The URL can be used to link to this page

2015-043ORDINANCE NO. 2015 -043 AN ORDINANCE ACCEPTING COMPETITIVE PROPOSALS AND AWARDING A CONTRACT FOR THE RENTAL OF HEAVY EQUIPMENT FOR VARIOUS CITY OF DENTON DEPARTMENTS; PROVIDING FOR THE EXPENDITURE OF FUNDS THEREFOR; AND PROVIDING AN EFFECTIVE DATE (RFP 5639- RENTAL OF HEAVY EQUIPMENT AWARDED TO THE LOWEST RESPONSIBLE BIDDER MEETING SPECIFICATION FOR EACH ITEM, IN THE ANNUAL ESTIMATED AMOUNT OF $1,175,000 FOR A THREE (3) YEAR NOT -TO- EXCEED AMOUNT OF $3,525,000). WHEREAS, the City has solicited, received and evaluated competitive sealed proposals for the rental of heavy equipment in accordance with the procedures of State law and City ordinances; and WHEREAS, the City Manager or a designated employee has received and reviewed and recommended that the herein described proposals are the most advantageous to the City considering the relative importance of price and the other evaluation factors included in the request for proposals; and WHEREAS, the City Council has provided in the City Budget for the appropriation of funds to be used for the purchase of the materials, equipment, supplies or services approved and accepted herein; NOW, THEREFORE, THE COUNCIL OF THE CITY OF DENTON HEREBY ORDAINS: SECTION 1. The items in the following numbered request for proposal for materials, equipment, supplies or services, shown in the "Request for Proposals" on file in the office of the Purchasing Agent, are hereby accepted and approved as being the most advantageous to the City considering the relative importance of price and the other evaluation factors included in the request for proposals. RFP NUMBER CONTRACTOR AMOUNT 5639 B &R Equipment Co. Exhibit A 5639 Kirby -Smith Machinery Exhibit A 5639 United Rentals Northwest, Inc. Exhibit A 5639 Bane Machinery Exhibit A 5639 T -K -O Equipment, Inc. Exhibit A 5639 R.B. Everett & Co., Inc. Exhibit A 5639 Landmark Equipment, Inc. Exhibit A 5639 Hertz Equipment Rental Corp. Exhibit A 5639 Associated Supply Co, Inc. Exhibit A 5639 Blue Line Rental Exhibit A 5639 Closner Equipment Company, Inc. Exhibit A SECTION 2. By the acceptance and approval of the above numbered items of the submitted proposals, the City accepts the offer of the persons submitting the proposals for such items and agrees to purchase the materials, equipment, supplies or services in accordance with the terms, specifications, standards, quantities and for the specified sums contained in the Proposal Invitations, Proposals, and related documents. - SECTION 3. Should the City and person submitting approved and accepted items and of the submitted proposals wish to enter into a formal written agreement as a result of the acceptance, approval, and awarding of the proposals, the City Manager or his designated representative is hereby authorized to execute the written contract; provided that the written contract is in accordance with the terms, conditions, specifications, standards, quantities and specified sums contained in the Proposal and related documents herein approved and accepted. SECTION 4. The City Council of the City of Denton, Texas hereby expressly delegates the authority to take any actions that may be required or permitted to be performed by the City of Denton under File 5639 to the City Manager of the City of Denton, Texas, or his designee. SECTION 5. By the acceptance and approval of the above enumerated bids, the City Council hereby authorizes the expenditure of funds therefor in the amount and in accordance with the approved proposals. SECTION 6. This ordinance shall become effective immediately upon its passage and .. . rov......� ........... approval. al. PASSED AND APPROVED this the / % day of , 2015. �i CHRIS WATTS, MAYOR ATTEST: JENNIFER WALTERS, CITY SECRETARY I: TO LEGAL FORM: , N['l`A BURGESS, CITY ATTORNEY �'.... f ct a w w E a m w I mm IN 25 -6 -6 uj Z 15 t5 2 > UJ > > Z (0 x m 0 0 I L 2 Ir -6 K6 2 0 U (D A UJ :n M �2 �2 I IL t5 V M --- --- 0) L l Z �l I Lu 2 z z LLI z P 0 w z 0 P Q w V) z 0 0 P: U) a a 1 E E E z 2 > z 4 ou z 0 z 0 I P U'j w N w mm IN 25 -6 -6 uj UJ Z (0 x m 0 0 I L 2 Ir -6 K6 2 1 A A A UJ :n M (L I IL x -2 5 --- --- 0) L l �l I 2 z z LLI z P 0 w z 0 P Q w V) z 0 0 P: U) L", j 0. (L z 2 > z 4 U'j z--- ----- - - — U w u P ui to LLA w (n IBM CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND B &R EQUIPMENT COMPANY (FILE 5639) THIS CONTRACT is made and entered into this P? day of fta'ress D., 2015, by and between B &R EQUIPMENT COMPANY a corporation, who is 3100 KELLER HICKS RD, FT WORTH, TX 76244, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written. APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY BY : Ile, M File # 5639 Title: 4�/*i 42,lil- jjwA -do, ' / PHONE NUMBER CITY OF DENTON TEXAS BY. GEORGE t'`. CAMPBELL, CITY MANAGER Date: 22,1 174/f' Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $750,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Standard Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on the face of the contract /purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, and 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 1 l , 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE /TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box 1 of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non- complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of: i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable fling of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 15. FINAL PAYMENT AND CLOSE -OUT: A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE /WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of I% or greater. If an overpayment of I% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books" "records" "documents" and "other evidence" as used above shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE /MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File # 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY- PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non- conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. If such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on any policy. It is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon location, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon either of the parties hereto or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii. The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the claimant(s); the basis thereof; and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLES: The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 shall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made - for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work - made - for -hire agreement, in a form to be reasonably approved by the City, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the same secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE RESOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the filing of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a meeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If, within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 5l. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. "Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. I Oa - l Od) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at dzgp ��ww � do[. w It l ��tm -a is /dbra.htni and at the Wage Determinations website www.wdgl.gov for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day. 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. RFPBid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File 4 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted. • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. ■ That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted: [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury. • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required,. File # 5639 Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required. Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. File # 5639 IXl ATTACHMENT 1 Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File # 5639 and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: 1. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 Exhibit E CONFLICT OF INTEREST QUESTIONNAIRE - FORM CIQ For vendor or other person doing business with local governmental entity This questionnaire reflects changes made to the law by H.B. 1491, 80th Leg., Regular Session. This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. Name of person who has a business relationship � nship with local governmental entity, Check this box if you are .. 2 filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7'h business day after the date the on iinall filed uestuonnaire becomes incom lete or inaccurate. 3 Name of local government officer with whom tiler has an employment or business relationship. Name of Officer This section, (item 3 including subparts A, 13, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? fl� Yes a Na 1. Is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? Yes E No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? Yes No D. Describe each affiliation or business relationship. ._ � I have no C��. - ........,, ... ... - ....... 4.. onflict of Intere disclose. 5 "`rig�r� p�,r:��rtr doing business with _.�� - ....... ... ....� .— ...,.�.._ .� the governmental entity Date ......... - ...... ..... _ ......_ i' RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT item I uoM I Product Description # SECTION A - DOZERS I EA Dozer, Cat D10T orer4ruvaloni 2 EA Dozer, Cat D9T or equivalent 3 EA Dozer, Cat D13T ore quIvalent 4 EA Dozer, Cat C17T orequivalepil 5 EA Dozer, LGP Cat D7R or equivalent 6 EA Dozer, Cat D6R ore quivalonl 7 EA Dozer, LGP Cat D6R or equivalent — 8 ---------- EA Dozer, Cat DISK or±Tuillalll 111 9 EA Dozer, Cat D5M or equivalent 10 EA Dozei, Cat D5Koreqolvallent 11 EA Dozer, LGP Cat 1351<orequivalent 12 EA Dozer, Cat D4K or equivalent 13 EA LGP Cat D4K or equivalent SECTION B 'poz.r. - WHEEL LOADERS 14 EA Whed Loader, Cat 988H, or equivalent 15 . . . EA . ..... .... Wfiee[Loader,CM9801-lor ( �iw,�lent .. 16 . ..... . ....... EA ---- — Wheel Loader, Cat 966K or equivalent ---- . ......... 17 EA Wheel Loader. 962K or_�-qyivalen;I 18 EA Wheel Loader, Cal 950H or equivalent EA 'W- heel Loader. Cat 938H or equivalent 20 EA Wheel Loader, Cal �301-1 or oqLiyj,!e2l 21 EA Wheel Loader, Cat 924H or equivalent SECTION C- MOTOR GRADERS 22 - Motor &.d.,, Cat 12M or equWalent T 23 1 EA Motor Grader. Cat 140M or equivalent SECTION D- EXCAVATORS 24 EA Excavatair, Cat 34t CoL ore dvalent 25 EA Excavator. Cat 336DL or equivalent 26 EA Exca vatot, Cal 325 or equivalent 27 EA Excavator, Cat 329E or equivalent w/Grapi 28 EA Excavator, Cat 324E or ecluivalent 29 EA Excavator, Cat 320 or equivalent 30 EA Excavator, Cat 320DL or equivalent w/Gra 31 EA 32 EA Excavator, with hydraulic breaker 3,000 (ft I 33 EA mm� with hydraulic breaker 5,00O (ft I 4 3 i' A �E�xcavMor, Exr, , Excavator, Cat 320 with zero tailspin or eqL _av, SECTION E- SOIL SCREENERS 35 EA Soil Screener, Terex/Fqntay 770 or erpj,'Lvaei 36 EA e,0l4 „z,,creener. Terex /Rruet 790 or equivalleR SECTION F - TRUCKS (OFF ROAD) 37 EA cat 725.�r �t_ 3 T8 EA � Truck, pff-Road), Cat 7309 or 9 39 EA Truck. (Off-Road), Cat 740 or equivalent 23G or eauivalent class, Cal 312D class, Cat 320DL class, Cat 320DL ,lent, Cat 320D screen 3/8” - 1/4" screen EXHIBIT F B&R Equipment Company Ft. Worth, TX Make/Model offered Weekly Rental I Montly Rental I Delivery/Pickup Charge D8T. D8R T D6K, D6N 966H 140H. 160H DOOSAN DX300 CAT 324D $ 4.500.00 1 $ 13,500,00 1 $1960 One time fee $ 1,833.00 1 $ 5,500.00 1 5900 One time fee $ 2,333,00 19 7,000.00 a $900 onetime fee $ 1,667.00 1$ 13,000,00 1 $901) 0111-- 6010 fP:-e $ 1.833,00� $ 5,500.00 1 S900 Onetime fee ..... ---- - $ 1,667.00 $ 5,000.00 � 5900 one time fee T 740. VOLVO A40, JD400 1� $ 3,000.00 1 %Offl 00 $12,()0 One time fee — — — — ------- . .... T 623G 4.33"3.00� $ 13,000 00� 5 1,960 One time fee EXHIBIT F 41 EA Scraper, Cat 621G or equivalent 42 EA Scraper, Cat 615C or lenl 43 EA Sctalvr, Cat 61)�,,q!,quivalpnj - — ----- -------- — S Ec'nON H -TRACK LOADERS ........... 44 EA Track Loader, Cat 973D or equivalent ............ 45 EA Track Loader, Cat 963D ore jival,ent Lqp CAT 963C . ........... . .. ...... 46 EA Track Loader, Cat 953D or equivmmmm SECTION I- COMPACTORS 47 E A Compactor. Cat 825 or equivalent 48 EA Cornpactor, Cat 815F or equNalenl 49 EA Compactor, Cat CP56 or equivalent . . . ....... or 50 EA Compactor. Cat CS56 or equivalent 51 EA Compactor, Cat CP-323-C or equivalent 52 EA Wacker Trench Roller, RT5620 or - equivalent with 22" drum SECTION J - WATER WAGONS (OFF-ROAD) 53 EA Water Wagon. (Off-Road). Cat 613 or equivalent CAT 613 5000 GALLON EA -5� Water Wagon. (Off-Road), Cat 725 or equivalent . ..... SECTION K - WATER TRUCKS (ON-ROAD): Must be TxDOT Approved with License Plates and Tags Water T�uq,k�(qn.Road), 2,D00 gal Truck 5 7 _ — - r 5 W' 5fl EA]EW.terTT�ruck (On -Road), 3,750 or4.000 gal. SECTION L - MIXERSIRECYCLERS 5'7 EATM�- . Xer Png,122R-c-r 58 EA _]!M KeORecy0N, CMI 325n?r eLjulya�enf x� ' EA rrjR . c , Cl�l 500 or equivalent 59 VlixerlRec clef, C . . ..... SECTION M - ASPHALT LAY DOWN MACHINE Machine, 60 EA A phalt; Lay Down 8ft. - 15 ft. SECTION N - ASPHALT ROLLERS 61 EA Asphalt Roller, 9 ton . .. ......... . . . . . ................ . . . -- --------- EA ton 62 SECTION 0 - ASPHALT MILLING MACHINES j - - I'll, 1.11111111-1 . . . . ........ . 1-1111111". . . ......... ------ . . . . . .......... . . . . . 63 EA Asphalt Millino Machine. 4 ft. head .. . . . . . ..... ... . . . . . . . . . ............... . EL41,EA Machine, 6 ft head SECTION P - BROOM 65 FEA Brock FRJ350 Broom or equivalent 5 �aE A Option: Additional cost for gutter boom attachment ...... ..... SECTION 0 - DUMP TRUCK (ON-ROAD): Must be TxDOT Approved with License Plates and Tags J]6:EA: , 12 Yard -- .......... . ........ SECTION R - BACKHOES . . . ........... 67 EA Bacgliven, Case 58ON or 68 EA Backhoe. Case 590N or equivalent - 1 00hp class Options added to Backhoe base price:_ �7,68; EA Additional cost for cab with air conditioning �7.68 EA Additional cost for 4-wheel drive a7-68 Additional EA �d� cost for extendadliq — -- - — .......... SECTIONS - SKIDSTEERS 69 EA Skidsteer, Cat 216B or equivalent 69a EA 22622L.A�ional cost for tracks 70 EA SkidMeer, Cat 226B or eqtavalenl 71 EA Skidsteer. Cat 236B or equivalent 72 EA Skidsteer, Cal 246C or equivalent 73 EA Skidsteer, Cat 256C or equivalent 74 EA Skidsteer. C or equivalent Ej Ski; steer 75 EA �Skidsteer, Cat 272C or equivalent $ 2,000.00 1 $ 6,000.00 1I $900 One time fee $ 1,500,001'$ 4,500,001 $J000netirnefee CERTIFICATE OF LIABILITY INSURANCE DA 0TE 1/29/2015YY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Holl`ie O'Steen Ki0n4nN rdaR�T sander & Perr A enc Inc ( HON ho(254)te FAk _,.,. _ Y 9 Y PHONE, 254 629 3933 (254) 629 1165 (A)P. NP. Exi). ( ) INC, No) PO Box 351 DRCss, en @sbcglobal.net Eastland, TX 76448 _....._ MWuI§FIO_ kFFp,,,rkDINC CovEac ......... NAIC 9 INSURERA, MAXUM INDEMNITY COMPANY A0158 ......... m., —. _ ......... - -- INSURED SouthlakE Equipment Company, Inc. INSURERB: AMERICAFIRST A0092 ......... ... dba B &R Equipment Company, Inc. INSURERC: TEXAS MUTUAL INSURANCE COMPANY 3100 Keller Hicks Rd .. ......... w... ......... Ft Worth, TX 76244 INSURER . INSURER E A INSURER F COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: _wwWWwwwwmm -.. v THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. .... _... ...`" ............. AbOL SOW a ®.,.,., P1�41f"Y' Ef"'F 1041!f.Y' ExP rNSR LIMITS I-TR TYPE GENERAL LIABILJTYFINSURANCE INeR wvn POLICY NUMBER MIWV,IfJOVYYYY MMrIS.[7/YYYY A GLP6019919-03 08/0612014 08106/2015 EACH OCCURRENCE $ 1,000,000 � DAMAGE YO R"I. rrancel 50,000 000 COMMERCNAa G iRAl LIAOIL1`Y PRFMIQF4 lF e-7(Z- . $ I. I aw xW ,m . ..... . ........ . " a WMS•MA.IE rrlR (Y � $ EXCLUDED PERSONAL aaovINJURY �. $ 1,000,000 --------- -GENERAL AGGREGATE $ 2,000,000 Gl --N'L- AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP /OP AGG $ 2,000 „Ot O �h1LL 4 AUTOMOBILE � L AB W(ITIN_Y G�%A 1 �LCG .�. „......� CCTC'MI�IhJI.Y -M �StlhdriLr I� MIT $ I (Fa eu;.ad�allY_„ BODILY INJURY (Per person) $ ALL OWNED SCHEDULED _.ent .. . ... _. ........ AUTOS AUTOS BODILY INJURY accident) $ NON -OWNED ,,,,,, . ._._._ ......._ .. Im�r!cldnn'ikAU'+drti $ "RED AUTOS AUTOS ,( �' ,,,. -- -......... --- -- A uMBRELw uAe OCCUR EXC6019921 -03 08/06/2014 08/0612015 EACH occuzREn. $ 3,000,000 EXCESS LJAB CLAIMS -MADE AGGREGATE $ 000'0W nFn I/ RETENTION s... _ 0 $ WORKERS COMPENSATION •_ TSF- 0001082558 9/12/14 9/12/15 VvL STAT l r Hr C o ® wM ®MBER EXRTNERI 7 N NIA I TOpY t wnIID EMPLOYEE 1,000,000 ANY PRRIMEM OR/PARINER F clmvE E L. EacEHAECCIEDAENr $$ 1,000.000 (Mandatory In NH) .,. K yes, describe under�� DESCRIPTION OF OPERATIONS below Inland Marine _ .... IM8928196 � .... 11/01/2014mmmm mm E L�DISEASE POLICY $ 1,000,000 _ B 11/01/2015 Owned equipment- per schedule Leased/rented Equipment - $500,000 agg DESCRIPTION OF OPERATION LOCATIONS I VEHICLES (.. _.. s Schedule, e .. �.. . S I (Attach ACORD 101, Additional Remarks Schedule, if more space is required) ..... _... ........ .. CERTIFICATE HOLDER �... CANCELLATION Fax#. (940) 293 -1837 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Cityof Denton THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 901 B Texas Street ACCORDANCE WITH THE POLICY PROVISIONS. Denton, TX 76209 AUTHORIZED REPRESENTATIVE @ 1988 -2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010/05) The ACORD name and logo are registered marks of ACORD CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND KIRBY SMITH MACHINERY, INC. (FILE 5639) 1IIIS CONTRACT is rnaleaal entered, into this day 015, by and bctweei K"IRBY SMITI 1 MA.- WIRY, INC. a corporation, whose aaddrp s is 1450 CAL' 1 -00' 82,0 F1.�vOR1 °11 TX 76106, herein alter rel'cr•red to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFPww# 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E" ); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File 9 5639 IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written. ATTEST: JENNIFER WALTERS, CITY SECRETARY BY:� �. APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY File # 5639 CONTRACTOR, BY; �.� Al.pITYt1E tZ1;D SIGNATURE Date:-- - -.�.� Name: ' ", Title: ...,wad yr PHONE NUMBER o. EMAIL ADDRESS CITY OF DENTON, TEXAS BY . GEORGE,, C. CAMPBELL, CITY MANAGER Date: Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $150,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Standard Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on the face of the contract/purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, and 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 11, 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE /TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box I of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property. i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the j ob. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of- i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 15. FINAL PAYMENT AND CLOSE -OUT: A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE /WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of 1% or greater. If an overpayment of 1% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books ", "records ", "documents" and "other evidence ", as used above, shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE /MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File # 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY - PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non - conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. If such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on any policy. It is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon location, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon either of the parties hereto or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii. The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the claimant(s); the basis thereof; and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies.the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLES: The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 shall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made - for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work = made - for -hire agreement, in a form to be reasonably approved by the City, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the same secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE RESOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the filing of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a meeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If; within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639. may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. "Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. 1 O - l Od) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at http: / /www.dol.y,ov /whd/contracts /dbra.htm and at the Wage Determinations website www.wdol.gov for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day. 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, ' supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. RFPBid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted. Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted. [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury. • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. File # 5639 [ ] Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. [ ] Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. [ ] Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required. [ ] Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. File # 5639 ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File # 5639 and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 Exhibit E CONFLICT OF INTEREST QUESTIONNAIRE - FORM CIQ For vendor or other person doing business with local governmental entity This questionnaire reflects changes made to the law by H.B. 1491, 80th Leg., Regular Session. This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. ......... __.........._ _...m....ww _. business relahip with local governmental entity. Name o person who as a bu tions ..._ ............... El 2 Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7'h business day after the date the originally filed questionnaire becomes Incomplete or inaccurate. 3 Name of local government officer with whom filer has an employment or business relationship. Name of ffio ( "" . This section, (item 3 including subparts A, B, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? Yes No B. Is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? Yes a:� o C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? Yes = No D. Describe each affiliation or business relationshi�p�. a ..__... _ � ........................................................ .... ...._.................. .. have no Conflict of Interest to disclose. 5. _ .... .. ....... _.......... _ Is m... Signature of person doing business with the governmental entity _ Date File # 5639 RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT 7-: Item UOM Product Description SECTION A - DOZERS .......... . .... I EA Dozer, Cat D 1 OT or equivalent �C' N A DOZERS EA Do er, PCaD z t 10T or �T or e9 2 EA Dozer, Cat D9T or equivalent 3 EA Dozer, Cat DST or equWalent Dozer" 4 EA Dozer, Cat D7T or equivalent 5 EA Dozer, LGP Cat D7R or equivalent . . ........ . . . ..... . ....... 6 EA Dozer, Cat D6R ore uivalent . . . . ......... . . .... IT_ _7 EA Dozer, LGIPI Cat D61R orequivaler,1 8 EA Dozer, Cat D6K or equivalent 9 EA Dozer, Cat D5M or equivalent 10 EA Dozer,, Cat D5K ore ulvaiand 11 EA Dozer, LGP Cat D51K or equivalent 12 EA Dozer, Cat D4K or eq ulvalent 13 EPA Dozer. LGP Cat DdlKorequIvalent .... . ..... SECTION B - WHEEL EOADERS 14 EA Whael' Loader, Cat 988H or a ulvalartt EA 15 EA Wheel Loader, Cat 980H or equivaland . ..... . . . ..... 16 EA VV�jee Loader, Cat 966K �.r �e L_ __ Wheel EAT 17 EA Wheel Loader, Cat 962K or -±.q!�±4 ��eal . . . . ....... 18 EA Wheal Loader Cat 950H or equivalent .... . . .... ...... . 19 EA Wheel Loader , Cad 938H or eqyivalenl 20 EA� Wheel Loader Cat 930H or equwalent 2 JIE A Wheel Loader, Cat 9241di ore iverarit _q jL SECTION C- MOTOR GRADERS "-" -�' —mill —r--"' . ..... . ........ . ....... 22 EA Mot., der, Cal 12M or equivalent ;EA Grader [2:3 EMoft, Grader„ Cat 140M, or equivalent SECTION D- EXCAVATORS ............... . . .... . ....... 24 EA Ex a Cat 345 K.-2L1)-r _11141,,Iy,�leril . . ........ 25 EA Excavators Cat 336D �` —01"UValent 26 EA Excavator, Cat 325 or atauvalent. 27 EA Excavator, Cat 329E or equivaient w /Ctrs le 28 EA Excavator, Cal j24E or N�IL�dent . .......... 29 EA Excavator, Cat 320 of a, OvMenj 30 EA Excavator, Cat 320DL of equivalent vv/Grapple 31 EA Emla to,, with hyqaullc breaker 1,500 ftjb Lclass, Cat 312D 32 EA Excavator, with hydraujlr breaker 3,000 (it lb) chase, Cat 320DL ---n 33 EA Excavator, with hydraulic breaker 5,000 (ft 1b) class, Cat 320DL 34 EA Excavator, Cat 320 Cat 320D SECTION E- SOIL SCREENERS �j . . .......... 35 MEA ;0, 1 Screener, Tere�jFjrvey 770 or equNalent - 3/8" - 1/4" screen 1; S 36 EA Soil[ Screener, Terex/Firiely 790 2r eqdvale� - 318" 1/4�1�reen SECTION F - TRUCKS (OFF ROAD) 37 EA Fruc �Off-Ro�ad),2at725 ore .qiivalerit . .......... 38 EA 1, ruc [3 91E A jLriwLck. (Off-Road), at 740 or eq valetlit (Off Ofd- Road)" SECTION G. SCRAPERS ------------------- - 40 EA Soraper, Cat 623G or eouivalent EXHIBIT F Kirby-Smith Machinery Dallas, TX Make/Model offered Weekly Rental Montly Rental Dellverye /Plckup I I I Charg D85 11 $ 4,433.00 1 $ 13,300.00 1 $850 ea. Way 42 7 EA � . .. Scra er _� 61162 G or e U alera 4 EA Scraper Cat 615C or ---- 43 EA S 3r faeU Ca330 or etaafuyecrECTION H -TRACK LOADERS amm 44 EA rrack l.oaeleU, Cat 973D or 45 EA .__._.�.eclarlyafeUtt Track Loader Cat 9630 ore UrwaJeat!t� _�..... Track i,oador Cat 95 3D oralerat SECTION I- COMPACTORS eq 47 EA Co r actoa ..� CadCat 825 a 4 P __.—._.. vaicanrt 49 EA Coan�aotor CatCP�,zsor�m e�d..�._..� -.�.� [ate arc�ior� Cat 815E or et art 50 EA � yr��ent Cooc tomcat SB or er1�a(vaWe¢aC 51 EA Con? aac�or Cat CIS'- 32,3 - o �LIIII.valenl w SECTIONµ) quiv 52 EA_ 414Uaok,pr'I "reUroln NoiNer, RT5620 or cn�apaA�bC wvdCr rp �� drum _ WATER WAGONS (OFF -ROq,D 53 EA Water We on . _. at w--"- (Off-Road), Ca� t�13 tar GUlvarartt 54 EA Water WE C 11- Road), Cat 725 or equlvaNerrt ... SECTION K -WATER TRUCKS] -RyAD Must be TxDOT Approved K 55 EA '✓1raPer Frwldlw (On-Road), 2,00pi �. 56 EA n-Ro � � aier TrWCtc Cn.. �.. ..�_ Idt7pd ,7$0 coF4 0G7�1 a0 SECTION L -MIX ERSIRECYCL,ER'S 57 EA e "_° �• M@ e"r ecy +cla� r' o,rlag 100Fk ore uVvaianl 58 EA Mixer/ rrF ecyo'Mer, CMi 325 ore prrwaPent 59 EA Mixer /RacYcler, CMN 500 or a !Alva _. .. .. SECTION M - ASPHALT -LAY DOWN MACHINE 60 .. EA Aspira_ tt - m _ Machine, af't" . 15 ftt.. . SECTION N - ASPHALT ROLLERS ' 61 EA A` fA,haAt RtAlNer,+ ton _62 EA AslahalN Rolier 12 toll SECTION O - ASPHALT MILLING MACHINES _. 63 EA A3 i7ait MrN11rU I4iartzdrro s, ff ad •_ .L k? . 64 EA Asphalt Milling Machine, 6 ft. head SECTION P - BROOM` " 65 EA Sroolk R,1350 Broonr or e _. E lent �- 65a EA �Ia¢lVa 0 tfo�n. -Addition at cost for gtyiler boo' attachment SECTION" Q -DUMP TRUCK $ON•ROADI; Must b p� •_ Approved with LicE 86 EA Da rnp Truck, 122 Yard 5ECTION R - BACKHOES 67 EA t3aokhoea Casa!180N orequpvaPern Gays .. 68 EA Backhoe„ Casa 590NN ore Ual a @east,. _1iJCPph ..ofass . .. AY litron, l for oaf�rth err oU7trtrorcala� •68 EA Addtdonat cost ft n`4 -wheat drive .� 68 EA Additlraraap ooaat for extentlaataa� —_. . e _ _ ECTION S - SKIDSTEERS — ° - -. qEAdstrer Cat 2165 or a rain va _.21G `. U iron. Addlt otia�i�r traces, staer Cat 226x3 or_ste r Cat 2365 or eciuivaNettfteer Cat 46C Inc.11", `_— steer, Cat 256C or erygalvaleruf stear, Cat 262C or aUyaitalent . "" teer, Cat 272C or en,dn—p..A« EXHIBIT F KIRBMIAC -01 CKOON CERTIFICATE OF LIABILITY INSURANCE DAB (MWDDM"Y) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER. AND THE CERTIFICATE HOLDER. IMPORTANT. K the cerliflcats holder Is an ADDITIONAL INSURED, the poticy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement A statement on this csrtlfteate does not confer rlghts to the P+trrtlflc*ts holder In Neu of such endoreementtel. PRODUCER SancFlmt Insurance Services, Inc. 6400 N. Grand Blvd Suite 400 Oklahoma City, OK 73112 Kirby -Smith Machinery, Inc. P.O. Box 270360 Oklahoma City, OK 73137 INSURER A: Phoenix Insurance Co. nweuRaT.a!The Charter Oak Fire Insurance 2b616 INSURER D:Travelers Indemnity Co of America 126666 COVERAGES, CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. . . ....... .-- . -_..._ .... TYPE OF INSURANCE ... .IICI. sum POLICY NUMBER„ k(MYOO1Y % I L1MITe A X comet OurLeENERALLIABILITY EACH OCCURRENCE s 1.000.00 CLAIMS-MADE 0 OCCUR X X 630GA44298214 10/0112014 1010112016 ICES Ea s 300,00 MED EXP (Arty one person) 1.0, _ PERSONAL &ACV INJURY 4 11000,00 CN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE f 2.000.00 POLICY I PRO- POLICY a LOC PRODUCTS - COMPIOP AGG a 21000,00 TNER: __1111. i AUTOMOBILE uAaurr C i � � IN � err $ 1A00.00 d B X ANY AUTO X X 8108A442982COF14 10/01/2014 10101/2016 BODILY INJURY (Per person) _ s BODILY INJURY (Peracddnd) -_. AUTOS ED 1111 AUTOSIJ =D S X, HIRED AUTOS X AUTO ED 1T(I E X UMBRELLA LIAR X OCCUR EACH OCCURRENCE a 16.000.00 C Exalts lue CLAIM$ -MADE X X UPGA44299214 10/01/2014 1010112016 AGGREGATE s 111,000, O aETENT!ON a e WORKERS D AMEMPLOVIIRP AIRTNE'trl�luTti1+E Y°rM X YHtiB6A44296214 10/01/2 X PT—V1 _ RH ANY 0OPPJETORuATNfiR 014 1010112016 iIWrtNIIWBWBER ErLUDEDI NIA LACHAC.0 CIDENT s 1.000. (Mkoderori In NN) E L DISEASE - EA EMPLOYEE S 11000. If deeerll«I' uo*r 0PS4d?rEn% TONS bolowr I I EL DISEASE - POLICY LIMB L 1,000,00 ..e... ....... 1111 raPTM Of OPERATIONS I LOCATIONS I YEwrrCLES (ACORD 7011, Addracwoael AAmaft Sonedalo, mmy bra oltortfutol If none apace tie m4urrodf City of Dsllee end Its oilTcare, amployess and elected reprBsentatives are Included within the Blanket AddlOonal Insured endDneernerrt CGD248(0808') ae requiredbyw0ttanconifact on sal pollc)ss exce�rt Workers C`ompsnsatiom The Sisnket Addltionst Insured sndoneement includee the Primary a'nd Non -Contributory Insurance wording as rsyulrer�l by written contract on the Gerwsrel Liability Policy. City of Dallas, No officers, employass and elected repromonbltivemI, are Incl d vAth'ln the Blsnket Waiver of Subrogatloo sa required by erri -Herr contract endorsement on all plol'foles. Thirty (30) days notice of cancellation applies on all pol(cles per ILT3 20 (0997) end WC9 1.1 (AI attsclrsd.. CERTIFICATE HOLDER r"aalr'CI I ATIr7Nr SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BlE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE 1988.2014 ACORD CORPORATION. All rights reserved. ACORD 28 (2014101) The ACORD name and logo are registered marks of ACORD .W JIM .pie .m A im A t� COMMERCIAL GENERAL LIABILITY I. How, when and where the 'occurrence" or offense look place; If. The names and addresses of any Injured persons and witnesses; and Iii. The nature and location of any Injury or damage arising out of the "occurrence" or offense. b) If a claim is made or "ault" Is brought against the aWillonal insured, the additional Insured must: I. immediately record the specifics of the claim or "salt" and the date reoehrod; and If. Notify us as soon as practicable. The additional Insured must see to It that we receive written notice of the claim or "suit" as soon as practicable. Q The additional Insured must fmmentately send us copies of ant 1 papers received In connection with the shim or "suit ", cooperate with us In the investigation or settlement of the claim or defense against the * uM, and otherwise comply % h all policy conditions. d) The additional Insured must tender the de- fense and Indemnity of any claim or "sult" to any provider of "other Insurance" which would cover the additional Insured for a loss we cover under this endorsement. Hawever, this condition does not affect whether the Insur- ance provided to the additional insured by this endorsement is primary to 'other Inaur- ance" available to the additional insured which covers that person or organization as e named Insured as described In paragraph 3. above. 5. The following definition is added to SECTION V. -- DEFINITIONS: 'Written contract requiring insurance means that part of any written contract or agreement under which you are required to Inchrde a person or organization as an additional in- sured on this Corrorege Pan, provided that the "bodily Injury" and "property damage' oc- curs and the "personal injury" is caused by an offense committed: a. After the signing and execution of the contract or agreement by you: b. While that pad of the contract or agreement Is in efl'ect; and c. Before the end of the policy period. Page 2 of 2 m 2005 The 8l Paul Travelers Companies. Inc CG 02 46 00 06 owl" COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY BLANKET ADDITIONAL INSURED (CONTRACTORS) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART 1. 2. WHO IS AN INSURED — (Section II) is amended to include any persm or organization that you agree In a OvAftten contract requiring Insurance" to include as an additional Insured on this Cover- age Part, txt: a) Only with respect to liability for 'bodily injury", "property damage" or'personel injury'; and b) If, and only to the extent that, the Input' or damage is caused by acts or omissions of you or your subcontractor In the performance of "your work" to which the Nwitten contract requiring Insurance" applies. The person or organization does not qualify as an additional Insured with respect to the Independent acts or omissions of such person or ofgantrAlon. The Insurance provided to the additional Insured by this endorsement is limited as follows: a) In the event Not the Limits of Insurance of this Coverage Part shown In the Declarations exceed the Wilts of liability requWed by the "written contrail requiring insurance', the in- surance provided to the additional Insured shall be *nkW to the limits of liability re- quired by that 'written contract requiring in- surance". This endorsement shall not In- crease the limits of Insurance described In Section III — Limits Of Insurance. b) The Insurance provided to the additional in. sured does not apply to "bodily Injury-, 'Wop. any damage' or "persona) Injury" arising cut of the rendering of. or failure to render, any professional arddtecturN. engineering or sur- veying services, including: I. The preparing. approving, or falling to prepare or approve. maps, shop dm%* Ings, opinions. reports, surveys, meld or- ders or change orders. or the preparing, approving, or falling to prepare or ap- prove, drawings and specifications. and It. Supervisory, Inspection, architectural or engineering activities. c) The Insurance provided to the additional in- sured does not apply to "bodily Injury" or "property damage" caused by "your work' and included In the 'products - completed op- erations hezard" urgers the "VNItten contract requiring insurance" specifically requires you to provide such coverage for That additional insured. and then the Insurance provided to the additional Insured applies only to such 'bodily Injury" or "p(Operty damage" that 00, curs before the end of the period of time for which the "written contract requiring Insur- ance" requires you to provide such Coverage or the and of the policy period. whichever Is earlier. 2. The Insurance provided to the additional Insured by this endorserneM Is excess over any valid and collectible 'other Insurance", whether primary, excess, contingent or on any other basis, that Is available to the additional Insured for a loss we cover under this endorsement. However, if Hie "written Contract requirfng insurance" specifkally requires that this Insurance apply on a primary basis or a primary and non- contributory basis, this Insurance Is primary to "other Insurance" available to the additional Insured which covers that person or organization as a named Insured for such loss. and we will not share with that "other insurance". But the Insurance provided to the additional Insured by this endorsement still Is excess over any valid and collectible "other In- surance', whether primary. excess, contingent or on any other basis, that Is available to the addi- tional Insured when that person or organization is an additional Insured under such 'other insur- ance". 4. As a condition of Coverage provided to the additional insured by this endorsement; a) The additional insured must give us written notice as soon as practicable of an 'occur- rence" or an offense which may result in a claim. To the extent possible, such notice should Include: CO D2 46 08 05 02005 The St. Paul Travelers Companies. Inc. Page t of 2 CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND UNITED RENTALS (NORTH AMERICA), INC. (FILE 5639) 2015 THIS CONTRACT is made and entered into this _.t clay o � ., , by and between IJ Jl 1 #'D RENT LS 'N(�IZ11 -1 AMERICA RICA INC. a corpo��abon, ,Wi se address is 3909 I -35 FRONTAGE RD., DENTON, TX 76210, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document R EMI 115639 Rental of Imf+�r�w� I quj �ii��eitCmm, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written. CONTRACTOR ... . .... . . ..... BY: AITTFJJ(J' I" 'D SIGNATURE -7 00 Date: Name: 1, e'x' Title: e pi Ay"e (4) V4 Y /?- 2Z? - '? -? 3 � (6,910 PHONE NUMBER 015�4✓e4'1 P i1r, coo, EMAIL ADDRESS CITY OF DENTON, TEXAS ATTEST: JENNIFER WALTERS, Cr "Y SECRETARY BY: GEORG�It�t- �:f�,'CITYN47'�A(H--' BY Date: 7 7 APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY ... .. ... .. BY: 25� 4 ,7 File # 5639 Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $525,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers nricine sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Standard Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on the face of the contract /purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, and 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 11, 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE /TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box 1 of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of- i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 15. FINAL PAYMENT AND CLOSE -OUT: A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE /WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of I% or greater. If an overpayment of I% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books ", "records ", "documents" and "other evidence ", as used above, shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE /MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File # 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY - PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non - conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. If such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on any policy. It is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon location, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon either of the parties hereto or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii. The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the claimant(s); the basis thereof, and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLES: The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 shall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made - for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work - made - for -hire agreement, in a form to be reasonably approved by the City, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the same secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE RESOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the filing of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a meeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If, within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. "Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. 10a - 10d) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at http: / /www.dol.jzov /whd /contracts /dbra.htm and at the Wage Determinations website www.wdol.gov for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day. 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. RFPBid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted: • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. ■ That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to clairns made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted. [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury. • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. File # 5639 Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required. Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. File # 5639 ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File # 5639 and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: 1. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 Exhibit E ..................... . . . . .. .... ....�. _.....� _......_ CONFLICT OF INTEREST QUESTI ONNAIRE -FORM CIQ For vendor or other °fad ^son doi�a business with local Fr►vetwttttaerttal ctttit This questionnaire reflects changes made to the law by H.B. 1491, 80th Leg., Regular Session. This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(x). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor, ........ Name of person who has a business relationship with ocal governmental entity. ��"" p p . 2 Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7' business day after the date the on ia�all filed questionnaire becomes incomplete or inaccurate.' 3 Name of local government officer with whom filer has an employment or business relationship. Name of Officer This section, (item 3 including subparts A,13, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? El Yes E] No B. Is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? I1 Yes No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? II Y Yes F---]No D. Describe each affiliation or business relationship. .. .... ..,..,,_ . _.... — .... .. _... _._..... 4 I have no Conflict of Interest to disclose. art ral`wire of person doing business with the governmental entity I DGata EXHIBIT F RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT Item uom Product Description Make/Model offered 0 SECTION A - DOZERS . ....... — 1 EA . ... Dozer, Cat D1 OT or eq0vateM 2 EA Dozer, Cat D9T or equivalent 3 EA Dozer, Cat D8T or equivalent 4 EA Dozer, Cat D7T or quivaient 5 EA Dozer, LGP Cat D7R or oquivaleN 6 EA Dozer, Cat DISR or equNalenl 7 EA Dozer, LGP Cat D6R or equivalent 8 EA Dozer, Cat D61K or equivalent 9 EA Dozer, Cat D5M nqL� Lv�len[ 10 EA Dozer, Cat D5K or eciuvMent 11 L EA Dozer, LGP Cat D5K or euivalent 12 EA Dozer, Cat D4K or equivalent ......... . . 13 EA Dozer, LGP Cat D4K or equNaleiil SECTION B - WHEEL LOADERS 14 EA WheO Loader, Cat 908H or e L4valenf 15 EA LwlieO Loader, Cat 980H or equivalent . . . ........... 16 EA Wl-reld Loader, Ca!_� .EiKore%Lival-1 .......... 17 EA Wheel Loader, Cat 962K —Oreqwvalenl 18 EA Wjsool Loader, Cat 950H or 1L 1jeni 19 EA Wheel .0W ef, Cal 9 38 H or eq!uiva I ent . ............ 20 EA Wtieei Loader, Cat 930H or e� uivalem 'W'heol 2"1— EA Loader, Cat 9 4 SECTION C- MOTOR GRADERS 22 E/ Motor Gqlq�!r, Cat 12M or equivaient Cat Motor ....... . . . . [Mlotor 'Grader, ILI EA Grader, C� C��ivajent SECTION D- EXCAVATORS ... . . . ...... 24 EA Excavator, Cal 3450L ore uivalent 25 EA Excavator, Cat 336DL or w4olvalent 26 EA -... Excavnlw, Cat 3�� 27 E_ A Excavator, Cat �329E �®r lwaient w)Grappl 28 EA Excavator, Cat . ....... 29 EA Excavator, Cat 320 or 2-4HLva!e—"(— 30 EA Excavator, Cat 3'20DI. or 31 EA Excavalm, with hydrakific breaker 1,600 (fj lb) chars l Cat 312D 32 EA Excavator wilh hyqr�iu!'uEbreaker _3,000 01!tLc, lassCar320LQL._ 33 EA Excavator, with �y±ekjllc ciass, Cat 32qDL EA Excavatoc Cat 320 with zero tall�Tin or equlvMent, Cat 320D SECTION E- SOIL SCREENERS . . ........ 35 1 EA Fos.11"Screen.rjr L.,�LFNeyj7o e - 1/4" screen or _qu�valent • 3/8" 36 1 EA 'j S, 3f - 1/4" screen lsoji screener, Tar SECTION F - TRUCKS (OFF ROAD) -- .... ....... 37 EA.._ Off-Ro � r1j, Cat 72,5 or e ent ............ 38 EA Truck, (Off-RoWl, Cat 730 ore oltt t 39 EA 6�,Cal.Z��.!Lre J-aj� �t ...... . ...... _qL SECTION G- SCRAPERS 40 T IiWjScraDer. Cat 623G or em6wflani Ca�s,8501- Case 850L Case 850L LGP Case 750l- Case 750L LGP 721F United Rentals North America Denton,. TX Weekly Rental N Montly Rental I Delivery/Pickup Charge $ 1;287.00 $ 2,979.00 9125 one tlmefee $ 1.287.00 S 2,979.00 $125 one time fee $ 1.496.00 $ 3,459.00 S125 one time fee $ 1,199.00 $ 2,669.00 $125 one time fee $ 1.227.00 S 2,929.00 $125onetimefee John Deere 200D�I-q.,gr Case CX?IPB John Deere 200DLC or Case CX210B $ 2 Deere 200DLC or Case CX21 OB JIS 1 $ 3,829.00 [ 5125 onetime fee 4,529.00 $450 one time —fee $ 4,679.00 $450 onetime fee $450 one time fee 41 EA Scraper, Cat 6216 or r)tI xiyagaatl 42 EA or, aq.L.4valefil 43 EA ScTp�r, Cal, 613E OE!nivaNent SECTION H-TRACK LOADERS 44 EA Track Loader, Cat 973D or n_tlKi Len t 45 EA 'Track Loader, Cat 963E oa eauLafent 46 EA Track L92der, Cat .953D ore quiwalant��__ SECTION I- COMPACTORS .... . ...... . . ........ . . .... 47 EA.., mpartor„ Cat 825 or txlyalerctl 48 EA foll, actaT C,,IjLj5F or aqtivalent 49 EA Com actor, Cat CP56 or aryxalvaterat . ...... S56 or a tgsr(vaBexrol _ . ......... _ 50 EA 51 EA Co I Cat CP 323 C or equlyalerO 'C'O' :52::rW:a�cM' � Trench Roller, RT5620 or equivalent with 22" drum _.±A SEC"nON J - WATER WAGONS (OFF-ROAD) 53 EA Water Wagon,Lo�ffj�o t 61 3 or 2qul vTf!Ljt a' ate EA Water Wagon, Off-Ro 54 EA ,!Cat 725 or eq Lji�Merjf_ SECTION K - WATER TRUCKS (OWROAD), Must be TxDOT Approved with Licei EA A,- 156E V" [!EAq- jWaterjwck (Orr mRoad), 3,750 at 4,000 gaL .- SECTION L - MIXERSIRECYCLERS; .......... 57 EA Mba Recycter, Boma g 1008 -or.Squivalent 58 EA Mi ��,r/rj,,5y Cm 1325 59 EA Mixe0ftcycier, CMl 500 or equivalent SECTION M - ASPHALT-LAY DOWN MACHINE As hatt - Lay Down Ma0flne, 8ft. - 15 ft. SECTION N - ASPHALT ROLLERS E 6 JAA link Rollei, 9 ton T A 62 EA Asp±,. t L R.11-1, 12 top ........... . ..... . . SECTION 0 - ASPHALT MILLING MACHINES ............. i 6=3 EA Machine, 4 ft. head 6 EA .�4 ]]� Asphatt Mffin(j Machhle 6 ft. head SECTION P - BROOM :65 PEA ja �, Lo_'k rr 6 6 0 '1." ta EA 0 %ow Additional cost fcaa a,uttev boom attachment SECTION Q - DUMP TRUCK (ON-ROAD): Must be TxDOT Approved with Llcens( 66 _[:�ADn SECTION R BACKHOES 67 EA Backhoo, Case 5801 or equivalenj._85hp r1ass 68 EA Backhoe, Case 592equivalent - _100hp class 0 bons added to Backhoe base price- . . . . ......... 7-6& EA Additional cost for cab with air conditioning -GF'j EA Addidonal cost for 4-wheel drive EA Ad; nM cost for extendad SECTION S - SKIDSTEERS .... . .... . 69 EA Skidsteer, Cat 216��j 69a EA Qptlwj Addiflonalcom for tracks 70 EA Skidsteer, Cat 226B or 71 EA ISMdsteer , Cat 2368 or equNalenl 72 A Skxdsteer, Cat 246C or 0 uivalent 73 EA Skidsteer, Cat 256C or2_q��iva[ent 74 EA SkOqteer, Cat 262C or 75 EA SMdsleer Cat 272C or equiva@ent EXHIBIT F Hamm 3410P Single Pad Roller $ 12579.00 $ 3.359.00 8125 one time fee Hamm 34 10 Slngle Smooth Roller $ 1.579.00 $ 3.359.00 $125 one time fee �omaq BV�124pDH 820.00 $ 1.659.00 S125 one time fee Wacker RT82SC Trench Roller 638.00 $ 1.329.00 __ $125 one time fee . . . . ....... . M2 106 $ 11408.00 I $mmm 3.520.00 1 S125 onetime fee RJ350 8' Enclosed Cab Broom 1 $ 979.00 V $ 1.389.00 1 $125 onetime fee :reiahtliner M2 106 Case 580N or John Deere 310J Case 58ON or John Deere 310J Case 58ON or John Deere 310J Case 58ON or John Deere 310J $ 1,412.00 1 $ 2.919.00 one time Fee . ..... . �T$5 1on $ 682.00 F$' 1.349. 0 e time fee $ 25.00 $ 75.00 N/A 15.00 $ 45.00 N/A $ 25.00 $ 75.00 NIA AC"R ' CERTIFICATE OF LIABILITY INSURANCE DATE(MMIDD/YYYY) L — 10/L/2015 1/28/2015 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER LOCKTON COMPANIES 2100 ROSS AVENUE, SUITE 1400 DALLAS TX 75201 214 - 969 -6700 INSURED UNITED RENTALS (NORTH AMERICA), INC. 1352196 3120 SPUR 482 SUITE B IRVING TX 75062 ACE PrODertv & _North American Capacity Insurance Co Indemnitv Insurance Co of North America ACE Fire Underwriters Insurance Compan COVERAGES* r I AU I NUKILCU Kcr --ni rA I rvc TTHISRIS TOO CERTIFY THAT THE POLICIES OF IC SURA CREEL SRTED BELOW AVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ...LIMITS tl SR'. AQW, W3R L TYPE OF INSURANCE POLICY NUMBER P (C;YYF„YF1dy 'P'OE�ICYLXP 1 A COMMERCIAL GENERAL LIABILITY N N XSL 027337478 10/1/2014 10/1/2015 EACH OCCURRENCE a 3. 000.000 -MADE E OCCUR P T rJ Ee inCLAIMS FIREM, ptrr 2;000.000 X 2 000 000 SIR.. L7 QQ Q( MFO FXP (Anv one Derson) R _ ....................... PERSONAL & ADV INJURY s 3.000,000 C PP# L AGXY PI E.A1'C' r IMP APPLIES PER GENERAL AGGREGATE s 6.000.000 POLICY �ECOT- F—] LOG ,PRODUCTS - COMP /OP AGO s 6.000.000 OTHER $ AUTOMOBILE LIABILITY A N N ISAH08828313 r °M17&tNllhvFl,"t "r?INITLi L1N'IIF. 10/1/2014 30/1(2015 n„=tdSal s 5.000000 �X, ANY AUTO BODILY INJURY (Per person) $ .. AUT OWNED AU EDUCED ° 84.7911L "N' INJURY gear u3eChpalap $ _ NON -OWNED m OPERA "Y DA AU $ -- HIREDAUTOS AUTOS i u.._..I $ - I:1 )( UMBRELLA LIAB X OCCUR N N XOO 027423553 10/1/2014 10/1/2015 EACH OCCURRENCE $ 25.000.000 EXCESS LIAB �T Ci AIPA„y, MADE AGGREGATE s 25.000.000 DED RETENTION s $ WORKERS COMPENSATION II N 111 l•�all 1 PER 10/l/2014 10/1/2015 X STATUTE GFG AND EMPLOYERS' LIABILITY A VIN 1n11 ICE "Q81111'11)117(aMka1F NIA) 1()/1/2014 1()/1%2015 ACCIDENT 2.000.00(,1 I:. OFFICER MEPd ERr EXCLUDED ?ECUTIVE N NIA �l 1 E 1i3(11180971At1S I8glPrq, I) ICL EACH $ 10/1/2014 ]0/1/2015 (Mandatory In NH) 'r n r)ISFAS'E - r. A F1API.LiYYE.E R 2.000.0/00 Ir yes, describe under DESCRIPTION OF OPERATIONS bale. 2.00U -VO(F r I DI 7 AGE. - rO ICY MIT' < F A Excess Workers Compensation N N th/CU C48018105(CA, WA) 10/1/2014 10!1(2015 s2M Eiach ACC /LMP /AGO C Tx Non-Subscriber EEGO000367 -00 10/1/2014 10/1/2015 $5MMCSLrrOT /IND /OCC DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks _.� Schedule, may be attached if more space is required) ADDITIONAL INFORMATION ATTACHED. ..._ ................... CERTIFICATE HOLDER ._._............, �...._, ... _..........,_.. CANCELLATION °L4 �EGSC7Y7v.n� i, .. _,..... SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 13328562 AU I NUKILCU Kcr --ni rA I rvc CITY OF DENTON, TX 910 B TEXAS ST. DENTON TX 76209 AC'6R0 25 (2014/01) 0195'8 -2014 ACORD CORPORATWK All rights reserved The ACORD name and logo are registered marks of ACORD DESCRIPTION OF OP ADDED BY ENDORSEMENT/SPECIAL PROVISIONS CONT. RE: ALL OPERATIONS PERFORMED FOR THE CERTIFICATE HOLDER. BLANKET ADDITIONAL INSURED - ANY PARTY, WHERE REQUIRED BY WRITTEN CONTRACT, APPLIES TO GENERAL LIABILITY FORM XS- 21164a (04/13) AND AUTO LIABILITY FORM DA -9U74a (04/11). BLANKET WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US - ANY PERSON OR ORGANIZATION, WHERE REQUIRED BY WRITTEN CONTRACT. APPLIES TO GENERAL LIABILITY, AUTO LIABILITY AND WORKERS' COMPENSATION POLICIES. PER STATE LAWS, WAIVER OF SUBROGATION DOES NOT APPLY IN NEW JERSEY, NEW HAMPSHIRE AND KENTUCKY FOR WORKERS COMPENSATION. COVERAGE IS PRIMARY AND NON - CONTRIBUTORY PER TERMS OF ENDORSEMENT XS- 20288. u um ADDITIONAL INSURED WHERE REQUIRED BY WRITTEN CONTRACT FORM XS -21164 (04/13); ADDITIONAL INSURED - OWNERS, LESSEES, OR CONTRACTORS - COMPLETED OPERATIONS. CONTRACTUAL LIABILITY "XCU" HAZARDS BROAD FORM PROPERTY DAMAGE COVERAGE INDEPENDENT CONTRACTORS COVERAGE STATE OF CALIFORNIA - SELF INSURED CA -SI 2142 -C STATE OF WASHINGTON - SELF INSURED CERTIFICATE # 601, 908, 516 STATE OF NORTH DAKOTA - STATE FUND EMPLOYER ACCT # 821330 STATE OF OHIO - STATE FUND POLICY # 1303683 STATE OF WEST VIRGINIA - STATE FUND POLICY # 20302489 -101 STATE OF WYOMING - STATE FUND POLICY # 00134808 Standard Attachment : NIRE12att Master ID: 1352196, Certificate ID: 13328562 CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND BANE MACHINERY, INC. (FILE 5639) THIS CONTRACT is made and entered into this day o'fALWAA ^' , 2015, by and between BANE MACHINERY, INC. a corpor tioii, whose address is 10505 N. FREEWAY, FT. WORTH, TX 76177, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit `B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $600,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of. i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY - PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) L.New-Year's.Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate", , 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at Ni��pi �J �,1n11,7F`�pml /a�u��l�R�w p�,ra and at the Wage Determinations website Wa�,i()lm�)y for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted: • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. ■ That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required, File # 5639 ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions; Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT Item UOM Product Description SECTION A - DOZERS 1 EA Dozer, Cat D10T orequtvalenl 2 EA IDoze,r, Cat D9T or equlvalenI 3 EA Dozer, Cat D8T oreLulva—lelll 4 EA Dozer, Cat D7T orequiva�ent 5 EA Drizer, LGP Cat D7R or equNalent 6 1 EA Dozer, Cat D6R or equNale nt 7 EA Dozer,, LGP Cat, 136fl: or e Lilvalent 8 EA Dozer, Cat D61K or equivalent . .......... 9 EA Dozer, Cat D5M or equivalent 10 EA Dozer, Cat D5K or wlulvaleni 11 EA EA Dom, LGP Cat D5K or equivalent 1-2 Dozer, Cat D4K or equiivalent 13 EA Dozer, LGP Cat D4K or equivalent SECTION B - WHEEL LOADERSmmmmmm 14 EA Wheel Loadpr, Cat 988H or equivalent 15 EA !Wheel Loader, Cat 980H or.1 16 EA WheelLoWer, Cat %6Korequivaleril 17 EA MieelLoodier, Cat 962KoreAijlva!rsn0_ 18 EA VWhael Loader, Cat 9501-lorequivalegil 19 EA Wheel Loader, Cat 938H or 20 EA Wheel Loader, Cat 930H or eAo!vatei �I 21 EA ,] J.oaer, q��924H or equivaienI �t SECTION C- MOTOR GRADERS Z3'EA E Moto _ Er.der, C at 12M 2� g.�yalent ]�:2Lor; e M A Motor Grader it 1 1t dyatorut ot., SECTION D. EXCAVATORS 24 EA Excavator, Cat 345DL oreqWvWent 25 EA Excavator, Cat 336DL or eqOvalent 26 EA Excavator, LC-1t3251o,,,qulva1ent_,_ 27 EA Excavator, Cat 329E or equovWent w1G 28 EA Excavator, Cat 324E oreclowalent., 29 EA Excavalor, Cat 320 or e t ivalent 30 EA r-xcavalor, Cat 320DL ore ulvaleni wh 31 EA Lxcav ntor , with h alraullc breaker 1,500 32 EA Excavator, with hydfaulic breaker 3,000 33 EA • Excavalor, _,�ith hyLi �jfllr imake, 50000 3 =��A� _, onvatrii-, Cat 320 with zero tails In or SECTION E- SOIL SCREENERS 5 — 1�*�eener,j!�r �"Lq �! §q 36 EA EA Soil Screener, TerexEnel; 79 ore _y (�quN SECTION IF - TRUCKS (OFF ROAD) 1 37 EA Truck, (Off-Roadj, Cal 725 or equuvaleni 38 EA Truck, (Cif-Roatt) Cat 73,0 or eq 39 EA Truck, (00 -Road), Cat 740 or equnvalenl SECTION 'ION G- SCRAPERS 0 EA [Scianer Cat 623G or eatilvalent dass, Cal 312D class, Cat 320DL glass, Cat 320DL dent, Cat 320D 3/8" - 1/4" screen 3/8" - 1/4" screen EXHIBIT F D6T Bane Machinery, Inc. Ft. Worth, TX Make/Model offered Weekly Rental I I MontiV Rental DeliveChary/Pickup rge .00 1 1; 8,500.00 saki 85Z $ —.. 2,350.00 S_ 7,000.00 S600 each wa, Kawasaki 70Z $ 1,500.00 S 4,500.00 $300 each way 't 300X3 1 $ 2,175.001S 6,500.00 1 $300 each Kobelco SK140 w/ Atlas AR 95 $ 2.50000 7,500.00 S300 each wav 95 2.67500 8,000.00 �300 each way _10X ? OX3!�w A�i Kobelco SK210 I LBX, �;/AR130 W/ AR140 Kobelco SK210 / LBX 210X3 w/ AR140 $ 2,850.00 S 8,500.00 $300 each way $ 8,500.00 a $300 each CITY OF DENT0N 9018 TEXAS ST D[NTON, TX 70209 GEORGE P BANE INC BANE MACHINERY INC BANE MACHINERY FORT WORTH LP BANE MACHINERY HOUSTON LP P0 BOX 4555 TYLER, TX 75712 This certificate is issued on 11-01-2014 and is effective until 11-01-2015. It certifies that po|lci�s of |msuramoe I istmd be|ow have been issued to the insured named ubmve Not-withstanding any requirement term or condition of on contract or -- her�ocmmem� with xespect to whic h this certificate my be issued or may rtaTn' the im5mranK.a afforded by the pm| icies descred here in is subiecL �o eI| Lhm teIrms^ exc|uaions. and conditions of such po|icies. I,x�wit's shown may have reduced by paid claims. Automobile Liability Includes: Bodily Injury and Property -Any Auto Excess/Umbrella Policy Number Coverage Limits 25-37750-04 General Aggregate 1'500.008 Products Aggregate 1.500.000 OCCUR ENCE Pers/Kdv Injury 500.000 Each Occurrence 500.000 Premises Damage $ 100.000 Medical Expense $ 5.000 25-37750-04 Each Accident $ 500.000 25-37750-04 Each Occurrence 10^000.000 General Aggregate $ 30^000'000 Products Aggregate $ 30.000'000 Should any of the above described policies be cancelled before the expiration data thereof' notice will be delivered in accordance with the policy provisions. 80'C1035 (SFA) GEO 25-37750 01-116442 LD| COI 269828-1 02 11 01-30-2015 PAGE 7 "'`'"""~ CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND TKO EQUIPMENT COMPANY (FILE 5639) THIS CONTRACT is made and entered into this day 2015, by and between TKO EQUIPMENT COMPANY a c��rporatioii, � 110sc a ss is 2850 HARDROCK ROAD, GRAND PRAIRIE, TX 75050, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C"); (d) Insurance Requirements (Exhibit "D ") ; f (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $525,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers Dricine sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C These standard Toonm and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Dentoo`o contract are applicable to contracts/purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the 3ol|ec or respondent boccin after rc{bcced to as Coo1cuotnr or Supplier. Any deviations nnoat be in writing and signed by a representative of the City's Procurement Dcpudolout and the Supplier. No Tconm and Conditions contained in the ne||or`m proposal response, invoice or ota1ccnerd ahu|| serve to modify the tornzo set fbdb herein. If dborc is u conflict bc1w/cco the provisions on the face of the contract/purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5' 6, 7, O, 20, 21, and 36 shall apply only to u solicitation topurchase goods, and sections 9, 10, |l, 22 and 32 shall apply only to u solicitation to purchase services to be performed principally mtthe City's premises or on public rights-of-way. l. S OBLIGATIONS. The Contractor nbaU fJk/ and timely provide all deliverables described io the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE/TERM.Unless otherwise specified in the Solicitation, this Contract obaU he effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package dolh/crab|co in accordance with good commercial practice and ubmJ| include u packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall boclearly and permanently marked as follows: /»\ The Contractor's onms and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (m) Container number and total number ofcontainers, e.g. box l of boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be auiioh/y packed to secure lowest transportation costs and to coo{bon to all the requirements of coozonou ourciuro and any applicable mpeoi/lou1ioo. The City's count or weight shall be final and conclusive on shipments not accompanied hypacking lists. 4. SHIPMENT UNDER RESERVATION : The Contractor is not authorized to ob' the deliverables under reservation and no tender of a bill of lading will operate as a tender of 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass tothe City only when the City actually receives and accepts the deliverables. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. F C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ("IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time-sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work-hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need tobc sent WAccounts Payable. Approved invoices will be paid within thirty G0calendar days of the City's receipt of the deliverables mof the invoice being received io Accounts Payable, whichever iulater. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid buUunum at the lummmr of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for u reason for which the City may withhold payment hereunder, interest shall not uoorme until bon (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, on stated above, provided that the invoice ouaicbnm the ubipouoo1 or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent oo may bc necessary ou account of- i. delivery of defective or non-conforming deliverables by the Contractor; ii. third party claims, Yvbicb are not covered by the insurance which the Contractor is required to provide, are filed orreasonable evidence indicating probable filing o[ such claims; iii. fbUoco of the Contractor to pay Subcontractors, or for labor, ouutedolu or equipment; iv. damage to the property ofthe City orthe City's agents, onup/oyoou nrcontractors, vvb/uh ix not covered by insurance required tnbuprovided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order uuroboc, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any ouotodo[ provision of the Contract [)oouuuordm. E. Notice is hereby given that any uvvurdod firm who is in arrears to the City of Denton for delinquent taxes, the City may nDhot iudobtodu000 owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic 1rauatec of funds. The Contractor agrees that there abaK be on additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. Q. The awarding or continuation of this contract is dependent upon the availability of funding. The City's paynoco1 obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other /avvfh[{y uvuUab[s funds shall render the Contract null and void to the ox1cn1 funds are not Appropriated or available and any du|iYorab|oo delivered but unpaid nbu|l bu returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per them expenses in connection with the Contract shall be paid by the Contractor, uo[nus otherwise o1u1od in the contract terms. During the term of this contract, the contractor oba]) bill and the City ubo]/ reimburse contractor for all reasonable and approved out of pocket expenses vvbicb are incurred in the cnouootiou with the NO�� performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE/MBE/WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor • T shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City io writing. Nnacceptance by the City of any Subcontractor shall constitute a waiver nf any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a 000ndb)y Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day nf each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and aho/{ contain provisions that: i. require that all deliverables to be provided by the Subcontractor boprovided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and upp/ioa1/nno for payments, including any claims for additional payments, damages or otherwise, tn the Contractor io sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all 0ubuoutrootnco obtain and maintain, throughout the term of their contract, insurance in the type and uc000n1m specified for the Contractor, with the City being a named insured oo its interest shall appear; and v. require that the 3ub000booCor indemnify and hold the City harmless 1n the uoo/e extent as the Contractor is required to indemnify the City. C. The Contractor uhu|| be fully responsible to the City for all acts and Vroimainua of the Subcontractors just uathe Contractor is responsible for the Contractor's ovvo acts and nnoiuoiouu. Nothing in the Contract ohuU create for the benefit of any such Subcontractor any uouiozchua| relationship between the City and any such Subcontractor, nor shall it create any obligation oo the pod of the City 10 pay or to see to the payment of any rnoocya duo any such Subcontractor except uu may otherwise be required bylaw. D. The Contractor shall pay each Subcontractor its appropriate share uf payments made tothe Contractor not later than too (10) om1ondor days after receipt of payment from the City. A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Cooi(uoLor certifies that the prices in the Offer have been arrived at independently vvitbnot consultation, communication, oc agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C.lo addition to any other remedy available, the City may deduct from any amounts owed tothe Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on nodora by others for like do}iYorub|ua under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, o}uicoo` security irdcroatm and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims 10 the deliverables. . � a 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 2•. FRAUD: Fraudulent statements • the Contractor on any Offer or in any report or deliverable required to be submitted • the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 32. INSURANCE: The following ivancaocs requirements are oppUcoh/o, in addition to the specific bzoucuoco requirements detailed in Appendix A for services only. The ouccsoafb| fion shall procure and maintain insurance of the types and in the minimum amounts acceptable k/the City ofDenton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City ofDenton. A. General Requirements: i. The Contractor shall uiuminimum carry insurance io the types and a000uuiu indicated and agreed to, as submitted to the City and approved by the City within the proour0000cd pc0000n, for the duration of the Contract, including cx1cuoiou oyd000 and bold over periods, and during any warranty period. ii. The Contractor nbul) provide Certificates of Insurance with the cnvocoge`a and oudnrocnueotm required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after vvri1tou request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor nonat also fbmvucd a Certificate of Insurance iothe City whenever apreviously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed bythe City. Anynnva/ of insurance bythe City mbul/ not relieve or decrease the liability of the Contractor hereunder and oba11 not be construed tnbcu limitation of liability oo the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the oubooubrVo1oco oouzououoiog work on the project. v. The Contractor's and all mubunobaotnru" insurance coverage uhu]| be written by companies licensed to do business in the State of Texas a1 the time the policies are issued and obul) be written by unnoyaoioa with A.M. Best m1iogn of A- VII or better. The City will accept workers' 000zpnnon1ioo coverage vvrii1eu by the Texan Workers' Compensation Insurance Fund. vi. All nodoroenocn{u naming the City as additional insured, waivers, and notices of cmzcc/)a1inu oodoronnuco{o as well as the Certificate of Insurance shall contain the solicitation number and the following information: City o[Denton Materials Management Department 9OlB Texas Street Denton, Texas 76209 File #5639 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 39. PUBLICATIONS: All published material and written reports submitted under the Contraffi must • originally developed material unless otherwise specifically provided in the Contra When material not originally developed is included in a report in any form, the source shall identified. I 0 97,14, M 1 OW11 M WAM IM 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre-printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 'lililillillil F IIIIII1I 11111 IIIIIIII 111111111!11 ill! lill III pill If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Leg Holiday falls on Sunday, it will be observed on the following Monday. Normal hours operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City IWenton Holida s. An scheduled deliveries or work i erformance not within the normal hours 1 01 Iasi a rim 11im lmaiwm W 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON-SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub-awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File 4 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non-Procurement Programs, the State of Texas, or the City of Denton. delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at I'M fJym�l�wAl gty(1�mtll[�<�dtw and at the Wage Determinations website wymw d ➢ „g®y for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. RFP/Bid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions M Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted: Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. U That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted. [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury, • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. ® Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than ,, each occurrence are required, [ ] Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. [ ] Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. [ ] Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ .... each occurrence are required. [ ] Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. MRIMOM ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: 1. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self - Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. MEMMMM Exhibit E -- - .,.......... QUESTIONNAIRE -FORM CIQ ......_ __- - - - -- ...u.......,.. �.,_........... .. CONFLICT OF INTEREST QUEST For vendor or other person doing business with local governmental entity This questionnaire reflects changes made to the law by H.B. 1491, 80th Leg., Regular Session. This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(a). By law this questionnaire must be fled with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. Name of erson who has a bustness... ... ., ,,.... __— �........... p relationship with local governmental entity. ..._..__ �� - ECheck this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than this 7th business government officer with whom filer has an employment Yncompleta -� or inaccurate.) _ ...,.,.,_.... � � .. ................_ questionnaire becomes 3 Name ofllocalftger themm a „mmmmm� _ ...._......._._... _..._.� -a.�. or business relationship. Name of Officer This section, (item 3 including subparts A, I§, C & I)), must be completed for cacti officer with whore the filer has an employment or other business relationship as defined by Section 176.(}01(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer ofthe questionnaire? I.. ..I Yes �p No B. Is the filer ofth.e questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer nained in this section AND the taxable income is riot received from the local governmental entity? C....µ.....:1 Yes F--J No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or mare? Yes L .................� No D. Describe each affiliation or business relationship. �. .. ........ ........ ......... -- - ... 4 I have no Conflict of Interest to disclose. -� 7 1 / / - — �., lay R u5wd.airiaas��athil entity l: ,�, _..... —_.. Sid;utrlrrtr.° of erson ai�rGw,,, lour �ir� ss with the ; ate EXHIBIT F RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT TKO Equipment Co. Grand Pra[Av, TX - — --------- . . . ..... . ...... . . . ..................... . . . . . . I I—, � __ . . . . ............ . ............... Rem Weekly Merrily Rental Delivery/Pickup # i uom Product Descriptlon Make /Model offered Merr Rental Charge SECTION A - DOZERS 1 EA Dozer, Cat D1 OT or equivalent 2 EA J)ozcn, Cat D9T or equivalent ,3 EA Dozoi, Cat D8T or equf"Ienil . . . . . ............. 4 EA i-Xizim, Cat D7T or uivalmil 5 EA Dozer, LGP Cat D7R or eqOvalenl .. ................................................ . ..................... 6 F:A Drizer, Cat D6R or equivalent - - - — _____----------- F.'A Dozer, LGP Cat D6R or equivaloril. .. . .......... ___ . .... ....... . 8 EA Dozer, Cat D61K or equivalent 9 EA Dozer, Cat D5M or N2xii.0w4unt 10 EA Dozer, Cat D5Korucluivalpill 11 . . EA . . .......... Dozer, LGP Cat D5K or equivalent .... . . .............. . . . . ........ ........................................... . . ....... . . . . . . _ . ........ .. 12 l ..:A 13 ......... . . EA Dozer, LGP Cat D4K or ciquivalent SECTION B - WHEEL LOADERS . - ------- 14 .. . . ........... - -- E A..... .. ..... Y.Y.ho-el Lo later, Cat 988H or e,iqylvdent 15 EA Whm,.1 Loader, Cat 980H or equivalent 16 EA Wheel Loader, Cat 966K or Prlulw9wil 17 EA Wheel Loader, Cat 962Korequivaic'nil . ... ... .. ... ... 18 EA . . . . . Whool Loader, Cal 96M 1 or .. . . ................................. . ...................... ......... .... . 1-9 . . . . .. .... EA ................. Whoel I oadei, Cat 938H or a, Ovalent 20 .................. EA Whe*A I oader, Cat 930H or equMfleril _1111 ................................ . ........ ___,__ 21 EA Wheal Loader, Cat 924H oroqu valart SECTION C- MOTOR GRADERS '55-- A I - ------ Grader M.ior r.der, Cat 12M of ........... 3 EA . ............... Motor Grader 140M or equivalent Gd . ........... ... SECTION D- EXCAVATORS 24 EA Excavator, Cat 345DL or oquIvilent 25 . EA ...... . . . ..... r-`xcavalor, Cat 336DL or equivalent 26 - EA - - - -- Excavator, Cat 325 or equivalent . .... . . ................................ 27 EA Cat 329E. ore uivalent vy/G, ---------------- . ............... - q,r ..... ....... .. . . . ...... 28 EA Lxa,rdeakerr, Cal324E or eqijivaleM . ......... _,", ____ 29 ............ EA ' F. xcrivalof, Cat 320 or eqijivalant 11111111 . . .... - ................. ........ - . . . . . .. .......... --- 30 [:A Excavator, Cat 320DL Or OCILUValeml, w/, ------------ 31 1:A Excavator, with hydraulic breaker 1,500 . . .. . ............ . . . . . . . ................... 32 EA Excavator, with hydraulic breaker 3,000 . . . . . . .................. �3 EA , w'it'h 'd, !re.a... . .k. eI I 11 r I 5.0 0 - . � 34 LA Excavator, Cai;20 with zero t n i 1 r- )yu o r ...... . . ... . SECTION O CREENERS Cat 312D class, Cat 320DL - -1-1-1-111, ----------------- class, Cat 320DL flent, Cal 3200 I . .. .......... cro, �5,mley 770 or ec Ov lc,,nt - 3/8" - 1/4" screen ... . .............. 3 6 EA SW vrmier�ei, Te,,� ex]HnMy ... .......... ------------- . . . . . . . . . . . . . . .................. rrl 318" - 1/4" screen SECTION F - TRUCKS (OFF ROAD) . . . ......... . 37 EA Truck, (Ciff-Road), Gio 725 or equivalent ...... . .. ................................................ . . . . . . A I ruck, (011-Rcw(J), tat 730 or e(lyivalei,it . - -- . ...... ..... ...... ....... . .................... . ............ ................ . ............... 39 1 rkjch, (011,Road), Cat 740 or equivalurd SECTION G- SCRAPERS . ..... ..... 4......... I -- ... .................... . ....................... --------------- -------------- - - 0 �. �AI r cmrwr Cat 623G or Pouivalogil same sarrie I $ 9,043,20 400�00/40(.Wo . ......... — , 1111- ................. 111 .......... . . . .... . .. ................... . . $ 7,284.80 400.001/400.00 EXHIBIT F ... ............. __ 41 :A e�< raa rot Cat 621U or eepuivalero _1111 ... 1111....... ,E. .......,R. " _ _ ...____ - ... _ -. _ 42 EA `,cra:por, Cat 615C or eagwvaoril same _111__1 - $ 7 536 00 400 O0f4f1(1.0(:D _ 43 ''_-EA- Scruapaor, Car 613E or oc.i ,,deny „,.. . same...... 1111.. S ®.....6,028.80 300.00 {300.00 1111, SECTION H -TRACK LOADERS .. . .,.. ... , ._._ __ 44 FA T rack Loades Cat 973Doreigailvrafeiat ..... ...... ....... 45 j'_ EA hack Loader, Cat 963D or ecgOvalent ......... ......... .. ......... __.4EA _ 0 ack Loader, Cat 953D or equlvr-aloN samf* 1111.. - - $ 6 028 80 300.00/300.00 SFC (ION 1- COMPACTORS .. __ ... 47 EA Coamp aeslor, Cat 825 or ey'.ulvra9eN .. . _ 48 EA CornRaacla Cat 815E or rrgWW'4ent _.__ __- same $ 63,540.80 500.00/500.00 49 :A (crnagassc ecd Gat CP56 or ccgnavaCent ...... m _1111 -- -- - - - - -- -- - - - - -- ------------- ................................... . . .. So C ompaoctoi, Cat CS56 or etl0vcafent EA. .....„ ....... -_._. - - - - -_- .. ____ ..... -- ............. ..... ... ----- 51 A C onr eutcer, Cat CP -323 -C or c,gOvalunt 52 EA Wacker Trench Roller„ RT5620 or trgcatvaalonr with 22” drum - - - _ _ ........ ....... - _ - - - -_ ..... .,,, - SECTION J - WATER WAGONS (OFF -ROAD) —. - ._ 53 EA Water'�Adtggaaaa (fYRtRwair9) Cat 613 or _. - _ 54 EA Water W aryrara (1161 Road) Cat 725 or equry aloaal ,111,1 , , a , ,.,. ..., ... same ..... _ $ 7,536,00 - 300 001300 00 _- SECTION K - WATER TRUCKS (ON- ROAD): Must be TxDOT Approved with Licei _. y, EA VaYea Fiuc,k (Cm Roady 2 000 gal, __. ----- , _ 56 A Water Truck (On Rvad) 3,750 or 4,000 q rI . S'E'CTION L - MIXERSIRECYCLERS ;i7 EA Mixar7Rncyr, It r Bon ary 10011 or c,) guivalent Boman MPH364R -2 $ 7,988,16 400 00(400.00 58 EA Mkxu riRec yaYrt a CMI 325 ore alent 59 A.. Ml tr alldr, r yr R+ t GM1 500 or t ruivalent ........ .,.., ...,, 111.1 -- -- � -- � .�.�..,. ___. SECTION M - ASPH ALT -LAY DOWN MACHINE SECTION - - - -- ____ - - - - - - -- 60 EA As chalk Lay Down Machine„ 8ft. - 15 ft. „ - -- R ..... 1111 m...�_..___. — ..........� SECTION N - ASPHALT ROLLERS t 6TA �A agah tlk Roller 9 tan 6A agate alt Roller, 12 tan .. SECTION O - ASPHALT MILLING MACHINES I f-sr, +a la-fi M s hin 4 fr head 63 Aq . .... .... . _ 64 EA head - -- -- ----------- ..... .-------- . _ SECTION P - BROOM 65 FA 1i_r9ck RJ350 Broom or r alulvalent __ . g5 EA Op ron= Addition�a�l cost for tyriYRo- r boom attachment - .pp... ®..1111..__ ...... . (.. ) with SECTION Q - DUMP TRUCK (ON-ROAD): Must be TxDOT A th License __6� - .... 6(d J `A..... 1I)urrapa Il ick 12 Yard ..... ,. ... -- -- - - - - -- .. _ -- - - -- —1111 SECTION R - BACKHOES __ ...... .......... ..... ... ........................... ... , ,. _ -_... - -- . 67 EA Hackhoo Case 580N or equivalent - 85htr class - - .. .. . _ ._ -__,_. 68 EA Backhce, Case 590N or cacltar al anC I00hp class - - -. - - - - - - -- _, ...... .. CPpbons added to Backhoe base p nc�er: .... - - - - -- .... EA rC 68 Arla1 #t¢onmal cost for - - cab with air r,r)a01tiurrRrPrg -.� ... {7- 66.......' EA Adrfi iunaal cost For 4- utrheel drive . . _. ®.._ 7-681 EA Ac ddion al cost for extendadleq . . m_ -.. -.. _ 1_11_1. .._. ..... ..... - -- - -. ...... SECTION S - SKIDSTEERS .... -- ......... _.. _. - - - - ......... ......... ......... 69 :A Skidsteer, Cat 216B of equivalent ........ _ ................. ........... ... . -- -- - ........ __ ... ....... 69a I A opallon: Additional cost for tracks .,,- .,_____, _ -_..._ - -- _ .... 70 EA Skifiste e r Cat 2,x613 or equivalcq t ...71 . 1111... .................... -- - -- - - - -- ... E /'t... Skidf ear, Cat 236E or Of.gLJ vagrent _ 1111... - -.. ... . _ .... ... .. . .... ... -------- EA 72 Skidsteer, Cat 2460 or raclu'I alent _... 73 EA Skied e(,n, Cat 256C or equivalent - - .... !4 EA kid tic car Coat 2620. o e cguivalent ..... ... ----------- - ---- ............. - _ ------ .. 1111.. -1111. 75 EA Skidsteer, Cat 272C or equivalent . 111- 0 a _T T UU11 I THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE —6 1988-2610 ACORD CORPORATION. All rights reserved. ACORD 25 (2010/05) 1 of I The ACORD name and logo are registered marks of ACORD #S14240504/MI4192720 CLEHB 1N9UKrK1'A1: —11 ------ F . .... ... ......... -------- INSURED INSURER 13; Liberty Insurance Underwriters 19917 T-K-0 Equipment Co. - .. .... ...... . - I I I I INSURER A. I I C: Texas - - M .. utual Insurance I 1 -, Company 2 1 2 1 94 1 5 P. O. Box 153389 INSURER D Argonaut insurance Company 19801 Irving, TX 75015-3389 __ - - - E - MCAS - CO . ......... . ......... 7 - --------- 2 - i - - ---- -- 40 RER E INSURER . ... .......... . . . . . . . . . . . . . . . . ... .. ... ...... . .............. . ............................ . ..... . . . ......... ...... ...... . . . . ..... I INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER- THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. R IY . .......... . . . . . . . ..... . . . . . . . . . . . . . . . . . . ............. . . .. . ...... . . .............................. TYPE OF INSURANCE ADDL INOR 908k WV�D . . . . ......... POLICY NUMBER '_ — ----d ---'—i7-- POLI Y EF � W ll991YYYYY ____ — ..1111 POLICY EXP (M"001YYYY). I'll 11-11, I'll — � � . . —1.1.1.1.1—.11.1 ...... . . . ......... . .............. .......... LI I M11TS A GENERAL LIABILITY 100000361006 01117/2015 01/17/2016 EACHOCCURRENCE $1.000.000 X COMMERCIAL GENERAL LIABILITY PA �D F" NT&' $50.000 CLAIMS-MADE IV] OCCUR MED EXP (Any one person) so X BI/PD Dedt: $5,000 PERSONAL &Apy�N�IYRY $1.000.000 -- --------------------------------------------- -------- --- -- ------------------------ ---- ..... GENERAL AGGREGATE $2.000.000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP /OP AGG $2,000,000 $ POLICY LOC E AUTOMOBIL�LL..., -JES11 ------------ - ------------------- A BILITY ...... . .. . ... . ........... . .... .... . . ..... . ......... ... 2EI849416 01/17/2015 . .. . . . . . . ...................... —... 01/1712016 ----------------- c(3MI31INC.0 SINGLE LIM11 ff&ff 9no . . ..... . .... . .............. . . . ..... . ...... ..... . . . ....... ....... 0,000,000 ------------- --------------- - X ANY AUTO BODILY INJURY (Per person) $ ALL OWNED SCHEDULED . .... ........ .......... ..... BODILY INJURY (Per accident) . . . ............. . ........... $ AUTOS AUTOS X HIRED AUTOS I x NON-OWNED AUTOS $ '01/'17'/'2'01'5' .... UMB .. R - E . L .- LA LIAB --- 100-0-0-3043-1-06 '0'1'/"1"712-0-1-6" -------- ------ - EACH -OCCURRENCE $5.000.000 AB EXCESS LIRETENTIONS - C------A---- I. M.........-........ A. . D. ..E A G G AT E 000 C WORKERS COMPENSATION TSF0001 132604 - TX 06/09/2014 06/09/2015 j WC SfA_TU- Co Co AND EMPLOYERS Y/N . ........... . D ANY PROPRIETOR/PARTNER/EXECUTIVE --N WC927798338504 - OK 06/09/2014 06/09/2015 E.L. EACH ACCIDENT $1.000.000 OFFICER/MEMBER EXCLUDED? NIA . ..... . .... . . (Mandatory In NH) E,L EMPLOYEE. $1.000.000 If es, describe under 'Py�SCRIPTION OF OPERATIONS below E,L �ISEASE- POLICY LIMIT $1.000.000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, Addidonal Remarks Schedule, If more space Is required) The General Liability and Auto policies Include a blanket automatic Additional Insured endorsement that provides Additional Insured status to the Certificate Holder (and other entities as required by the Prime Contract), only when there is a written contract that requires such status and only with regard to work performed on behalf of the named Insured. . 111- 0 a _T T UU11 I THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE —6 1988-2610 ACORD CORPORATION. All rights reserved. ACORD 25 (2010/05) 1 of I The ACORD name and logo are registered marks of ACORD #S14240504/MI4192720 CLEHB CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND R.B. EVERETT & CO. (FILE 5639) w THIS CONTRACT is made and entered into this Lly, day of 2015, by and between R.B. EVERETT & CO. a corporation, whose address is 65.61-M ID Y 1�I:: HALTOM CITY, TX 76117, hereinafter referred to as "Contractor," and tlic CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. T hese documents shall be referred to collectively as "Contract Documents." File # 5639 IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written. APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY .w,. BY: File # 5639 CONTRACTOR BY: AIJ1,1101ZI I [:) SIGNA �[ � Date: /— 7—S- Name, PHONE NUMBER EMAIL ADDRESS CITY OF DENTON, TEXAS BY: GEORGE (.. CAMPBE L, 01 "Y MANAGER AGER Date: _..... d .�... Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $225,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Standard Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on t he face of the contract /purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, a nd 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 11, 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE /TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box 1 of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of- i. delivery of defective or non- conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 15. FINAL PAYMENT AND CLOSE -OUT: A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE /WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of I% or greater. If an overpayment of I% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books" "records" "documents" and "other evidence" as used above shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE/MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File 4 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no 1 ater than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit a] I invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY- PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for iterns in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless frorn and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non - conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File 4 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract frorn the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon dernand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, ( c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a m aterial misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. if such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901 B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on a ny policy. it is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon I ocation, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon e ither of the parties hereto or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii. The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the clairnant(s); the basis thereof; and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File 4 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLES: The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 s hall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made - for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work - made - for -hire agreement, in a form to be reasonably approved by the City, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a ., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the sarne secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE RESOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the fling of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a m eeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If, within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639 may utilize to represent there or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its fine and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded frorn Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 pe rcent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a s atisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. "Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. I Oa - l Od) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at http: / /www.dol.gov /whd /contracts /dbra.htin and at the Wage Determinations website www.wdol.gov for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day. 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. RFPBid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted: • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: a Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. • That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted. [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury. • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $600,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. File # 5639 Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required. Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. File # 5639 ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File # 5639 and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: 1. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entities the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 Exhibit ....... . CONFLICT OF INTEREST QUESTIONNAIRE - FORM CIQ For vendor or other person doing business with local governmental entity This questionnaire reflects changes made tot the law by H.B. 1491, 80th Leg., Regular Session., This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176,001(1 ®a) with a local governmental entity and the person ineets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7tb business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176,006, Local Government Code. An offense under this section is a Class C misdemeanor. Name of person who has a busines r ativ ......... — ________________ _ _____ � p p wi oc I vernme tai entity. ....� ._Check this box if yo... .... ..sue ,......._�.�rr —...�, ... .. .. ........ ____.......... 2 u are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7`h business eft local tovernment officer with filer has becomes lotop'rlpleti or lira is r uYale j � Name of to � stl _ ....,� ..... �...... g employment or business relationship. Name of Officer This section, (item 3 including subparts A, B, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A, is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer ofthe questionnaire? �I = Yes No B. is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? Yes I 1 No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? l .. -J, Yes E.....I No D. Describe each affiliation or business relationship. I have no Conflict"+'' „,Nnterest to disclose, ..,,, ......... ......... ......... ........ ................................. ......... ...................... .. — zVIn , of person doing a x�ness Ih the governmental entity al �w EXHIBIT F RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT R.B. Everett & Co. Haltom CRV, TX .............. Item UoM Product Description Make/Model offered Weekly Rental Montly Rental Delivery/Pickup # Charge )N A - DOZERS EA I Dozer, Cat D10T or equivalenil 2 EA Dozer, Cat D9T or equivMent 3 EA Dozer, Cat DBT orequivaient 4 EA Dozer, Cat D7T or equivalent 5 EA Dozer, LGP Cat D7R or equivalent 6 EA Dozes, Cat D6R or equivalent 7 EA 1Dozer, LGP Cat D6R or eqjivaienf 8 EA Dom, Cat D6K or equivalool 9 EA Dozer, Cat D5M or equivalent .. . . . . . . . . . ...................................... EA Dozer, Cat D5K or equivalent C 0 ---- 11 EA Dozer, LGP Cat D5Korequivalent 12 EA Dozer, Cat D4K or equivalent 13 EA �Dozer, LGP Cat D4K or eqUNOiellt SECTION B - WHEEL LOADERS — - 1 11 4 EA A . .... ..... Wh.e.el L.o,ade.'f,-.Cat .... .. . ... 988H or eu uuly alt rat 15 - -------- EA Wheel Loader, Cat N01-1 or _quivalent - — -- - -------- 16 EA Wheeq Loader, Cat 966K Or L quivalent___ 17 .... . ........... EA 16 EA Wfirae[ Loader, Cat 9501-lor!n�!ni�qt 19 EA Wheel Loader, Cat 938H or equiva tent - - - - -------- . ... . ............... - --- — ------------- 20 EA Wheel Loader, Cal 930illofequivalent 21 . EA ......................... Wheel Loader, Cat 9241-lor ec . . ....... v �'-Ilenl ...... . . .......... SEC11ON C- MOTOR GRADERS i A E-lt . . ............... .................. .. . .......... . Motor Grader, Cat 12M or e UwNeRll ... ... 23 EA Motor Grader, Cat 140M or equivalont SECTION D- EXCAVATORS 24 EA Fxcavatcx, Cat 3,45 or uivale"I — ------------------- - — ----------- - — ----- 25 EA Fxcavator, Cat336DLo e �jvalenl � q �' Doosan DX350LC 26 EA Excavalor, Cat 325 or eqkflvraent 27 EA Excavator, Cat 329E or eqdvalent wlGrapple 28 EA Excavatcx, Cd 324E or (,)Tdvalent 29 EA Excavator, Cat 320 or uaiaav [e� 30 .- EA - ........................... Excavator, Cat 32 D o e -- 9 � ! 31 EA Excavator, with hydraulic breaker 1,500 (fl 11b) class, Cat 312D . . . . . . ........................................................... 32 EA Excavator, with hydrook breaker 3,,00O (fl lhl class„ Cat 320DL 33 EA Excavator, with hydratific breaker 5,000, (t lb ogws Cal 320DL 34 EA with zero Cat 320D Excavalor, Cat 320 Na �noreq SECTION E- SOIL SCREENERS 35-F EA I Sail 'Sco4wer, Torex/Foifley 770 of equlvafieM 318" � 114" sweem 36 I EA — boat e r -j , .r...e.....x..../ ... -lne x 3/8 1/4 screen SECTION F - TRUCKS (OFF ROAD) 37 EA Truck, (Off -Raad), Cil 725 or equivalam — - --- - --------------------- 38 EA Cat 7�O o� e9owalent 39 EA rruck, (Off -Road), Cat 740 or eriqivaienl SECTION G- SCRAPERS ...................... EA 6, —aoe r . . ............ . Scraper, Cat 623G or eq0valerrI 41 EA $cra aeo Cat 62IG ore ulv al'errt 42 EA q'craper Cat 615C or e ,3uly agent 43 EA � ... Srcra er„ Cat 613G or equaivalcant SECTION H -TRACK LOADERS Track L..� 44 EA Loader, Cat 973D or equiivMent -- -- ...... ...... equivalent 46 45 ETrack ... Track Loader, C¢r % 963D or e .... ... .. .. .. _� ........__ .......... 46 EA T rack Loader Cat 953D or equivNont SECTION I- COMPACTORS .... 47 k ctow EA Cat 825 or cc trly alr'rert 48 EA I t-, I anYon„ Cat 615E or e urlvalent 49 k non aerator, Cat' C' t EA I #? aIr or s m{u?]v slea"F� 50 EA C<srrotqarrclou °, Cat CS56 or eot,uly�ulerod p�' 3- l.. 51 EA t Drat aokor, at CP -323 -C or o amvolehq 52 EA VV., k r Trench Roller, RT56 20 or atgifivalent with 22" drum SECTION' J - WATER WAGONS (OFF -ROAD) 54.. —EA ij .� at 613 0 er 1Naa oar, IOII•l�o�dj Ca�v�ruiv rloaal m4EWat._. Cat 725 or ram alrnnC . SECTION K - WATER TRUCKS (ON- ROAD): Must be TxDOT Approved with Licer 55 EA lw:�58 uck (On -Road) 3,750 or 4,000 glat m SECTION L - MIXERSIRECYCLERS 57 EA MlxerlRerc:ycler, Borrra(1100R. or eyuar aPent _ 58 EA 149ixerlr ecycler t;,MI 325 or e(Irrnva(oarot 59 twlax.. n_ 5 EA 00 or eluarValeryl erPP�t�a�rrl�p CMI 5...., - SECTION M - ASPHALT -LAY DOWN MACHINE Lay Down Machine, 811 15 k SECTION N - ASPHALT ROLLERS 61 EA A� IaaI4 Rdailoa 9 to n . ... 62 Asphalt Roller, 12 ton _. SECTION O - ASPHALT MILLING MACHINES EA 63 A phaalt Milling maclaane 4 k head . — E -64 Appall Millers M1aGachine 6 ft herd 6 ... .... SECTION P - BROOM rtq [E]AO 65 Broiow Addit onal cost for lterboom eattechnwt _ SECTION Q - DUMP TRUCK (ON- ROAD): Must be TxDOT Approved with Licens( aa5 EA IJuua a T'oucl 12 Yard rd I a SECTION R - BACKHOES A 1658 _- . 67 Baokhoe Case d dru o ralv,alnrat Bah(S class 68 EA Sddkhoe„ Case 590N or erjuivalent - 10'0NuIr olass m yLW'a'oaaa aaddert to Backhoe base kruucxa_ EA ,. luap 7_68 Additional cost for cab with �alr condition lap I EA Additional cost for 4 -wheel drive 7 -68 EA mm Additonal cost for exterrd' O .., SECTION S - SKIDSTEERS 69 ,�k4d EA s1cer Ca 1 216B or e u lvalent �._............ ... .. ,9. ................. ----- � ._.. 69a EA 2puan Additional coat for Iraoks EA Skldstr, er Cat 226B or e�uiv Le!it 7 EA 4 aler 71 ,kaa1 aleoI Cat 2368 or er ulv.- ._� it ...... .. . _... _ 72 EA Skldsteer, Cat 246C or epuiv�aleni 73 EA.. Skldsteer, Cat 256. ..._.__ _ C or edla lvtalorsl 74 EA 'aklrltbeer, Cat 262C, or err oiiwater)t 75 EA SkOsteer, Cat 272C or eululvalent EXHIBIT F CITY OF DENTUN 901B TEXAS ST DENT0N, TX 76209 Bodily Injury and Property Damage Combined Automobile Liability Policy Number Coverage Limits 49-53232-38 General Aggregate 1'500.000 Products Aggregate 1,500,000 OCCURRENCE Pars/Adv Injury 500.000 Each Occurrence 500.000 Premises Damage $ 100.000 Medical Expense $ 5.000 rM Includes: Bodily Injury and Property -Any Auto Excess/Umbrella 49-63232'36 Each Occurrence Does Not Include: General Aggregate -Excess Employers Liub Products Aggregate 500,000 10,000,000 $ 30.000.000 $ 30.000.000 Should any of the above described policies be cancelled before the expiration date thereof, notice will be delivered in accordance with the policy provisions. R B 49-63232 01-718642 LD| COI 269628-1 02 11 O1-30-2Ol5 PAGE l ,`,,C,° +_ E DATE (MMIDDIYYYYp �I�� AN 01 /29/15 LIABILITY INSUR C E R-�- F ��++ _ _ THIS CERT(FICATE 'IS ISSUED AS A MATTER OFF CERTIFICATE ONLY AND CONFERS NO ATE CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. olic les must be endorsed. If IIBROGATIONes not confer .. the terms and conditions lof the policy, Dl of ciI sL ae require an -- INSURED, the .. Y( I ,,, a ect to P Y. P Y q endorsement. A statement on this certificate do rights to the certificate holder In lieu of such endorsement(s). k Jao Krahch P RODUCER NAm r 1111... r t1C 7 Ax (817) 453-1473 KnH Insurance Services LTI_ i17 1701 Highway 287 N., Suite 105 ¢ "MANE knprrn uranre., canl ArJpLt�S"s. }krill – Mansfield, TX 76063 RL s AFFORDINra, �qYr AW F _ .- ....,t±Aro _ Phone.. _.. 117) 453 -1477 Fax (1317) 453-1473 .. . m ._ ieSURER A...... ....__ '.N.. »Q,UrxEf# tf _... INSURED Ikl...,. .., .. _. ....m _ R B Everett & Co IN MAVZJ4 4 : m,, v__ -- ..._ I ___. _ .,, - ... -_. INSURt sz D Service Lloyds Insurance Compmy PO Box 7300 _ -. ' 1111.. � _ _... __ 11,11 _ ...1111. . - -- ..... Pasadena, TX 77508 _ --ItlVe,&FftGOT.F. CERTIFICATE NUMBER .. .�. REVISION NUMBER. oHls Its Go SrRT11 Y THaT THE Pal rCICEOF wl SURANCE LtlSTFO BELOW HAVE BI. °:1 N ISSUED TO THE INSURED NAMO D ABOVE I OR TBiF POLICY PERIOD INDICATED„ NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, CONDITIONS AVE BEEN REDUCED BY PAID CLAIMS EXCLUSIONS NS OF SUCH POLICIES LIMITS SHOWN MAY INSR TYPAND E NCE OF INSURANCE AL r,(y NHB S ,,.,. (MMI CY EFF rOLm07"YYY) POLICY Xp (,tPAdDDdYYY) ( LIMITS _ • -- I 1, 1" ERALLIABILITY GENERAL LAgJII_OCt.PU ,REE^C •' -,— OAMAGI If D RPt,OT ED ........ S °" "m' ❑ COMMERCIAL GENERAL LIABILITY 0 � ° {Ltr r" ZPpwwperi�;c1...... ❑ ❑ CLAIMS -MADE ❑ OCCUR EXP (Any on_ xperson ,....,,, . .. yy PERSONAL & ADV INJURY m ....� . ..S 1 _........ 111 1... _ -._ GENERAL AGGREGATE „$. PRODUCTS COMPIO P AG G S GEN'L AGGREGATE LIMIT APPLIES PER: - ° -- .. ......... f..� t"td L-1 its E 1 _ . _ _ I�,IttlE .._....... ., __ w 1111.— _111,1. � C'fMk7 +IVCrJ wNC�a r f yrullt AUTOMOBILE LIABILITY AE ✓�'k, eI4 _ .. .. "� .. BODILY INJURY (Per person) S ❑ ANY AUTO ALL OWNED SCHEDULED ❑ ❑ AUTOS BODILY INJURY PereN.ridenAl ", AUTOS ❑ NON-OWNED 4�J Cr I Nd f Y DAPuM%O (6inccayr�f.iet).. _ ..._ $ .,. .. ❑ HIRED AUTOS .,.,,.,.... A ;,.. ... 1111. - 1111._ ., .. ...,,...._._._. e,� .. .m._,....— . ,�._,.... __ . . ,� 1111 ....--- ............ _ ..... ,,.,,1111.. —.. . ❑ UMBRELLA LIAB ❑ OCCUR E EA(1,j OCCURRENCE EXCESS LIAB L.) CLAWS—MADE REGATE S _ ., , WORKERS COMPENSATION 1 - 1....1. 6TAJ � �, l tly"UM17 1I. . e— -_ AND EMPLOYERS LIABILITY YIN ArwfYPROPRrI TOWPARINfwVEXECtT IVF SRZG28597 -15 02101/2015 02/01/2016 L I EACH ACCT1'JN NI - -- - S 1 000 000,00 1111. D OF raf.-tl JMEMCreLTt LXC.LUt: ED? fl NIA Y L� L AFL �A rMI,1,OYE s 1,000,000-00 (M nd:wdoNy in NH) 4 Y .� if pp�, ds..c6bez undrrr E ....,. .DISEASE - POLICY LIMIT 1111 S 1 000,000.00 , d7d. aCrN Irri lOrl OF OPERATIONS S bebw ESCRIPTION OF OPERATIONS �- - - -� e � - ..a,,,._ ! LOCATIONS /VEHICLES ACORD 101, Additional Remarks Schedule, If more space is required) ._......_.._ s.._- 1111... ,,.....,,.. ,,, , 1111 - ............... ........ .. _ � --- __ .. 1111._.. — CERTIFICATE HOLDER CANCELLATION ...., _1111,.., 1111, _— , ........ _- .._ -_ J SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Denton ACCORDANCE WITH THE POLICY PROVISIONS. 901 B Texas Street Denton TX 76209 AUTHORIZED REPRESENTATIVE i° ©1988 -2010 ACORD CORPORATION. ---- •� ® -- ° ° — . All rights reserved. ACORD 25 (2010105) QF The ACORD name and logo are registered marks of ACORD CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND LANDMARK EQUIPMENT, INC. (FILE 5639) THIS CONTRACT is made and entered into this /1—h day 4, 1:., 2015, by and between LANDMARK EQUIPMENT, INC. a corporation, whose Aad ess is 1351 SOUTH LOOP 12, IRVING, TX 75060, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $150,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricinu sheet used to the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Standard Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on the face of the contract /purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, and 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 11, 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE /TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box 1 of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance 'address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of: i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 15. FINAL PAYMENT AND CLOSE -OUT: A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE /WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of I% or greater. If an overpayment of I% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books" "records" "documents" and "other evidence" as used above shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE /MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File # 5639 shall , not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY - PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non - conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks' relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable, required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. If such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE ' CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on any policy. It is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon location, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon either of the parties hereto' or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii: The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the claimant(s); the basis thereof; and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLES: The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 shall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made - for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work - made - for -hire agreement, in a form to be reasonably approved by the City,, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the same secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE RESOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the filing of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a meeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If, within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision, of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as'possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. "Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. 10a - 10d) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at htt.:CNvwnEA2p and at the Wage Determinations website w. ;�.�a;.��.:.g: v for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day. 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. RFPBid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File 4 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted. • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. ■ That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted. [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury. • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has. Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. File # 5639 [ ] Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. [ ] Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. [ ] Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required, [ ] Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. File # 5639 ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions, Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File 4 5639 and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 Exhibit E CONFLICT OF INTEREST QUESTIONNAIREmmmm- FORM CIQ For vendor or other person doing business with local governmental entity This questionnaire reflects changes made to the law by H.B. 1491, 80th Leg., Regular Session. This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. Name of person who has a business relationship with local governmental entity. Check this box if you are filing an Z .. _ c y g update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7th business dav after the date the orlquna[ly filed uestionnaire becomes incomplete or inaccurate., 3 Name of local government officer with whom filer has an employment or business relationship. Name of Officer This section, (item 3 including subparts A, B, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? El Yes No 14. Is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? Yes El No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? Ell Yes E—] No D. Describe each affiliation or business relationship. m4 ..... .... . ............. ........ V have no ..._......................._. Conflict of Interest to disclose. I ..... JL 5 m Si nalur at w i )' I do lg b i u s with IBac governmental cntnly Date File # 5639 EXHIBIT F RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT Landmark Equipment, Inc. Irving, TX ................ Urn uoM Product Description Make/Model offered Weekly Rental Montly Rental Delivery/Pickup Charge SECTION A - DOZERS 1 EA Dozer, Cat D1 OT or aqolvalent 2 EA Dozer, Cat D9T or equivaWnt 3 EA Dozer, Cat D8T or equivalent 4 EA Dozer, Cat D7T or equivalent 5 EA Dozw, LGP Cat D7R or equivalent 6 EA Dozer, Cat DER or equivalent 7 EA Dozer, LGP Cat D6R or equivalent 8 EA Dozer, Cat D61K or aclOvateN -97 EA Dozer, Cat D5M or ejulyalent.. EA Dozer, Cat D5K or eldviWnt 1 EA Dozer, LGP Cat D5K or equivaWnt 12 EA Dozer. Cat D4K or aq0valerrl 13 mmmmEA Dozer, LGP Cat D4K or equivalent SECTION B - WHEEL LOADERS 14 EA Wheel Loader, Cat 9881-1 ore i��enl 15 EA Whool Leader, Cat 980H or! quivalent 16 EA Wheel Loader, Cat 966K or equivalent 17 EA Wheel Loader, Cat 962K or equlvalent 18 EA Wheel Loader, Cat 9541H or e 19 Emmmmm WheeJ Loader, Cat 9381-1 ore urv�rlDrrl 20 EA Wheel Loader, Cat 930H or �nnvalerul 21 EA Wreel Loader, Cat 924H or equivalent SECTION C- MOTOR GRADERS 22 EA Motor Grader, Cat 'I 2M of equivalent 23 EA Motor Grader, Cat 140M or equuvalwit SECTION D. EXCAVATORS 24 EA Excavator, Cat 3451DI-orequivaJerft 25 EA Excavator, Cat 336DL or equ"ant 26 EA Excavator, Cat 325 or egeiva9auat 27 EA Excavator, Cat 329Eor equivalent wJG' 28 EA Excavator, Cat 324Eor ecgulvarent _ 29 EA Excaw for Cat 3209r equlvalerri 30 EA Excavator, Cat 320DL or eculwalent wl, 31 EA Excavator, with l gdraulic breaker 1,500 32 EA Excavator, with hydraulic breaker 3,000 33 EA Excavator, with hydraulic breaker 5,000 34 EA Excavator, Cat 320 with zero tall±eLn.R� SECTION E- SOIL SCREENERS; 35 FEA Soil Scr I"; 1"e x'J F'liil'e-' 77'0 are utv 36 1 EA Soil ScreenerJ'ere!jney120_ororgu[? SECTION F - TRUCKS (OFF ROAD) ............ 37 EA Fruqlk, (Off-Road), Cat 726 o�r wlifivalwil 38 EA Truck .(Off, Road), Cat 730 or eciulvaleni 39 EA �Trvck, (0#�Road), Cat 740 or equivaleni SECTION G- SCRAPERS ........... 40 1 EA rraraer. Cat 623G or equivalent class, Cat 312D class, Cat 320DL class, Cat 320DL ilenk, Cat 320D :!/E- .... 1/4" screen ... . ... - - 3/8" - 1/4" screen 41 EA Scraper, Cal 621G or egulvalent 42 EA Scrapern Cat 615CoreguNdent ...... 43 EA crsm Cat 613G or equGval'ent SECTION H -TRACK LOADERS 44 EA Track. Loader Cat MD or . 5 1 "rack loader, Cat 963r1 tar ulvrslen 45 EA ^ 46 EA Track Lraader Cat 953D or ealuivssienl SECTION I- COMPACTORS 47 EA•.•_ CornZaokear, Catm825 or equivalent 48 EA.... Com�sackor. Cat 815F or aquNalent 49w ww „EA Ltor, Cat CP56 or equivalent 50 EA Compactw, Cat CS56 ore sutvAen! 51 EA Compactor Cast CP- 323-0 or tq�alvalerd ...... ........................ .....�. EA j valerit with 22" drum 52 VNac,kar Trench Roller RT5620 or ec u¢ _ ... . -- .....�. SECTION J - WATER WAGONS (OFF -ROAD) 53 EA Water W'a,on (Off -Roam) Cat 613 or equivalent 54 EA Water W'a ouw (C fIIT•Poad), Cat 725 or equivalent SECTION K - WATER TRUCKS (ON- ROAD): Must be TxDOT Approved with Licet 55 A tr Truck (i1o"t- Roaxd) ?,000 9sd. 56 r Truck (On-Road), 3,750 or 4,000 gal SECTION L - MIXERS /RECYCLERS .......................... ..... . .... . 57 EA P ixor /Rec daf Bogiag 100R or is utvalent 58 EA MrxerfRsa: cler, CMI 325 or equivalent 59 EA Wxerf o cler, CMI 500 orequivalanl SECTION M - ASPHALT -LAY DOWN MACHINE 60 EA Asphalt Lay Down Machl,u7e eft. 15 ft. ........ -_ ._. -- .......... N N - ASPHALT ROLLERS 61 on - Aa...hagt Roller 9 t......... EA Asrhad Roller, 12 ton SECTION O - ASPHALT MILLING MACHINES . _ EA _ _ -- 63 EA AsphaVl Mffl nq Mar;Nne 4 ft head 64 m^ As hall fluplddr fW6aCl1lne2 6 ft. head _._. SECTION P - BROOM 65a CY loran ... o 65 EA Brcx.k RJ350 Broom or eCgulvtaVent _ EA Adduluonal cost fear gUlter boom attachment SECTION Q - DUMP TRUCK (ON- ROAD): Must be TxDOT Approved with Licensi 8'8 EA tYua roro Truck, 12 Yard SECTION R - BACKHOES B7 EA Bsarkhoe Case 580N or z quNalentl 85hp class 68 EA Backhoe, Case 590N or aqulValanl 100hp mass Options added to Backhoe base prtce. 17.68 EA Addllinnal cast for cab with air condutionin�� 7 -68 EA AddiWnM cost for 4 -wheel drive EA Arldillcraal cost for extc naladt SECTION S - SKIDSTEERS 89 EA SklcV eer, Cat 2168 or eguivallerrl 69a EA Op0ow Additrsanal cost for tracks 70 EA Skldsteer, Cat 2268 or a uivale rop 71 EA Skldskeer, Cat 236B or e esavalenl EA W. _..., 72�.W....... Skadsteerer, Cat 246,.. Cor equivalent . 73 EA Skidsteef, Cat 256C or equivalent 74 ...... EA Skldsteet, Cal 2829 ce onNrwl,va3earC .... .. - -.. 75 EA Skidsteer, Cat 272C or erluNalent EXHIBIT F LANDMARK EQUIPMENT INC 1351 SOUTH LOOP 12 |RV|NS. TX 75080 This certificate is issued on 01-01-2015 and is effective until 01-01-2016. It certifies that policies of insurance listed below have been issued to the insured named above, Notwithstanding any requirement, term or condition of any contract or other document wn_� respect to which this certificate may be issued or ma pertain, the insurance afforded by the policies described herein is sub]ect to all the termo, exclusions, and conditions of such policies. Limits shown may have been reduced by paid claims, General Liability Bodily |»�ury and Property Demage Combined ^ Automobile Liability Policy Number Coverage Limits 25-48713-01 General Aggregate 1.500.000 Products Aggregate 1^500.000 OCCURRENCE Pers/Adv Injury 500.000 Each Occurrence 500.000 Premises Damage $ 100.000 Medical Expense $ 5'000 Includes: Bodily Injury and Property -Any Auto Excess/Umbrella 25-48713-01 Each Occurrence 5.000.000 Does Not Include: General Aggregate $ 15.000.000 -Excess Employers Liob Products Aggregate $ 15.000.000 Should any of the above described policies be cancelled before the expiration date thereof, notice will be delivered in accordance with the policy provisions. LAN 25-48713 01 -121342 LD| COI 259828'1 02 11 O1-3O-2O15 PAGE 1 Mumm CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND HERTZ EQUIPMENT RENTAL CORPORATION (FILE 5639) d THIS CONTRACT is made and entered into this diy cal. 2015, by and between HERTZ EQUIPMENT RENTAL CORPORATION, whose address "aw 46,3„7 W. UNIVERSITY DR., DENTON, TX 76207, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $270,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of +/ -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manaifacttirers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Sta-cif a94 Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on the face of the contract /purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, and 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 11, 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE/TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLE& The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box 1 of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of- i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE /WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of I% or greater. If an overpayment of I% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books ", "records ", "documents" and "other evidence ", as used above, shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE /MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File 4 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY-PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non - conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File 4 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON-CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. If such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on any policy. It is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon location, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon either of the parties hereto or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii. The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the claimant(s); the basis thereof; and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLE& The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 shall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made -for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work -made- for -hire agreement, in a form to be reasonably approved by the City, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the same secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File 4 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE SOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the filing of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a meeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If, within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. 'Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. I Oa - l Od) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at tl °1r aN�� 1�1.A.rwJtif� �� mVmtITM and at the Wage Determinations website w .wd for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day: 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. RFPBid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COM PEN SENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS; Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted: Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. ■ That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. c • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted. [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury, • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $600,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. M Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required,. Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, lam' and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: 1. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on r...N' the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. IM Exhibit E .._� .............. ------------ _ ....---- ....... ..... ............ ......,.... CONFLICT OF INTEREST QUESTIONNAIRE - FORM CIQ For vendor or other person doing business with local governmental entity This questionnaire reflects changes made tot the law by H.B. 1491, 80th Leg., Regular Session. This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. 1 Name of person who has a business relationship with local governmental entity, �_.m ............ _ ... ., ... _.... . ... ------ - , 2 Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7'h business day after the date the originally filed questionnaire becomes incomplete or inaccurate. ....... ....................._.......__ . 3 Name of local government officer with whom filer has an employment or business relationship. Name of Officer This section, (item 3 including subparts A, B, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? Yes E- -1 No EJ la. Is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? D Yes 0 No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? EJ Yes El No D. Describe each affiliation or business relationship. m.......... I have no Confli........ ..... — .. .......... � ....... ......___ .... n...... 4� ® c - Conflict of Interest to disclose. .. . _ ... ___ 5 _ .: ..w. 01-23-15 utiu c of person doing business � �� u tyro r' p g with the governmental entity Bate EXHIBIT F RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT Hertz Equipment Rental Corporation Bonita Soeinres, FL item '....... uoM Product Description Make /Model offered Weekly Rental Montly Rental Delivery/Pickup Charge # . ........... . . ' . ..._......_ - -- _...... .....- - - -... SECTION A - _ __ _........ 1 E EA . D_o_z_er, Cat D10T . � .. ... _.,.. .......m. 2 E ., . . .o..r ..0.g. u . ... 3 E EA D Dozer, Cat D8T or equlrvalent 4 E EA D Dozer„ Cat D7T or equivalent . ... .. . .. W.. EA D Dozer, LGP Cat D7R or equiv,rlenl . - _...._ _ ..... 11, — 6 E — 1 1 ��. ......_ - Deere 650 $ _ $ 1.210.00 $ $ 3,255.00 $150.00 Each way 7 E EA D Dozer LGP Cat DER or equiv ulerat _ _ ....,,,,,...m..' _ __ ..___ 8 E EA D Dozer, Cat D6K or aquivalent 9 E EA D Dozer„ Cat D5M or o ulv<aien " 10 E EA _ Dozer„ Cat D5K or e e uival q nl ....., LL 11 E EA D Da7er, LGP Cat D r q -� � D5K or egerivalcnd 12 E EA K Dozer, Cat D4. q _ 13 E EA D Dozer, SECTION B - WHEEL LOADERS m, .... _ _ 14 E ...-- .... Wheel Loader, Cat 988H or equivaleanrl 11 15 E EA — — __ .... , ,,,. ,,,,m _ _ ..., ,... . .... . ............._ 16 E EA W Wheel Loader„ Cat 966K or ea uivalrarrrl 17 E EA Wheel Loader, C.k 962K or eepavalerut 18 E EA W Wheal Loader, Cat 950H or eq(dvalent D Deere 644 $ $ 2.110.00 5 5,800.00 $ $99,00 each way 19 E EA W Wheel Loader, Cat 938H or equwvalanR 20 E EA D vUheeil I. , Deere 544 $ ..._ , $ 1,30000 $ 3,950.00 $99 00 each way 41 EA pe lent .....: ,._. �au�a or C ndCllttora�irlya. ....... .............._ _.. ........... 42 EA Ir a orar)uivalent _ _...— �a a ur Cat 615C - - - ------- -- - ..................... _. 43 EA Sc raV, ea Cat 613G or eequlvale rit SECTION H -TRACK LOADERS - _ - - -- 44 EA l «rk Loader Cat 973D or plv alcnt .... 45 EA Track Loader Cat 963D or eaaly tle ad -- ... - 46 EA i ruck Loader Cat 953D or r aLuivm�lend SECTION I- COMPACTORS 47 _Ceauaaatrror CatB...... nnnnn _m EA 25 or acpa�ti'vadenq 48 —� Co ra7 actor, Cat 815F or acquflva00nt 1. EA 49 EA CoaviCnadol Cat CP56 oa eaquly adunt _.... ....... .,------ ....... 50 E C onrpaatoj,, Cat CS56 or ea:lurva &exnt 51 EA Compactor, Cad C P 321 C or k�a)taavalelu0 __ 52 EA _ Warker Trench Rodker RT5620 ore uivatenl with 22 druuu . ....... -em_� .�... an.., .......gym. Um.... ....... _� SECTION J - WATER WAGONS (OFF -ROAD) .........m,�_ 53 LEA Cat 613 or e gauly 0 nt 54 Water Wa0rair (Off Road), Cat 725 or ealuly ada rid SECTION K - WATER TRUCKS (ON- ROAD): Must be TxDOT Approved with Licei �. .. i.. w 55 Water Truck L)nlrtaa"1n,d 000a�ak 56 EA Water Truck Gn-Pr oad t 750 or 4 000 gal SECTION L - MIXERSIRECYCLERS 57 EA Mlxer)[3 ex ap Bcaruua 10R eN � � -... � 0 °f,e aaiva9ent .... , ., 58 EA MlxcadRa r r deer e. or CMI 325 ulvak mt �.. w... ...._. i -_. _,.........ww.. .�_m...�_ 59 EA Mdxa rlR cya ler CMI 500 Or wauluiv akur t SECTION M - ASPHALT -LAY DOWN MACHINE 60 EA �,phak - Lay Down Machine, 8ft 15 ft SECTION N - ASPHALT ROLLERS 62 Ae lk 89llar 12 61 EA Aspha ald kCr ller on 9 t ton EA rkaa SECTION O - ASPHALT MILLING MACHINES 64 EA jAs ah uaall Milllra Mar kiurie 4 ft head 63 As Iactll Mlllln M as hone 6 ft, head d..,._ . _. m -...m _ __ .,_ SECTION P - BROOM 65a Yr dIo rR Addit oval cost foal clelyd. .. EA adtrii boom attachment SECTION Q - DUMP TRUCK (ON- ROAD): Must be TxDOT Approved with Licens( 6t1 EA Iaarrapa Track 12 Yard — -- SECTION SE'TION R - BACKHOES 1111111-11-1-1 67 Barkilou„ Case 580N or nekuly aleup k 5bp class EA _.- Ea _ ,._ 68 A Backhoe, Case 590N or ea uaavale d 1 00h class I ----------- — �icoe ri: ....m..._. — doras added to Ba ..........kh ba se . .,. p__ ._ ce ..... ...._____. 7 -68 EA A dddtlon al cost for cab with air conditionln,tq 7 -68 Adalutkearaal cost fo.......am. ..., _ EA r 4 -wheel drive 768 EA. 1t r. 9eddlonalcostforertona4sud'dp SECTION S - SKIDSTEERS _ 69 Ea Skid,ter Cat 216E a.r .. t.i.gy niv cde9it y .._._ _ ....... ......_, EA cost for tracks 69a C7�ad(nn�AddltloneL ._.,_,.,.,....,,,_._._....._.. _.......- ....._ ......, -n,n._ ...... 70 EA Skidsdee�e, Cat 226B or equivalent 71 dsqoea. ., k Cat 2368 ore aalvaga.aut ..........................Ea m .. EA aa9crud ..7.2 .................____ Skred�s�dclrorp i:ad 246C or 73 EA Skidskaer, Ca eqkerud _. t 256C or Lugva ................ ._...__. . ................ ....,.. ...._ --------- 74 �EA Slkla 9.r4'ten n', Cat 262C or egLlyakcnt 75 Skledsde�� ..m ce Cat 272C or eacauivMe N r:ir: DATE (M MIDD/YYYY) CERTIFICATE OF LIABILITY INSURANCE 01/27/2015 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT MARSH USA, INC. NnMr _ „.. m 445 SOUTH STREET (,TIP, Noy E31 }, „. (MC, Noj MORRISTOWN, NJ 07962 -1966 E -MAIL Attn: Hertz- certrequesl @marsh.com Fax 212 - 948 -0979 9 DRrS�. -_..... .. ....... INSI.IRFRIM AFFORDING. COVE.RAGE. ........ � NAIL # 100595 -STND- MAIN -14 -15 Koban INSURER A : ACE American Insurance Company 22667 ._._.___ INSURED _ __._ - INSURER B: Indemnity Ins Co Of North America 43575 INSURER GLOBAL HOLDINGS, INC. -~ ... ._ ACE Fire Underwriters Co 20702 (SEE ATTACHED LISTING) INSURER C . 999 VANDERBILT BEACH ROAD INSURER D: NAPLES, FL 34108 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: NYC- 007003775 -01 REVISION NUMBER:2 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, INSR LTR TYPE OF INSURANCE ACYtYo nBin POLICY NVM13ER _,.... POta�� POLICY EXP MM6DCIJYYYY fMMIDDIYYYY I LIMITS A GENERAL LIABILITY HDOG27340982 12/31/2014 12/31/2015 EACH OCCURRENCE $ 1,000,000 X OKMAbE 10 (TENT iJ — 1,000,000 COMMERCIAL GENERAL LIABILITY PREMISES (F ocrnrra+ra(;vr) $ CLAIMS -MADE X I OCCUR I _ _ ME D EXP (An. one person) $ 10,000 —..... PERSONAL & ADV INJURY $ 1,000,000 _.. - ....... ......... __... - ----- . GENERAL AGGREGATE $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP /OP AGG $ 1,000,000 X POLICY LOC $ AUTOMOBILE LIABILITY Self- Insured up to $1,000,000 12/31/2014 12131/2015 a OMWNCO $ING I~T 1,000,000 (e.�( Rtpng . . ... — -- X ANY AUTO AIR other States BODILY INJURY (Per person) $ ,...Mn'. ALL OWNED — .... -_.. SCHEDULED BODILY INJURY (Per accident) $ AUTOS AUTOS ,,. ., ,.. NON -OWNED > ". See Attached • "" PROPERTY DAMAt L $ HIRED AUTOS AUTOS (Per areldanll _ w -_ .. $ p UMBRELLA LIAB [ OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS -MADE AGGREGATE $ $ $ WORKERS COMPENSATION LN. WLR 048145772 AOS 011mm 01I2U15 0110112016 X we sTATU- oTro Y ANY OFFICER/MEMBER EXCLUDED? E EcurivE I N 'I CA, MA) ACCIDENT NIA -- 461145784 C �'_ SCF (W�� 01/0112015 .01/0112016 E LA D EMPLOYEE' $ 1 0 000 ... If yes, describe under DESCRIPTION OF OPERATIONS below E,L. DISEASE - POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attar . more s ... (Attach ACORD 101, Additional Remarks Schedule, If more space Is required) CITY OF DENTON IS NAMED AS ADDITIONAL INSURED WITH REGARDS TO GENERAL LIABILITY FOR ALL WORK CONTRACTUALLY OBLIGATED PURSUANT TO THE AGREEMENT, CERTIFICATE HOLDER CANCELLATION CITY OF DENTON SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE ATTN: REBECCA HUNTER THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN MATERIALS MANAGEMENT DEPARTMENT ACCORDANCE WITH THE POLICY PROVISIONS. 901 B TEXAS STREET DENTON, TX 76209 AUTHORIZED REPRESENTATIVE of Marsh USA Inc. Manashi Mukherjee �*= 0 ACORD CORPORATION. All rights reserved. ©1988 -201 _ ACORD 25 (2010/05) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: 100595 LOC #: Morristown ,---) a c- " R L? ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY MARSH USA, INC. POLICY NUMBER CARRIER NAIC CODE NAMED INSURED HERTZ GLOBAL HOLDINGS, INC. (SEE ATTACHED LISTING) 999 VANDERBILT BEACH ROAD NAPLES, FL 34108 EFFECTIVE DATE: ACORD 101 (2008/01) @ 2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND ASSOCIATED SUPPLY CO., INC. (FILE 5639) THIS CONTRACT is made and entered into this day n 2015, by and between SSO IA"I'El") SmUPI -1, (f ),, 11 i ". ,� corloration„ whose �c;l is 201m9 AIRPORT FRWY, EULESS, TX 76040, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $150,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of +/-l%, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of: i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii, require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY - PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post - judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision- making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at littp: / /www.dol. og v /wlld /contracts /dbra.litm and at the Wage Determinations website www.wdol. ov for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted. • Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. • That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. File # 5639 EXHIBIT F RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT Associated Supply Co., Inc. Euless, Texas Item uoM Product Description Make /Model offered Weekly Rental Montly Rental Delivery/Pickup # Charge SECTION A- DOZERS 1 EA iDozer, Cat DI OT or rtarpuuivaaent 2 " EA .._ ...... Dozer, Cat D9T or egutvalent 3 j EA Dozer, Cat D8T or ec uivMenl I 4 EA Dozer, Cat D7T or eriu valerst ... 5 EA... Dozer, LGP CM D7 R or egulvraptaxret 6 EA Dozer, Cat D6R or e uivale nt .._.._ - m..__ ........ ............................... 7 EA Dozer, LGP Cat D6R or eguuvalent 8 EA Dozer, Cat D6K or egAvalerat 9 EA Dozer, Cat D5M or ecluivaient 10 EA Doze), Cat D5K or uquivaalont 11 EA " Dozer, LGP Cat D51< or equNalent 12 EA Dozer, Cat D4K or vqulvaleral 13 E GP Cat D4K or eu t jkv akat SECTION B - WHEEL LOADERS 14 EA Wtyal, Loader„ Cat 988H or ogiliv8alent 15 EA Whoel Loader, Cat 980H or erluivaalenrl 16 EA 1 Wheal Loader, Cat 4166K or uwgulvelent �1P 17 EA Wpoet Loader, Cat 962K ore qulvaleni 18 EA Whrrel Loader. twat 91,3014 or egtIrvallent 19 EA.......... W.ho�r'.l...Loader, Cat 23.�1-...or ... „� I m.donr etch... .,., . , ................................. ....................�.�.,..�... 20 EA Whoel Loader Cat 930H or egauvaleaal 21 EA Wheal Loader Cat 924H or egp.irvalent SECTION C- MOTOR GRADERS 22 EA Motor grader, Cal 12M or , u,ulvalent 23 EA Molnar Grader, Cal '140M or equlvaloEt SECTION D- EXCAVATORS _. .._.._...�. 24 EA , ' aatva8rial Excavator, Cat 345DL or e 25 EA Excavator Cad 336DL art as ulvaattant . - ......I .__..... 26 E_ f °xr.avatot Cat 325 orequlvalent 27 EA Excavator, Cat 329E or erc ulvalortltl wdr'tr'gs�sle 28 EA Excavator Cat 324E or e rAakrnl 29 EA Excavator, Cat 320 ore, Ivaakarit 30 EA Excavator Cal 32'diDt Oar t rtalv.alant W10a t lr!a 31 EA Excavator, w iih 1 "t drauIlc hreaaker l 500 ft 1hy daao, Caal 3112D 32 EA Excavator, with by lr italic breaker 3, 000 hilt lh) r raee, Cat 320DL _a_ - _....__ ...- ..-- .-.. -- L -�_- ....- 33 EA Excavator, with 1, dr atulac breaker 5,000 '0 1b) ctaSa, Cat 32ODL y i 34 EA Excavator, Cat 320 with zero ta"0lwpin1 or equatvrpalont, Cat 320D SECTION E- SOIL SCREENERS 35 — EA __ 1 36 EA r VF4 acmes soulS[r rier„ 're in 700ora uaivalorrt 3,ftl" en SECTION F - TRUCKS (OFF ROAD) 37 Truck, (Off floral,). Cat 725 or oaiuivatent 38 TEA EA ......,� Truck, (011 Rorad), Cat 730 or equuivaMnl 39 EA 1 ruckIT fl7tt ! icr roc Cat SECTION G- SCRAPERS Il,wcraner, Cat 623G or eaulvale rut _.._. 40 EA � R" CERTIFICATE OF LIABILITY INSURANCE DA ��) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT _uenac CLIENT C ONTAC:T CFITF_R FEDERATED MUTUAL INSURANCE COMPANY HOME OFFICE: P.O. BOX 328 a/cNea ExtL 888-3334949 (A/C. Nol: 507 - 446 -4664 _. OWATONNA, MN 55060 onneESS: CLIFNTCONTACTCENTER(c FEDINS.COM �� :.._. •- INSURERIS) AFFORDING COVERAGE NAIC # COMPPANY ANY 1 139 INSURER A: FEDERATED MUTUAL INSURANCE •mm - � 3935 INSURED 038 -597 -1 INSURER B: ASSOCIATED SUPPLY CO INC INSURER c PO BOX 3888 LUBBOCK, TX 79452 INSURER D: INSURER E: INSURER F: .......................m.. ,..................... COVERAGES CERTIFICATE NUMBER: 503 REVISION NUMBER: 0 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. - .- .,W ................ 1 S BR POLICY EFF POLICY EXP LIMITS I NSR TYPE OF INSURANCE ° NSR WVD POLICY NUMBER fMM /nD /YYYY1 1MM /DDIYYYYI GENERAL LIABILITY EACH OCCURRENCE $1,000,000 .,d. X COMMERCIAL GENERAL LIABILITY PREMISES 1Ea RENTED nce) $,100,0,0,0 MED EXP (Any one person) $5,000 �. CLAIMS-MADE X OCCUR .� A N N 9077187 07/01/2014 07/01/2015 PERSONAL& ADV INJURY 1,000,000 GENERAL AGGREGATE $2,000,000 - ........ ...._ . ..._ GEN PRODUOTS COMPIO AGO 'L Af;.GRE«NATE� LIMIT A6�1^"i.YE'S PER: P AGO $2,000,000 X POLICY PRO^ LOC JECT AUTOMOBILE LIABILITY C OMBINEDISI�NGLE LIMIT $1,000,000 X ANY AUTO BODILY INJURY (Per person) ALL A I AUTOS OWNED AUTOSULED N N 9077187 07/01/2014 07/0112015 BODILY INJURY (Per acc _ _�,,..mmmm._.�......�.. IdenQ NON -OWNED PROPERTY DAMAGE pn HIRED AUTOS ._.._. ......... AUTOS 1Per ceidentl X UMBRELLA LIAR X OCCUR EACH OCCURRENCE $30,000,000 A EXCESS LIAB CLAIMS -MADE N N 0709592 07/01/2014 07/01/2015 AGGREGATE $30,000,000 DED RETENTION WORKERS COMPENSATION X WC STIMIT OTH- TORY LIMITS ER AND EMPLOYERS' LIABILITY �I' .- ...• .- .... -....- —_.••••...,. ..,.,.,m.e,,,,,,,m,,,,,,,,,,,,, ANY PROPRIETORIPARTNER /EXECUTIVE Y�. ACCIDENT $1,000,000 A OFFICERIMEMBER EXCLUDED? N I A N 9424011 07/01/2014 07/01/2015 E.L. DISEASE ._.,.,�,�,„...,..,.,.... (Mandatory in NH) • EA EMPLOYEE $1,000,000 If yes, describe under E.L DISEASE •POLICY LIMIT DESCRIPTION OF OPERATIONS below $1,000,000 ........._ •........... .., ............................................................... . DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, it more space is required) CERTIFICATE HOLDER CANCELLATION 038 -597 -1 5030 CITY OF DENTON SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE 901B TEXAS STREET THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN DENTON, TX 76201 ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE © 1988 -2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010/05) The ACORD name and logo are registered marks of ACORD CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND BLUE LINE RENTAL (FILE 5639) THIS CONTRACT is made and entered into this day 2015, by and between BLUE LINE RENTAL a corporation, whose address is l ill () �M 60NA LI:) ST., MCKINNEY, TX 75071, hereinafter referred to as "Contractor," and the CITY OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written. APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY File 4 5639 CONTRACTOR BY: __.. A1J 11IORI MD SIGNATURE Date: / -17 -4,x/5 Name: G yby A z?,vzF.,& 86 4y PHONE NUMBER Cvoy. Bu -ru2 �BLUECr�v�/L�vrar, co,� EMAIL ADDRESS CITY OF DENTON, TEXAS BY: w a GEORGE C. CAMPBELL, CITY MANAGER Date: „ Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $150,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of +/-I%, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Standard Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on the face of the contract /purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, and 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 11, 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE /TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box 1 of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non- conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property . i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of- i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii. failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional' charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 15. FINAL PAYMENT AND CLOSE -OUT: A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE /WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of 1% or greater. If an overpayment of 1% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books ", "records ", "documents" and "other evidence ", as used above, shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE /MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File # 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY- PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non - conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non- conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. If such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of_insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on any policy. It is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon location, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon either of the parties hereto or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii. The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the claimant(s); the basis thereof; and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File 4 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLES: The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 shall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made - for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work - made - for -hire agreement, in a form to be reasonably approved by the City, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the same secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE RESOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the filing of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a meeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If, within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. "Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. I Oa - l Od) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at http: / /www.dol.gov /whd /contracts /dbra.htm and at the Wage Determinations website www.wdol.gov for Denton, County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day. 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. 1. Final negotiated contract 2. REP /Bid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted. • Each policy shall be issued by a company authorized to do business in the State of g Texas with an A.M. Best Company rating of at least A- VII or better, Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. ■ That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted: [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury. • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. File # 5639 [ ] Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. [ ] Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. [ ] Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required. [ ] Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. File # 5639 ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions: Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File # 5639 and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: 1. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 Exhibit E CONFLICT OF INTEREST QUESTIONNAIRE — CONFL QE _ ".,.� NAIRE -FORM CIQ For vendor or other person doing business with local governmental entity This questionnaire reflects changes made to the law by H.B. 1491, 80th Leg., Regular Session. This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(a }. By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. a ... � Name of p rson who has a business relationship with local governmental al entity. 1—�j... ... --- - - - - -- ------- ••------------- - - - - -- -- 2 .—Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7th business day after the date the originally filed questionnaire becomes incomplete or inaccurate.) 3 Name of local government officer with whom filer has an employment or business relationship. Name of Officer This section, (item 3 including subparts A, B, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? El Yes B. Is the tiler of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? 0 Yes E] No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? E:1 Yes No D. Describe each affiliation or business relationship. 4 I have no Conflict of Interest to disclose. ....... ....... . . . . �... ... ,�... 5 Si gn ature of person d�it �arss with the governmental entity Date RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT EXHIBIT F Blue Line Rental I Woodlands, TX Item Product Description # UoM 7 Make/Model offered Weekly Rental Montly Rental Delivery/Pickup Charge SECTION A - DOZERS 1 EA Dozer, Cat DlOTorequivalent 2 EA Dozer, Cat D9T or equivalent 3 EA Dozer, Cat D8T or equivatent 4 EA Dozer, Cat D7T or equivalert 5 EA Dozer, LGP Cat D7R or equivalent 6 EA Dozer, Cat D6R orequlva@enl . . ........ . .w ... .. .... . ..... 7 EA Dozer, LGP Cat D6R or equivalent 8 EA Dozer, Cat D6K or equivainni 9 EA Dozer, Cat D5M or equivalent 10 EA Deter, Cat D5K or equivalent 11 EA Dozer, LGP Cat D5K or equivalent . . ................ . .......... . . ....................... . . 12 EA Dozer, Cat D4K or equivaleriI .............. Dozer, r. LGP Cat D4K or equivalenli SECTION B -WHEEL LOADERS 14 EA Wheel, Loader, Cat 988H or equivalent 15 EA Wheel Loader, Cat 98011 or equivalent. 1 16 EA Wheel LoI Cat 966K or ec alent 17 EA Wheel Loader, Cat 962K or equivalent 18 EA Wheel Loader, Cat 951:88 f or equivsIoni 19 EA VMieel Loader, Cat 938H or equivaient 20 EA Whee9 Loader, Cat 930H or o q ulvaUo w 21 EA VI wader, Cat 924H orequJuMent SECTION C- MOTOR GRADERS 220 _jE�A�*tqr Grader, Cat 12M or equivateni Volvo G930 - 14' blade $ 3,070.00 S 1,200..11 SH,10 One time fee 23 EA Motor GrI Cat 140M 2r . . . ........ . SECTION D- EXCAVATORS 24 ...- .m__....- EA ........ ExcawAor, Cat 345DL oreqwvalent 25 EA Excavator, Cat 336DL or eqwNalent 26 EA Excava;aor , Gat 325 or equivarent 1_. 27 EA rxcavalor, Cat 329E or 'tq�vq�ent I r _ _ 28 EA Excavator„ Cat 324E or equivalent 29 EA Excavator, Cat 320 or equivalent 30 EA Excavator, Cat 320DL or et)ualw anent w G a ............ . . . 31 EA ExcavI with hydraqAc breaker 1,50Q, ('it 11b) rJass, Cat 312D 32 EA Ex avataa , with h yq r2uVc breaker 3 f70 (ft 1b) class, Cat 320DL - 33 EA Excavator, with hydraulic breaker 5A 000, (it 11h) class, Cat 320DL EA nvator, Cat 320 With zero tailspin or eq ivalem, Cat 320D ........... . . . ................................. _P .......... ......... . . . ......... . .......... . SECTtON E- SOIL SCREENERS 5 EA So0 Screener, 770 or equivaIent W8", 114 screen r, e - y��22! 3/8" - 1/4" screen EA ISoil Screene , IFJ Z�q _L'L�Z_ �T SECTION F - TRUCKS (OFF ROAD) ...... . . . ........ 37 EA Truck, (Cfl goad ), Cat 725 ore uivalent 38 EA gat 730 or jqLAIvilent _= ... . . . ........................... . 39 EA T ruck, (Io(toad ,Cat 740oreqiflva1cnl SECTION G- SCRAPERS 40 EA SoTaper, Cat 623G or equivaleni 41 EA Scr,a em, Cat 621 G or equivalent 42 EA Scra)aer Cat 615 or oquivYale M _W.. ...... _ 43 EA ua rsa,ar„ Cat 613G or ezulvaflenl SIECTfON H -TRACK LOADERS 44 EA Track, Loader Cat 9731D ore gvalonlwwwwwww ...EA jTrack Loader, Cat 963D or equgvalent 46 EA Track Loader, Cat 953D or eCquNaleni ,SECTION I- COMPACTORS 47 EA Compactor, Cat 825 or equiyaenl �48-- -- EA]f,onr actor, Cat 815E or equivalent EA aalvolenl 49 Con, ff aulur (ag C or a � 50 EA Caoraclor Cat CS56 or < r(,uivaienl 51 EA Comcaatoa Cat CP -323 -C or etiuNalent 52 Wackef Trench Roller„ RT5620 ore r,aivalent with 22" drum _ - EA tl. ...__ww ....... . _ .. SECTION J - WATER WAGONS (OFF -ROAD) 5 ta ter W aa�on C(ff Roadj, Cat 613 or equirraleni A al w:r Wagon (011`.Road), Cat 725 or equlvaienI SECTION K - WATER TRUCKS (ON- ROAD): Must be TxDOT Approved with Llcet 56 EA ruck (Onu Road) 3,750 or 4 001) 55 Water Truck 0114 56 al SECTION L - MIXERSIRECYCLERS 57 . MrxerlRoo3?v�ler, Bo... -- - -... _ .........� _ ,..... EA rnag 100R or equivalent 58 EA Mjxer1Rq , �cor, Chill 325 ore ulvalent 8 —.. w lR e alent 59 EA Mixed ... fler„ CMI 500 or „ uiv.._ SECTION M - ASPHALT -LAY DOWN MACHINE �60 ... EA �Asphall Lay Machine„ Bft. - 15 ft. .. -. -- .. �...m . _.. _.. __ _... SECTION N -ASPHALT ROLLERS E. q62 A Asplragt Roller 9 ton A Asplr ult Roller 12 ton �. SECTION O - ASPHALT MILLING MACHINES 63 EA Asphalt Milling Machine, 4 ft. head 64 1 EA Asph I M(ldan9 Muchtne 6 ft head SECTION P - BROOM 65a EA Opt om Additional cost for gt dterlboom attachment SECTION Q - DUMP TRUCK (ON- ROAD): Must be TxDOT Approved with License __E — __ ..... -, 66 EA C1um)a T�raaa k 12 Yard SECTION R - BACKHOES 67 EA _- Barkgroo Case 580N or ectulvnlearl 851h a class 68 EA Backhoe, Case 590N or equivalent . 100hp class .. _ O llons added to Backhoe base price 7-681 EA Addiffon al cost for cab with air r ondifrorpin(q __..,_ .. ..... .. ..... ......... ........................... ...... ...... 7-681 EA Adddi,a roam cost for 4 -wheel drive ."....��......., -- 1.1.11. -, _. 7-68 EA IAdd ti cnel cost for extendadk,tg SECTION S - SKIDSTEERS 8sakidstleer, Cal 21CS11 or a uaiV... .....�.... .. „ ........................... - -..... EA c q alone 69a EA rr Additional cost for tracks 70 EA Skidsteer, Cat 2268 or equivalen 71 EA Skid!steer, Cat 23613 or equivalent -- 1_111 72 EA ;kidsteer„ Cat 246C or c gtwalent 73 1_111_ �k #dsteer„ Cat 256C EA or erque valent 74 EA Skidsjeer,_Cat 262C or egquyalent 75 EA Skidsteer, Cat 272 ��... �. C or ecpfatvalent. EXHIBIT F CERTIFICATE OF LIABILITY INSURANCE DATE( 011281/2015 2015 YYYY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsernant:(s):. PRODUCER CONT _AZ T Marsh USA Inc. NAMt ° EAR PHON 1717 Arch Street E 11, _ ; °a N.oi. ..... Philadelphia, PA 19103 -2797 E-MAIL c . ,...... _ INSURERISI AFFORDING COVERAGE . . . 710470- BLR- GAWX -14 -15 INSURER A, National Liability Y & Fire Insurance Company 20052 INSURED INSURER B : Greenwich Insurance Company 22322 BlueLine Rental, LLC . . "° __ 127 Walnut Bottom Road INSURER C XL Insurance America Inc. 24554 _ -- ._..... _ _ ... ... .. Shippensburg, PA 17257 INSURER D INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: CLE- 004195719 -01 REVISION NUMBER:2 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES: LIMITS•SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. _,.. — — m... __ INSR ADOL SCIFJI, POLICY EFF POLICY EXP I TR TYPE OF INSURANCE co �nnm POLICY NUMBER MMIDDIYYYYI M&1 /Oti"IpYYYY LIMITS A GENERAL LABILITY 43 GLO 100147 01 01/31/2014 01/31/2015 EAC "H OCCURRENCE $ 1,000,000 X COMMERCIAL GENERAL LIABILITY I h9AsE 1 O RLfii1E I 100,000 t �f11 MI1 t ~a t(° cr�raluq falri pL .., $ OCCUR son) $ CLAIMS -MADE X ' PERSONAL & ADV INJURY $ 1000,000 - -----. ............ ---- GENERAL AGGREGATE $ 2 000,000 PRODUCTS 2,000,000 � GEN'L AGGREGATE LIMIT APPLIES PER. P /OP,AGG $ __.. PRO, ( ) m...� _ Cj ads 133 I,4 E) SINOLL LIMI1 5,000,000 X POLICY LOC B AUTOMOBILE LIABILITY RAD9437685 (ADS) 0113112014 0113112015 SIR $ 100 000 B X ANY AUTO RAD9437666 (MA) 01/31/2014 01/31/2015 BODILY INJURY (Per person) $ ALL OWNED' SCHEDULED BODILY INJURY Per accident) $ AUTOS AUTOS leeraccdentuAMAGE NON-OWNED PROr'ER1 Y 1 $ i HIRED AUTOS .AUTOS __..__ .... .... ...._._.... .:........ A X — UMBRELLA LIAB X OCCUR 43 UMO 100148 01 01/31/2014 01/31/2015 EACH OCCURRENCE s 5,000,000 e mn. 5 000000 EXCESS LIAB CLAIMS -MADE .AGGREGATE $ C _ �.. -. -� _ rnRV $ �jj 01/31/201 0 C AND EMPLOYERS' LIABILITY E TIVE Y / N RWR9435446 (WI) 0113112014 0113112015 E L EACH i Annlrc l „ _ oGA _- ,,,,,,,,,, _ -__ DED RETENTION ANY PROPRIETOR /PARTN CU $ 1 �� OFFICER /MEMBER EXCLUDED? N NIA E,L DISEASE - EA EMPL ACCIDENT T (Mandatory In NH) OYE $ 1 000,000 if es, describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L DISEASE POLICY LIMIT $ DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES Attach ACORD 101, Additional Remarks Schedule, If more ( re space is required) The Certificate Holder is Included as additional insured (except workers compensation) where required by contract. The General Liability is primary and non contributory over any existing insurance and limited to liability arising out of the operations of the named insured where required by contract. Waiver of Subrogation is applicable where required by contract. ww CERTIFICATE HOLDER CANCELLATION City of Denton, its Officers, Agents, SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Employees and Volunteers THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 901 B Texas St. ACCORDANCE WITH THE POLICY PROVISIONS. Denton, TX 76209 AUTHORIZED REPRESENTATIVE of Marsh USA Inc. l Manashi Mukherjee 1,a .......W.... � .� ©1988 -2010 ACORD CORPORATION. All rights reserved.: ACORD 25 (2010/05) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: 710470 LOC #: Philadelphia ADDITIONAL REMARKS SCHEDULE AGENCY NAMED INSURED Marsh USA Inc. SIUeLine Rental, LLC 127 Walnut Bottom Road POLICY NUMBER Shippensburg, PA 17257 CARRIER 11 NAIC CODE EFFECTIVE DATE: Page 2 of 2 ACORD 101 (2008101) © 2008 ACORD CORPORATION. All rights reservea,. The ACORD name and logo are registered marks of ACORD CONTRACT BY AND BETWEEN CITY OF DENTON, TEXAS AND CLOSNER EQUIPMENT CO., INC. (FILE 5639) THIS CONTRACT is made and entered into this , K "day oi" 01.5, by and between Q- 0Sl'�IFR1 T:I�T C(. li C. ". c rl.c tic 1z„ wow rsc adca 1819 LACY DR., FT. WORTH, TX 76177, hereinafter referred to as "Contractor," and OF DENTON, TEXAS, a home rule municipal corporation, hereinafter referred to as "City," to be effective upon approval of the Denton City Council and subsequent execution of this Contract by the Denton City Manager or his duly authorized designee. For and in consideration of the covenants and agreements contained herein, and for the mutual benefits to be obtained hereby, the parties agree as follows: SCOPE OF SERVICES Supplier shall provide products and /or services in accordance with the City's document RFP # 5639 Rental of Heavy Equipment, a copy of which is on file at the office of Purchasing Agent and incorporated herein for all purposes. The Contract consists of this written agreement and the following items which are attached hereto and incorporated herein by reference: (a) Special Terms and Conditions (Exhibit "A "); (b) Request for Proposal (Exhibit "B" on File at the Office of the Purchasing Agent); (c) City of Denton Standard Terms and Conditions (Exhibit "C "); (d) Insurance Requirements (Exhibit "D "); (e) Form CIQ — Conflict of Interest Questionnaire (Exhibit "E "); (f) Contractor's Proposal. (Exhibit "F "); These documents make up the Contract documents and what is called for by one shall be as binding as if called for by all. In the event of an inconsistency or conflict in any of the provisions of the Contract documents, the inconsistency or conflict shall be resolved by giving precedence first to the written agreement then to the contract documents in the order in which they are listed above. These documents shall be referred to collectively as "Contract Documents." File # 5639 IN WITNESS WHEREOF, the parties of these presents have executed this agreement in the year and day first above written. ATTEST: JENNIFER WALTERS, CITY SECRETARY BY: , - QI IK464'11" APPROVED AS TO LEGAL FORM: ANITA BURGESS, CITY ATTORNEY BY File # 5639 I: ORIZED SI6NATURE Date: O . I Name Title: I 0 7 Ile t f I _._.n.. PHONE NUMBER y EMAIL ADDRESS CITY OF DENTON, TEXAS B� M 1 . (AN 'iP B EIL L, 0'1 V MANAGER ` ... . Date: -7 /5 Exhibit A Special Terms and Conditions Total Contract Amount The contract total for services shall not exceed $255,000. Pricing shall be per Exhibit F attached. Contract Terms The contract term will be one (1) year, effective from date of award. The City and the Supplier shall have the option to renew this contract for an additional two (2) one -year periods. The contract shall commence upon the issuance of a Notice of Award by the City of Denton and shall automatically renew each year, from the date of award by City Council, unless either party notifies the other prior to the scheduled renewal date. At the sole option of the City of Denton, the contract may be further extended as needed, not to exceed a total of six (6) months. Price Escalation and De- escalation The City will implement an escalation/de- escalation price adjustment annually. The escalation/de- escalation will be based upon manufacturer published pricing sheets to the vendor. The price will be increased or decreased based upon the annually percentage change in the manufacturer's price list. The price adjustment will be determined annually from the award date. Should the change exceed or decrease a minimum threshold value of + / -1 %, then the stated eligible bid prices shall be adjusted in accordance with the published price change. It is the supplier or the Cities responsibility to request a price adjustment annually in writing. If no request is made, then it will be assumed that the bid price will be in effect. The supplier must submit or make available the manufacturers pricing sheet used to calculate the bid proposal, to participate in the escalation /de- escalation clause. File # 5639 Exhibit C Standard Purchase Terms and Conditions These standard Terms and Conditions and the Terms and Conditions, Specifications, Drawings and other requirements included in the City of Denton's contract are applicable to contracts /purchase orders issued by the City of Denton hereinafter referred to as the City or Buyer and the Seller or respondent herein after referred to as Contractor or Supplier. Any deviations must be in writing and signed by a representative of the City's Procurement Department and the Supplier. No Terms and Conditions contained in the seller's proposal response, invoice or statement shall serve to modify the terms set forth herein. If there is a conflict between the provisions on the face of the contract /purchase order these written provisions will take precedence. The Contractor agrees that the contract shall be governed by the following terms and conditions, unless exceptions are duly noted and fully negotiated. Unless otherwise specified in the contract, Sections 3, 4, 5, 6, 7, 8, 20, 21, and 36 shall apply only to a solicitation to purchase goods, and sections 9, 10, 11, 22 and 32 shall apply only to a solicitation to purchase services to be performed principally at the City's premises or on public rights -of -way. 1. CONTRACTOR'S OBLIGATIONS. The Contractor shall fully and timely provide all deliverables described in the Solicitation and in the Contractor's Offer in strict accordance with the terms, covenants, and conditions of the Contract and all applicable Federal, State, and local laws, rules, and regulations. 2. EFFECTIVE DATE /TERM. Unless otherwise specified in the Solicitation, this Contract shall be effective as of the date the contract is signed by the City, and shall continue in effect until all obligations are performed in accordance with the Contract. 3. CONTRACTOR TO PACKAGE DELIVERABLES: The Contractor will package deliverables in accordance with good commercial practice and shall include a packing list showing the description of each item, the quantity and unit price unless otherwise provided in the Specifications or Supplemental Terms and Conditions, each shipping container shall be clearly and permanently marked as follows: (a) The Contractor's name and address, (b) the City's name, address and purchase order or purchase release number and the price agreement number if applicable, (c) Container number and total number of containers, e.g. box 1 of 4 boxes, and (d) the number of the container bearing the packing list. The Contractor shall bear cost of packaging. Deliverables shall be suitably packed to secure lowest transportation costs and to conform to all the requirements of common carriers and any applicable specification. The City's count or weight shall be final and conclusive on shipments not accompanied by packing lists. 4. SHIPMENT UNDER RESERVATION PROHIBITED: The Contractor is not authorized to ship the deliverables under reservation and no tender of a bill of lading will operate as a tender of deliverables. 5. TITLE & RISK OF LOSS: Title to and risk of loss of the deliverables shall pass to the City only when the City actually receives and accepts the deliverables. File # 5639 6. DELIVERY TERMS AND TRANSPORTATION CHARGES: Deliverables shall be shipped F.O.B. point of delivery unless otherwise specified in the Supplemental Terms and Conditions. Unless otherwise stated in the Offer, the Contractor's price shall be deemed to include all delivery and transportation charges. The City shall have the right to designate what method of transportation shall be used to ship the deliverables. The place of delivery shall be that set forth the purchase order. 7. RIGHT OF INSPECTION AND REJECTION: The City expressly reserves all rights under law, including, but not limited to the Uniform Commercial Code, to inspect the deliverables at delivery before accepting them, and to reject defective or non - conforming deliverables. If the City has the right to inspect the Contractor's, or the Contractor's Subcontractor's, facilities, or the deliverables at the Contractor's, or the Contractor's Subcontractor's, premises, the Contractor shall furnish, or cause to be furnished, without additional charge, all reasonable facilities and assistance to the City to facilitate such inspection. 8. NO REPLACEMENT OF DEFECTIVE TENDER: Every tender or delivery of deliverables must fully comply with all provisions of the Contract as to time of delivery, quality, and quantity. Any non - complying tender shall constitute a breach and the Contractor shall not have the right to substitute a conforming tender; provided, where the time for performance has not yet expired, the Contractor may notify the City of the intention to cure and may then make a conforming tender within the time allotted in the contract. 9. PLACE AND CONDITION OF WORK: The City shall provide the Contractor access to the sites where the Contractor is to perform the services as required in order for the Contractor to perform the services in a timely and efficient manner, in accordance with and subject to the applicable security laws, rules, and regulations. The Contractor acknowledges that it has satisfied itself as to the nature of the City's service requirements and specifications, the location and essential characteristics of the work sites, the quality and quantity of materials, equipment, labor and facilities necessary to perform the services, and any other condition or state of fact which could in any way affect performance of the Contractor's obligations under the contract. The Contractor hereby releases and holds the City harmless from and against any liability or claim for damages of any kind or nature if the actual site or service conditions differ from expected conditions. The contractor shall, at all times, exercise reasonable precautions for the safety of their employees, City Staff, participants and others on or near the City's facilities. 10. WORKFORCE A. The Contractor shall employ only orderly and competent workers, skilled in the performance of the services which they will perform under the Contract. B. The Contractor, its employees, subcontractors, and subcontractor's employees may not while engaged in participating or responding to a solicitation or while in the course and scope of delivering goods or services under a City of Denton contract or on the City's property. i. use or possess a firearm, including a concealed handgun that is licensed under state law, except as required by the terms of the contract; or ii. use or possess alcoholic or other intoxicating beverages, illegal drugs or controlled substances, nor may such workers be intoxicated, or under the influence of alcohol or drugs, on the job. File # 5639 C. If the City or the City's representative notifies the Contractor that any worker is incompetent, disorderly or disobedient, has knowingly or repeatedly violated safety regulations, has possessed any firearms, or has possessed or was under the influence of alcohol or drugs on the job, the Contractor shall immediately remove such worker from Contract services, and may not employ such worker again on Contract services without the City's prior written consent. Immigration: The Contractor represents and warrants that it shall comply with the requirements of the Immigration Reform and Control Act of 1986 and 1990 regarding employment verification and retention of verification forms for any individuals hired on or after November 6, 1986, who will perform any labor or services under the Contract and the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 ( "IIRIRA) enacted on September 30, 1996. 11. COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS: The Contractor, it's Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor's obligations under this paragraph. Environmental Protection: The Respondent shall be in compliance with all applicable standards, orders, or regulations issued pursuant to the mandates of the Clean Air Act (42 U.S.C. §7401 et seq.) and the Federal Water Pollution Control Act, as amended, (33 U.S.C. §1251 et seq.). 12. INVOICES: A. The Contractor shall submit separate invoices in duplicate on each purchase order or purchase release after each delivery. If partial shipments or deliveries are authorized by the City, a separate invoice must be sent for each shipment or delivery made. B. Proper Invoices must include a unique invoice number, the purchase order or delivery order number and the master agreement number if applicable, the Department's Name, and the name of the point of contact for the Department. Invoices shall be itemized and transportation charges, if any, shall be listed separately. A copy of the bill of lading and the freight waybill, when applicable, shall be attached to the invoice. The Contractor's name, remittance address and, if applicable, the tax identification number on the invoice must exactly match the information in the Vendor's registration with the City. Unless otherwise instructed in writing, the City may rely on the remittance address specified on the Contractor's invoice. C. Invoices for labor shall include a copy of all time - sheets with trade labor rate and deliverables order number clearly identified. Invoices shall also include a tabulation of work -hours at the appropriate rates and grouped by work order number. Time billed for labor shall be limited to hours actually worked at the work site. D. Unless otherwise expressly authorized in the Contract, the Contractor shall pass through all Subcontract and other authorized expenses at actual cost without markup. E. Federal excise taxes, State taxes, or City sales taxes must not be included in the invoiced amount. The City will furnish a tax exemption certificate upon request. File # 5639 13. PAYMENT: A. All proper invoices need to be sent to Accounts Payable. Approved invoices will be paid within thirty (30) calendar days of the City's receipt of the deliverables or of the invoice being received in Accounts Payable, whichever is later. B. If payment is not timely made, (per paragraph A); interest shall accrue on the unpaid balance at the lesser of the rate specified in Texas Government Code Section 2251.025 or the maximum lawful rate; except, if payment is not timely made for a reason for which the City may withhold payment hereunder, interest shall not accrue until ten (10) calendar days after the grounds for withholding payment have been resolved. C. If partial shipments or deliveries are authorized by the City, the Contractor will be paid for the partial shipment or delivery, as stated above, provided that the invoice matches the shipment or delivery. D. The City may withhold or set off the entire payment or part of any payment otherwise due the Contractor to such extent as may be necessary on account of. i. delivery of defective or non - conforming deliverables by the Contractor; ii. third party claims, which are not covered by the insurance which the Contractor is required to provide, are filed or reasonable evidence indicating probable filing of such claims; iii, failure of the Contractor to pay Subcontractors, or for labor, materials or equipment; iv. damage to the property of the City or the City's agents, employees or contractors, which is not covered by insurance required to be provided by the Contractor; v. reasonable evidence that the Contractor's obligations will not be completed within the time specified in the Contract, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; vi. failure of the Contractor to submit proper invoices with purchase order number, with all required attachments and supporting documentation; or vii. failure of the Contractor to comply with any material provision of the Contract Documents. E. Notice is hereby given that any awarded firm who is in arrears to the City of Denton for delinquent taxes, the City may offset indebtedness owed the City through payment withholding. F. Payment will be made by check unless the parties mutually agree to payment by credit card or electronic transfer of funds. The Contractor agrees that there shall be no additional charges, surcharges, or penalties to the City for payments made by credit card or electronic funds transfer. G. The awarding or continuation of this contract is dependent upon the availability of funding. The City's payment obligations are payable only and solely from funds Appropriated and available for this contract. The absence of Appropriated or other lawfully available funds shall render the Contract null and void to the extent funds are not Appropriated or available and any deliverables delivered but unpaid shall be returned to the Contractor. The City shall provide the Contractor written notice of the failure of the City to make an adequate Appropriation for any fiscal year to pay the amounts due under the Contract, or the reduction of any Appropriation to an amount insufficient to permit the City to pay its obligations under the Contract. In the event of none or inadequate appropriation of funds, there will be no penalty nor removal fees charged to the City. 14. TRAVEL EXPENSES: All travel, lodging and per diem expenses in connection with the Contract shall be paid by the Contractor, unless otherwise stated in the contract terms. During the term of this contract, the contractor shall bill and the City shall reimburse contractor for all reasonable and approved out of pocket expenses which are incurred in the connection with the File # 5639 performance of duties hereunder. Notwithstanding the foregoing, expenses for the time spent by the contractor in traveling to and from City facilities whall not be reimbursed, unless otherwise negotiated. 15. FINAL PAYMENT AND CLOSE -OUT: A. If a DBE /MBE /WBE Program Plan is agreed to and the Contractor has identified Subcontractors, the Contractor is required to submit a Contract Close -Out MBE/WBE Compliance Report to the Purchasing Manager no later than the 15th calendar day after completion of all work under the contract. Final payment, retainage, or both may be withheld if the Contractor is not in compliance with the requirements as accepted by the City. B. The making and acceptance of final payment will constitute: i. a waiver of all claims by the City against the Contractor, except claims (1) which have been previously asserted in writing and not yet settled, (2) arising from defective work appearing after final inspection, (3) arising from failure of the Contractor to comply with the Contract or the terms of any warranty specified herein, (4) arising from the Contractor's continuing obligations under the Contract, including but not limited to indemnity and warranty obligations, or (5) arising under the City's right to audit; and ii. a waiver of all claims by the Contractor against the City other than those previously asserted in writing and not yet settled. 16. SPECIAL TOOLS & TEST EQUIPMENT: If the price stated on the Offer includes the cost of any special tooling or special test equipment fabricated or required by the Contractor for the purpose of filling this order, such special tooling equipment and any process sheets related thereto shall become the property of the City and shall be identified by the Contractor as such. 17. RIGHT TO AUDIT: A. The City shall have the right to audit and make copies of the books, records and computations pertaining to the Contract. The Contractor shall retain such books, records, documents and other evidence pertaining to the Contract period and five years thereafter, except if an audit is in progress or audit findings are yet unresolved, in which case records shall be kept until all audit tasks are completed and resolved. These books, records, documents and other evidence shall be available, within ten (10) business days of written request. Further, the Contractor shall also require all Subcontractors, material suppliers, and other payees to retain all books, records, documents and other evidence pertaining to the Contract, and to allow the City similar access to those documents. All books and records will be made available within a 50 mile radius of the City of Denton. The cost of the audit will be borne by the City unless the audit reveals an overpayment of 1% or greater. If an overpayment of 1% or greater occurs, the reasonable cost of the audit, including any travel costs, must be borne by the Contractor which must be payable within five (5) business days of receipt of an invoice. B. Failure to comply with the provisions of this section shall be a material breach of the Contract and shall constitute, in the City's sole discretion, grounds for termination thereof. Each of the terms "books ", "records ", "documents" and "other evidence ", as used above, shall be construed to include drafts and electronic files, even if such drafts or electronic files are subsequently used to generate or prepare a final printed document. 18. SUBCONTRACTORS: A. If the Contractor identified Subcontractors in a DBE /MBE /WBE agreed to Plan, the Contractor shall comply with all requirements approved by the City. The Contractor shall not initially employ any Subcontractor except as provided in the Contractor's Plan. The Contractor File # 5639 shall not substitute any Subcontractor identified in the Plan, unless the substitute has been accepted by the City in writing. No acceptance by the City of any Subcontractor shall constitute a waiver of any rights or remedies of the City with respect to defective deliverables provided by a Subcontractor. If a Plan has been approved, the Contractor is additionally required to submit a monthly Subcontract Awards and Expenditures Report to the Procurement Manager, no later than the tenth calendar day of each month. B. Work performed for the Contractor by a Subcontractor shall be pursuant to a written contract between the Contractor and Subcontractor. The terms of the subcontract may not conflict with the terms of the Contract, and shall contain provisions that: i. require that all deliverables to be provided by the Subcontractor be provided in strict accordance with the provisions, specifications and terms of the Contract; ii. prohibit the Subcontractor from further subcontracting any portion of the Contract without the prior written consent of the City and the Contractor. The City may require, as a condition to such further subcontracting, that the Subcontractor post a payment bond in form, substance and amount acceptable to the City; iii. require Subcontractors to submit all invoices and applications for payments, including any claims for additional payments, damages or otherwise, to the Contractor in sufficient time to enable the Contractor to include same with its invoice or application for payment to the City in accordance with the terms of the Contract; iv. require that all Subcontractors obtain and maintain, throughout the term of their contract, insurance in the type and amounts specified for the Contractor, with the City being a named insured as its interest shall appear; and v. require that the Subcontractor indemnify and hold the City harmless to the same extent as the Contractor is required to indemnify the City. C. The Contractor shall be fully responsible to the City for all acts and omissions of the Subcontractors just as the Contractor is responsible for the Contractor's own acts and omissions. Nothing in the Contract shall create for the benefit of any such Subcontractor any contractual relationship between the City and any such Subcontractor, nor shall it create any obligation on the part of the City to pay or to see to the payment of any moneys due any such Subcontractor except as may otherwise be required by law. D. The Contractor shall pay each Subcontractor its appropriate share of payments made to the Contractor not later than ten (10) calendar days after receipt of payment from the City. 19. WARRANTY- PRICE: A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. 20. WARRANTY — TITLE: The Contractor warrants that it has good and indefeasible title to all deliverables furnished under the Contract, and that the deliverables are free and clear of all liens, claims, security interests and encumbrances. The Contractor shall indemnify and hold the City harmless from and against all adverse title claims to the deliverables. File # 5639 21. WARRANTY — DELIVERABLES: The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned. A. Recycled deliverables shall be clearly identified as such. B. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law; and any attempt to do so shall be without force or effect. C. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the date of acceptance of the deliverables or from the date of acceptance of any replacement deliverables. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand either repair the non - conforming deliverables, or replace the non - conforming deliverables with fully conforming deliverables, at the City's option and at no additional cost to the City. All costs incidental to such repair or replacement, including but not limited to, any packaging and shipping costs shall be borne exclusively by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach of warranty, but failure to give timely notice shall not impair the City's rights under this section. D. If the Contractor is unable or unwilling to repair or replace defective or non - conforming deliverables as required by the City, then in addition to any other available remedy, the City may reduce the quantity of deliverables it may be required to purchase under the Contract from the Contractor, and purchase conforming deliverables from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such deliverables from another source. E. If the Contractor is not the manufacturer, and the deliverables are covered by a separate manufacturer's warranty, the Contractor shall transfer and assign such manufacturer's warranty to the City. If for any reason the manufacturer's warranty cannot be fully transferred to the City, the Contractor shall assist and cooperate with the City to the fullest extent to enforce such manufacturer's warranty for the benefit of the City. 22. WARRANTY — SERVICES: The Contractor warrants and represents that all services to be provided the City under the Contract will be fully and timely performed in a good and workmanlike manner in accordance with generally accepted industry standards and practices, the terms, conditions, and covenants of the Contract, and all applicable Federal, State and local laws, rules or regulations. A. The Contractor may not limit, exclude or disclaim the foregoing warranty or any warranty implied by law, and any attempt to do so shall be without force or effect. B. Unless otherwise specified in the Contract, the warranty period shall be at least one year from the Acceptance Date. If during the warranty period, one or more of the above warranties are breached, the Contractor shall promptly upon receipt of demand perform the services again in accordance with above standard at no additional cost to the City. All costs incidental to such additional performance shall be borne by the Contractor. The City shall endeavor to give the Contractor written notice of the breach of warranty within thirty (30) calendar days of discovery of the breach warranty, but failure to give timely notice shall not impair the City's rights under this section. File # 5639 C. If the Contractor is unable or unwilling to perform its services in accordance with the above standard as required by the City, then in addition to any other available remedy, the City may reduce the amount of services it may be required to purchase under the Contract from the Contractor, and purchase conforming services from other sources. In such event, the Contractor shall pay to the City upon demand the increased cost, if any, incurred by the City to procure such services from another source. 23. ACCEPTANCE OF INCOMPLETE OR NON - CONFORMING DELIVERABLES: If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City's evaluation of and determination to accept such defective or non - conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non - conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor. 24. RIGHT TO ASSURANCE: Whenever one party to the Contract in good faith has reason to question the other party's intent to perform, demand may be made to the other party for written assurance of the intent to perform. In the event that no assurance is given within the time specified after demand is made, the demanding party may treat this failure as an anticipatory repudiation of the Contract. 25. STOP WORK NOTICE: The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice. 26. DEFAULT: The Contractor shall be in default under the Contract if the Contractor (a) fails to fully, timely and faithfully perform any of its material obligations under the Contract, (b) fails to provide adequate assurance of performance under Paragraph 24, (c) becomes insolvent or seeks relief under the bankruptcy laws of the United States or (d) makes a material misrepresentation in Contractor's Offer, or in any report or deliverable required to be submitted by the Contractor to the City. 27. TERMINATION FOR CAUSE: In the event of a default by the Contractor, the City shall have the right to terminate the Contract for cause, by written notice effective ten (10) calendar days, unless otherwise specified, after the date of such notice, unless the Contractor, within such ten (10) day period, cures such default, or provides evidence sufficient to prove to the City's reasonable satisfaction that such default does not, in fact, exist. In addition to any other remedy available under law or in equity, the City shall be entitled to recover all actual damages, costs, losses and expenses, incurred by the City as a result of the Contractor's default, including, without limitation, cost of cover, reasonable attorneys' fees, court costs, and prejudgment and post judgment interest at the maximum lawful rate. Additionally, in the event of a default by the Contractor, the City may remove the Contractor from the City's vendor list for three (3) years and any Offer submitted by the Contractor may be disqualified for up to three (3) years. All File # 5639 rights and remedies under the Contract are cumulative and are not exclusive of any other right or remedy provided by law. 28. TERMINATION WITHOUT CAUSE: The City shall have the right to terminate the Contract, in whole or in part, without cause any time upon thirty (30) calendar days' prior written notice. Upon receipt of a notice of termination, the Contractor shall promptly cease all further work pursuant to the Contract, with such exceptions, if any, specified in the notice of termination. The City shall pay the Contractor, to the extent of funds Appropriated or otherwise legally available for such purposes, for all goods delivered and services performed and obligations incurred prior to the date of termination in accordance with the terms hereof. 29. FRAUD: Fraudulent statements by the Contractor on any Offer or in any report or deliverable required to be submitted by the Contractor to the City shall be grounds for the termination of the Contract for cause by the City and may result in legal action. 30. DELAYS: A. The City may delay scheduled delivery or other due dates by written notice to the Contractor if the City deems it is in its best interest. If such delay causes an increase in the cost of the work under the Contract, the City and the Contractor shall negotiate an equitable adjustment for costs incurred by the Contractor in the Contract price and execute an amendment to the Contract. The Contractor must assert its right to an adjustment within thirty (30) calendar days from the date of receipt of the notice of delay. Failure to agree on any adjusted price shall be handled under the Dispute Resolution process specified in paragraph 49. However, nothing in this provision shall excuse the Contractor from delaying the delivery as notified. B. Neither party shall be liable for any default or delay in the performance of its obligations under this Contract if, while and to the extent such default or delay is caused by acts of God, fire, riots, civil commotion, labor disruptions, sabotage, sovereign conduct, or any other cause beyond the reasonable control of such Party. In the event of default or delay in contract performance due to any of the foregoing causes, then the time for completion of the services will be extended; provided, however, in such an event, a conference will be held within three (3) business days to establish a mutually agreeable period of time reasonably necessary to overcome the effect of such failure to perform. 31. INDEMNITY: A. Definitions: i. "Indemnified Claims" shall include any and all claims, demands, suits, causes of action, judgments and liability of every character, type or description, including all reasonable costs and expenses of litigation, mediation or other alternate dispute resolution mechanism, including attorney and other professional fees for: (1) damage to or loss of the property of any person (including, but not limited to the City, the Contractor, their respective agents, officers, employees and subcontractors; the officers, agents, and employees of such subcontractors; and third parties); and /or (2) death, bodily injury, illness, disease, worker's compensation, loss of services, or loss of income or wages to any person (including but not limited to the agents, officers and employees of the City, the Contractor, the Contractor's subcontractors, and third parties), ii. "Fault" shall include the sale of defective or non - conforming deliverables, negligence, willful misconduct or a breach of any legally imposed strict liability standard. File # 5639 B. THE CONTRACTOR SHALL DEFEND (AT THE OPTION OF THE CITY), INDEMNIFY, AND HOLD THE CITY, ITS SUCCESSORS, ASSIGNS, OFFICERS, EMPLOYEES AND ELECTED OFFICIALS HARMLESS FROM AND AGAINST ALL INDEMNIFIED CLAIMS DIRECTLY ARISING OUT OF, INCIDENT TO, CONCERNING OR RESULTING FROM THE FAULT OF THE CONTRACTOR, OR THE CONTRACTOR'S AGENTS, EMPLOYEES OR SUBCONTRACTORS, IN THE PERFORMANCE OF THE CONTRACTOR'S OBLIGATIONS UNDER THE CONTRACT. NOTHING HEREIN SHALL BE DEEMED TO LIMIT THE RIGHTS OF THE CITY OR THE CONTRACTOR (INCLUDING, BUT NOT LIMITED TO, THE RIGHT TO SEEK CONTRIBUTION) AGAINST ANY THIRD PARTY WHO MAY BE LIABLE FOR AN INDEMNIFIED CLAIM. 32. INSURANCE: The following insurance requirements are applicable, in addition to the specific insurance requirements detailed in Appendix A for services only. The successful firm shall procure and maintain insurance of the types and in the minimum amounts acceptable to the City of Denton. The insurance shall be written by a company licensed to do business in the State of Texas and satisfactory to the City of Denton. A. General Requirements: i. The Contractor shall at a minimum carry insurance in the types and amounts indicated and agreed to, as submitted to the City and approved by the City within the procurement process, for the duration of the Contract, including extension options and hold over periods, and during any warranty period. ii. The Contractor shall provide Certificates of Insurance with the coverage's and endorsements required to the City as verification of coverage prior to contract execution and within fourteen (14) calendar days after written request from the City. Failure to provide the required Certificate of Insurance may subject the Offer to disqualification from consideration for award. The Contractor must also forward a Certificate of Insurance to the City whenever a previously identified policy period has expired, or an extension option or hold over period is exercised, as verification of continuing coverage. iii. The Contractor shall not commence work until the required insurance is obtained and until such insurance has been reviewed by the City. Approval of insurance by the City shall not relieve or decrease the liability of the Contractor hereunder and shall not be construed to be a limitation of liability on the part of the Contractor. iv. The Contractor must submit certificates of insurance to the City for all subcontractors prior to the subcontractors commencing work on the project. v. The Contractor's and all subcontractors' insurance coverage shall be written by companies licensed to do business in the State of Texas at the time the policies are issued and shall be written by companies with A.M. Best ratings of A- VII or better. The City will accept workers' compensation coverage written by the Texas Workers' Compensation Insurance Fund. vi. All endorsements naming the City as additional insured, waivers, and notices of cancellation endorsements as well as the Certificate of Insurance shall contain the solicitation number and the following information: City of Denton Materials Management Department 901B Texas Street Denton, Texas 76209 File # 5639 vii. The "other" insurance clause shall not apply to the City where the City is an additional insured shown on any policy. It is intended that policies required in the Contract, covering both the City and the Contractor, shall be considered primary coverage as applicable. viii. If insurance policies are not written for amounts agreed to with the City, the Contractor shall carry Umbrella or Excess Liability Insurance for any differences in amounts specified. If Excess Liability Insurance is provided, it shall follow the form of the primary coverage. ix. The City shall be entitled, upon request, at an agreed upon location, and without expense, to review certified copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modification of particular policy terms, conditions, limitations, or exclusions except where policy provisions are established by law or regulations binding upon either of the parties hereto or the underwriter on any such policies. x. The City reserves the right to review the insurance requirements set forth during the effective period of the Contract and to make reasonable adjustments to insurance coverage, limits, and exclusions when deemed necessary and prudent by the City based upon changes in statutory law, court decisions, the claims history of the industry or financial condition of the insurance company as well as the Contractor. xi. The Contractor shall not cause any insurance to be canceled nor permit any insurance to lapse during the term of the Contract or as required in the Contract. xii. The Contractor shall be responsible for premiums, deductibles and self - insured retentions, if any, stated in policies. All deductibles or self - insured retentions shall be disclosed on the Certificate of Insurance. xiii. The Contractor shall endeavor to provide the City thirty (30) calendar days' written notice of erosion of the aggregate limits below occurrence limits for all applicable coverage's indicated within the Contract. xiv. The insurance coverage's specified in within the solicitation and requirements are required minimums and are not intended to limit the responsibility or liability of the Contractor. B. Specific Coverage Requirements: Specific insurance requirements are contained in the solicitation instrument. 33. CLAIMS: If any claim, demand, suit, or other action is asserted against the Contractor which arises under or concerns the Contract, or which could have a material adverse affect on the Contractor's ability to perform thereunder, the Contractor shall give written notice thereof to the City within ten (10) calendar days after receipt of notice by the Contractor. Such notice to the City shall state the date of notification of any such claim, demand, suit, or other action; the names and addresses of the claimant(s); the basis thereof; and the name of each person against whom such claim is being asserted. Such notice shall be delivered personally or by mail and shall be sent to the City and to the Denton City Attorney. Personal delivery to the City Attorney shall be to City Hall, 215 East McKinney Street, Denton, Texas 76201. 34. NOTICES: Unless otherwise specified, all notices, requests, or other communications required or appropriate to be given under the Contract shall be in writing and shall be deemed delivered three (3) business days after postmarked if sent by U.S. Postal Service Certified or Registered Mail, Return Receipt Requested. Notices delivered by other means shall be deemed File # 5639 delivered upon receipt by the addressee. Routine communications may be made by first class mail, telefax, or other commercially accepted means. Notices to the Contractor shall be sent to the address specified in the Contractor's Offer, or at such other address as a party may notify the other in writing. Notices to the City shall be addressed to the City at 901B Texas Street, Denton, Texas 76209 and marked to the attention of the Purchasing Manager. 35. RIGHTS TO BID, PROPOSAL AND CONTRACTUAL MATERIAL: All material submitted by the Contractor to the City shall become property of the City upon receipt. Any portions of such material claimed by the Contractor to be proprietary must be clearly marked as such. Determination of the public nature of the material is subject to the Texas Public Information Act, Chapter 552, and Texas Government Code. 36. NO WARRANTY BY CITY AGAINST INFRINGEMENTS: The Contractor represents and warrants to the City that: (i) the Contractor shall provide the City good and indefeasible title to the deliverables and (ii) the deliverables supplied by the Contractor in accordance with the specifications in the Contract will not infringe, directly or contributorily, any patent, trademark, copyright, trade secret, or any other intellectual property right of any kind of any third party; that no claims have been made by any person or entity with respect to the ownership or operation of the deliverables and the Contractor does not know of any valid basis for any such claims. The Contractor shall, at its sole expense, defend, indemnify, and hold the City harmless from and against all liability, damages, and costs (including court costs and reasonable fees of attorneys and other professionals) arising out of or resulting from: (i) any claim that the City's exercise anywhere in the world of the rights associated with the City's' ownership, and if applicable, license rights, and its use of the deliverables infringes the intellectual property rights of any third party; or (ii) the Contractor's breach of any of Contractor's representations or warranties stated in this Contract. In the event of any such claim, the City shall have the right to monitor such claim or at its option engage its own separate counsel to act as co- counsel on the City's behalf. Further, Contractor agrees that the City's specifications regarding the deliverables shall in no way diminish Contractor's warranties or obligations under this paragraph and the City makes no warranty that the production, development, or delivery of such deliverables will not impact such warranties of Contractor. 37. CONFIDENTIALITY: In order to provide the deliverables to the City, Contractor may require access to certain of the City's and /or its licensors' confidential information (including inventions, employee information, trade secrets, confidential know -how, confidential business information, and other information which the City or its licensors consider confidential) (collectively, "Confidential Information "). Contractor acknowledges and agrees that the Confidential Information is the valuable property of the City and /or its licensors and any unauthorized use, disclosure, dissemination, or other release of the Confidential Information will substantially injure the City and /or its licensors. The Contractor (including its employees, subcontractors, agents, or representatives) agrees that it will maintain the Confidential Information in strict confidence and shall not disclose, disseminate, copy, divulge, recreate, or otherwise use the Confidential Information without the prior written consent of the City or in a manner not expressly permitted under this Agreement, unless the Confidential Information is required to be disclosed by law or an order of any court or other governmental authority with proper jurisdiction, provided the Contractor promptly notifies the City before disclosing such information so as to permit the City reasonable time to seek an appropriate protective order. The Contractor agrees to use protective measures no less stringent than the Contractor uses within its File # 5639 own business to protect its own most valuable information, which protective measures shall under all circumstances be at least reasonable measures to ensure the continued confidentiality of the Confidential Information. 38. OWNERSHIP AND USE OF DELIVERABLES: The City shall own all rights, titles, and interests throughout the world in and to the deliverables. A. Patents. As to any patentable subject matter contained in the deliverables, the Contractor agrees to disclose such patentable subject matter to the City. Further, if requested by the City, the Contractor agrees to assign and, if necessary, cause each of its employees to assign the entire right, title, and interest to specific inventions under such patentable subject matter to the City and to execute, acknowledge, and deliver and, if necessary, cause each of its employees to execute, acknowledge, and deliver an assignment of letters patent, in a form to be reasonably approved by the City, to the City upon request by the City. B. Copyrights. As to any deliverables containing copyrightable subject matter, the Contractor agrees that upon their creation, such deliverables shall be considered as work made - for -hire by the Contractor for the City and the City shall own all copyrights in and to such deliverables, provided however, that nothing in this Paragraph 38 shall negate the City's sole or joint ownership of any such deliverables arising by virtue of the City's sole or joint authorship of such deliverables. Should by operation of law, such deliverables not be considered works made -for- hire, the Contractor hereby assigns to the City (and agrees to cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver an assignment to the City of) all worldwide right, title, and interest in and to such deliverables. With respect to such work made - for -hire, the Contractor agrees to execute, acknowledge, and deliver and cause each of its employees providing services to the City hereunder to execute, acknowledge, and deliver a work - made - for -hire agreement, in a form to be reasonably approved by the City, to the City upon delivery of such deliverables to the City or at such other time as the City may request. C. Additional Assignments. The Contractor further agrees to, and if applicable, cause each of its employees to, execute, acknowledge, and deliver all applications, specifications, oaths, assignments, and all other instruments which the City might reasonably deem necessary in order to apply for and obtain copyright protection, mask work registration, trademark registration and /or protection, letters patent, or any similar rights in any and all countries and in order to assign and convey to the City, its successors, assigns and nominees, the sole and exclusive right, title, and interest in and to the deliverables. The Contractor's obligations to execute, acknowledge, and deliver (or cause to be executed, acknowledged, and delivered) instruments or papers such as those described in this Paragraph 38 a., b., and c. shall continue after the termination of this Contract with respect to such deliverables. In the event the City should not seek to obtain copyright protection, mask work registration or patent protection for any of the deliverables, but should desire to keep the same secret, the Contractor agrees to treat the same as Confidential Information under the terms of Paragraph 37 above. 39. PUBLICATIONS: All published material and written reports submitted under the Contract must be originally developed material unless otherwise specifically provided in the Contract. When material not originally developed is included in a report in any form, the source shall be identified. 40. ADVERTISING: The Contractor shall not advertise or publish, without the City's prior consent, the fact that the City has entered into the Contract, except to the extent required by law. File # 5639 41. NO CONTINGENT FEES: The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure the Contract upon any agreement or understanding for commission, percentage, brokerage, or contingent fee, excepting bona fide employees of bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty, the City shall have the right, in addition to any other remedy available, to cancel the Contract without liability and to deduct from any amounts owed to the Contractor, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 42. GRATUITIES: The City may, by written notice to the Contractor, cancel the Contract without liability if it is determined by the City that gratuities were offered or given by the Contractor or any agent or representative of the Contractor to any officer or employee of the City of Denton with a view toward securing the Contract or securing favorable treatment with respect to the awarding or amending or the making of any determinations with respect to the performing of such contract. In the event the Contract is canceled by the City pursuant to this provision, the City shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 43. PROHIBITION AGAINST PERSONAL INTEREST IN CONTRACTS: No officer, employee, independent consultant, or elected official of the City who is involved in the development, evaluation, or decision - making process of the performance of any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation. Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of this provision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Contractor shall complete and submit the City's Conflict of Interest Questionnaire. 44. INDEPENDENT CONTRACTOR: The Contract shall not be construed as creating an employer /employee relationship, a partnership, or a joint venture. The Contractor's services shall be those of an independent contractor. The Contractor agrees and understands that the Contract does not grant any rights or privileges established for employees of the City of Denton, Texas for the purposes of income tax, withholding, social security taxes, vacation or sick leave benefits, worker's compensation, or any other City employee benefit. The City shall not have supervision and control of the Contractor or any employee of the Contractor, and it is expressly understood that Contractor shall perform the services hereunder according to the attached specifications at the general direction of the City Manager of the City of Denton, Texas, or his designee under this agreement. The contractor is expressly free to advertise and perform services for other parties while performing services for the City. 45. ASSIGNMENT - DELEGATION: The Contract shall be binding upon and ensure to the benefit of the City and the Contractor and their respective successors and assigns, provided however, that no right or interest in the Contract shall be assigned and no obligation shall be delegated by the Contractor without the prior written consent of the City. Any attempted assignment or delegation by the Contractor shall be void unless made in conformity with this paragraph. The Contract is not intended to confer rights or benefits on any person, firm or entity not a party hereto; it being the intention of the parties that there are no third party beneficiaries to the Contract. File # 5639 46. WAIVER: No claim or right arising out of a breach of the Contract can be discharged in whole or in part by a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. No waiver by either the Contractor or the City of any one or more events of default by the other party shall operate as, or be construed to be, a permanent waiver of any rights or obligations under the Contract, or an express or implied acceptance of any other existing or future default or defaults, whether of a similar or different character. 47. MODIFICATIONS: The Contract can be modified or amended only by a writing signed by both parties. No pre - printed or similar terms on any the Contractor invoice, order or other document shall have any force or effect to change the terms, covenants, and conditions of the Contract. 48. INTERPRETATION: The Contract is intended by the parties as a final, complete and exclusive statement of the terms of their agreement. No course of prior dealing between the parties or course of performance or usage of the trade shall be relevant to supplement or explain any term used in the Contract. Although the Contract may have been substantially drafted by one party, it is the intent of the parties that all provisions be construed in a manner to be fair to both parties, reading no provisions more strictly against one party or the other. Whenever a term defined by the Uniform Commercial Code, as enacted by the State of Texas, is used in the Contract, the UCC definition shall control, unless otherwise defined in the Contract. 49. DISPUTE RESOLUTION: A. If a dispute arises out of or relates to the Contract, or the breach thereof, the parties agree to negotiate prior to prosecuting a suit for damages. However, this section does not prohibit the filing of a lawsuit to toll the running of a statute of limitations or to seek injunctive relief. Either party may make a written request for a meeting between representatives of each party within fourteen (14) calendar days after receipt of the request or such later period as agreed by the parties. Each party shall include, at a minimum, one (1) senior level individual with decision - making authority regarding the dispute. The purpose of this and any subsequent meeting is to attempt in good faith to negotiate a resolution of the dispute. If, within thirty (30) calendar days after such meeting, the parties have not succeeded in negotiating a resolution of the dispute, they will proceed directly to mediation as described below. Negotiation may be waived by a written agreement signed by both parties, in which event the parties may proceed directly to mediation as described below. B. If the efforts to resolve the dispute through negotiation fail, or the parties waive the negotiation process, the parties may select, within thirty (30) calendar days, a mediator trained in mediation skills to assist with resolution of the dispute. Should they choose this option; the City and the Contractor agree to act in good faith in the selection of the mediator and to give consideration to qualified individuals nominated to act as mediator. Nothing in the Contract prevents the parties from relying on the skills of a person who is trained in the subject matter of the dispute or a contract interpretation expert. If the parties fail to agree on a mediator within thirty (30) calendar days of initiation of the mediation process, the mediator shall be selected by the Denton County Alternative Dispute Resolution Program (DCAP). The parties agree to participate in mediation in good faith for up to thirty (30) calendar days from the date of the first mediation session. The City and the Contractor will share the mediator's fees equally and the parties will bear their own costs of participation such as fees for any consultants or attorneys they File # 5639 may utilize to represent them or otherwise assist them in the mediation. 50. JURISDICTION AND VENUE: The Contract is made under and shall be governed by the laws of the State of Texas, including, when applicable, the Uniform Commercial Code as adopted in Texas, V.T.C.A., Bus. & Comm. Code, Chapter 1, excluding any rule or principle that would refer to and apply the substantive law of another state or jurisdiction. All issues arising from this Contract shall be resolved in the courts of Denton County, Texas and the parties agree to submit to the exclusive personal jurisdiction of such courts. The foregoing, however, shall not be construed or interpreted to limit or restrict the right or ability of the City to seek and secure injunctive relief from any competent authority as contemplated herein. 51. INVALIDITY: The invalidity, illegality, or unenforceability of any provision of the Contract shall in no way affect the validity or enforceability of any other portion or provision of the Contract. Any void provision shall be deemed severed from the Contract and the balance of the Contract shall be construed and enforced as if the Contract did not contain the particular portion or provision held to be void. The parties further agree to reform the Contract to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent this entire Contract from being void should a provision which is the essence of the Contract be determined to be void. 52. HOLIDAYS: The following holidays are observed by the City: New Year's Day (observed) MLK Day Memorial Day 4th of July Labor Day Thanksgiving Day Day After Thanksgiving Christmas Eve (observed) Christmas Day (observed) New Year's Day (observed) If a Legal Holiday falls on Saturday, it will be observed on the preceding Friday. If a Legal Holiday falls on Sunday, it will be observed on the following Monday. Normal hours of operation shall be between 8:00 am and 4:00 pm, Monday through Friday, excluding City of Denton Holidays. Any scheduled deliveries or work performance not within the normal hours of operation must be approved by the City Manager of Denton, Texas or his authorized designee. 53. SURVIVABILITY OF OBLIGATIONS: All provisions of the Contract that impose continuing obligations on the parties, including but not limited to the warranty, indemnity, and confidentiality obligations of the parties, shall survive the expiration or termination of the Contract. 54. NON - SUSPENSION OR DEBARMENT CERTIFICATION: The City of Denton is prohibited from contracting with or making prime or sub - awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Denton Contracts. By accepting a Contract with the City, the Vendor certifies File # 5639 that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non - Procurement Programs, the State of Texas, or the City of Denton. 55. EQUAL OPPORTUNITY A. Equal Employment Opportunity: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, age, disability, creed, color, genetic testing, or national origin, be refused the benefits of, or be otherwise subjected to discrimination under any activities resulting from this RFQ. B. Americans with Disabilities Act (ADA) Compliance: No Offeror, or Offeror's agent, shall engage in any discriminatory employment practice against individuals with disabilities as defined in the ADA. 56. BUY AMERICAN ACT - SUPPLIES (Applicable to certain federally funded requirements) The following federally funded requirements are applicable. A. Definitions. As used in this paragraph — i. "Component" means an article, material, or supply incorporated directly into an end product. ii. "Cost of components" means - (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty -free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product. iii. "Domestic end product" means - (1) An unmanufactured end product mined or produced in the United States; or (2) An end product manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic. iv. "End product" means those articles, materials, and supplies to be acquired under the contract for public use. v. "Foreign end product" means an end product other than a domestic end product. vi. "United States" means the 50 States, the District of Columbia, and outlying areas. B. The Buy American Act (41 U.S.C. IOa - IOd) provides a preference for domestic end products for supplies acquired for use in the United States. C. The City does not maintain a list of foreign articles that will be treated as domestic for this Contract; but will consider for approval foreign articles as domestic for this product if the articles are on a list approved by another Governmental Agency. The Offeror shall submit documentation with their Offer demonstrating that the article is on an approved Governmental list. D. The Contractor shall deliver only domestic end products except to the extent that it specified File # 5639 delivery of foreign end products in the provision of the Solicitation entitled "Buy American Act Certificate ". 57. RIGHT TO INFORMATION: The City of Denton reserves the right to use any and all information presented in any response to this contract, whether amended or not, except as prohibited by law. Selection of rejection of the submittal does not affect this right. 58. LICENSE FEES OR TAXES: Provided the solicitation requires an awarded contractor or supplier to be licensed by the State of Texas, any and all fees and taxes are the responsibility of the respondent. 59. PREVAILING WAGE RATES: The contractor shall comply with prevailing wage rates as defined by the United States Department of Labor Davis -Bacon Wage Determination at http: / /www.dol.gov /whd/contracts /dbra.htm and at the Wage Determinations website www.wdol.gov for Denton County, Texas (WD- 2509). 60. COMPLIANCE WITH ALL STATE, FEDERAL, AND LOCAL LAWS: The contractor or supplier shall comply with all State, Federal, and Local laws and requirements. The Respondent must comply with all applicable laws at all times, including, without limitation, the following: (i) §36.02 of the Texas Penal Code, which prohibits bribery; (ii) §36.09 of the Texas Penal Code, which prohibits the offering or conferring of benefits to public servants. The Respondent shall give all notices and comply with all laws and regulations applicable to furnishing and performance of the Contract. 61. FEDERAL, STATE, AND LOCAL REQUIREMENTS: Respondent shall demonstrate on -site compliance with the Federal Tax Reform Act of 1986, Section 1706, amending Section 530 of the Revenue Act of of 1978, dealing with issuance of Form W -2's to common law employees. Respondent is responsible for both federal and State unemployment insurance coverage and standard Workers' Compensation insurance coverage. Respondent shall ensure compliance with all federal and State tax laws and withholding requirements. The City of Denton shall not be liable to Respondent or its employees for any Unemployment or Workers' Compensation coverage, or federal or State withholding requirements. Contractor shall indemnify the City of Denton and shall pay all costs, penalties, or losses resulting from Respondent's omission or breach of this Section. 62. DRUG FREE WORKPLACE: The contractor shall comply with the applicable provisions of the Drug -Free Work Place Act of 1988 (Public Law 100 -690, Title V, Subtitle D; 41 U.S.C. 701 ET SEQ.) and maintain a drug -free work environment; and the final rule, government -wide requirements for drug -free work place (grants), issued by the Office of Management and Budget and the Department of Defense (32 CFR Part 280, Subpart F) to implement the provisions of the Drug -Free Work Place Act of 1988 is incorporated by reference and the contractor shall comply with the relevant provisions thereof, including any amendments to the final rule that may hereafter be issued. 63. RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY: The Respondent shall be liable for all damages to government- owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance File # 5639 pursuant to the Contract. The Respondent shall notify the City of Denton Procurement Manager in writing of any such damage within one (1) calendar day. 64. FORCE MAJEURE: The City of Denton, any Customer, and the Respondent shall not be responsible for performance under the Contract should it be prevented from performance by an act of war, order of legal authority, act of God, or other unavoidable cause not attributable to the fault or negligence of the City of Denton. In the event of an occurrence under this Section, the Respondent will be excused from any further performance or observance of the requirements so affected for as long as such circumstances prevail and the Respondent continues to use commercially reasonable efforts to recommence performance or observance whenever and to whatever extent possible without delay. The Respondent shall immediately notify the City of Denton Procurement Manager by telephone (to be confirmed in writing within five (5) calendar days of the inception of such occurrence) and describe at a reasonable level of detail the circumstances causing the non - performance or delay in performance. 65. NON - WAIVER OF RIGHTS: Failure of a Party to require performance by another Party under the Contract will not affect the right of such Party to require performance in the future. No delay, failure, or waiver of either Party's exercise or partial exercise of any right or remedy under the Contract shall operate to limit, impair, preclude, cancel, waive or otherwise affect such right or remedy. A waiver by a Party of any breach of any term of the Contract will not be construed as a waiver of any continuing or succeeding breach. 66. NO WAIVER OF SOVEREIGN IMMUNITY: The Parties expressly agree that no provision of the Contract is in any way intended to constitute a waiver by the City of Denton of any immunities from suit or from liability that the City of Denton may have by operation of law. 67. RECORDS RETENTION: The Respondent shall retain all financial records, supporting documents, statistical records, and any other records or books relating to the performances called for in the Contract. The Respondent shall retain all such records for a period of four (4) years after the expiration of the Contract, or until the CPA or State Auditor's Office is satisfied that all audit and litigation matters are resolved, whichever period is longer. The Respondent shall grant access to all books, records and documents pertinent to the Contract to the CPA, the State Auditor of Texas, and any federal governmental entity that has authority to review records due to federal funds being spent under the Contract. Should a conflict arise between any of the contract documents, it shall be resolved with the following order of precedence (if applicable). In any event, the final negotiated contract shall take precedence over any and all contract documents to the extent of such conflict. L Final negotiated contract 2. RFP /Bid documents 3. City's standard terms and conditions 4. Purchase order 5. Supplier terms and conditions File # 5639 Exhibit D INSURANCE REQUIREMENTS AND WORKERS' COMPENSENTATION REQUIREMENTS Upon contract execution, all insurance requirements shall become contractual obligations, which the successful contractor shall have a duty to maintain throughout the course of this contract. STANDARD PROVISIONS: Without limiting any of the other obligations or liabilities of the Contractor, the Contractor shall provide and maintain until the contracted work has been completed and accepted by the City of Denton, Owner, the minimum insurance coverage as indicated hereinafter. Contractor shall file with the Purchasing Department satisfactory certificates of insurance including any applicable addendum or endorsements, containing the contract number and title of the project. Contractor may, upon written request to the Purchasing Department, ask for clarification of any insurance requirements at any time; however, Contractor shall not commence any work or deliver any material until he or she receives notification that the contract has been accepted, approved, and signed by the City of Denton. All insurance policies proposed or obtained in satisfaction of these requirements shall comply with the following general specifications, and shall be maintained in compliance with these general specifications throughout the duration of the Contract, or longer, if so noted: Each policy shall be issued by a company authorized to do business in the State of Texas with an A.M. Best Company rating of at least A- VII or better. Any deductibles or self- insured retentions shall be declared in the proposal. If requested by the City, the insurer shall reduce or eliminate such deductibles or self- insured retentions with respect to the City, its officials, agents, employees and volunteers; or, the contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. Liability policies shall be endorsed to provide the following: ■ Name as Additional Insured the City of Denton, its Officials, Agents, Employees and volunteers. ■ That such insurance is primary to any other insurance available to the Additional Insured with respect to claims covered under the policy and that this insurance applies separately to each insured against whom claim is made or suit is brought. The inclusion of more than one insured shall not operate to increase the insurer's limit of liability. File # 5639 • Cancellation: City requires 30 day written notice should any of the policies described on the certificate be cancelled or materially changed before the expiration date. • Should any of the required insurance be provided under a claims made form, Contractor shall maintain such coverage continuously throughout the term of this contract and, without lapse, for a period of three years beyond the contract expiration, such that occurrences arising during the contract term which give rise to claims made after expiration of the contract shall be covered. • Should any of the required insurance be provided under a form of coverage that includes a general annual aggregate limit providing for claims investigation or legal defense costs to be included in the general annual aggregate limit, the Contractor shall either double the occurrence limits or obtain Owners and Contractors Protective Liability Insurance. • Should any required insurance lapse during the contract term, requests for payments originating after such lapse shall not be processed until the City receives satisfactory evidence of reinstated coverage as required by this contract, effective as of the lapse date. If insurance is not reinstated, City may, at its sole option, terminate this agreement effective on the date of the lapse. SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS: All insurance policies proposed or obtained in satisfaction of this Contract shall additionally comply with the following marked specifications, and shall be maintained in compliance with these additional specifications throughout the duration of the Contract, or longer, if so noted. [X] A. General Liability Insurance: General Liability insurance with combined single limits of not less than $1,000,000.00 shall be provided and maintained by the Contractor. The policy shall be written on an occurrence basis either in a single policy or in a combination of underlying and umbrella or excess policies. If the Commercial General Liability form (ISO Form CG 0001 current edition) is used: Coverage A shall include premises, operations, products, and completed operations, independent contractors, contractual liability covering this contract and broad form property damage coverage. • Coverage B shall include personal injury. • Coverage C, medical payments, is not required. If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition and ISO Form GL 0404) is used, it shall include at least: • Bodily injury and Property Damage Liability for premises, operations, File # 5639 products and completed operations, independent contractors and property damage resulting from explosion, collapse or underground (XCU) exposures. • Broad form contractual liability (preferably by endorsement) covering this contract, personal injury liability and broad form property damage liability. [X] Automobile Liability Insurance: Contractor shall provide Commercial Automobile Liability insurance with Combined Single Limits (CSL) of not less than $500,000 either in a single policy or in a combination of basic and umbrella or excess policies. The policy will include bodily injury and property damage liability arising out of the operation, maintenance and use of all automobiles and mobile equipment used in conjunction with this contract. Satisfaction of the above requirement shall be in the form of a policy endorsement for: • any auto, or • all owned hired and non -owned autos. [X] Workers' Compensation Insurance Contractor shall purchase and maintain Workers' Compensation insurance which, in addition to meeting the minimum statutory requirements for issuance of such insurance, has Employer's Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a $500,000 policy limit for occupational disease. The City need not be named as an "Additional Insured" but the insurer shall agree to waive all rights of subrogation against the City, its officials, agents, employees and volunteers for any work performed for the City by the Named Insured. For building or construction projects, the Contractor shall comply with the provisions of Attachment 1 in accordance with §406.096 of the Texas Labor Code and rule 28TAC 110.110 of the Texas Workers' Compensation Commission (TWCC). [ ] Owner's and Contractor's Protective Liability Insurance The Contractor shall obtain, pay for and maintain at all times during the prosecution of the work under this contract, an Owner's and Contractor's Protective Liability insurance policy naming the City as insured for property damage and bodily injury which may arise in the prosecution of the work or Contractor's operations under this contract. Coverage shall be on an "occurrence" basis and the policy shall be issued by the same insurance company that carries the Contractor's liability insurance. Policy limits will be at least $500,000.00 combined bodily injury and property damage per occurrence with a $1,000,000.00 aggregate. [ ] Fire Damage Legal Liability Insurance Coverage is required if Broad form General Liability is not provided or is unavailable to the contractor or if a contractor leases or rents a portion of a City building. Limits of not less than each occurrence are required. File # 5639 [ ] Professional Liability Insurance Professional liability insurance with limits not less than $1,000,000.00 per claim with respect to negligent acts, errors or omissions in connection with professional services is required under this Agreement. [ ] Builders' Risk Insurance Builders' Risk Insurance, on an All -Risk form for 100% of the completed value shall be provided. Such policy shall include as "Named Insured" the City of Denton and all subcontractors as their interests may appear. [ ] Commercial Crime Provides coverage for the theft or disappearance of cash or checks, robbery inside /outside the premises, burglary of the premises, and employee fidelity. The employee fidelity portion of this coverage should be written on a "blanket" basis to cover all employees, including new hires. This type insurance should be required if the contractor has access to City funds. Limits of not less than $ each occurrence are required.. [ ] Additional Insurance Other insurance may be required on an individual basis for extra hazardous contracts and specific service agreements. If such additional insurance is required for a specific contract, that requirement will be described in the "Specific Conditions" of the contract specifications. File # 5639 ATTACHMENT 1 [X] Workers' Compensation Coverage for Building or Construction Projects for Governmental Entities A. Definitions:. Certificate of coverage ( "certificate ") -A copy of a certificate of insurance, a certificate of authority to self- insure issued by the commission, or a coverage agreement (TWCC -81, TWCC -82, TWCC -83, or TWCC -84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. Duration of the project - includes the time from the beginning of the work on the project until the contractor's /person's work on the project has been completed and accepted by the governmental entity. Persons providing services on the project ( "subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food /beverage vendors, office supply deliveries, and delivery of portable toilets. B. The contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any overage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services on the project, for the duration of the project. C. The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. D. If the coverage period shown on the contractor's current certificate of coverage ends during the duration of the project, the contractor must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The contractor shall obtain from each person providing services on a project, File # 5639 and provide to the governmental entity: 1. a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and 2. no later than seven days after receipt by the contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. F. The contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. G. The contractor shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. H. The contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The contractor shall contractually require each person with whom it contracts to provide services on a project, to: 1. provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; 2. provide to the contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; 3. provide the contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 4. obtain from each other person with whom it contracts, and provide to the contractor: a. a certificate of coverage, prior to the other person beginning work on File # 5639 the project; and b. a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; 5. retain all required certificates of coverage on file for the duration of the project and for one year thereafter; 6. notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and 7. Contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7), with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this contract or providing or causing to be provided a certificate of coverage, the contractor is representing to the governmental entity that all employees of the contractor who will provide services on the project will be covered by workers' compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self- insured, with the commission's Division of Self- Insurance Regulation. Providing false or misleading information may subject the contractor to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The contractor's failure to comply with any of these provisions is a breach of contract by the contractor which entitles the governmental entity to declare the contract void if the contractor does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. File # 5639 Exhibit E CONFLICT OF INTEREST QUESTIONNAIRE - FORM CI For vendor or other person doing business with local governmental entity This uestionnaire reflects changes nges made to the law by H.B. 1491, 80th Leg., Regular Session„ This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person who has a business relationship as defined by Section 176.001(1 -a) with a local governmental entity and the person meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section 176.006, Local Government Code. A person commits an offense if the person knowingly violates Section 176.006, Local Government Code. An offense under this section is a Class C misdemeanor. me ..o Name ... �p erso.r.... . w �-m h �s ;el iq� with local governmental entity, .. .................... ...._ ... �.. 2 Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7`h business day after the date the oriainally filed questionnaire becomes incomplete or inaccurate.) 3 Name of local government officer with whom filer has an employment or business relationship. Name of Officer This section, (item 3 including subparts A, B, C & D), must be completed for each officer with whom the filer has an employment or other business relationship as defined by Section 176.001(1 -a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the filer of the questionnaire? Yes No B. Is the filer of the questionnaire receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer named in this section AND the taxable income is not received from the local governmental entity? Yes E:1 No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership of 10 percent or more? ED Yes F—] No D. Describe each affiliation or business relationship. 4 I have no Conflict of Interest to disclose. m r I M 1 211191 7 — ��w wa � "�� .gy rct cMrr 1 1 vranamal unlRy . Date File # 5639 EXHIBIT F RFP 5639 - Award Sheet for RENTAL OF HEAVY EQUIPMENT Closner Equipment Company, Inc. Ft. Worth, TX Item uoM Product Description Make /Model offered Weekly Rental Montly Rental Delivery /Pickup Charge ........... ........... SEC TION A - DOZERS 1� EA Dozer, Cat D10T or equivalent 2 EA Dozer, Cat D9T or ectuivalerai. 3 EA Dozer, Cat 138T or ecluivalent 4 i EA t}dAfL'r, Cat D7T OP F' LIIV&3G'. tilt 5 EA Dozer, LGP Cat D7R or ecquwv<alent __..._... __ ._.._...m... 6 EA t'loz er, Cat D6R or edq�uivta0or4 7 EA .. .... Dozer, LGP Cat D6R or eguiv.alenl ,.,n.........._.m n_......... ......... ................... 8 EA Dozer, Cat DISK or e qulvaloat 9 EA DDZew, Cat D5M or a tcgtapvalenI ........ 10 EA Dozer, Cat D5K or ergulva0tgnt 11 EA Dozen„ LGP Cat D5K or equivalent 12 EA Dozer, Cat D4K or eaquivalont 13 EA Dozer, LGP Cat D4K or ectozwyalerit, SECTION B WHEEL LOADERS 14 EA Wheel Loader„ Cat 988H or ealuuvalel'at —.. _ 15 EA Wheel Loader, Cat 980H or edquw alenl L .,mm.... 16 EA Wh'arael Leoadw, Caal 966K or atguiuvaa0ent 17 EA Wlata el Loader, Cat 962K or uau)laivalent 18 EA Wheel Loader Cat 950H or oq uNakenI 19 EA Wheel Loader, Cat 938H or ecq[uivalenq 20 EA Wheel Loader, Cat 930H ore tuhvale,ril 21 EA Whed0 trader, Cat G2411 or on ra1r nt. SECTION C- MOTOR GRADERS 22 EA rader Cat 12M or uaa)tavalt uil G Motor 23 EA or t�raawrar, Cat 140M or equivalent ECTION D- EXCAVATORS 24 EA avtataa 7;at tx45t1L or ea;gulvagr +nt 25 EA Excavator Cat 336DL or ey0valont .. 26 EA for, Cat 325 or raalulvsalent Excavamm.. __.. _. 27 EA Lxcavaular, Cat 329E or equivalent MGLC ii a0a 28 EA t.xcavarrtor', Cat 324E or nquivaa0ent L. 29 EA Excavator, Cal 320 or equivagent — -------------------- .------- _ __..__ ___________ 30 EA Excavator, Cat 320DL or etquwvalent WGrapple 31 EA Exa avalor with h. atrauhc tare aldor 1 00 ftl tta ctles Cal 312D 32 EA doatutwu breaker ,1,000 (I Iqa a p sa, Cat 32ODL L s ravaatrar w6th 3y- .._... _._.. ..._)....._. 33 EA t`xa °avaltor, with 11y utrauluo„. breaker 5,000 (fC Iqr class Cat 320DL 34 EA En av8ior, Cat 3211 with xdre dallslain or equiva0ent Cat 320D SECTION E- SOIL SCREENERS .. k ..e_, 36 EA.... 8 ©a9 Screener, Trrexa'ri 9u � 790 or or ugly a0er»t 3l creep _ ................... SECTION F - TRUCKS (OFF ROAD) 37 EA (Off Read`, ('a x725 or e uswalunt truck, : -._� �.m... 38 EA Truck'Aelf[ Rorsrd).,, Cat 730 or uyuwvaloaag _ 39 EA t ra c*, (Off Road), Cat 740 or tnpuww�rlent mm m..�, ... ... ...___- ---------- SECTION G- SCRAPERS 40 EA a uivalent _ ........ qua agaumr mCat 623G or._ equivalent 41 I L EA jScrapw CM621Gorequwalen4 42 EA cragaer Cat 615C or equlyaleflI 43 EA aar'tipeP' Cat 613E or equauvalent SECTION H -TRACK LOADERS 44 EA n r rat to v Iaatt, g i'tack Loader, µCat 973D o ........:...... "....�_...�.... 45 EA Trasak q.,uaaaJcrr, Cat 963D or equivalent ql or:k a -aa ader ...� 46 EA _. m Cat 953D or equbyalent SECTIONI- COMPACTORS 47 EA Compwx,,, or, Cat 625 or ecluatvaalloni -...48 EA CorvNpactor, u5at 8 115 F or pa lvalcrnt 49 EA C am actor., Cat CP56 or erqulvMe N 50 EA Conugrwor, Cat CS56 or etiqulvah enl 51 EA Caaraagactua Cat CP -323 -C or equivalent 52 EA ae ker Trench Roller, RT5620 or equivalent with 22" drum SECTION J WATER WAGONS (01eF -ROAD) 53 age 54 EA mater "Vvu n (tiff Roads Cat 613 or equrwaaeratt r E� Wagon, on Oft Rouarl Cat 725 or e9uly aleint SECTION K - WATER TRUCKS (ON- ROAD): Must be TxDOT Approved with Licei 55 EA Watea° Trur k Ctn Rcaad) 2 m41t.10...£);al . ........................ EA wwwwww.. L. , r 4 tb¢rot ".1 q al. 56 VVfakrsaTruck Cgrr Ronaf 1 7 ate o... SECTION L - MIXERS /RECYCLERS EA ecyrlei Boni... 57 rvka;aerdR ama,q 100R crr equivalent. 58 EA M werfRerycler, CMI 325 or equivalent 9 EA Cv xerlRocyular, CM11 500 or equivalent ................... .. SECTION i M - ASPHALT -LAY DOWN MACHINE .� a Pµ1 �IVI EA �?... .... nu n'Inrv;, 8ft. - 15 ft. &r9„q As ,Moat! • Lu __. SECTION N - ASPHALT ROLLERS 61 1 EA da lvMtaa6q Roller 9 on 62 EA Asl rgrraEt Roller, 12lon „�. SECTION O - ASPHALT MILLING MACHINES EA q M gi rat far lobar, 4 ft head -�_ 63 Asph I Milling 64 EA A atrtat � ,chine 6 ft. head SECTION P - BROOM 6655 a Rlta0, Bro orn or eauiyatont Option Ad al o m achment SECTION Q - DUMP TRUCK (ON- ROAD): Must be TxDOT Approved with Licens E 66 EA glurruga'q'rtaoqt 12 Yard ...... . .... SECTION R - BACKHOES�� 67 EA Brut kho 68 EA B ackhoe Case 590N or emgiv�al em - 100ho class _ ( phons added to Backhoe base gnras,el. �7 ^Fs8 EA I ddMgnat cost for cab with air condition �.._ 7-681 EA Addlrorml cost for 4-wheel drive �7 -68. EA w.. o _. ______________ Arfcla0.gor0.al cost for or rarugESndcra"rr� SECTION S - SKIDSTEERS 69 EA ._.....�. Skddsteer, fiat 210.1E or erqu ivalenaq 69a EA O rglon, Additional cost for tracks 70 EA Skla;Pstm, Cat 2268 or uaquivala, M 71 EA Skidsteer, Cat 2368 or er �ulvaleN EA mEAmmm Skidsleer, Cat 246C or etquivalem 73 Skidsteer, Cat 2560. or equivalent. 74 EA ____ Skidsteer, Cat 262C or aquhv rdrarrk 75 EA Skidsteer, Cat 272C or equivalent EXHIBIT F 6 I a a 0 NOWM01111130"a S I 0 M! 1 0 1 a Nalik "a IN 0 1 kas 0 CLOSNER EQUIPMENT CO INC 21910 FM 2252 PO BOX 917 SCHERTZ, TX 78154 This certificate is issued on 01-01-2015 and is effective until 01-01-2016, It certifies that policies of insurance listed below.have F een issued to the insured named above. Notwithstandin R any req ther uirement, term or condition of any contract or o document wit respect to which this certificate may be issued or may pertain, the insurance afforded by the policies described herein is subject to @11 the terms, exclusions, and conditions of such policies. Li'mits shown may have been reduced by paid claims, Coverage Provided Policy Number Coverage Limits General Liability 49.64503-03 General 1gregate $ 1,500.000 Products g9regate $ 1,500,000 Bodily Injury and OCCURRENCE Pers/Adv injury $ 500,000 Property amage Combined Each Occurrence $ 500,000 Premises Damage $ 100,000 Medical Expense $ 5,000 Automobile Liability 49-64503-03 Each Accident $ 500,000 Includes: Bodily Injury and Property -Any Auto Excess/Umbrella 49-64503-03 Each Occurrence $ 5.000,000 General ARgregate $ 115,000.000 Products ggregate $ 15,000,000 Workers' Compensation 49-64503-05 Statutory and Employer's Each Accident $ 500,000 Each Disease/Employee $ 500,000 Each Disease /Policy $ 500,000 CL O 49-64503 01-120342 LDI COI 269628-1 02 11 01-29-2015 PAGE I CERTIFICATE OF INSURANCE - (CONT) ACCOUNT NUMBER 49-64503 Should any of the above described policies be cancelled before the expiration date thereof, notice will be delivered in accordance with the policy provisions. 80-C1035 (SFA) CLO 49-64503 01-120342 LDI COI 269628-1 02 11 01-29-2015 PAGF 2 W !� Wa A CNS SENTRY SELECT INSURANCE COMPANY THE SENTRY PLAN STEVENS POINT WISCONSIN POLICY (A PARTICIPATING STOCK COMPANY A MEMBER OF THE SENTRY FAMILY IF INSURANCE COMPANIES GENERAL LIABILITY DECLARATIONS POLICY NUMBER 49- 64503 -03 NAME INSURED: CLOSNER EQUIPMENT CO INC ADDITIONAL INSURED SCHEDULE The following information is required to complete the accompanying additional insured endorsement which forms a part of the Named Insured's COMMERCIAL GENERAL LIABILITY COVERAGE PART. ADDITIONAL INSURED ENDORSEMENT CITY OF DENTON CG 20 10 04 13 MATERIALS MANAGEMENT DEPARTMENT 901 -B TEXAS STREET DENTON TX 76209 (CERTIFICATE NUMBER 0039) LOCATIONS OF COVERED OPERATIONS ALL LOCATIONS CG 89 01 11 85 (MECH) CLO 49- 64503 -03 40 151 01 -29 -2015 (000 0039) FOR ENDORSEMENT TEXT EFFECTIVE FROM JANUARY 01, 2015 TO JANUARY 01, 2016