57 [ ] Builders' Risk Insurance Builders' Risk Insurance, on an All-Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. [ ] Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside/outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a"blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required. [ ] AdditionalInsurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. [ ] Umbrella Liability Insurance Depending on the size of the project, the City may require the Contractor to obtain, pay for, and maintain umbrella liability insurance during the Contract term, insuring Contractor for an amount of not less than $3,000,000 per occurrence combined limit for Bodily Injury (including death) and Property Damage, that follows form and applies in excess of the primary coverage required hereinabove. The Owner and Engineer shall be named as additional insureds using the broadest form of endorsement available, with such status extended to include the extension of the completed operations coverage as described in this Attachment. The policy shall provide "drop down" coverage where underlying primary insurance coverage limits are insufficient or exhausted. 58 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ("certificate")-A copy of a certificate of insurance, a certificate of authority to self-insure issued by the commission, or a coverage agreement (TWCC-81, TWCC-82, TWCC-83, or TWCC-84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's/person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ("subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner-operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food/beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and fling of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certifcate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providir�g services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. 59 F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certifed mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: l. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certifcates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually reyuire each person with whom it contracts, to perform as required by paragraphs (1) -(7), with the certificates of coverage to be provided to the person for whom they are providing services. so By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self-insured, with the commission's Division of Self-Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. 61 1 It `c " Bond��3375534 �TAT� i�� 'r'� � § • . KNOV�T ALL MEN BY THESE PRE�ENTS: That Durable �pecialties, Inc.�hose address is2302 Paddock Way Dr Grand Prairie TX* hereinaffer called Principal, and Great erican Tnsurance Compan-� ,of New Yark corporat�on organized and exisiing under the laws of the Siaie af r� ,�nd fully autharized to transact business in the Staie of Texas, as Suret�/, are held and f ly bound unto tne City of Denton, a mLmicipal corparaiion arg 'zed and existing under the la�xrs af the State af Texas, hereina r cailed Own�r, in the penal sum of Two Hundred and Fifty Thousand d no/1QQ DdLL 250,Q00.0(�in lavF�fial money of the United �tates, to be paid in Denton County, Texas, for the paymeni of which sum well and truly ta be made, we hereby bind aurselves, our heirs, executors, administraiars, successors, and assigns, jaintly d sev�rally, f y by these presents. This Band sha1l autamatically be increased by the o t af any Ch ge Order or Supplemental A�°eemeni; wh�ch increases the Caniract price, but in na e�Tent sha11 a Ch ge Order ar Sup�lemental Agreement, vlhich reduces the Contract pr�ce, decrease the penal s of this Band. *7saso T OBLIGATION TO PAY S rIE is candiiioned as fo1lo�Ts: ereas, the Principal entered inta a certain Cantract, fdent�iied by Ordin�r��.�. I� �.��-��r ?�? ��-- ��89, with the City af Denion, the O er, dated the 1 day af April A.D. '{.� I��,` a c-c�� ` �� is hereto attached d made a p hereof, for P# 5442 Construction u� ��`��'�� t�� z-�c:c��c��.�. � . � _ . .� " + . � _ _ . � - ♦ � # ; + , .. �;, , � ! - + - . _ # . _ . r + - � - - � _ * - - . � . ,� . � _ . # . . .�� -,� . � ° . � �- . • � � . ° � r� . - , ■ . • -� +� , , � • . . . . - � • . � . --r - -' • - , - � � . . . � � r ill � �. I. �. / I . J � � � *� �': � _! .•.. � a � �.. # ! _ �, . � � r � _ . .. � , . . � . .� * ' + .. .. i ' � ! " �' + ' � • ii ' � . i . ' ' * • + �, � . . � r PROVIDED FURTHER, that if any legal action be frled upon this Bond, exclusive venue shall lie in Denton County, State of Texas. AND PROVIDED FURTHER, that the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the Work to be performed thereunder, or- to the Plans, Specifications, Drawings, etc., accompanying the same, shall in anywise affect its obligation on this Bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract, or to the Work to be performed tl�ereunder, or to the Plans, Specifications, Drawings, etc. This Bond is given pursuant to the provisions of Chapter 2253 of the Texas Govemment Code, as arnended, and any other applicable statutes of the State of Texas. The undersigned and designated agent is hereby designated by tl�e Surety herein as tlie Resident Agent in Denton County to whom any requisite notices may be delivered and on whom service of process may be had in matters arising out of such suretyship, as provided by, Article i.19-1 af the Insurance Code, Vernon's Annotated Civil Statutes of the State of Texas. TN WITNESS WHEREOF, this irt�t��ent is executed in four copies, each one of which shall be deemed an original, this the I day of April, 2014. ��'� ATTEST: � � BY: ...��.�..�... _...e�. w�� .� SECRETARY ATTEST: ,, BY � ,� � ��'��`° : �., � ,�.. � �` .�� -� �� ........�. PRINCIPAL l��r��si-�1 �; �t��,��.a�s. it�c. B � : u ..._ ° E, �� t4'`� . SURETY Great American Insurance Ca��any ��.....�. w....__m � ._�,, : : �a York ATTO��+,�-II�r�A�'"�" Jack M Crowley The Resident Agent of the Surety in Denton County, Texas for delivery of notice and service of the process is: NAME: �niith�aa�t AG.G11YAnra ('�rn7�� Tnr �_ / Rret Tnml in�nn _.��..�.�.�. � ��. � ��-�.� --_ �... �..,_. STREET ADDRESS: 124 Old Town Blvd. ,��200, Ar�y�e T�,,,, 7F226 ___ _._... -�� . (NOTE: Date of Performance Sond must be date of Contract. If Resident Agent is not a corporation, give a person's name.) 63 � �H `��"� „E� . �; ��'��r ' a ,,+',,:^ �� - �4.,n�� GREAT AMERICAN INSURANCE COMPANY OF NEW YORK �.��` New York Administrative Office: 301 E 4TH STREET • CINCINNATI, OHIO 45202 • 513-369-5000 • FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than FOUR No. 0� 9950 POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY OF NEW YORK, a corporation organized and existing under and by virtue of the laws of the State of New York, does hereby nominate, constitute and appoint the person or persons named below its true and lawful attorney-in-fact, for it and in its name, place and stead to execute on behalf of the said Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof; provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not �xc��r3 the limit stated below. P��m� Address Limit of Power JACK M. CROWLEY �,�� PATRICIA A. SMITH ALL OF ALL STEVEN R. FOSTER MARIE PERRYMAN ADDISON, $75,000,000.00 TEXAS This Power of Attorney revokes all previous powers issued on behalf of the attorney(s)-in-fact named above. IN WITNESS WHEREOF, the GREAT AMERICAN INSURANCE COMPANY OF NEW YORK has caused these presents to be signed and attested by its appropriate officers and its corporate seal hereunto affixed this 29TH day of NovEMBER , 2012 , Attest ��",�` �`� fI,/qOx�lAfy�y.. �µ�:Y � �i �.. . �"� ':w�.= .....� A.rsi,slan! Secrelaiy GREAT AMERICAN INSURANCE COMPANY OF NEW YORK Divisional Senior �ce Presiden! DAVID C. KITCHIN (877-377-2405) STATE OF OHIO, COUNTY OF HAMILTON-ss: On this 29TH day of NOVEMBER , 2012 , before me personally appeared DAVID C. KITCHIN, to me known, being duly sworn, deposes and says that he resides in Cincinnati, Ohio, that he is a Divisional Senior Vice President of the Bond Division of Great American Insurance Company of New York, the Company described in and which executed the above instrument; that he knows the seal; that it was so affixed by authority of his office under the By-Laws of said Company, and that he signed his name thereto by like authority. *' �� • KAREN L. GROSHEIM '�� `' f� NOTARY PUBLIC, STATE OF OHIO �*� � MY OOMMI8810N ExPIRES oa-2ai6 £,,F This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company of New York by unanimous written consent dated May 14, 2009. RESOLVED: That the Divisional President, the several Divisional Senior Vice Presidents, Divisional Vice Presidents and Divisional Assisfant Vice Presidents, or any one of them, be and hereby is authorized, from time to time, to appoint one or more Attorneys-in-Fact to execufe on behalf of the Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof,• to prescribe their respective duties and the respective limits of their authority,• and to revoke any such appointment af any time. RESOLVED FURTHER: That the Company seal and the signature of any of the aforesaid officers and any Secretary orAssistant Secretary of the Company may be affixed by facsimile to any power of attorney or certificate of either given for the execution of any bond, undertaking, contract of suretyship, or other written obligation in fhe nature thereof, such signature and seal when so used being hereby adopted by the Company as the original signature of such officer and the original seal of the Company, to be valid and binding upon the Company with the same force and effecf as though manually affixed. CERTIFICATION I, STEPHEN C. BERAHA, Assistant Secretary of Great American Insurance Company of f��r Yr�r°k, do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of May 14, 2009 I�ravrr r��fi been revoked and are now in full force and effect. Signed and sealed this 1 st day of April , 2014 �_'` �*� � �fG4�itlaug1�.. 4 SEAL�+� ��u. � '�*';!�" si i eai (a/i � ) A,s.ci.rlanl Secrela�y , j" � �'" � � } 4��4 1 4��a � �i{ � � Ib 66 79 8 �� ° � �ond��3375534 �TA"IE C?F T'E S GC}�T,rT�' C3F DE?erTQl`�T Q�J L � Bi' S�, P SE:[�7'�: �`h�t L�urab)e S�ecialties. �SC.;��uhose addr�ss is � a.�:? T'��3t,1��.��.�.�� l..a�,�7e.. {�a7°��u P��-��.� �� ...... 7505Q, here�aaft�r called Pri��i�aai; az�d Great �rican Insuranc� Co of <�, a corparatian or�aniz�r� �d ��stixz,� u�d.er �e l�ws af the Sta.te af Tex�s, d fuily �ui�°Aarized to tr sact b�xsi�ess i.n the State c�f Tex�s, �s S ety, � held �nd f Iy bc�und unta ihe C'rty af T3�n�ar�; a mur�ic�pai carpordtiaz� or�aniz�d ° d e�stin� u�d�r t1�e ia��s af� f1�� tai� af Texa.�; l�ere�rsaEter called O��r, d ta �II per�ons, fir�s, C� C%CiI�)C�S'a.�i0L15 Viiho �ay 'sh ma�erials for, or pez°fr� labc�r upor�, ihe buzldin� c�r ` prc�v��ents �iere�safier referred ta, in ihe p�xa�l surn �f T'�c� :E�undred and F'ifty T��us• d d�0/l00 L�(�LL. S(�250,U00.00} ziz ia 1 maney of� �h� U`t�d S�at�s, to be �aid it� L��ton, Cc� ty, T�x�s, fc�r �e pay�caent of vrh��h s we11 d ty to be m�de, we hereb� bind �urseiv�s, c�ur heirs, �x�c�atc�rs, � za�s�a�ars; s�ccessc�rs, d a.ssi� s, ja' tly d sev�rally, farmIy �ty i�es� presents. T`�is 13ond sraall autornatically be iracr��sud by the c�uslt of r y Cn�n�e Clyder crr Sup�le�s�ezltal P��reerne�t w�iic�l zra�reases �e Cantx°aci price, but in s�o e�jent s�ZaII a Ch �e C�rd�r or S�.ppl�r��r�t�l A�ree��nt �rh�ch reduces the Ccs�ir�ct �r�ce a�cre�se the pe�dl s�rn of this �car�d. T C�BL�CaAT�C3N '�C9 PAY 5 � is candrti�r�ed �s fc�lla�us: ere�s, ti�Ae �' � cipal en�ered '�:o � certt�in Ct�n�ract, iC��ifltL�flPd �J�r r._x��-��j��:;1 N ber 2014- Q89, �xrith th� Ci�gt of��e�a�:ara., the C9��er, c��ii�.� iLi}ti= 1�� G,.�.��ri.] .�;..L7 �"�);; ��.,�'�;c��,� t�i"�=��ac:b i� I�v�-ti��, a° c]�ed d zza�de a p h�reof for F'� ��v'-i�x7;is�°L�i�ll+:�il �.l �i'��:�Z�� ..;C7�gl.i"i�a �:i.d�t�i`s`�,��9C??1s �OW, �� , if�tl�� P'�ipa1 sh�Il r��ll, iy d faz � 1}3r p�rfa gts ciutaes d�ake �rc� pt �Sayment to aI1 parsa�s, f s, stabcc�ntr�ctars, carpc�r�tac�ns d cIa° ts s�ppi�P� g l�bar� ° dlcsr �saieraa.l ir� Y�he �rasecu�ia�t of ih� Wor� �r��Tided far � said Ca�tra.at d y° d all duly �uihcsrized rrcadific�tions crf said Gant��ct �a�.t �y b�r�aiier be nzade, �at�ce �f wh�ch x�e�difacations te� the �tireij, be' g��reb�= e�pressly s�raiv�d; ihe� °s c�bli�atac�� slaa�Il be vaid; c�ther�rise pt s�alI re a�n i� fu�I force d eif�r�. ��2.0 ED F� ,12, tt��t rf �ny �e�al �ci��n be fi1�d on �h.�s Bonc� ��cl�sr�e �pen�e s�all li� irs l��ni:c�r� Co ty, Te��s. # 1 . � . � _ . ° � -♦ . .�� fr•° _ � ��- . �. � •�� . ��r � �� .�_� �• - �� ... �� }. ' �,, .: �. ,.,. y #� r 1��.. ��. r �1... • i I �� . 11 " � �,.. • �� .. � . „ � _ +, � I �! i , i# /" . ^ # / .1' il�*. . a �� . �... �.�. �. �- ° •.. .. _ �� .:�� i w ...: . �,,. - ��. �.. � .. This Bond is given pursuant to the provisions of Chapter 2253 of the Texas Govemment Code, as amended, and any other applicable statutes of tl�e State of Texas. The undersigned and designated agent is hereby designated by the Surety herein as the Resident Agent in Denton County to whom any requisite notices may be delivered and on whom service af process may be had in matters arising out of sucl� surety, as provided by Article 7.19-1 of the Insurance Code, Vernon's Annotated Civil Statutes of the State of Texas. IN WITNESS WHEREOF, this insti•umes�i ��,-�xecuted in four copies, each one of which shall be deemed an original, this the ] day of April, 2014. --��''� ATTEST: BY: ,�,'' SECRETARY � PRINCIPAL �_� °�t�i�: ��c�i�l��:�, ia7c, �. �-- !,, .r�. B . _ l', .�. i1:3'°; -�` ATTEST: SURETY: ��,�.. , � n� �� .� � w�. , x-y�� ' G�s�.:� ��:7�T,�7�rs��r,•yr�f �' � e��T��'.tiaT York � , .� � ' BY< ,�� .�� ;,�f � � � �_. .�� ,� $Y� � ��' � ��fi,�,� �� . , �, �� ,,.� n � . ; A`i'�'�?�;��:Y-IN-FA4�"�T .. ��c: �-��,t �y � � � �� T�.�� The Resident Agent of the Surety in Denton County, Texas for delivery af notice and service of the process is: NAME: Southwest Assurance Group, Inc./ Bret Tomlins_on STREETADDRESS: 124 Old Town Blvd., i�200, Ar�vle, TX�76226 (NOTE: Date of Payrner�t Bond rnust be date of Contract. If Resadent Agent is not a corporation, gave a person's nanze.) 65 � °�� , , t r. � s, %�f` "�r �,�,b,,��,, e:,.w� GREAT AMERICAN INSURANCE COMPANY OF NEW YORK�t,a��'� New York Administrative Office: 301 E 4TH STREET • CINCINNATI, OHIO 45202 • 513-369-5000 • FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than FOUR No. 0 19950 POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY OF NEW YORK, a corporation organized and existing under and by virtue of the laws of the State of New York, does hereby nominate, constitute and appoint the person or persons named below its true and lawful attorney-in-fact, for it and in its name, place and stead to execute on behalf of the said Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof; provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not �xtY¢ec� the limit stated below. �l�r�i� Address Limit of Power JACK M. CROWLEY��'� PATRICIA A. SMITH ALL OF ALL STEVEN R. FOSTER MARIE PERRYMAN ADDISON, $75,000,000.00 TEXAS This Power of Attorney revokes all previous powers issued on behalf of the attorney(s)-in-fact named above. IN WITNESS WHEREOF, the GREATAMERICAN INSURANCE COMPANY OF NEW YORK has caused these presents to be signed and attested by its appropriate officers and its corporate seal hereunto affixed this Z9TH day of NOVEMBER , 2012 , Attest GREAT AMERICAN INSURANCE COMPANY OF NEW YORK ��"bw �iznpbnatt� . , . SEAL;�" �� "� Assisranr Secrelary Dit�isional Senior Uce Presrden! DAVID C. KITCHIN (877-3774405) STATE OF OHIO, COUNTY OF HAMILTON-ss: On this 2sTH day of NOVEMBER , 2012 , before me personally appeared DAVID C. KITCHIN, to me known, being duly sworn, deposes and says that he resides in Cincinnati, Ohio, that he is a Divisional Senior Vice President of the Bond Division of Great American Insurance Company of New York, the Company described in and which executed the above instrument; that he knows the seal; that it was so affixed by authority of his office under the By-Laws of said Company, and that he signed his name thereto by like authority. � `� KAREN L. GROSHEIM '�y�°`�'` NOTARY PUBUC, srat� o� oHio � MY GOMM18810N Ex�IRES o�-2o-ie .�_. p �' This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company of New York by unanimous written consent dated May 14, 2009. RESOLVED: That the Divisional President, the several Divisional Senior Vice Presidents, Divisional Vice Presidents and Divisional Assistant Vice Presidents, or any one of them, be and hereby is authorized, from fime to time, to appoint one or more Attorneys-in-Fact to execute on behalf of the Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof,• to prescribe their respective duties and the respective limits of their authority; and to revoke any such appointment at any time. RESOLVED FURTHER: Thai the Company seal and the signature of any of the aforesaid officers and any Secretary orAssistant Secretary of the Company may be affixed by facsimi/e to anypower of attorney or certificate of either given for the execution of any bond, undertaking, contract of suretyship, or other written obligation in the nature thereof, such signature and seal when so used being hereby adopted by the Company as the original signature of such officer and the original seal of the Company, to be valid and binding upon the Company with fhe same force and effect as though manually affixed. CERTIFICATION I, STEPHEN C. BERAHA, Assistant Secretary of Great American Insurance Company of New York, do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of May 14, 2009 have w�nt ta�en revoked and are now in full force and effect. Signed and sealed this lst day of April , 2014 `�-�r� � �� t,�� '� :�„� �* siiesi�aiii> A.s,ri,slan� Sea�clary � �'' '�` � {' �-s� � �.� . !!v � �ry ...._.-�,°°.�.g. -- � �� .� �� w�� iNSURANCE GROUP 1'!' � i ! ' - � i. + • - � E � r :. .�� . � t�.R i. .fI ! �,:.: ` . �.�...�i l.�. Yau may contact the Texas Departmeni af Lnsurance to obtai� infar�atian on companies, coverages, rights ar camplaints at: :; .: �i�a 1• ... ,...b ��i�.: ■� ri ��` .�:� PoC9. Box 149104 Aust�, TX 7 � 714�-9104 � #1-512-475-1771 �� • . �■ . ��.� r .��. �- a� .� - � �• _ #n�.� � � -� � . �� , � - _ ■ . �- � , ■ � ' +� - Great American Insurance Cornpany Claim P.O. Box 2575 Cinc` ati, Ohia 452Q1-2575 Physz�al Address: Great ericaa Ins�z.rance Cornpany Ciaim 580 Walnut Street 7th Floar C' c` ati, Ohio 452Q2-31$0 • � ti� . . �� • r . , t . . . ' +�� - . � � . � � - �r � � M� �� - � � � � Telepha�� Number: 1-513-369-5064 CL IS LTT S: , . - � . � .. . � . •., .� � . .. . . _ . w. . •...��,�_ .�.� ��. .�� '# i 1y�.�.. � t.�:' lf�1��.: � �-.! .•. i� • ��. . .M/ ,+ �: . � ..�, ' � .. � � " i + 11i� ' � ��; i . �: ;. �: +.._ _ _ .. #_ _ 4i �' ':�. �! � '�... * e !, �.' �'.. ,�. 'I°his notice is far i�.farmation o�ty and does not becorne a part ar condition of the attached doc e�t � . , uRQB�.E pEC'Q�.T'ES, 'NC. Exhibit "F" P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 � ■ �' . � i � � � � � � � ' �' � _ �' � � � , �; + . * � 1 P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-7411 ! � • � , r ' � i � � � � ' � • It is Dw�ablc Specialties, lnc. ui�derstanding we will be providing a turnkey construction of ncw tratlic signals, modiiication to cxisting tral7ic signals and span wire traftic signal installations. Pavement markin�s to be perl��rmed by others. • Installation of traf�iic signals will be on a work order basis with a work. •'The contract is for one ycar with an option tor rcnewal after one year. •"l�he goal is to perform installation of traffic signals in a timely manncr and to the standards and expectations of the City of Denton. • The unique and long lead items will be supplied by tlie City of Denton; i.e. controller cabinets, vehicic detection equipment, preemption equipmcnt, communication equipment, su►•veillance equipment, signal housings & LEDs, traffic signal pole assemblies and etc. • Durable Specialties, [nc. will supply the concrete, conduit, wire, cable, pul] boxes, signal head mounting ha�•dware, sign mounting hardware, electrical services, wood poles and down guys whcre indicated by their corresponding pay item. DElC)2GG1 l f71:ti'I'(i\ \'OV 51'I I:: S'fA'C�VIFi\'"f OF fFIE CO\'1'RACiORS I:�DFifZS'CA\'I�I\Ci (7F 7l{I: PItU.ILC.I. 68 � " .:�� . � P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 � � , � � � � � Or�anization n. Dui•able Specialties, ]nc. Physical Address: 2 i02 I'addock Way llrive (irand Prairie, "I'X 75050 Vlailing Address: I'O BOX 535969 Grand Prairie, TX 75053-5969 B. Durable Specialties, Inc. has been in business since 1984 �ls a traflic signal conti•actor providing turnkey trafiic signal installation for \�orth "I'exas Vlunicipalities and `1�xDot. C. Business Profile; 1) Corporation 2) }:stablished in 1984, 30 years doing business 3 ) 65 �mployees 4) Specializing in tratfic signal installation 5) 972-296-6324 I'hone; 972-780-7411 Fax � 6) 30 Years in business 7) \ot npplicable 8) Single office location 9) Single office location 10) We pravide turnkey tral�ic signal installation and own all of ow» equipment to prc�vide this service. 1 I} Drew Shipman; 817-401-3070 Cell; drew �r>durablespecialties.com Attached is our previous work cxpericnce and rel`crenccs. ui:vozoc,ia nE:� ro` ��ov srri:; nsi oiicn�izn'i io� 69 E� � 0 S S E 5 � 0 I ' ' I � Exhibit °'F" __ P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 . �z� - . t�cri�;-��v . . _- - � MAJOR CONTRAC7S 2007 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED AMT � _._�..�.......� 215,250.00 TRAFFIC SIGNAL �w�� 2007/702 AUSTIN 183A - TURNPIKE 219,500 00 TRAFFIC SIGNAL SYSTEM UPGRADE 102,750,00 TRAFFIC SIGNAL 357,900 00 ADAPTIVE CONTROL SIGNAL SYS 120,921.50 TRAFFIC SIGNAL 122,750.00 TRAFFIC SIGNAL 206,150.00 TRAFFIC 51GNAL 107,500.00 TRAFFIC SIGNAL 201,14920 TRAFFiC SIGNAL KF �� l� I#� i i � i �: 7_l 7� C� I.9 [eI ► I I � S 4,234,419 95 TRAFFIC SIGNAL E � � F� 299,800,00 TRAFFIC SIGNAL 397,350 00 TRAFFIC SIGNAL 103.600.00 TRAFFIC SIGNAL 117,300.00 TRAFFIC SIGNAL IMPRVTS 2d07/704 CITY OF DESOTO VARIOUS LOCATIONS 2007/706 GRAND PRAIRIE DORYN DR. & MAGNA CARTA 2007l708 TYLER US 69 2007/710 SEAGOVILLE DIVIDEND DR. & POINT WEST BLVD 2007/711 DENTON FM 407 2007J712 DALLAS N. GALLOWAY AVE TO BELTLINE RD 2007/714 WISE FM 51 & PRESKITT RD 207/720 TARRANT IH 30 & CENTER ST 2007/721 TARRANT SH 199 2007/723 DALLAS VARIOUS LOCATIONS DART- CMGC-3 LINE NW-2, NW3, NW-4 2007/725 DALLAS NAAMAN SCHOOL RD NAME AND ADDRESS MICA CORPORATION PO BOX 161609 FT WORTH, TEXAS 76161 CITY OF DESOTO 211 E PLEASANT RUN RD DESOTO,TEXAS75115 SPRING VALLEY CONSTRUCTION 10950 ALDER CIRCLE DALLAS. TEXAS 75238-1359 CITY OF TYLER Pd BOX 2039 TYLER, TEXAS 75710 DUKE CONSTRUCTION 5495 BELTLINE RD #360 DALLAS, TEXAS 75254 ED BELL CONSTRUCTION PO BOX 540787 DALLAS, TEXAS 75354-0787 REBCON, INC. 1868 W. NORTHWEST HWY DALLAS,TEXAS75220 TXDOT-TARRANT PO BOX 6868 FT. WORTH, TEXAS 76115 MICA CORPORATION PO BOX 161609 FT WORTH. TEXAS 76161 MICA CORPORATION PO BOX 161609 FT WORTH, TEXAS 76161 ARCHER WESTERN 2121 AVENUE J, #103 ARLING7dN, TEXAS 76006 TRI-CON SERVICES, INC 3010 W MAIN ST. ROWLETT, TEXAS 75088 2007l729 WEATHERFORD ED A WILSON MAIN ST - DOWNTOWN PO BOX 11423 FT WORTH, TEXAS 76110-0423 20d7l732 PLANO - VARIOUS LOC JIM BOWMAN CONSTRUCTION 1111 SUMMITAVE, #1 PLANb, 7EXAS 75074 2007/735 HOLLAND RD & BROAD L H LACY CONSTRUCTI(?N STREET P(7 BOX 541297 DALLAS,iEXAS 70 . �, � � � � 1 P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 --- ----- t�� a�t�� , �t� �; _tv� . _ MAJOR CONTRACTS 2007 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND AM7 ADDRESS . �.._. _.m, _. _w,...�P_. $ 136,715,00 T�l��[C �[�NAL MODIFY 2007/737 LUNA RD � VI�LL�Y 4"IE1N� JFG CONCFtS��'TE, 16��";,. (RACETRAC) PC7 BOX 550 PRINCETON, TEXAS 75407 $ 164,000,00 TRAFFIC SIGNAL 2007/739 SH 170 & PARK VISTA CITY OF FT. WORTH 5001 JAMES AVE, #301 FT WORTH, TEXAS 76115 � 123,3Qd.00 TRAFFIC SIGNAL 2007/743 AMARILLO BLVD & BRAD DRAKE CONSTRUCTION LOWES LANE 3737 LAMAR AVE, #700 PARIS, TEXAS 75462 S 666,720 00 TRAFFIC SIGNAL 20d7/744 MOCKINGBIRD LANE GIBSON & ASSOCIATES, INC PO BOX 80d579 BALCH SPRINGS, TEXAS 7518Q 5 101,000.00 TRAFFIC SIGNAL 2�07/745 BU 287P & FM 157 TXDOT - TARRANT PO BOX 6868 FT. WORTH, TEXAS 76115 � S 117,453.00 STREET LIGHTS/ TRAFFIC SIGNALS 462,568.80 TRAFFIC ISIGNALS $ 2,835,QOd.00 TRAFFIC SIGNALS � � � � 254,500.00 RECONSTRUCT TRAFFIC SIGNALS 334;800.00 TRAFFIC SIGNALS 369,165.00 TRAFFIC SIGNAL IMPROVEMENTS 2007/746 TCCD SOUTH CAMPUS CAMPUS & JOE B RUSHING 2007/751 FM 2499 r�� :1 2007l757 VARIOUS LOCATIONS 20071761 EXCHANGE PKWY T1NIN CREEKS & SH 121 ROEBUCK CONCRETE CONTRACTORS PO BOX 301 FT, WORTH, TEXAS 76101 MICA CORPORATION PO BOX 161609 FL WORTH, TEXAS 76161 7XDOT-TYLER 15986 5H 155 TYLER, TEXAS 75703 CITY OF WACO PO BOX 2570 WACO, TEXAS 76072 LACY CONSTRUCTION PO BOX 541297 DALLAS. TEXAS 75354 20071762 SHADY OAKS & BRINKER LACY CONSTRUCTION PO BOX 541297 DALLAS, TEXAS 75354 929,807.02 TRAFFIC SIGNAL 2007/763 IH 30 INSTALL m i•'!•• • •• :• .t� *. . , �; + � � � 1 P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 MAJOR CONTRACTS 2008 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND AMT ADDRE3S S 644,378 30 TRAFFIC SIGNAL 2008/801 PAN7HER CREEK PKWY mm MARIO SINACOLA & SONS IMPROVEMENTS AND LEGACY DR. PO BOX 2329 CITY OF FRISCO FRISCO, TEXAS 75034 S 103,400.00 TRAFFIC SIGNAL 2008/805 SH 198 TEXAS STERLING TXDOT KAUFMAN COUNTY 2100 N. HWY 360, #106A GRAND PRAIRIE, TEXAS 75050 S 130,375 00 TRAFFIC 51GNAL 2008/806 ROUTH CREEK PKWY L H LACY CITY OF ARLlNGTON PO BOX 541297 DALLAS,TEX575354 5 142,OQ0.00 TRAFFIC SIGNAL 2008l8Q7 BRIARGROVE TO REBCON NTTA RAILROAD NORTH TO 1868 W. NORTHWEST HWY PGBT DALLAS, TEXAS 75220 S 559,OOQ 00 TRAFFIC SIGNAL 2008/808 VARIC3US LOCA71C7NS CITY OF GRAND PRAIRIE 206 W. CHURCH ST GRAN PRAIRIE, TEXAS 7505d S 454:250 00 TRAFFIC SfGNAL 2008/809 PLEASANT RIDGE RD, L H. LACY CITY OF ARLINGTdN PO BOX 541297 DALLAS,TEXS 75354 5 111,000.00 TRAFFIC SIGNAL 2Q08/811 WINSCOTT RD. 8 OLD CITY OF BENBROOK BENBROOK RD/BECKMAN 911 WINSCOTT RD DRIVE BENBROOK, TEXAS 76126 S 413,022.00 TRAFFIC SIGNAL 2008/812 BELTLINE RD, ARAPAHO REBCON CITY OF RICHARDSON RD, CAMPBELL RD & COIT 1868 W NORTHWEST HWY RD DALLAS,TEXAS75220 � 379,290.00 TRAFFIC SIGNAL 2008/819 SH 360 @ SH 180(DIVISION MICA CORPORATION TXDOT TARRANT STREET) PO BOX 161609 FT WORTH, TEXAS 76161 S 420,483.00 7RAFFIC SIGNAL 2008/821 FM 2934 (ELDORADO MICA CORPORATION TXDOT COLLIN PKWY) PO BOX 161609 FT. WORTH, TEXAS 76161 5 651,165 00 TRAFFIC SIGNAL 2008/825 IH 30 TEXAS STERLING TXDOT DALLAS 2100 N. HWY 360, #106A GRAND PRAIRIE, TEXAS 75050 S 124,500.00 TRAFFIC SIGNAL 2008/826 5H 183 APAC-TEXAS, INC. TXDOT TARRANT PO BdX 1807 FT, WORTN„ TEXAS 76101 S 899,397.00 TRAFFIC SIGNAL 2008(827 FM 1 t71 GLENN THURMAN TXDdT DENTON PO BOX 850842 MESQUITE, 7EXAS 75185-0842 S 472,400 00 TRAFFIC SfGNAL 2008/828 STADIUM DR. - DIVISION JACKSON CC}NSTRUCTIC3N CITY OF ARLINGTON STREET TO RANDOL MILL 5112 SUN VALLEY DR ROAD FT. WORTH. TEXAS 76119 S 365,037.50 TRAFFPC SIGNAL 2008/829 MAYFIELD DR JACKSON CdNSTRUCTION CITY OF GRAND PRAIRIE 5112 SUN VALLEY DR FT WORTH. TEXA5 76119 72 L ' ' ' ' � Exhibit "F" .._ _ _. P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 MAJOR CONTRACTS 2008 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND AMT �� _..._.�._. _.. S 1 145,000 00 NON-SITE 2008/830 VARIOUS t C�G�TIC]h#� TXDOT - DALLAS TXD07 dALtAS PU BdX 133067 DALL4S, TEXAS 75313 S 656,000.00 TRAFFIC SIGNAL 2008/831 BARNETT RD & JOHNSON TXDOT - WICHIiA ROAD 16d1 SOUTHWEST PKWY WICHI7A FALLS, TEXAS 76302 S 328,000.00 TRAFFIC SIGNAL 2008/832 VARIOUS LOCATIQNS TXDUT - DALLAS PO BOX 133067 DALLAS, TEXAS 75313 S 125,600.00 TRAFFIC SIGNAL 2008I835 TEASLEY LN & HICKORY C D HENDERSON CITY OF DENTON CREEK 1985 FOREST LANE GARLANd, TEXAS 75042 S 398 600.00 TRAFFIC SIGNAL 2008/837 MOUNTAIN CREEK PKWY TEXAS STERLING TXDOT DALLAS 2100 N NWY 360, #106A GRANd PRAIRIE, TEXAS 75050 S 168,500.00 VIDEO DE7ECFION 2008/838 VARIOUS LOCATIONS CITY OF HALTOM CITY 4200 HOLLIS ST HALTOM CITY, TEXAS 76111 S 471,009.00 7RAFFIC SIGNAL 2008/845 GEORGE BUSH TURNPIKE MICA CORPORATION PO BOX 161609 FT WORTH, TEXAS 76161 S 167,192.13 TRAFFIC SIGNAL 2008/845 US 75 UNDERPASS @ MICA CdRPORATION TXDOT DALLAS PARKER RD PO BOX 161609 F7 WORTH, 7EXAS 76161 $ 98,800 00 TRAFFIC SIGNAL 2008t849 DENTdN TAP RD @ UNITED COMMERCIAL DEVELOPMENT CITY dF LEWISVILLE HIGHLAND DR. 7001 PRESTON RD ,#500 DALLAS, TEXAS 75205 S 148,700,00 TRAFFIC SIGNAL 2008/850 IH 20 (FM 3325/FM 1187) MICA CORPORATION PO BOX 161609 FT WORTH, TEXAS 76161 S 124,300 00 TRAFFIC SIGNAL 2008/852 BELKNAP ST & GRdVE ST. ClTY OF FT. WORTH GROVE ST. & WEATHERFCJRC 5001 JAMES AVE, #301 ST FT. WCIRTH, TEXAS 76115 S 383,500.00 TRAF'FIC SIGNAL 2008(856 FM 544 - WOODBRIDGE L. H. LACY CROSSING IMPRVMT PO BOX 541297 DALLAS. TEXS 75354 S 1,117,000 00 TRAFFIC SIGNAL 2008/857 IH 35E TXDOT - DALLAS PO BOX 133067 DALLAS, TEXAS 75313 S 302,000.00 TRAFFIC SIGNAL 2008/858 SH 121 - NTTA MIGA CORPORATION PO BOX 161609 FT. WORTH, 7EXAS 76161 73 , � � ! � � , ' 1 P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 __ t� _ �r , � - � _ MAJOR CONTRACTS 2009 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND AMT ADDRESS � � _. _..�._..___. ..... ..LL_, ._....,.�. _ $ 129,849.00 SIGNAL MODIFICATION 2009/901 W. 7TH & CURRIE ST. CONATSER CONSTRUCTION CITY OF FORT WORTH S 0 260,077.00 TRAFFIC SIGNAL TXDOT TARRANT COUNTY 302,700.00 TRAFFIC SfGNAL IMPRdVEMENTS S 1,098,700.00 TRAFFIC SIGNAL TXDOT DALLAS � � 367,900.00 TRAFFIC SIGNAL SYSTEMIMPROVEMENTS 149,000,00 7RAFFIC SIGNAL TXDC7T PARKER CdUNTY � 585,148.00 VITRUVIAN PARK PUBLIC INFRASTRUCTURE PHASE 16 TOWN OF ADDISON 5 471,658.40 INSTALL 4 NEW TRAFFIC SIGNALS S 122,660.00 STREETSCAPE IMPROVEMEN75 CITY OF DALLAS S 315,517.00 0213-PGB-06-CN-EN SECTIdN XXXI NTTA S 482,330,00 TRAFFIC SIGNAL DALLAS COUNTY S 122,820 00 TRAFFIC SIGNAL F� S S 121,120.00 INTERSECTION IMPROVEMENTS 149,505,00 TRAFFIC SIGNAL TXDOT DALLAS 150,700 00 TRAFFIC SIGNAL CITY OF HURST S 1,016,43520 REVERSIBLE LANE SYS 5327 WICHITA ST. FT WORTH, TEXSA 76102 2009/902 IH 20 (GREAT SOUTHWEST MCMAHON CONTRACTfNG PARKWAY) PO BOX 153066 IRVING, TEXAS 75015-3086 20091904 VARIOUS LOCATIONS CITY OF NORTH RICHLAND HILSS 7200 A dICK FISHER DR. S NORTH RICHLAND HILLS, TEXAS 76182-0609 2009/906 L(70P 12 MICA CORPORATION PO BOX 161609 FT. WORTH, TEXAS 76161 2009/910 VARIOUS LOCATIONS TOWN OF ADDISON PO BOX 9010 AbDISON, TEXAS 75001-9010 2009/911 SH 171 PRATER EQUIPMENT Cd , INC Pd BC3X 746 CQMANCHE, TEXAS 76442 2009/914 VITRUVIAN PARK NdRTH TEXAS CONTRACTfNG PO BOX 468 KELLER,TEXAS 76244 2009/915 VARIOUS LOCATIONS CITY C1F ALLEN 305 CENTURY PARKWAY ALLEN, TEXAS 75013-8042 2009l916 ELM ST - FROM AKARD TO TEXAS STANDARd CONSTRUCTIC7N ERVAY PO BC7X 210768 DALLAS. TEXAS 75211 2009(918 SQUTH dF MAIN ST Tb MlCA CORPORA710N NORTH OF SHOR OF LAKE PO BdX 161605 RAY HUBBARD FT. WORTH, TEXAS 76161 2009/919 BELTLINE RD Td CASH CONSTRUCTION CO , INC.. WHEA7LAND RD. Pd BbX 1279 FLUGERVILLE, TEXAS 78691 2009(920 DEBBIE LANE @ BEN CBTY OF MANSFIELd BARBER ACADEMY 1200 E BROAD ST, MANSFIELD, TEXAS 76063 20091921 SARA JANE @ GREAT MCMAHON CONTRACTlNG SOUTHWEST PARKWAY PO BOX 153086 IRVING TEXAS 75015-3086 2009/922 FM 1382 REBCON, WC 1868 W NORTHWEST HWY DALLAS, TEXAS 75220 2009/924 W PIPELINE RD @ AUI CONTRACTORS FUTURE RD 4775 N FREEWAY FT. WdRTH, TEXAS 76106 2009/927 ROAD TO SIX FLAGS, C6TY OF ARLINGTON COLLINS � DIVISON ST 1011 W. MAIN ST. ARLINGTdN. TEXAS 76013 74 , ■ 1 � ! ■ � '' � P.O. BOX 535969 � GRAND PRAIRIE, TX 75053-5969 • PHONE 1-97z-296-6324 • FAX 1-972-780-741 1 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRAC7S 2009 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND AMT ADDRESS �.. _ .�.. �_,., S 169,819 45 INTERSECTION IMPRVTS 2009/929 TOWN EAT BLVD & NORTH JIM BOWMAN CONSTRUCITON` PHASE 1 B GALLOWAY AVE 1111 SUMMIT AVE, #1 PLANO, TEXAS 75074 S 233,OOOAO TRAFFIC SIGNAL INSTALL 2009/930 FM 1378 & COUNTRY CLUB L H. LACY COMPANY, LTD. DRIVE PO BOX 541297 DALLAS, TEXAS 75354-1297 S 590;113.80 TRAFFIC SIGNAL INSTALL 2008/931 RIDGEVIEW DR. & ALMA CITY CYF ALLEN AT 4 LOCATIONS EXCHANGE PKWY & 305 CENTURY PARKWAY RIDGEVIEW DR ALLEN, TEXAS 75013 RIDGEVIEW DR & WALNUT SPRINGS DR. EXCHANGE PKWY & TWIN CREEKS DR $ 128,807.50 TRAFFIC SIGNAL INSTALL 20091937 SH 289 & LEGACY DR MICA CORPdRATION E S � 241,150.00 RED OAK RD STREET & 2009/940 RED OAK RD & VARIOUS UTILITY IMPROVEMENTS LOCATIONS 469,000.00 TRAFFIC SIGNAL INSTALLTATION 102,000 00 TRAFFIC SIGNAL INSTALLATION 2009/944 VARIOUS LOCATIONS 20091946 US 1 BO & TOWN CREEK & UPPR (WB & EB) 75 PO BOX 161609 FT. WORTH, TEXAS 76161 XIT PAVING & CONSTRUCTION 3934 S, HWY 287 WAXAHACHIE, TEXAS 75165 CITY OF FT. WORTH 5001 JAMES AVE, #301 FT. WORTH, TEXAS 76115 MICA CORPORATION PO BOX 161609 FT WORTH, TEXAS 76161 , �,, � : ' � � , ' I 1 P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2010 CON7RACT SCOPE OF WORK YEAR1J06 # LOCATED NAME AND AMT ADDRESS ..... __ .. .._._. � � a �. .�w.....� 5445,380.00 TRAFFIC SIGNAL INSTALL 2010/001 VARIOUS LOCATIONS CITY OF FT. WORTH 5001 JAMES AVE, #301 FT_ WORTH, TEXAS 76115 S630,000.00 TRAFFIC SIGNAL INSTALL 2010/002 VARIOUS LOCATIONS IN TXDOT - AU571N GEORGETOWN PO BC7X 15426 AUSTIN. TEXAS 78761-5426 $53,000.00 ANNUAL LOOP INSTALL 2010/003 VARIOUS LOCATION6 5135,000.00 TRAFFIC SIGNAL INSTALL 2010/004 PLEASANT RUN RD S73,000.00 TRAFFIC SIGNAL INSTALL 2010/005 ALSBURY BLVD & SUMMERCREST BLVD 582,000.00 TRAFFIC SIGNAL INSTALL 2010/006 5105,960 00 TRAFFIC SIGNAL INSTALL 2010/007 5219,375.00 TRAFFIC SIGNAL INSTALL 2010/008 S90,101.95 TRAFFIC 81GNAL INSTALL 2010/011 5115,500.00 TRAFFIC SIGNAL INSTALL 2010/012 5132,OOOAO TRAFFIC SIGNAL INSTALL 2010I013 S192,000 00 TRAFFIC SIGNAL INSTALL 2010/014 5315,165.00 PRVING & DRAINING IMPROVEMENTS $151,245.00 WAL-MARTTRAFSIG IMPROVEMENTS $828,000 00 TRAF SIGNAL INSTALL 5105,500.00 TRAF SIGNAL INSTALL CITY OF GARLAND 409 FOREST GATE GARLAND, TEXAS 75041 L H LACY COMPANY PO BOX 541297 DALLAS, TEXAS 75354-1297 CITY OF BURLESON 141 W. RENFRO ST. BURLE60N. TEXAS 76028 BARR RD MCCLENDON CONSTRUCTION PO BOX 999 BURLESON, TEXAS 76097 FM 407 & CHIN CHAPEL TISEO PAVING PO BOX 270040 DALLAS, TEXAS 75227-0040 OLD DECATUR TO BUSINESS AUI CdNTRACTORS, INC 287 4775 NORTH FREEWAY FT. WORTH, TEXAS 76106 CEDAR SPRINGS - DALLAS MICA C(JRPORATICJN LOVE FIELD PO BOX 1616b9 FT. W(7RTH, TEXAS 76161 N, COUNTRY CLUB RD & GLENN THURMAN W BROWN ST Pd BdX 850842 MESQUITE, TEXAS 75185-0$42 US 380 TXD(7T - TARRANT PO BOX 6868 FT WORTH, TEXAS 76115 VARIOUS LOCATIONS CITY OF WACO PC3 BOX 2570 WACd. TEXAS 76702-2570 2010/017 DIRKS RD - FROM BRYANT JACKSON CONSTRUCTION IRVIN RD TO HARRIS PKWY 5112 SUN VALLEY DR FT WORTH, TEXAS 76119 2010/018 EXCHANGE PKWY & EMJ CORPORATION WALMART DR 5525 N, MACARTHUR BLVD, #400 IRVING, TEXAS 75038 2010/021 IH 30 & FERGUSON RD. TXDOT DALLAS PO BC7X 133067 DALLAS. TEXAS 75313 2010/023 CS (MdNTFORT DR.) MCMAHON CONTRACTING PO BOX 153086 76 IRVING. TEXAS 75015-3d86 i , ■ � � ■ � 1 P.O. BOX535969 • GRAND PRAIRIE, TX75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-7411 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2010 CONTRACT SCOPE OF WORK YEAR/JOB # LOCA7ED NAME AND AMT A�C]R��S. �5938,300.00 PREVENTA7IVE 201�{j��7�� }•9 3�.� @�VARIOUS T�CICCIT DALLAS MAITENANCE LOCA7fONS PO BOX 133067 S233,5Q0.75 7RAFFIC SIGNAL INSTALL S760,234 00 TRAFFIC SIGNAL INSTALL DALLAS, TEXAS 75313 2010/028 GRENNVILLE AVE & HIGH CITY OF ALLEN POINT 7RAIL RD AND 305 CENTURY PKWY MCDERMOTT DR & ALLEN, TEXAS 75013 SHALLdWATER DR 2010/30 FM 720 (ELDORADO PKWY) MICA CORPORATIdN PO BOX 161609 FT WORTH, TEXAS 76161 51,358,000.00 2010 GRANd TASK ORDER 2010/031 VARIOUS LOCATIONS CITY OF FT WORTH CC}NSTRUCTI(7N SVCS 5001 JAMES AVE, #301 FT WORTH, TEXAS 76115 S147,76Q00 VIDEO IMAGE DETECTION 201Ql032 FM 1171 @ VAR LOCATIONS CITY OF LEWfSVILLE PO BOX 299002 LEWfSVILLE, TEXAS 75029-9002 S198,400.00 VIVDS AT TEN LOCATIONS 2010/033 VARIOUS LOCATIONS CITY OF LEWISVILLE S354,000.00 TRAFFIC SIGNAL INSTALL 5116,400.00 TRAFFIC SIGNAL INSTALL 51,255,000.00 NON-SITE SPECIFIC S137,000 00 INSTALLATION OF STREETLIGHTING 5365,735 Od TRAFFIC SIGNAL INSTALL 5415,90d,00 C(TY WIDE TRAFFIC SIGNAL IMPRVTS S105,000.00 TRAFFIC SIGNAL INS7ALL 5120,425 d0 TRAFFIC SIGNAL INSTALL 5278,9Q0.00 TRAFFIC SIGNAL PNSTALL PO BOX 299002 LEWISVILLE, TEXAS 75029-9002 2010/039 SPRING VALLEY NORTH TEXAS CONTRACTING WIDENING PO BOX 468 KELLER, TEXAS 76244 201 D/040 IH 35 A7 HERTIAGE TRACE TXdOT - TARRANT PKWY PO BOX 6868 FT WORTH, TEXAS 76115 2010/041 VARIOUS LOCATIONS 7XDOT DALIAS PO BdX 133067 DALLAS, TEXAS 75913 2010(042 GREENVILLE FROM CITY OF ALLEN EXCHANGE PKW TO S7ACY 305 CENTURY PKWY ROAD ALLEN, TEXAS 75013 201Ql045 ARKANSAS LANE REBUfLD JACKSQN CONSTRUCTION 5112 SUN VALLEY DR. FT WORTH, TEXAS 76119 2010l047 VARIOUS LOCATIC}NS C17Y OF BEDFORD 1813 RELIANCE PKWY BEDFOR0. TEXAS 76021 2010ld48 CLAY RD TOWN OF SUNNYVALE 127 COLLINS RD SUNNYVALE, TEXAS 75182 2010/049 WEBB CHAPEL @ EMJ CORPORAT{ON WALMART DRIVEWAY 5525 N. MACARTHUR BLVD, #40Q IRV6NG, TEXAS 75038 2010/050 N MAIN ST - PHASE 1 XIT PAVING & CC}NSTRUCTION 3934 S. HWY 287 77 WAXAHACHIE, TEXAS 75165 Exhfbit "F" ' - P.O. BOX 535969 • GRAND PRAIRIE, TX 75059-5968 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2011 CONTRACT SCOPE OF WORK YEAR/JOB �t LC7CATED AMT — _— _��e� � 5408,849 00 TRAFFIC SIGNAL INSTALL 2011/101 RUFF SNOW DR AT VARIOU5 LOCATIONS 5177,000.00 TRAFFIC SIGNAL INSTALL 2011/103 FM 741 5213,252.00 TRAFFIC SIGNAL INSTALL 2011/106 INWOOD IMPROVEMENTS 5140,940.00 TRAFFIC SIGNAL INSTALL 2011/113 FM 1187 5762,79Q.Oa TRAFFIC SIGNAL INSTALL � f 111 1� � S354,000.00 TRAFFIC SIGNAL INSTALL 3201,700.00 TRAFFIC SIGNAL INSTALL 5129,472.92 TRAFFIC SIGNAL INSTALL 51,300,OOQ00 ADV�NCEt7iRANSPORTATION MANAGEMENl SERVICES S285,OOQ 00 TRAFFIC SfGNAL INSTALL 2Q11(114 SdUTHEAST PKWY TO WEBB FERRELL rllSilfiiG��i►il,�'il 2011/117 SH 34 2011/120 VITRUVIAN WAY AT BELLA WAY 2611/121 SH 183/ SH 121 INTERCHANGE 2011/123 VARIOUS LOCATIONS 2011/125 MEMC?RIAL DR & STANDRIDGE . ��1 �� -,. , , � � +. S182,000.00 7RAFFIC SIGNAL INSTALL 2011/127 BU 190F @ FM 3219 S226,000,00 SIGNAL & INTERSECTION IMPROVEMENTS 2011/128 CANNON @ BROAD & CANNON @ MATLOCK NAME AND ADDRE35 m.m._... .a. __ AUI CONTRACTORS, INC. 4775 NORTH FREEWAY FT. WORTH, TEXAS 76106 ED BELL CONSTRUCTION PO BOX 540787 DALLAS, TEXAS 75354-0787 LEMCO CONS7RUCTION SERVICES 14131 MIDWAY RD, #600 ADDISON, TEXAS 75001 LONE STAR CONS7RUCTION 4320 WINDSOR CENTRE TRAIL, #500 FLOWER MOUND, TEXAS 75028 L H LACY COMPANY PO BOX 541297 DALLAS. TEXAS 75354-1297 TXDOT-TARRANT PO BOX 6868 FT. WORTH, TEXAS 76115 AUI CONTRAC70RS, INC. 4775 NORTH FREEWAY FT. WORTH. TEXAS 76106 CPS CIVIL 1215 CREST LANE DR. DUNCANVILLE, TEXAS 75137 MICA CORPORATION PO BOX 161609 FT WORTH, TEXAS 76161 DFW AIRPORT 3003 S SERVICE RD. DFW AIRPORT, 7EXAS 75261 CITY OF THE COLONY C/O HDR ENGINEERING, INC 17111 PRESTON RD., #200 DALLAS, TEXAS 75248-1232 TXDOT-TARRANT PO BOX 6868 FT. WOR7H, TEXAS 76115 TXDOT - WACO 100 S LOOP DR. WACO. TEXAS 76704-2858 MCCLENDON CONSTRUCTION, INC PO BOX 996 BURLESON,TEXAS76097 S104,500 00 TRAFFIC SIGNAL IMPROVEMENTS 2011/129 ELDORADO @ HILLCREST & CITY OF FRISCO ELDORADO @ COIT RD 61�1 FRISGO SQUARE BLVD, 3RD FLdOR 78 FRISCO, TEXAS 75034 DURABLE SPECIALTIES, INC. Exhibit ��F�� P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2011 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND ��T ADDRESS ..... � �_.. 5483 350.00 IH 635 Pi��f�J'a�CD LANES 2011/130 VARIOUS LOCATIOf'�d� µ TRINITY INF��/1 i�'6�l�CTC7�t�, LLC 5520 I-635 EAST, #150 DALLAS, 7EXA5 75240 5140,000 00 TRAFFIC SIGNAL INSTALL 2011/131 FM 51 TXD(7T - TARRANT FO BOX 6868 FT. WORTH, TEXAS 76115 5222,000 00 TRAFFIC SIGNAL 2011l136 GASTON AVE & CPS CIVIL IMPROVEMENTS WASHINGTON AVE 1215 CREST LANE DR. DUNCANVILLE, TEXAS 75137 S150,900.00 RICHLAND HILLS TRE 2011/137 HANDLEY-EDERVILLE @ NORTH STAR CONSTRUCTION, INC STATION ACCESS BURNS RD/TRINITY BLVD 3210 JOYCE DR. ENHANCEMENT FT.WORTH,TEXAS S142,000,00 ST. LIGHT IMPROVEMENTS 2011/140 GIFFORD ST & BAGDAD RD. HAYDEN BUILDING CORPORAT{ON 4640 E. COTTON GIN LOOP PHOENIZ, AZ 85040 S143,144.00 TRAF SIG INSTALL & LEFT 2011/144 UP70WN BLVD & S WALMART CITY OF CEDAR HILL TURN LAN IMPRVTS & FM 1382 Pd BOX 96 CEDAR HILL, TEXAS 75106 S301,300.00 LAKE RIDGE PKWY 2011/148 LAKE RIDGE PKWY @ MCMAHON CONTRACTING, L P. WIDENING VARIOUS LOCATIONS PO BOX 153086 IRVING, TEXAS 75015-3086 5539,530.00 TRAFFIC SIGNAL INSTALL 2011/147 SH 171 - FM 1884 TO IH 20 JAY MILLS CONTRACTING, INC PO BOX 1669 STEPHENVBLLE, TEXAS 76401 5104,OOOAO 9500476; DFW AIRPORT 2011/148 NORTH SERVICE RD @ NORTH TEXAS CONTRACTING, INC CROSS UNDER #1 CROSS UNDER #1 Pd BOX 468 KELLER, TEXAS 76244 5428,000.00 TRAFFIC SIGNAL INS7ALL 2011/150 VARIOUS LOCATIONS CITY dF GRAND PRAIRIE AT 4 LOCATION5 PO BOX 534045 GRAND PRAIRIE, TEXAS 75053-4045 S129,177.00 COOKS CHILDREN'S 2011/151 6 TH & 7TH STREET @ CONATSER CONSTRUCTION TX LP MEDICAL CENTER PENNSYLVANIA AVE Pd BdX 15448 FT WORTH, TEXAS 76119 5138,596.25 INTERSECTION IMRPVTS 2011/154 MATLOCK ROAD MCMAHON CdNTRACTING, L P PO BOX 1530$6 IRVING, TEXAS 75015 S330,000.00 TRAFFIC SIGNAL INS7ALL 2011/155 FM 407 MICA CORPORATION PO BOX 161609 FT. WORTH, TEXAS 76161 5178,Od0.00 TRAFFIC SIGNAL INS7ALL 2011/156 NORTH BEACH ST CONATSER CONS7RUCTION TX., LP. PO BOX 15448 FT WORTH, TEXAS 76119 � u LE E I LTI ,' � Exhibit "F" P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-fi324 • FAX 1-972-780-741 1 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2012 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND ` AMT ADDRESS _.—. _.__�.m�. .._...._ .R� S 197,000.00 TRAFFIC SIGNAL INSTALL 2012 / 203 WEST BERRY�STREET MCCLENDON CONSTRUCTION Pb BOX 996 BURLESdN, TEXAS 76097 S 98,000.00 INTERSECTION 2012 / 205 PARKER RD, SPRING VALLEY JIM BOWMAN CdNSTRUCTION IMPROVEMENTS PKWY & JUPITER RD 2716 S. RIGSBEE DRIVE PLANO,TEXAS 75074 S 194,204.00 WEST BROWN STREET 2012 / 207 COUNTRY CLUB RD TO NORTH MCMAHON CC7NTRACTING, LP IMPROVEMENTS BALLARD AVE PO BOX 153086 IRVING, 7EXAS 75015 S 104,500 00 TRAFFIC SIGNAL INSTALL 2012 /208 MILITARY PARKWAY AT LEMC(7 CONSTRUCTION SERVICE5 CEDAR LAKE DRIVE 14131 MIDWAY ROAD ADDISON, TEXAS 75001 5 173,000.00 PRESTON R(7AD ADA 2012 /210 GAYLORD PKWY, WARREN CfTY OF FRISCO IMPROVEMENTS PKWY, LEBANON RD 6101 FRISCO SQUARE BLVD WADE BLVD FRISCO, TEXAS 75034 $ 349,600.00 PLEASANT RUN RD 2012 / 212 PLEASANT RUN RD L.H. LACY COMPANY, LTD RECONSTRUCTION PH 46 1880 CROWN ROAD (PW06-0039) DALLAS, TEXAS 75234 S 162,447.95 BLUE LINE EXPANSION 2012 / 213 SH 66 @ MARTIN AUSTIN BRIDGE & ROAD 4817 ROWLETT ROAD ROWLETT, TEXAS 75088 S 15d,000A0 ROADWAY ILLUMINATION 2012 / 214 NORTH BEACH ST JLB CONTRACTING, LP KELLERY HICKS TO TIMBERLAND Pd BOX 24131 BLVD FT. WORTH, TEXAS 76124 5 180:OQ0.00 TRAFFIC SIGNAL INSTALL 2012 / 217 W. WINDSOR DRIVE MCMAHON CONTRACTING, L.P. PO BOX 153086 IRVING. TEXAS 75015 S 120,000 00 TRAFFIC SIGNAL INSTALL 2012 /218 BU 377H @ RESORT TXDOT - TARRANT CONFERENCE CENTER PO BOX 6$68 FT. WOR7H, 7EXAS 76115 S 140,OOQ 00 ILLUMINATION & TRAFFIC 2012 ( 221 JOHN HICKMAN PARKWAY MCMAHON C�NTRACTING, L.P SIGNAL INSTALL FROM WES7 OF PRESTON ROAQ PO BOX 153086 TO OHIO QRIVE IRVING, TEXAS 75Q15 S 215,000 00 TRAFFIC SIGNAL INSTALL 2012 / 222 DFW AIRPdR7 CROSSUNDER #2 PHfLLIPS MAY CORP(7RATION 4861 SHARP STREET DALLAS. TEXAS 75247 S 202,000 00 TRAFFIC SfGNAL INSTALL 2012 / 224 SACHSE ROAD AT MILES/ CITY OF SACHSE BRYAN STREET 3815-B SACHSE ROAD SACHSE, TEXAS 75048 S 1Q8,000 00 TRAFFIC SIGNAL INSTALL 2012 / 225 US 67 (CR 209 E. OF ALVARRDO) TXDOT - TARRANT PO BC7X 6868 FT. WORTH, TEXAS 76115 5 97,700 00 7EMP & PERM TRAFFIC SIGNAL INSTALL 2012 / 228 DART ORANGE LINE I-3 MASS ELECTRIC CONSTRUC710N COMPANY FREEPORT PARKWAY @ &700 FREEPORT PARKWAY, #160 AIRFIELD DRIVE IRVING, 7EXAS 75053 BO L I LTI , I , EXnibit ��F�� P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-7411 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2012 CONTRACT SCOPE OF WORK YEARlJOB # LOCATED AM�' a��.�. x.�_.� ��.._..__� � . ,,,�,,.�m.— � 129,ffi49.75 SF�Vu` ��U i LC�[�F�� 2012 / 229 SH 180 $ 437,000 00 TEMP & PERM TRAFFIC 2012 / 231 SH 26 SIGNAL INSTALL S 147,074.Q0 7RAFFIC SIGNAL BNSTALL 2012 ( 233 US 180 . ��i M� S 456,000.00 TEMP & PERM TRAFFIC SIGNAL INSTALL 2012 / 236 N. TARRANT PKWY @ KELLER SMITH 2012 / 237 FM 1187 81 NAME AND ADD��55 i�f'l��;-TEXAS 1�1C __...� 2121 IRVING BLVD dALLAS, TEXAS 75207 AUICONTRACTORS,LP 4775 NORTH FREEWAY FT. WORTH, TEXAS 76106 ED BELL CONSTRUCTIdN 10605 HARRY HINES BLVd DALLAS, TEXAS 75220-2634 L H LACY COMPANY, LTD. PO BOX 541297 DALLAS. 7EXAS 75354-1297 MCMAHON CONTRACTING, L.P. PO BOX 153086 IRVING, TEXAS 75015 u A LE pE 1 LTIE , 1 . Exhibit "F" P.O. BOX535969 • GRAND�PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-7411 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2013 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND AMT ADDRESS —�.� �, ,�.._ ,_ � _..�.. � _ -. S t,679,500.00 TRAFFIC SIGNAL & 2Q131 301 US 287 TO MILLER AVENUE JACKSON CONSTRUCTION. LTD. ILLUMINATION MODIFICATlbN 5112 SUN VALLEY DRIVE FT. WORTH, TEXAS 76119 2013 ( 302 FM 1187 TXDOT - TARRANT 2510 SW LOOP 820 FT. WOR7H, TE S 76133 2013 t 3d4 INDEPENDENCE & CUSTER TISEO PAVING C(7MPANY PO BOX 27Q040 QALLA5, TEXAS 75227 2�13 P 305 FM 156 @ BASSWOOD BLVD D R HdRTON , INC 6751 NORTH FREEWAY F7 Wt?RTH, TEXAS 76131 2013 ( 306 MAIN ST @ LAKESNORE DR. XIT PAVING & CdNSTRUCTION, INC. AND BEARD PARK 3934 S. HIGHWAY 287 WAXAHACHIE, TEXAS 75166 2013 P 308 US 377 TXDOT - TARRANT 2510 SW LOOP 820 FT WORTH, TEXAS 76133 2013 / 310 ELDORADO PARKWAY (FM 2994} CITY OF FRISCO AT WAL-MART 6101 FRISCO SQUARE BLVd 3RD FLOOR EAST FRISCC7, TEXAS 75Q34 2013 ( 312 IH 35W MICA CORPC}RA71tJN PO BOX 181609 FT. WORTH, TEXAS 76161 2013 ( 317 HAMP7'ON ST: BELKNAP ST & AUI C6NTRAC7dRS, LP WEATHERFORd ST 4775 NOFZTH FREEWAY F7. WORTH, TEXAS 76106 2013 / 319 TURTLE CREEK 1 CEC}AR SPRINGS AUI GQNTRACTORS, LP AT TUR7LE CREEK BLVD 4775 NC7RTH FREEWAY FT WORTH, TEXAS 76106 2b13 f 920 VARIOUS LOCATIONS TXDOT - TARRANT 2510 SW LOOP 820 FT WORTH, TEXAS 76133 2013 ( 321 US 287 TXD07 - WF 1601 SOUTHWEST PKWY WICHiTA FALLS, TEXAS 76302-4906 2013 P 323 VARIOUS LOCA76QNS KEN-DQ CONTRACTING, LP Po Bax zoal dESOTO,TEXAS75123 2013 / 324 FM 548 @ KR(?GER DRIVE HAWKINS CONSTRUCTIC7N, ING. PO BOX 1636 TARPC7N SPRING, FL 34688-1636 2�13 ! 327 FM 6B3 ED BELL CONSTRUCTION CdMPANY PCJ BOX 540787 DALLAS, TEXAS 75354-Q787 20131 329 FM 2499 @ LIVE OAK CI1Y C7F HIGHLAND VILLAGE 100b HIGHLAND VILLAGE RD HIGHLAND VILLAGE, TEXAS 75�77 s �zs,oao.00 TRAFFIC SIGNAL INSTALL $ 363,000.00 PERM & TEMP TRAFFIC SIGNAL INSTALL i. ••, r �: �4 `�� ' � �! .. S 417,155D6 LIGHTING PHASE II & PARKING LOT LIGHTS $ 105,000,oa TRAFFIG SIGNAL INSTALL 5 105,UQ0.00 TRAFFIC SIGNAL INSTALL $ 447,�OQ00 PERM & TEMP TRAFFIC SIGNALINSTALL S 152,875.00 TRAFFIC SIGNAL INSTALL BNSF TOWERS 55 S 111,oao.00 TRAFFIC SIGNAL INSTALL S &15,OQ0.00 NC}N-SIiE SPECIFIC $ 91,300 00 MAINTENANCE s i 7o,00a.00 SOLAR PWRD CROSSWALK SYSTEM & SOLAR PWRD DRIVER SPEED AS5Y S 135,65Q OQ TRAFFIC SIGNAL INS7ALL S 28D,964.00 PERM & TEMP TRAFFIC SIGNALINSTALL S 182.�00.00 TRAFFIC SIGNAL IMPR(7VEMENTS � DURABLE SPECIALTIES, INC. Exhibit ��F�� P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 DURABLE SPECIALTIES, INC. WORK EXPERIENCE MAJOR CONTRACTS 2013 CONTRACT SCOPE OF WORK YEAR/JOB # LOCATED NAME AND AM7 J§[1��SS .� �..,,_. _.mm. ��_.._...... ..,_ ..._,M....... ...__�_... —. ..� �w —�_.�� wa__.�. e.....,....._,_ ., � 1,5��,OOO.DO NON-51TE SPECIFfC 2013 / 330 VARIOUS ¢.L�CIi i kC�N ; TXDO7 DALLAS PO BOX 183067 DALLA5, TEXAS 75313-3667 S 390,662 00 TRAFFIC SIGNAL INSTALL 2Q13 / 331 KENTUCKY STREET AT NORTH TEXAS CONTRAC7ING VARIOUS LOCATIONS Pd BdX 468 KELLER, TEXAS 76244 5 222.101.d0 STREET LIGHTING & SCHOOL 2013 f 335 EAST �ROAD STFdEEi XIT PAVING & CONSTRUCTION, ING. ZdNE FLASHER 3934 S. HIGHWAY 287 WAXAHACHIE, TEXAS 75165 5 109,100.(}0 TRAFFIC SIGNAL Ih157ALL 2d13 / 336 SH 289 REBCON, INC. 1868 W NORTHWE3T HWY DALLAS, TEXAS 75220 S 120,�00 00 TRAFFIC SIGNAL INSTALL 2013 / 337 FM 3629 TXD(JT - TARRANT z5�a sw LooP szo FT WORTH, TEXAS 76133 S 136,900 Od TRAFFIC SIGNAL INSTALL 2013 ( 338 INDEPENCE PKWY A7 KELMSCOT CITY OF FRISCO DRIVE 6101 FRISCC} SQUARE BLVD 3RD FLO(3R EAST FRISGO, TEXAS 75034 S 1b2,650.00 2011 INTERSEC71dN 2013 ( 34Q VARIdUS LOCATIdNS MCCLENDON CONSTRUCTION CAPACITY IMPROVEMENT PO BOX 999 BURLESC7N, TEXAS 76097 83 THE AMERICAN INSTITUTE OF ARCHITECI�"b't ��F�� AIA Document A310 Bid Bond KNOW ALL MEN BY THESE PRESENTS, THAT V11E Durable Specialties, Inc. P.O. Box 535969 Grand i�r�crie TX 75050 as Principal, hereinafter called the Principal, and Great American Insurance Company 301 East Fourth Street Cincinnati OH 45202 a corporation duly organized under the laws of the State of OH as Surety, hereinafter called the Surety, are held and firmly bound unto City of Denton, TX TX as Obligee, hereinafter called the Obligee, in the sum of Five Percent of the Greatest Am��nt g��1 Dollars ($ 5% GAB ), for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for RFP 5442/ Intersection Traffic Control Construction NOW, 7HEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contraci with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and materials fu�nished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obfigee the difference nat to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 6th day of February , 2014 �� . . j"i�Yrtrr�s�) Durable ��ecialties. Inc. (seu!) �' �� r,'�` � ,� , .� �+ . � �� W � `� k• � „� . . . _. ,# ,.�,� w �� ° , � , _.._._.� (Titfe) �� t�5t��` .�, � ��.;�� t As��eric�r��.�.r��urance Com ,� �•' '� �`Sur�tyi � � �.�. .�� 4 � . �'itraessY � : �. � �,�, ,�+' . T� ; � ; .. _�. �.°" ` �. .A=�_ .� ,�. rarrt�y�rtr�f=a��F � JackM'�r�a�,�v4ey �� '� ` �M.. . ��.. _.__n.., a��,..___ �. ��..�.w AI.4 DOCUMENT A310 • V ,� FEBRUARI' 1970 ED • THE AMERICAN INSTITI!T� OT .:tid�'IL#'I"�� i 1,.. �3� iV.l'. A1'E_, N.V1'., ��'ASIiINGTON, D.C. 2U(N)6 84 S9 Q29AB (2/11) Exhibit "F" GREAT AMERICAN INSURANCE COMPANY� Administrative Office: 301 E 4TH STREET • CINCINNATI, OHIO 45202 • 513-369-5000 • FAX 513-723-2740 ,- , � . . -.. �� c w . s - � � 1',�• � POWEI2 OF A'I"I'URNEY ICNOW ALL MElY B'Y TI�ESE PI2ESENTS: That the G12EAT AMERICAN INSURA]VCE COMPANY, a corporation organized and exisring under and hy virtue of the laws of the Slale of Ohio, does hereby nominate, consYitute and appoint the person or persons named below, each individually if more than one is named, its true and lawful atlomey-in-fact, for it and in its name, place and stead to execute on behalf of the said Company, as surety, any and all bonds, undertakings and contrac4s of suretyship, or other written obligatians in the nature thereof; provided that the liability of ihe said Company on any such bond, undertaking ar contract of suretyship executed under this authoriYy shall not exceed the limit stated below. Name JACK M. CROWLEY STEVEN R.FOSTER PATRICIA A. SMITH MARIE PERRYMAN Address ALL OF ADDISON, TEXAS Limit of Power ALL $75,000,000.00 This Power of Attorney revokes all previous powers issued in behalf of the attorney(s}-in-facY named above. IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be sigried and attested by its appropriate officers and its corporate sea] heeeunto affixed Yhis 215� day of, JULY, 20i 1. AtteSY �f a '� d,�:. r `-r. J ��'� - w� GREAT AMER[CAN INSURANCL COMPANY STATE OF OHId, COIJNTY OF HAMILTdN - ss: nawn c�TCwri (sts-atzaeoz) On tttis 21� day of JULY, 2011, before me personally appeared DAVID C. KITCHIN, to me known, being duly swom, deposes and says that he resides in Cincinnati, Ohio, that he is a Divisional Senior Vice President of the Bond Division of Great American Insurance Company, [he Company described in and which executed the above instrument; that he knows the seal of the said Company; that ihe seal affixed Ya the said instrument is such corporate seal; that iY was so affixed by authority of his office under the Hy-Laws of said Company, and that he signed his name thereto by like authority. KAREN L. GROSHEIM '"` ' MOTARY PUBLIC, STATF OF OHIO g� �° Y� MY CQMMISBION �XPIRES 02-2a16 ;� �j :�:. ��.� This Power of Attomey is granted by auYhority of the fallowing resolutians adopted by the Board of Directors of Great American Insurance Campany by unanimous written consent dated June 9, 2008. � RESOLC�ED: T%8Q1 /I12 DBVdS80Y1QI PYCShcIC7tF, the several Divisional Senior Yice Presidents, DIVlS101YQI VBCC PYC58(IC1tP5 Qt1CI Ii[V8SlO18QI fiSSlS[�/dl VBCC Prestdenes, or axy one of thern, be and hereby is authorized, from tlme to time, to appoinl one or more Attorneys-in-Fact to execule on behalf of the Campany, as surety, any and alt bonds, undertakings and contracts of sureryship, or other writlen obligalions in lhe nature lhereof,• !o prescribe lheir respective duties and the respeclive limils of thetr authoriry; and to revoke any such appointmeni at any time. RESOLVEl3 FU127'HER: Thai !hc Compa�sy seal arad the signature of any of lhe aforesaid o�cers and any Secretary or ,4ssistant Secretary of the Company may be a�xed by facsimile to any power of attorney or certifecaae of either given for the execucion of any bond, undertaking, coneract of sureryship, or olher written obligataon in the nature thereof, such signature and seal when so used being hereby adopted by the Company as the originat signature ofsuch officer and the ariginal seal of the Company, eo be valid and binding upon the Company with the same force and e�j'ect as though manually aff`rxed. ,[I�'�IFC�7►1 I, STEPHEN C. BERAHA, Assistant Secretary of Great American Insurance Company, do hereby certify that the fbregoing Power of Attorney and the Resolutions of the Board of Directors of June 9, 2008 have not been revoked and are now in ful] force and effect. Signed and sealed this ( ttl dayof FebYU3iy , 2�14 ,r ��. 1� ' � � ��.� S1029Y (10lOB) 85 Exhibit "F" �� , t� a�i�u', �'js �alt� �, l r ,� i �+�F�4 �`�'r�� i � fi �te . u �r�ss �,` qsa r e�a� � ut u ��~c �;n��,fi� �` � � �tt��e'�,�� 4�} .��11�, ,,� �,�i TM�r.�� , � Purchasing Department 901-B Texas St. Denton, TX 76209 (940) 349-7100 www.dentonpurchasing.com ADDENDUM # 1 R F P # 5442 For Construction of Traffic Control I ntersections for the City of Denton Issue Date: January 31, 2014 Response due Date and Time (Central Time): Thursday, February 6, 2014, 2:00 p.m. 86 RFP # 5442 ADDENDUM # 1 Addendum # 1 to be returned with Proposal The following are changes to the specifications: NO OTHER CHANGES AT THIS TIME. This form should be signed and returned with your proposaL Name: �°��c . 6�'��`� , - _ �•�' . � . "� �� _ �,� � ��- ._, Signature: ,�: -� �.-� � Company: Jr� f� � �c fc��"a°�s . /t� � Title: �f �� - r�.s �c-�� Date: Z ° 6 °/ 87 Exhibit "F" , 1, �; . � � ' ' , �, � ' � : , �' � � � ' � , ]. Contractor Name : Uurable Specialties, Inc. 2. Address (Principle Place of Business: 2302 Padclock Way Dr., Grand Prairie, TX 75U50 3. Does your company have an established physical presence in the State of Texas, or the City of Denton? Yes. in the State of Texas 4. Tax Payer ID#: 75-1963459 5. Email Address of Primary contact: I'ati•ick;a;durablespecialties.com 6. Website Address: N/A 7. Telephone:972-296-6324 8. F�:972-78U-7411 9. Other Locations: N/!� l0. Organization Class: Coapoi ation 11. Date Established: Jtine 15, 1984 12. Former Business Name: N/A 13. Date of Dissolution: N/A 14. Subsidiary of : l�T/!� 15. Historically Underutilized Business: No 16. Principals and Officers: See att�ched sheet Please detail responsibilities with the name of each principal or officer, 17. Key Personnel and Responsibilities: See altached sheet Please detail responsibilities with the name of each key personnel. Page 42 of RFP # 5442 68 , ! `( � ■ j '1 P.D. BOX535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-7411 � Cr,rua�y �th zo� a Contractor `amc & Address: Durable Specialties, Inc. PO I3ox 535969 Grand 1'rai�-ie, "I�exas 75030 Key I'ersonnel: Jeff 13ryan, Owncr 38 years experience in traific signalization construction 29 years as owner of the campany leferino Luna, Superintendent 29 years experience in traific signalization constructian 29 years with the company Kevin Holter, Superintendent 20 years experience in trafiic signalization construction 19 years with the company Durable Specialties has constructed traftic signalization projects f��i• 29 years with in- house crews. We have done about 1,200 traffic signalization prajects with aur in-house crews and in thc last three years we have done about l 50 traftic signalization projects. Safety Record: All oi• ow' ti•aff°re signal projects were completed, turned on and passed tlle required 30 day test period without any safety problems. ss , � ,, � � . � � . � 18. Number of Personnel by Discipline: 19. Discipline Number of Staff # Licensed or Certified 20. Services Provided by Firm: Please provide a detailed listing of all services that your company provides. Please detail your prior experience working on similar projects with Texas govemmental entities. Please detail your similar services provided over the past two (2) years. Detail documented proof of at least three (3) projects in the past two (2) years. Please detail these services, including, the nature of the services provided, and the scope of the activities, the organizations for which the services were provided, the dates of the projects, and the documented benefit to the governmental entity. 21. Has your company filed or been named in any litigation involving your company and the Owner on a contract within the last five years under your current company name or any other company name? If so provide details of the issues and resolution if available. Include lawsuits where Owner was involved. No. 22. Please provide at least (3) three references (preferably municipalities) and contract amounts. Include project description, contact names, position, and organization name and telephone number for each reference listed. See attachment F. 23. Have you ever defaulted on or failed to complete a contract under your current company name or any other company name? If so, where and why? Give name and telephone number of Owner. No. 24. Have you ever had a contract terminated by the Owner? If so, where and why? Give name and telephone number (s) of Owner (s). No. 25. Has your company implemented an Employee Health and Safety Program compliant with 29 CFR 1910 "General Industry Standards" and/or 29 CFR 1926 "General Construction Standards" as they apply to your Company's customary activities? lrtt��llu�w°s�v��3_��tr��M1��1�,'c��;latir�a�el�+ft�i�°��;��c:f�.��.at��:�� 9��•�a�`?� �1t7�: i��a� �}�..f"��IL}I�I�I�`�c�:�r lc�� _leve1=18cp ke,yvalue=1926 26. Please indicate the total number of projects your Firm has undertaken within the last five years? 27. Insurance Information a. Name of Insurance Carrier: Continental C;asualty Ins. Co, b. Agent Name: Frank Si�ldons c. Address of Agency: 29U0 Marquita Drive d. City/State: I'ort V>>ort11, TX 76116 e. Phone Number: 317-7�7-4943 f. Email address of Agent: h�raveilorra;fsi.f'w.com . .. , . ,, ., , � 1 � �' ' •: � , • ' � 28. List all subcontractors whom respondent estimates will fulfill 15% or more of the contract: 29. Resident/Non-Resident Bidder Determination: Texas Govemment Code Section 2252.002: Non-resident bidders. Texas law prohibits cities and other governmental units from awarding contracts to a non-resident firrn unless the amount of such a bid is lower than the lowest bid by a Texas resident by the amount the Texas resident would be required to underbid in the non-resident bidders' state. In order to make this determination, please provide the name address and phone number of: a. Proposing firms principle place of business: 2iO2 l.'addock Way :Dr., Grand Prairie, "!�X 7>OSO b. Company's majority owner principle place of business: ?302 Paddock ��ay Dr., Grand Prairie, 'I'X 7�050 Ultimate Parent Company's prineiple place of business: 2302 Paddock VJay Dr., Crrand :Prairie, 'I'X 7�OS� . � .. ,, . CITY OF DENTON Exhibit "F" CONSTRUCTION OF TRAFFIC INTERSECTIONS . �— , � �• � � � . ;. The City of Denton desires to avail itself of the benefits of Section 252.0435 of the Local Government Code, and consider the safety records of potential contractors prior to awarding bids on City contracts. Pursuant to Section 252.0435 of the Local Government Code, tlie City of Denton has adopted the following written definition and criteria for accurately determining the safety record of a bidder prior to awarding bids on City contracts. The definition and criteria for determining the safety record of a bidder for this consideration shall be: The City of Denton shall consider the safety record of the bidders in determining the responsibility thereof. The City may consider any incidence involving worker safety or safety of the citizens of the City of Denton, be it related or caused by environmental, mechanical, operational, supervision or any other cause or factor. Specifically, the City may consider, among other things: a. Complaints to, or final orders entered by, the Occupational Safety and Health Review Commission (OSHRC), against the bidder for violations of OSHA regulations within the past three (3) years. Citations (as defined below) from an Environmental Protection Agency (as defined below) for violations within the past five (5) years. Environmental Protection Agencies include, but are not necessarily limited to, the U.S. Army Corps of Engineers (USACOE), the U.S. Fish and Wildlife Service (USFWS), the Environmental Protection Agency (EPA), the Texas Commission on Environmental Qua]ity (TCEQ), the Texas Natural Resource Conservation Commission (TNRCC) (predecessor to the TCEQ), the Texas Department of Health (TDH), the Texas Parks and Wildlife Department (TPWD), the Structural Pest Control Board (SPCB), agencies of local governments responsible for enforcing environmental protection or worker safety related laws or regulations, and similar regulatory agencies of other states of the United States. Citations include notices of violation, notices of enforcement, suspension/revocations of state or federal licenses or registrations, fines assessed, pending criminal complaints, indictments, or convictions, administrative orders, draft orders, final orders, and judicial final judgments. c. Convictions of a criminal offense within the past ten (10) years, which resulted in bodily harm or death. d. Any other safety related matter deemed by the City Council to be material in determining the responsibility of the bidder and his or her ability to perform the services or goods required by the bid documents in a safe environment, both for the workers and other employees of bidder and the citizens of the City of Denton. In order to obtain proper information from bidders so that City of Denton may consider the safety records of potential contractors prior to awarding bids on City contracts, City of Denton requires tllat bidders answer the following three (3) questions and submit them with their bids: Page ] 02 of RFP # 5442 92 CITY OF DENTON Exhibit "F" CONSTRUCTION OF TRAFFIC INTERSECTIONS QUESTION ONE Has the bidder, or the firm, corporation, partnership, or institution represented by the bidder, or anyone acting for such firm, corporation, partnership or institution, received citations for violations of OSHA within the past three (3) years? YES NO�e�,...... lf the bidder has indicated YES for question number one above, the bidder must provide to City of Denton, with its bid submission, the following infor�nation with respect to eacli such citation: Date of offense, location of establishment inspected, category of ofiense, final disposition of offense, if any, and penalty assessed. QUESTION TWO Has the bidder, or the firm, corporation, parinership, or institution represented by the bidder, or anyone acting for such �rm, corporation, partnership or institution, received citations for violations of environmental protection laws or regulations, of any kind or type, within the past five years? Citations include notice of v'rolation, notice of enforcement, suspension/revocations of state or federal licenses, or registrations, Cnes assessed, pending criminal complaints, indictments, or convictions, administrative orders, draft orders, final orders, and j�udicial final judgments. YES NO X If the bidder has indicated YES for question number two above, the bidder must provide to City of Denton, with its bid submission, the following information with respect to each such conviction: Date of offense or occurrence, location where offense occurred, type of offense, final disposition of offense, if any, and penalty assessed. QUESTION THREE Has the bidder, or the firm, corporation, partnership, or institution represented by bidder, or anyone acting for such firm, corporation, partnership, or institution, ever been convicted, within the past ten (]0) years, of a criminal offense which resulted in serious bodily injury or death? YES NO X If the bidder has indicated YES for question number three above, the bidder must provide to City of Denton, with its bid submission, the following information with respect to each such conviction: Date of offense, location where offense occurred, type of offense, final disposition of offense, if any, and penalty assessed. Page l Q3 of RFP # 5442 93 uRQBLE PEC'/�LT'E$, 'NC. Exhibit "F" P.O. BOX 535969 • GRAND PRAIRIE, TX 75053-5969 • PHONE 1-972-296-6324 • FAX 1-972-780-741 1 DURABLE SPECIALTIES, INC. REFERENCES CITY OF FT. WORTH CITY dF FRISCO 5001 JAMES AVE ,#301 6990 MAIN STREET FT. WORTH, TEXAS 76115 FRISCO, TEXAS 75Q34 ATTN: MARK MATHIS-ENGINEER, KEN BROCK-INSPEG70R ATTN: BRIAN MOEN-ENGINEER 817-392-7974 OFC 972-335-5586 OFC 817-392-2533 FAX 972-731-4945 F,4X CfTY OF ALLEN 305 CEN7URY PARKWAY ALLEN, 7EXAS 75013 ATTN: DAVID WHITEHEAD-ENGINEER, MIKE KEALY-INSPECTOR 214-509-4580 OFC 214-509-459Q FRX 7XDdT dALLAS PC3 BOX 133067 DALLAS, TEXAS 75313-3067 ATTN: CHRIS BLAIN-ENGINEER, GREG PERKINS-fNSPEC7�R 214-32�-610d OFC 2i4-320-4492 FAX ! a s' �� . � a � �* � •', .� W. ,� * *�M 1 CITY OF DUNCANVILLE 330 SHADY TRAIL DUNCANVILLE, TEXAS 75138 S7EVE MILLER-ENGINEER, JOHN BORCHARDT-INSPEG70R 972-780-5059 OFC 972-780-6461 FAX CITY OF DALLAS 1500 MARILLA STREET bALLAS, TEXAS 75201 STEVE CHERRYHOLMES-ENGINEER 214-670-3113 dFC 2i4-670-3292 FAX �� ...�. !. � ... � � � +► . , ;� • : : � GITY OF MCKINNEY 1550 S CQLLEGE MCKINNEY, 7EXA8 75070 ATTN: SCOTTY STEWART 972-547-7350 OFC 972-548-1052 FAX 1��]'a�i[#7Zf�7�.'�il[.1�7xs�Cs7 � . .�. - : � ,i� , �� . R �* , � �.. � .+ . � �,. CITY dF DESOTO 809 WEST SPfNNER ROAD DESOTC7, TEXAS 75115 MATT MfSER-5UPERVISOR, BRAD RUSSELL-INSPEC70R 972-23�-5714 OFC 972-223-9518 FAX TOWN C}F ADDISON 16801 WEST GROVE DRIVE AddISON, TEXAS 750d1 JdHN THOMPSC7N-ENGINEER ROBIN JC7NES-ENGINEER, BRANDON GRAHAM-INSPEC70R 972-450-2871 OFC 972-450-2837 FAX CITY OF MESQfJITE 1515 NC7RTH GALLC7WAY AVENUE MESQUITE, 7EXAS 75185 SRINI MANDAYAM-ENGINEER, FRANK GANTRELL-INSPECTOR 972-216-6357 OFC 972-216-6360 FAX 94 ! +�� :^ ! li C :•�,� . � � + •1., !, ! :! _. ; . � �: # . >, ` , 1 ,. •` ' �' � ' • , ' � , � 1 � The undersigned agrees this Proposal becomes the property of the City of Denton after the official opening. The undersigned affirms he has familiarized himself with the specification, drawings and other documents; the local conditions under which the work is to be performed; satisfied himself of the conditions of delivery, handling and storage of materials and equipment; and all other matters that will be required for the work before submitting a proposal, ln submitting a proposal the undersigned fureher understands that the work required is to provide construction of the project that functions as described in the specification. The undersigned understands that all requirements of the construction may not be described in every detail and agrees to provide labor, tools, material and equipment necessary to complete all construction to make the fence functional as described in the specification and drawings before submitting a proposal. The undersigned agrees, if this proposal is accepted, to furnish any and all items/services upon which prices are offered, at the price(s) and upon the terms and conditions contained in the specification. The period for acceptance of this Proposal will be ninety (90) calendar days unless a different period is noted. The undersigned affirms that they are duly authorized to execute this contract, that this RFP has not been prepared in collusion with any other Proposer, nor any employee of the City of Denton, and that the contents of this RPP have not been communicated to any other proposer or to any employee of the City of Denton prior to the official opening of this bid. Respondent hereby assigns to the City any and all claims for overcharges associated with this contract which arise under the antitrust laws of the United States, 15 USCA Section 1 et se ., and which arise under the antitrust laws of the State of Texas, Tex. Bus. & Com. Code, Section 15.01, et seq. The undersigned affirms that they have read and do understand the specifications and any attachments contained in this RFP package. The undersigned agrees that the RFP posted on the website are the official specifications and shall not alter the electronic copy of the specifications and/or pricing sheet (Exhibit 1), without clearly identifying changes. The undersigned understands they will be responsible for monitoring the City of Denton Purcl�asing Website at: littp://www.cityofdenton.con�!index.aspx?pa�e=397 to ensure they have downloaded and signed all addendum(s) required for submission with their proposal. I certify that I have made no willful misrepresentations in this Proposal Submission, nor have 1 withheld information in my statements and answers to questions. I am aware that the information given by me in this proposal will be investigated, with my full permission, and that any misrepresentations or omissions may cause my proposal to be rejected. � Acknowledge receipt of following addenda to the proposal� Addendum No 1 Dated i°3'"'1 �_ Received _..._ - .. Addendum No 2 Dated Received _ Addendum No 3 Dated T Received � NAME AND ADDRESS OF COMPANY: AUTHORIZE `�,�^,�.1'1�"�l�l�[l;,�i�TIVE: ,_ �.-�a -_. ��ra� e S�¢c�c�.I�i��S. �/Ir.. Signature � � �- �° �. �...... _ -:_...___._._...— n�.� .. � . �r i�C� c� r�Y 5-3.5�9� � Date `" 6`�` `� � � . .__�. ��`� r; ;!� / r::r r r��c� � 1t� ......f��C�'.� Name PQ �Pr'c�' G�r yca r� Title ��G 'P��s��n �" Tel. Na �17�V z ��'� 32. � _ _._---- Email. ......._�k�f1el� �OVr«6��a!'�`,��, c��'m FaxNo. %7Z- 71�0- r�// i� . � . . 95 Exhibit "F" Respondent's Name: Durable Specialties, Inc. RFP 5442 - Pricing Sheet for CONSTRUCTION OF TRAFFIC CONTROL INTERSECTIONS The respondenl shal! canple�e !he jollowi�ig seclion, which directly corresponds 10 lhe specificalions. The conh�aclor sha!! no! rrtake changes ro Ihrs format. Product Proposal Pricing: We are estimatling on 10 intersections a year for 3 years — 30 intersections for the total estimated amount. _ _ EST. Item ANNUAL Product Description Description 2 QTY ' UOM Unit Price Extended Price . _ _ _ - 1 840 LF ''Trench 2" PVC Schedule 80 Fumish and Install $ 10.00 '$ 8,400.00 2 1,700 LF Trench 2" PVC Schedule 40 Furnish and Install $ 9.00 '$ 15,300.00 _ --_ __ 3 900 LF Trench 3" PVC Schedule 40 Purnish and Install $ ll.00 '$ 9,900.00 . _ _ 4 1,820 ' LF Trench 4" PVC Schedule 40 Furnish and Install $ 10.00 $ 18,200.00 _ . 5 460 LF Trench 6" PVC Schedule 40 Furnish and Install $ 17.00 $ 7,820.00 , 6 600 LP Directional bore 2" PVC Schedule 80 Furnish and Install $ 21.00 $ 12,600.00 _ -- - -- 7 600 ' LF Directional bore 2" PVC Schedule 40 Fumish and Install $ 20.00 $ 12,000.00 8 1,650 LF Directional bore 3" PVC Schedule 40 Furnish and Install $ 20.00 $ 33,000.00 9 1,650 LF Directional bore 4" PVC Schedule 40 Furnish and Install $ 21.00 $ 34,650,00 ----- _ _ _ __ ] 0 500 LP Directional bore 6" PVC Schedule 40 Purnish and Install $ 30.00 $ 15,000.00 .__ . 11 160 LF Rigid Metallic Conduit (RM) 1" Furnish and Install $ 12.00 $ 1,920.00 _ _ _ __ __ 12 160 LP' Rigid Metallic Conduit (RM) 1.5" Purnish and Install $ 14.00 $ 2.240.00 _ 13 210 LF Rigid Metallic Conduit (RM) 2" Furnish and ]nstall $ 15.00 � 3,150.00 _ - 14 320 LF Rigid Metallic Conduit (RM) 3" Furnish and lnstall $ 23.00 $ 7,360.00 . . _ . . _ 15 320 LF Rigid Metallic Conduit (RM) 4" Fumish and Install $ 25.00 $ 8.000.00 16 ' 24 EA ,Rigid Metallic Conduit (RM) various sizes on timber poles Remove $ 100.00 $ 2,400.00 17 12 EA Ground box Type B with apron Fumish and Install $ 780.00 $ 9,360.00 _ _ - - _ __ 18 12 EA Ground box (city su��nlicd box only) Type B with apron Fumish and Install $ 600.00 $ 7.200.00 ____ _ � 19 40 EA Ground box Type D with apron Fumish and install $ 800.00 $ 32,000.00 20 40 EA Ground box (cit� supplicd bos onl} } Type D with apron Purnish and Install $ 600.00 $ 24,000.00 _ _ 21 48 EA Ground box with apron Remove $ 100.00 $ 4,800.00 � ra ic s�gna ca met wi tertnmations pa mounte no 22 4 �A �oncrete or base Install $ 7,500.00 $ 30,000.00 ra ic stgna ca met re away ase an concrete pa 23 10 EA �g�x9'x6"1 Furnish and Install $ 2,400.00 $ 24,000.00 24 3 EA ��ffic si�nal cabinet concrete vad (8'x9'x6"} Furnish and Install $ 2,] 00.00 $ 6,300.40 25 4 EA Traffic sienal cabinet (oad mounted) with base Remove $ 500.00 $ 2.000.00 26 4 EA Traffic sienal cabinet (uad mounted) with base and concrete qad Remove $ 900.00 $ 3,600.00 .. _ _ - 27 3 EA Traffic signal cabinet concrete pad Remove $ 400.00 $ 1,200.00 attery ac up umt extema ca met on tra ic signa 28 ]0 EA �abinet Install $ 600.00 $ 6,000.00 --' ___ _ — eter pe esta service wi terminations pa rnoun[ no 29 2 EA �oncrete aad Install $ 2,000.00 $ 4,000.00 _ _ _ __ eter pe esta servrce v✓� termrnations pa mounte ) wt 30 10 EA �oncrete nad Fumish and Install $ 5,000.00 $ SQ000.00 96 Exhibit "F" Respondent's Name: Durable Speciaities, Inc. RFP 5442 - Pricing Sheet for CONSTRUCTION OF TRAFFIC CONTROL INTERSECTIONS The responde�r! shall comple�e !he jollowing seclion, which direclly corresponds lo �he specificalrons. The conlraclor sha!! no� make changes to lhis forntar. Product Proposal Pricing: We are estimatling on 10 intersections a year for 3 years — 30 intersections for the total estimated amount. �sr. _ _ _ _ _ _ — Item ANNUA� Product Description Descriptlon 2 qTY UOM Unit Price ' Exteoded Price 31 2 EA Meter nedestal service concrete pad Furnish and Install � 900.00 $ 1,800.00 32 4 EA Meter pedestal electrical service and concrete pad Remove S 500.00 $ 2,000,00 33 4 EA Electrical service, overhead Remave $ 500.00 $ 2,000.00 34 320 LF ��_� �r .�fal �ii9� foundation with f csur�d r�krJ, (:�nss C" concrete Furnish and lnstal] $ 175.00 $ 56,000.00 35 48 LF 30-A Si�al pole foundation with praund rod, Class C concrete Furnish and lnstal] $ 200.00 $ 9,600.00 36 52 LP �� foundation with x•�und reicl, Class C cs��e-ctc Furnish and Instail $ 225.00 $ 11,700.00 37 72 LF �� ,�t�l �c�i'e foundation with rt�u�td s��asl, Cia�� C concrete Fumish and lnstall $ 245.00 $ 17,640.00 38 528 LP 48-A SiQnal pole foundation wi4h �round rod, Class C concrete Furnish and lnstall $ 275.00 $ 145,200.00 39 12 EA �i �� a�� o�s�cisaii�srr {18" below r��n�l mdt7urnts�n} Remove $ 500.00 $ 6,000.00 40 16 EA f.om,. Rqust �trm n1:,��3�aaal�� p��iilt 5{k°-G5' mast arrn Install $ 1,800.00 $ 28.800.00 -- Loir�z I�i;i�i '1�m ! �i;,,� �,rt� x p xvil �� ->., i'�as�t arm, no urnsn�tr�� _ — - � 41 4 EA or ILSN �nsr Install $ 900.00 $ 3,600.00 42 6 EA Lon�z \last �1rm Pole Cnstall $ 900.00 '.G �,�t3(7'.�i�? 43 6 EA �.�}it,� i�qast nrm 50'�6g' Install $ 900.00 $ 5,400.00 _ __ , _ _ _ :- 44 8 EA �,�ma Mast :1rm (nssemhl� ) with 50'-65' mast arm Remove $ 1,100.00 $ 8,800.00 45 _ 8 EA l,sis i-L�=� lrria �U'-�a�` __ _ Remove $ 600.00 $ 4.800.00 _ __ _ _ _ ! 46 8 EA Sin�_Ic �I:�ti� nr�n (Asscn,hh•1 with 36'-48' mast arm Install � 1,�(1f�,�l�l $_ 9.600.00 _ Sicir.ly; �tast ltrm (l�:;srnrbl} } tvl[�9 ��r'�1�' mast arm, no 47 4 EA ��naire or 11,5�1 arm install $ 650.00 $ 2,600.00 __ _. _ _ _ _ 48 4 EA Sinrlir'�P jsi /�riri f'�rls� {`it�r a 36'-48' acnt) lnstall $ 650.00 $ 2,600.00 49 ' 4 EA Sinelc Ma,t Arm 36'-48' Install $ 650.00 $ 2,�i�}(1.{�U __ _ _ _ _ __ _ _ __ 50 8 EA ti1i!+�J� Matit nrni t�'1,w�� iii31�. j�*ith a 36'-4$' mast arm Remove $ 900.00 '6 7,�i�Q.[)t) ' 51 8 EA �in,J�a i�,r£,y �trr�� 3�+'_��' . ._ Remove $ 450.00 $ 3,600.00 , __ _ _ _ _ _ 52 2 EA Sinalc Miltil /�I�III (AtiSCI11I7I\') WICIl2O'-32' mast arm Install $ 1,100.00 '� 7.,7f��.�i�Y __ _ Sin�lc �4ast Arm (Asscnibl� ) with 20'-32' mast arm, no 53 2 EA �uminaire or ILSN arm Instali $ 1,100.00 $ 2,200.00 _- 54 2 EA 5,jrs�+.l� �t,�,� ��ri�r Pole (f�r a 20'-32' �� Install $ 550.00 S 1,100.00 55 2 EA �,�,s��i§ \��,s� hrm 20'-32' Install $ 550.00 $ 1,100.00 ' __ -- _ __ _ _ __ _ 56 4 EA SiEtale ft7usi nrm (Assenil�l� } v✓ith a 20'-32' cnast arnq Remove $ 500.00 $ 2,000.00 _ __ . _ — . __ _ _ 57 4 CA c;E��:_,�� q�is� ,y�•i.s ��+_3�� Remove $ 500.00 $ 2,000.00 58 4.. EA Strain l'crl�; l,�-,r,c i�9+1� �, 34' .. Install $ 800.00 $ 3.200.00 __—_ _ __ _ _ . 59 2 EA Strain Pole (,�sscinhl� l. 34', no luminaire or 1LSN arms Install $ 800.00 $ 1,6tit1.f1�1 __ _ 60 4 �� Strain Pole (Asscmhlv) Remove $ 400.00 $ 1,G�}i1,�7iD 97 Exhibit "F" Respondent's Name: Durable Specialties, Inc. RFP 5442 - Pricing Sheet for CONSTRUCTION OF TRAFFIC CONTROL INTERSECTIONS The respondent shal! complere rhe foJlowrng secrion, which direcdy corresponds ro rhe specificarrons. The conrracror shall nor make changes ro this jorina�. Product Proposal Pricing: We are estimatling on 10 intersections a year for 3 years - 30 intersections for the total estimated amount. _ _ _ ____ - _ EST, Item ��*�� Product Description Description 2 QTY � UOM Unit Price Extended Price ___ __.- . .. _ . 61 ] 6 EA Luminaire Arm 8-10' Install $ ] 50.00 $ 2,400.00 _ _ ._._ 62 24 EA Luminaire Arm 25' Install $ 200.00 $ 4,800.00 _ _ ____ _ 63 40 EA 'ILSN Arm 7'-9' lnstall $ 100.00 $ 4.000.00 _----- - --- - _ __ __ _ 64 4 EA Luminaire Arm Remave $ 50.00 $ 200.00 ' 65 4 EA R,SN Arnt Remove $ 50.00 '$ 200.00 ' _ __ __ __ _ - - 66 12 EA 50', Class 1 timber �ole Install $ 775.00 $ 9,300.00 _ ._ _ 67 2 EA 50', Class 1 timber uole Furnish and Install $ 1.800.00 $ 3,600.00 68 4 EA ,50', Class l, timber pole assembly, one tuschor design Furnish and Install S 2.100.00 $ 8,400.00 _ _ _ __ _ - _ _ 69 16 EA 50', Class 1, timber calc: ass�ml�l, , two anchor �c;::"r n Furnish and Install $ 2,400.00 $ 38,400.00 _ _. _ . _ _ _ _ __ 70 ' 8 EA Timber aole anchor assemblv Fumish and Install $ 275.00 $ 2,200.00 _- - - _ __ 71 4 EA Timber oole (entire oole) Remove $ 375.00 $ 1,500.00 i2 4 EA Timber nole (18" below eroundl Remove $ 375.00 $ 1.500.00 73 8 EA 5-section sienal head assemblv Install $ 700.00 '$ 5,600.00 ' 74 20 EA 5-section (cluster) signal head assembly Install $ 700.00 $ 14,000.00 _ _ _ __ 75 36 EA q_section siartal head assemblv Install $ 575.00 $ 20,700.00 76 72 EA 3_section sienal head assemblv Install $ 450.00 '$ 32,400.00 77 8 EA 5-section f�it� sunnlicd) siRnal head (pole mountcd) Furnish and Install $ 850.00 $ 6,800.00 . _ _ _ _ _- 78 20 EA 5-section (�:lusEer !� ra s�;i� ra+li��l �;si � e�l ia��d ( cal� mc��ntEs�� Furnish and [nstall $ 950.00 $ 19,000.00 79 64 EA 4-section (cit� 5upI�IiCd) SB�718I I108CI (pOIO Sri0Utl1Cd) Fumish and Install $ 750.00 $ 48,000.00 . ..._ . .... ___-_ .. ....___ 80 72 EA 3-section Icil� ,unnlic�ll sienal head (nole mountccJl Furnish and Install $ 650.00 $ 46,800.00 81 8 EA 5-section Ici�� suni�licd) sisnal hesd (span mountal} Fumish and Install $ 1,100.00 $ 8,800.00 ' 82 8 EA 5-section (cluster} (cii� supnlicd) si�nal head (span mounted} Furnish and Install $ 1,100.00 $ 8,800.00 $3 16 EA 4-section (cit� sunnlic�ll sienal head (snan mountaq Furnish and Install $ 1,000.00 $ 16,000.00 _ _ 84 48 EA 3-section (cil� sunnlicdl sisnal head (span mountcJ) Furnish and Install $ 850.00 $ 40,800.00 ' _ _ -- 85 48 EA Si�nal head assembly Remove $ I50.00 $ 7,200.00 86 20 EA Reeulatorv sien Install $ 70.00 $ 1,400.00 .___ -- __ 87 48 EA Reeulatorv sien (c:i�� s;uni7licdl lpole mounted) Furnish and Install $ 100.00 $ 4,800.00 8$ 36 EA �e�ulatorv si�n (cil� ,uonlicJ) (span mountcd} Furnish and Install '$ 235.00 $ 8,460.00 89 4 ' EA Street name siQn Install $ 140.00 $ 560.00 90 _4 EA Slre�� Srtot�r 4p y�� G�� ;�i � rli� �l ]�€�I�; n��s��il� ci Furnish and Install $ 200.00 $ 800.00 91 4 EA Street name si�n (cit� suni�licd) (span mountrclD Furnish and Inslall $ 300.00 $ 1,200.00 , .- - - 92 24 EA Sie,n (Re¢.ulatorv/Street name) Remove $ 70.00 $ 1,680.00 93 40 EA ILSN Si�n 6' Install $ 300.00 � 12.000.00 98 Exhibit "F" Respondent's Name: Durable Specialties, Ine. RFP 5442 - Pricing Sheet far CONSTRUCTION OF TRAFFIC CONTROL INTERSECTIONS The respondent shall complele !he following section, which directly cor•responds !01he specificalrons. 7he comracror sha!! no! make changes lo lhis forrnal. Product Proposal Pricing: We are estimatling on 10 intersections a year for 3 years - 30 intersections for the total estimated amount. __ _ __ _ __ __ _ - EST� Item pNNUa� Product Description Description 2 QTY UOM Unit Price Extended Price ' 94 12 EA �LSN Sien 6' Remove $ 200.00 $ 2,400.00 95 40 EA Luminaire iia��tl Install $ 70.00 $ 2,800.00 _ _ _ _ 96 4 EA Luminaire head Remove $ 70.00 $ 280.00 _ _ _. _ 97 40 EA �y�rid damuener (cit� sunnlicd si�n) for mast arm Furnish and Install $ 250.00 $ 10,000.00 ____ _ 98 4 EA W�nd tlarxa eG��° f�ar i��tist arm Remove $ 70.00 $ 280.00 _ _. _ ___ _ 99 8 EA VNIDS (video detection camera) lnstall $ 250.00 $ 2,000.00 __ _ __ _ ]00 12 EA p�ildZoom camera (PTZ) Install $ 250.00 $ 3,000.00 __ _ -- _ 101 20 EA pdvance radar detection Install $ 350.00 $ 7,000.00 -- _ ] 02 40 EA ��rescaa�c a°��icar c�e:tes�4�un Install $ 350.00 $ 14,000.00 103 20 EA pnticom detector Install $ 200.00 � 4,dlt)�l.i}Il __ ...s � __ _ __ ] 04 ] 0 EA Wireless radio with antenna(s) lnslall $ 200.00 $ 2.000.00 __ 105 2 EA Spread Spectrum Radio (SSR) antenna Install $ 125.00 $ 250.00 -- 106 12 EA y��r�l)5 vi��.rr detection ��:7�:r�) Remove $_ 125.00 $ 1,500.00 107 4 EA pan/TildZoom camera (PTZ) Remove $ 125.00 $ 500.00 ] 08 4 EA Advance radar detection Remove $ 125.00 $ 500.00 _ -- 109 8 EA �s��,nce r�t�ar detection Rernove $ 125.00 � 1,000.00 _ - . -_ __ _ 110 8 EA �� i�� detector Remove $ 125.00 $ ].000.00 . __ _ - _ .. 111 4 EA �rri,��s� radio witli �ntc€�nu s} Remove $ 125.00 $ 500.00 _ _ _. 1] 2 4 EA Spread Spectrum Radio (SSR) antenna Remove $ 60.00 $ 240.00 _ _ 1 13 2 EA Roadside flasher beacon assemblv (salar powered) Instal] $ 2,500.00 $ 5,000.00 ' _ ._. _ _ 114 2 ' EA Roadside flasher beacon assembly Remove $ 650.00 $ 1,300.00 115 48 EA }s��.��{;�� i�� th LED insert on metal �ric Install $ 255.00 $ 12,240.00 116 ' 32 �A pedestrian head with LED insert on timber pole Install $ 500.00 $ 1�{i,�(If:}.t)f) 117 48 EA pedestrian button station assembly on metal pole Install $ 70.00 $ 3,360.00 118 32 EA pedestrian button station assembly on timber pole Install $ 125.00 $ 4,000.00 . _ . _ . __ _ 119 24 EA pedestrian �ush button oole assemblv Install $ 375.00 $ 9,000.00 120 36 �A pedestrian nush button nole assembly with 4' pole Furnish and Instal] $ 725.00 $ 26,100.00 121 12 EA pedestrian push button pole assembly with 16' pole Purnish and Install $ 1.200.00 $ 14,400.00 __ . ___.__ .__ ___ _ _ _ 122 24 EA Pedestrian head Remove $ 125.00 $ 3,000.00 123 24 EA ��d��y��ayy button station Remove '$ 60.00 $ 1,440.00 124 8 EA • Remove $ 255.00 $ 2.040.00 Pedestram aush button pole assembly _ _ _ _ _ __ 125 600 LP Zino-coat steel wire strand (3/16 in) Furnish and install $ 2.00 $ 1,200.00 126 1,600 LF Zinacoat steel wire strand (1/4 inl Furnish and install $ 2.00 '$ 3,200.00 ��] Exhibit "F" Respondent's Name: Durable 5pecialties, Inc. RFP 5442 - Pricing Sheet for CON57RUCTION OF TRAFFIC CONTROL INTERSECTIONS The responden[ shal! complete lhe followrng seclion, which drrec[!y corresponds fo fhe specifrcalions. The con[raclor shalJ no1 make changes lo rhis jormat. Product Proposal Pricing: We are estimatling on 10 intersections a year for 3 years - 30 intersections for the total estimated amount. -- _---- EST. Item ANNUAI Product Description Description 2 qTY UOM Unit Price ' Extended Prlce 127 600 LF ��nc-coat steel wire strand (5/16 inl Furnish and install $ 2.00 $ 1,200.00 128 6,800 LF Zino-coat steel wire strand (3/8 in) Fumish and install $ 2.00 $ 13,600.00 ]29 ],200 LF zino-coat steel wire strand Remove $ 1.00 $ 1,200.00 . _ - ___ _ 130 2 EA Entire mast arm pole intersection, 3 pole desiRn Remove $ 2,100.00 $ 4,200.00 ' 131 2 BA i Entire mast arm oole intersection. 4 oole desien Remove $ 2,700.00 $ 5,400.00 -- _ _ - - -- - 132 1 EA Entire timber �ole intersection, 3 nole desi�n Remove $ 1,390.00 $ 1,390.00 133 2 �A Entire timber pole intersection, 4 pole desi�n Remove $ 1,800.00 $ 3.600.00 ' 134 ]4,200 LF °rraf6c Sienal Cable (Twe Al 14 AWG (7 conductorl Fumish and Install $ 1.00 $ 14,200.00 135 400 LF �'raffic Sienal Cable (Tvoe A) 14 AWG (9 conductor) Fumish and Install $ 1.00 $ 400.00 ' 136 400 LF Traffic Si�nal Cable (Type A) l4 AWG (10 conductor) Fumish and Install $ 2.00 $ 800.00 137 4,800 LF Traffic Simal Cable (Twe Al 14 AWG (21 conductor) Furnish and lnstall $ 3.00 $ 14,400.00 138 4,800 LF Traffic �ai f sa� Cable `f` c,�} 14 AWG (�5 cr��cl�et�s� Furnish and Install $ 3.50 $ 16,800.00 139 300 LF Traffic Si�nal Cable (Tvpe Cl 12 AWG (2 conductor) Furnish and Install $ 1.00 $ 300.00 _ __ 140 300 LF Traffic Si�nal Cable (Type C) ] 4 AWG (2 conductor) Furnish and Install $ 1.00 $ 300.00 141 300 LF ��°��c Si ��u1 Cable {"1" � C: 18 AWG 2 wnc�uctt�r Furnish and Install S 1.00 $ 300.00 142 950 LF Electric conductor stranded (No. 4 AWG) insulated Fumish and Install '$ 2.00 $ 1,900.00 --- _ . _ . _ 143 200 LF Electric conductor stranded (No. 4 AWG) bare Furnish and Install $ 2.00 $ 400.00 144 600 LF ��a��i��; conductor stranded NG�. 6 AGV(;t insulated Furnish and Instell $ 1.00 $ 600.00 ___ . __ 145 200 LF Electric conductor stranded (No. 6 AWG) bare Fumish and Install $ 1.00 $ 200.00 146 200 LF Electric conductor solid (No. 6 AWG) bare Furnish and lnstall $ 1.00 $ 200.00 __ 147 325 LF Electric conductor stranded (No. 8 AWG) insulated Furnish and Install $ 1.00 $ 325.00 148 125 LF Electric conductor stranded (No. $ AWG) bare Pumish and Install $ 1.00 $ 125.00 149 � 4,600 LF Tray Cable 12 AWG (3 conductor) Furoish and Install $ 1.00 '$ 4,600.00 . . _._ _ _ 150 4,600 LF •� �.� Cable 14 AWG {� t;�tt�luctt�r� Fumish and Install $ 1.00 $ 4,600.00 15 ] 720 LF Trav Cable 16 AWG (3 conductor) Fumish and ]nstall $ 1.00 $ 720.00 __ _ . _ __ . 152 450 LP Tray Cable 12 AWG (4 conductor) Fumish and Install $ 1.00 $ 450.00 153 320 LF Trav Cable 14 AWG (4 conductorl Fumish and Install $ 1.00 $ 320.00 _ . _. _ 154 ' 2,400 LF �'TT Opticom System Cable 20 AVJG (3 conductor} black sheilded Fumish and Install $ 1.00 $ 2,400.00 ' I55 1,000 LF gelden 7919A Cat SE black sheilded or equal Furnish and Install $ 3.50 $ 3,500.00 156 1,500 LF Multicondutor cable (1/4" O.D. and smaller 1 lnstall $ 1.00 $ 1,500.00 157 1,800 LF Multicondutor cable (5/16 "- 3/8" O.D.) [nstall $ 1.00 $ ],800.00 , . __ 158 1,200 LF 'Multicondutor cable (7/16" - 5/8" O.D.) Install $ 1.50 $ 1,800.00 159 1,200 LF Multicondutor cable (11/16" -7/8" O.DJ Install $ 1.50 $ 1,800.00 100 Exhibit "F" Respondent's Name: Durable Specialties, Inc. RFP 5442 - Pricing Sheet for CONSTRUCTION OF TRAFFIC CONTROL INTERSECTIONS The responden[ shall complete !he follotivrng sec�ian, whrch direcdy corresponds !o !he specifrcalions. The contraclor shal! no� make changes to Ihrs formar. Product Proposal Pricing: We are estimatling on 10 intersections a year for 3 years — 30 intersections for the total estimated amount. Item Q7Y UOM' 160 1,500 LF �� ]61 1,500 ' LP Si 162 .1,500 LF Si 163 1,500 ' LP �� Additional Services Product Description s�r multicondutor cable (1 /4" O.D. and sm�sl or multicondutor cable (5/] 6"- 3/8" O.D.) or multicondutor cable (7/16'° - 5/S°° O.D.} or rt�uliicc�rtduie�r cable ( l 1/16" -7/8" l},l)�') Descriptlon 2 Unit Price Extended Price Remove �I, $ 0.50 $ 750.00 Remove $ 0.50 $ 750.00 Remove $ 0.50 $ 750.00 Remove �� $ 0.50 $ 750.00 Total Cost of Products (Annual) $ �,396,500.00 .__ . . __ Item UOM Prods�ct �1�sc�iptior� Description 2 Unit Price ] 64 E�at�rl �ontractor Services Price Per Hour with Aerial Truck This includes aerial & gound services , $200.00 This includes aerial, growd, end span 165 Piniuly Contractor Services Price Per Hour for span wire intersections pole instailation/removai services 5400.00 7tus includes aerial, gound, and mast ' 166 ' Houriy Contractor Services Price Per Hour for mast arm pole intersections ami uole installation/removal services. '' $400.00 . _ _ _._ _ _ _ _ _ . - 'Percent of total purchase order amount 167 % Mt�!>�9ax�s13n�� (Smaller projects) nut ia cscrc.d ��"6 10 . _- _ __ 168 Ea Mobilization oer Interseetion For complete intersecaon builds $2,500.00 ' -- _ __ . — _ c e u 4�e�ie cmeaPractor c�n starf a si�¢al projecY in Denton altcr ioiriicc iu 169 Days 'Cimeline to start Projeci piucc��d ihr�5urh a pu�ehasa c}�de� 50 Emergency response for a contractor tQ � 7(} { �� y i\n i� al time to start Emergency Pro}ect repair/replace signals in Denton 4 fibS RFP #5442 Exhibit "F" Addendum # 1 GENERAL NOTES FOR BID LINE ITEMS: All materials shall be of the latest City of Denton / TXDOT specifications with their corresponding item codes Install items shall be with city supplied materials unless otherwise noted on line item Furnish and install items shall be with contractor supplied materials unless otherwise noted on line item All bid line item installations shall be completed with terminations and fully operational after installation Ground box, signal cabinet pad, and meter pedestal pad installations shall include conduit stub ups and tie-ins with bell ends at the end of each conduit. Traffic signal cabinet base shall be Armorcast A6001848X24TXDT or a predetermined city approved equal. Meter pedestal service shall be Electrol systems, TXDOT standard green powder coated aluminum type D pedestal, TYD 120/240 070 (NS)AL(E)PS(U): 1-SOa/1p for traffic signal, 2- 20a/1p for lighting, 1-15a/1p for control circuit, interior photo cell with windows, 30 amp lighting contactor, and HOA selector switch. All mast arm or timber pole assemblies shall include pickup and delivery from and to job site in Denton unless contractor supplied. Timber poles shall be creosote-treated southern yellow pine and shall be set using approved expanding foam method. Furnish and Install timber pole assemblies include a one or two anchor design, and in each case, shall contain all connecting hardware for each strand wire support and each pole anchor guy. Some installations may include a guy spreader. Timber pole anchors shall be set using Class C concrete and contain all guy cable and connecting hardware from anchor to timber pole. Pedestrian head installations on timber poles shall include a NEMA type 3R junction box with a liquid tight conduit to each pedestrian head and associated mounting hardware. Pedestrian push button station installations on timber poles shall include a liquid tight conduit to pedestrian head junction box with associated mounting hardware. Pedestrian push button pole assembly furnish and installs shall contain Pelco parts consisting of 1 EA: PB-5335-GL-PNC, PB-5306, PB-5325, PB-5401, AND PB-5100 � 102 Exhibit "F" RFP #5442 Addendum # 1 GENERAL NOTES F�R BID LINE ITEMS: Rigid metallic (RM) conduit shail contain appropriate weather head and mounting hardware. Salvage existing traffic signals and equipment as shown on plans and as directed by the City of Denton. Removal of each intersection shall include all above and below ground traffic signal related items except for electrical services. Conduit stub ups and concrete foundations must be removed 18" below ground and then can be abandoned. ADA ramps and pavement markings are excluded. Wind dampener (dampening plate) only will be supplied by the city; all other mounting hardware shall be provided and installed by the contractor. Traffic signal pole foundation anchor bolts will be supplied by the city at time of foundation installation. Long and single mast arm assemblies will contain a vertical pole assembly, a mast arm, a luminaire arm, an ILSN arm, and an anchor bolt base cover. Strain pole assemblies will contain the vertical pole, a luminaire arm, an ILSN arm, and an anchor bolt base cover. Install signal head items shall include labor only for a complete assembly using LEDs, visors, backplates, and mounting hardware. Furnish and Install signal head items shall include labor only except for contractor supplied Pelco AS-0125/AS-0138 signal head mounting hardware for pole mount or SP-3058-TX-ALO/AS- 0138 signal head mounting hardware for span mount. Furnish and Install Regulatory and Street name sign items shall be a city supplied sign and line item cost will only include the sign's mounting hardware and labor. Timeline to complete each workorder, after notice to proceed through a purchase order, will be 30 working days for a 4 pole intersection, and 45 days for a 6 pole intersection. City supplied materials to signal contractor that will need to be programmed for signal operation, will be the responsibility of the City of Denton. Installation/mounting and mounting adjustments of such items will be a pay item to the signal contractor. 12 103 Exhibit "F" Texas ranchise Tax u lic Infor ation e ort ��r ,� ��" 05-102 To be filed by CorporaPions, Limited LiabNiPy Companies (LLC) and Ffnancial tnstitutions 'f'� 4�`:=. (Rev.9 11/30) This report MUST be slgned and flled to satisfy franchlse tax requirements `" �� ` �a:��Ee 13196 Franchise ■ i,axqraye€ number � 6d�F;rcyrEyear Youhaveeertatnrl htsunderCha ter552and559 6overnmentC d 1 7 5 1 9 6 3 4 5 E,�xpayer name DURABLE SPECIA�.TIE �'7C INC. g p , o e, —��^�2 O, 1 � to review, request, and correct information we have on fife aboutyou. - �� Contact us at (8001 252-1 38 1 or (512) 463-4600. maning aaaress �ecretary of State (SUS} tile number or PO BOX 535969 Comptrollerfilenumber City State �IF' C:ode ;ylus 4 GRAND PRAIRIE TX 75053 0070837900 � 81ar.ken circle ifthere are r.urrently no changes from previous year; if nm infarrnation is displayed, complete 4he applicable inf�rm�Pion in Sections A, B and C. _ I�rkr7i r�a,al c�lt�res� " 2302 Paddock Vt►a Dr. Grand Prai��i�, Texas 75050 �'rl��ri�a�! �p�ace trf k��asi�s�ss 2302 Paddock W�y Dr. Grand Prairi�, Texas 75050 . C`'1€�C��, �1ieeCFar a€�d air;�n�ycat k�tii�tr'rr rfiearl i� rr�]�tries# �s c5f 9he ckaie a I�uL�96[ 9rlfr�rm 3t�s�ra . 'j��IQf� f� il ��pk/� �irF�3�i� i�, �i�n9g�alt T� �i. �PMi�=a�kdcarr�w�atihr� is u�j�d,�t¢�si.3tt�lwr�rf�� as �'�a�i a�{ iPro� #s�rtrit�s�° f�,x. 1.�---'�'°`^"�� tL'j1i..bE`1. � ili?fS" €S P1d5 fi,'S.�.t11fFf17iFit. t7f� �7Sf5C¢`i�t.3Y(.' �i,7f ?l4l�"7�7�F'€YSCPkEl1i(� 9�i1f"_ N�Y[UttT'il!lElUf1 s�Yr zaf�er��rs, clrr��cts�r�s trr ��t3o�:'sc�rrs cl��xn�f= tlrrrt�ic�ft�ua t6�e� y��ar, SECTION A Name, title ,�rtr1 r1'r�rlknt� ��it�res� t5f �trt d� �sf�rt,tt��, tS��s a':ts�p� csr r�a�q�n��f.r. 17519634590i3 SECTION B Enter the iriforma[ion required for each corporation or LLC, if any, in which this entity owns an interest af 10 percen[ or more. SECTION C Enter the information required for each corporation or LLC, if any, that owns an interest of 10 percent or more in [his entity or IimiYed liability company. Narne of owned (parent) corparation or limited IiabiliYy company State nf formatian Texas Sd5 file nurrt er, af any Perz erip�� c�ir�ws�kArsbispa ' Itegis[ered agent and registered office currently on file. (see instructions i(you need to make changesJ Blacken cirde if yau need forms to chanye � Agent: J�FF EY C RYQ O the registered agent or registered offiee information, luirice: 5208 BYERS AVENUE �`�' FORT WORTH ��"'V" TX �� 107 7hc above infiormation is requuca by Section t 71 203 of the Tax Codc foi cach coiporation or limited liability company thae files a iexas Franchise iax Report Usc add'scional shcets for Sectians P,, B, and C, if neressary, 7he in(onnatioiti will bc avai{abfe for public inspection, .......� � � i dedare that the infarmation in this document and any attachmcnts is crue and correct to the best of my know6edge and belief, as oe the date below, and Yhat a copy of this report has been mailed to each person named in this report who is en officcr, director or manager and who is not currcntly employcd by this, ar a related, mrpoiation or limited liability company, SIC�Ii � T�tde �� W� Date � Area code and phone number he1'e � CAROL A RICHTER 08-12-2013 ( 972 ) 296 - 6324 � Electronic � �exa� ��mp��lt�r �4�i+�i�! �� q�n�� ; - � � ; , �..,� , � �� 104 ATTACHMENT G CONFLICT OF INTEREST QUESTIONNAIRE FORM CIQ For vendor or other person doin� business with local �overnmental entity _ _ __ _ This questionnaire reflects changes made to the law by H.B. 1491, SOth Leg., Regular Session. OFFICE USE ONLY This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person ��t� �a�ce��ea who has a business relationship as defined by Section 176.001(1-a) with a local governmental entity and the person meets requirements under Section 176.006(a). By law this yuestionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. � Name of person who has a busincss relationship with local governmental entity. 2 ❑ Check this box if you are tiling an update to a previously filcd questionnaire. (The law requires that you 61e an updated completed questionnaire with the appropriate filing authority not later than the 7`" business day after the date the originally filed questionnaire becomes incomplete or inaccurate.) 3 Name of local government officer with whom filer has an employment or business relationship. Name of Off cer This section, (item 3 including subparts A, B, C& D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1-a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? 0 Yes No B. Is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? � Yes � No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? � Yes 0 No D. Describe each affiliation or business relationship. 4 Signature of person doing business with the governmental entity Date 105