Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
22-898
ORDiNANCE NO. 22-898 AN ORDINANCE OF THE CITY OF DENTON, A TEXAS HOME-RULE MUNIC'IPALCORPORATION, AUTHORIZING THE CITY MANAGER TO EXECUTE A PROFESSIONALSERVICES AGREEMENT WITH KIMLEY-HORN AND ASSOCIATES, INC., FOR REGULATORY PERMITTING/APPROVAL SUPPORT, PROCESS EVALUATION, DESIGNSERVICES, BIDDING ASSISTANCE, CONSTRUCTION PHASE SERVICES. AND EASEMENT ACQUISITION FOR THE 1-35 TO MILAM CREEK PHASE II PROJECT FOR THEWATER UTILITIES DEPARTMENT; PROVIDING FOR THE EXPENDITURE OF FUNDS THEREFOR; AND PROVIDING AN EFFECTIVE DATE (RFQ 7574-olo – PROFESSIONALSERVICES AGREEMENT FOR DESIGN AND CONSTRUCTION PHASE SERVICESAWARDED TO KIMLEY-HORN AND ASSOCIATES, INC., IN THE NOT-TO-EXCEED AMOUNT OF $751,100.00). WHEREAS, on March 23, 202 1, the City Council approved a pre-qualified engineer list for Water and Wastewater (Ordinance 2 1-546), and the professional services provider (the “Provider”) mentioned in this ordinance is being selected as the most highly qualified on the basis of its demonstrated competence and qualifications to perform the proposed professional services; and WHEREAS, the fees under the proposed contract are fair and reasonable and are consistent with, and not higher than, the recommended practices and fees published by the professionalassociations applicable to the Provider’s profession, and such fees do not exceed the maximum provided by law; NOW, THEREFORE, THE COUNCIL OF THE CITY OF DENTON HEREBY ORDAINS: SECTION 1. The City Manager, or their designee, is hereby authorized to enter into an agreement with to Kimley-Horn and Associates, Inc., to provide professional design and construction phase services for the City of Denton, a copy of which is attached hereto and incorporated by reference herein. SECTION 2. The City Manager, or their designee, is authorized to expend funds as required by the attached contract. SECTION 3. The City Council of the City of Denton, hereby expressly delegates the authority to take any actions that may be required or permitted to be performed by the City of Denton under this ordinance to the City Manager of the City of Denton, or their designee. SECTION 4. The findings in the preamble of this ordinance are incorporated herein byreference. SECTION 5. This ordinance shall become effective immediately upon its passage and approval. The motion to approve this ordinance was seconded by if ian b&AliBI F4Aqu\andmade by land approved byThis ordinance was pas: the following vote Ll - U Aye Nay Abstain Absent Mayor Gerard Hudspeth:Vicki Byrd, District 1 : Brian Beck, District 2:Jesse Davis, District 3 :IZb/ b/ /Alison Maguire, District 4:Brandon Chase McGee, At Large Place 5 : Chris Watts, At Large Place 6: PASSED AND APPROVED this the taM day of bAaLA 2022 bA ATTEST: ROSA RIOS, CITY SECRETARY L\\\\\11111111 M--A APPROVED AS TO LEGAL FORM: MACK REINWAND, CITY ATTORNEY Digitally signed by MarcellaLunn DN: cn=Marcella Lunn, o,LI on.com. c=US Date: 2022.05.1 0 10:51 :Zn -05'00' Fb :::fI!=rFID:rr:nmrittif\frIar\tou=City of Denton,I ]BY, MJMatJJ\ DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 DENTON Docusign City Council Transmittal Coversheet 7574-010 File Name I 135 SPLIT TO MILAM PHASE II P,rcha,i,gCo,tact c 'Y;t;1 w''tb'"k City Council Target Date MAY 17’ 2022 Piggy Back Option Contract Expiration Ordinance ron Not Applicab1 e N/A 22-898 DocuSign Envelope ID: 8C471F51-6D934D224A61-788413991955 CITY OF DENTON, TEXAS STANDARD AGREEMENT FOR ENGINEERING RELATED PROFESSIONALSERVICES This AGREEMENT is between the City of Denton, a Texas home-rule municipality("CITY"), and KIMLEY-HORN AND ASSOCIATES, INC., with its corporate office at 421 Fayetteville Street, Suite 600, Raleigh, NC 27601 and authorized to do business in Texas,("ENGINEER"), for a PROJECT generally described as: 135 Split to Milam Phase II (the"PROJECT") SECTION 1 Scope of Services A. The CITY hereby agrees to retain the ENGINEER, and the ENGINEER hereby agreesto perform, professional engineering services set forth in the Scope of Servicesattached hereto as Attachment A. These services shall be performed in connectionwith the PROJECT. B. Additional services, if any, will be requested in writing by the CITY. CITY shall not pay for any work performed by ENGINEER or its consultants, subcontractors and/orsuppliers that has not been ordered in advance and in writing. It is specifically agreed that ENGINEER shall not be compensated for any additional work resulting from oral orders of any person. SECTION 2 Compensation and Term of Agreement A. The ENGINEER shall be compensated for all services provided pursuant to this AGREEMENT in an amount not to exceed $751,100 in the manner and in accordance with the fee schedule as set forth in Attachment A. Payment shall be considered fullcompensation for all labor, materials, supplies, and equipment necessary tocomplete the services described in Attachment A. B. Unless otherwise terminated pursuant to Section 6. D. herein, this AGREEMENT shall be for a term beginning upon the effective date, as described below, and shall continuefor a period which may reasonably be required for the completion of the PROJECT,until the expiration of the funds, or completion of the PROJECT and acceptance by the CITY, whichever occurs first. ENGINEER shall proceed diligently with the PROJECT to completion as described in the PROJECT schedule as set forth in Attachment A. SECTION 3 Terms of Payment Payments to the ENGINEER will be made as follows: City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 1 of 18 DocuSign Envelope ID: 8C471F51-6D934D224A61-788413991955 A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation, including but notlimited to meeting the requirements set forth in the PROJECT schedule as set forth in Attachment A to reasonably substantiate the invoices. (2) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices for the uncontested performance of the particularservices are due and payable within 30 days of receipt by City. (3) Upon completion of services enumerated in Section 1, the final payment of anybalance for the uncontested performance of the services will be due within 30days of receipt of the final invoice. (4) in the event of a disputed or contested billing, only that portion so contested willbe withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. Nointerest will accrue on any contested portion of the billing until mutually resolved. (5) if the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7days' written notice to CITY, suspend services under this AGREEMENT until paid in full. In the event of suspension of services, the ENGINEER shall haveno liability to CITY for delays or damages caused the CITY because of suchsuspension of services. SECTION 4 Obligations of the Engineer Amendments to Section 4, if any, are included in Attachment B. A. General The ENGINEER will serve as the CITY's professional engineering representative under this AGREEMENT, providing professional engineering consultation and advice andfurnishing customary services incidental thereto. B. Standard of Care The ENGINEER shall perform its services: (1) with the professional skill and care ordinarily provided by competent engineers practicing in the same or similar locality and under the same or similarcircumstances and professional license; and City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18Page 2 of 18 DocuSign Envelope ID: 8C471F51-6D934D22-8A6 1-788413991955 (2) as expeditiously as is prudent considering the ordinary professional skill and care of a competent engineer. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity forsubcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerningthe results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. (2) in soils, foundation, groundwater, and other subsurface investigations, theactual characteristics may vary significantly between successive test points andsample intervals and at locations other than where observations, exploration,and investigations have been made. Because of the inherent uncertainties insubsurface evaluations, changed or unanticipated underground conditions mayoccur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of theENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink onreproducible mylar sheets and electronic files in .pdf format, or as otherwise approved byCITY, which shall become the property of the CITY. CITY may use such drawings in anymanner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site,whether as on-site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITYand/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means,techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with theAGREEMENT Documents and any health or safety precautions required bysuch construction work. The ENGINEER and its personnel have no authority toexercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 3 of 1 8 DocuSign Envelope ID: 8C471F51-6D93-+D22-8A61-788413991955 Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progressor quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being performed in a manner indicating that thePROJECT, when completed, will be in accordance with the AGREEMENTDocuments, nor shall anything in the AGREEMENT Documents or this AGREEMENT between CITY and ENGINEER be construed as requiringENGINEER to make exhaustive or continuous on-site inspections to discoverlatent defects in the work or otherwise check the quality or quantity of the workon the PROJECT. If the ENGINEER makes on-site observation(s) of adeviation from the AGREEMENT Documents, the ENGINEER shall inform theCITY (3) When professional certification of performance or characteristics of materials,systems or equipment is reasonably required to perform the services set forth inthe Scope of Services, the ENGINEER shall be entitled to rely upon suchcertification to establish materials, systems or equipment and performancecriteria to be required in the AGREEMENT Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1 ) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance withAttachment A. (2) in providing opinions of cost, financial analyses, economic feasibility projections,and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitivebidding procedures and market conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; andother economic and operational factors that may materially affect the ultimatePROJECT cost or schedule. Therefore, the ENGINEER makes no warrantythat the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections,or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge,information, and belief from selective sampling and observation that the work hasprogressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain thatthe construction contractor has completed the work in exact accordance with the City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 4 of 18 DocuSign Envelope ID: 8(>171F51-6D934D224A61-788413991955 AGREEMENT Documents; that the final work will be acceptable in all respects; that theENGINEER has made an examination to ascertain how or for what purpose theconstruction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, orencumbrances; or that there are not other matters at issue between the CITY and the construction contractor that affect the amount that should be paid . H. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiledand furnished by others, and may not always represent the exact location, type of variouscomponents, or exact manner in which the PROJECT was finally constructed. TheENGINEER is not responsible for any errors or omissions in the information from othersthat is incorporated into the record drawings. I. Right to Audit (1 ) ENGINEER agrees that the CITY shall, until the expiration of five (5) years after final payment under this AGREEMENT, have access to and the right toexamine and photocopy any directly pertinent books, documents, papers andrecords of the ENGINEER involving transactions relating to this AGREEMENT.ENGINEER agrees that the CITY shall have access during normal workinghours to all necessary ENGINEER facilities and shall be provided adequate andappropriate work space in order to conduct audits in compliance with theprovisions of this section. The CITY shall give ENGINEER reasonable advancenotice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITYshall, until the expiration of five (5) years after final payment under thesubcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant,involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall beprovided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this section together with subsection (3)hereof. CITY shall give subconsultant reasonable advance notice of intendedaudits (3) ENGINEER and subconsultant agree to photocopy such documents as may berequested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 5 of 18 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 J. INSURANCE (1) ENGINEER’S INSURANCE a.Commercial General Liability – the ENGINEER shall maintain commercial general liability (CGL) and, if necessary, commercialumbrella insurance with a limit of not less than $1,000,000.00 per each occurrence with a $2,000,000.00 aggregate. If such Commercial GeneralLiability insurance contains a general aggregate limit, it shall applyseparately to this PROJECT or location. 1.The CITY shall be included as an additional insured with all rightsof defense under the CGL, using ISO additional insuredendorsement or a substitute providing equivalent coverage, and under the commercial umbrella, if any. This insurance shall applyas primary insurance with respect to any other insurance or self-insurance programs afforded to the CITY. The CommercialGeneral Liability insurance policy shall have no exclusions or endorsements that would alter or nullify: premises/operations, products/completed operations, contractual, personal injury, or advertising injury, which are normally contained within the policy,unless the CITY specifically approves such exclusions in writing . ii.ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to theextent these damages are covered by the commercial generalliability or commercial umbrella liability insurance maintained inaccordance with this AGREEMENT. b Business Auto – the ENGINEER shall maintain business auto liabilityand, if necessary, commercial umbrella liability insurance with a limit ofnot less than $1,000,000 each accident. Such insurance shall cover liability arising out of “any auto”, including owned, hired, and non-ownedautos, when said vehicle is used in the course of the PROJECT. If theengineer owns no vehicles, coverage for hired or non-owned is acceptable. i.ENGINEER waives all rights against the CITY and its agents,officers, directors and employees for recovery of damages to the extent these damages are covered by the business auto liability orcommercial umbrella liability insurance obtained by ENGINEERpursuant to this AGREEMENT or under any applicable auto physical damage coverage. c. Workers’ Compensation – ENGINEER shall maintain workers City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18Page 6 of 18 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-78&113991955 compensation and employers liability insurance and, if necessary, commercial umbrella liability insurance with a limit of not less than$100,000.00 each accident for bodily injury by accident or $100,000.00 each employee for bodily injury by disease, with $500,000.00 policy limit. 1.ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to theextent these damages are covered by workers compensation andemployer’s liability or commercial umbrella insurance obtained byENGINEER pursuant to this AGREEMENT. d.Professional Liability – ENGINEER shall maintain professional liability, aclaims-made policy, with a minimum of $1,000,000.00 per claim and aggregate. The policy shall contain a retroactive date prior to the date ofthe AGREEMENT or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 yearsfollowing the completion of the AGREEMENT. An annual certificate of insurance specifically referencing this PROJECT shall be submitted tothe CITY for each year following completion of the AGREEMENT. (2) GENERAL INSURANCE REQUIREMENTS a. Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be attached to this AGREEMENT prior to itsexecution . b Applicable policies shall be endorsed to name the CITY an AdditionalInsured thereon, subject to any defense provided by the policy, as itsinterests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contractedservices c. Certificate(s) of insurance shall document that insurance coveragespecified in this AGREEMENT are provided under applicable policiesdocumented thereon. d. Any failure on part of the CITY to attach the required insurancedocumentation hereto shall not constitute a waiver of the insurance requirements. e.A minimum of thirty (30) days notice of cancellation or material change in coverage shall be provided to the CITY. A ten (10) days notice shall be acceptable in the event of non-payment of premium. Notice shall be sentto the respective Department Director (by name), City of Denton, 901Texas Street, Denton, Texas 76209. City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18Page 7 of 18 DocuSign Envelope ID: 8C471F51-6D93dID22-8A61-788413991955 f. Insurers for all policies must be authorized to do business in the State of Texas and have a minimum rating of A:V or greater, in the current A.M.Best Key Rating Guide or have reasonably equivalent financial strengthand solvency to the satisfaction of Risk Management. g.Any deductible or self insured retention in excess of $25,000.00 thatwould change or alter the requirements herein is subject to approval by the CITY in writing, if coverage is not provided on a first-dollar basis. TheCITY, at it sole discretion, may consent to alternative coveragemaintained through insurance pools or risk retention groups. Dedicatedfinancial resources or letters of credit may also be acceptable to theCITY h. Applicable policies shall each be endorsed with a waiver of subrogationin favor of the CITY as respects the PROJECT. i. The CITY shall be entitled, upon its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY’s discretion; the ENGINEER maybe required to provide proof of insurance premium payments. j. Lines of coverage, other than Professional Liability, underwritten on aclaims-made basis, shall contain a retroactive date coincident with or prior to the date of the AGREEMENT. The certificate of insurance shall state both the retroactive date and that the coverage is claims-made. k Coverages, whether written on an occurrence or claims-made basis, shall be maintained without interruption nor restrictive modification orchanges from date of commencement of the PROJECT until final payment and termination of any coverage required to be maintained afterfinal payments. 1.The CITY shall not be responsible for the direct payment of anyinsurance premiums required by this AGREEMENT. m. Sub consultants and subcontractors to/of the ENGINEER shall be required by the ENGINEER to maintain the same or reasonablyequivalent insurance coverage as required for the ENGINEER. When sub consultants/subcontractors maintain insurance coverage,ENGINEER shall provide CITY with documentation thereof on acertificate of insurance. K. Independent Consultant City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 8 of 18 DocuSign Envelope ID: 8C471F51-6D93zID22-8A61-78@113991955 The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. The doctrine of respondeat superiorshall not apply. L. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and businessrelationships with abutting property cities. The ENGINEER further acknowledges that it willmake disclosure in writing of any conflicts of interest that develop subsequent to thesigning of this AGREEMENT and prior to final payment under the AGREEMENT. M. Asbestos or Hazardous Substances (1) if asbestos or hazardous substances in any form are encountered or suspected,the ENGINEER will stop its own work in the affected portions of the PROJECTto permit testing and evaluation. (2) if asbestos or other hazardous substances are suspected, the CITY may request the ENGINEER to assist in obtaining the services of a qualifiedsubcontractor to manage the remediation activities of the PROJECT. N. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should havebeen aware of at the time this AGREEMENT was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published designcriteria and/or practice standards criteria which are published after the date of thisAGREEMENT which the ENGINEER could not have been reasonably aware of, theENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. O. Schedule ENGINEER shall manage the PROJECT in accordance with the schedule developed perAttachment A to this AGREEMENT. P. Equal Opportunity (1) Equal Employment Opportunity: ENGINEER and ENGINEER’s agentsshall engage in any discriminatory employment practice. No person shall, on the grounds of race, sex, sexual orientation, age, disability, creed, color, genetic City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 9 of 18 DocuSign Envelope ID: 8C471F51-6D934D22-8A6 1-788413991955 testing, or national origin, be refused the benefits of, or be otherwise subjectedto discrimination under any activities resulting from this AGREEMENT. (2) Americans with Disabilities Act (ADA) Compliance: ENGINEER and ENGINEER’s agents shall not engage in any discriminatory employmentpractice against individuals with disabilities as defined in the ADA. SECTION 5 Obligations of the City Amendments to Section 5, if any, are included in Attachment B. A. City-Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the informationprovided by the CITY. B. Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for theENGINEER's performance of its services. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of theCITY's facilities as may be required in connection with the ENGINEER's services. TheCITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, andpay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights-of-way, and access necessary for theENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurancecounselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timelymanner in accordance with the PROJECT schedule prepared in accordance withAttachment A. E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 10 of 18 DocuSign Envelope ID: 8CH71F51-6D934D224A61-788413991955 becomes aware of any development that affects the scope or timing of the ENGINEER'sservices or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containingmaterials, or conditions, and that ENGINEER had no prior role in thegeneration, treatment, storage, or disposition of such materials. Inconsideration of the associated risks that may give rise to claims by thirdparties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, releaseor escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER’s negligence or if ENGINEER brings such hazardous substance,contaminant or asbestos onto the PROJECT. G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV.E.regarding the ENGINEER's Personnel at Construction Site, and provisions providing for contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third-Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materialssuppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, andsubcontractors, for any claim arising out of, in connection with, orresulting from the engineering services performed. Only the CITYwill be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITYand the ENGINEER and there are no third-party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shallhave no third-party beneficiary rights under this AGREEMENT. (4) Nothing contained in this Section H. shall be construed as a waiver of any rightthe CITY has to bring a claim against ENGINEER. City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 1 1 of 18 DocuSign Envelope ID: 8C471F51-6D93dID22-8A6 1-788413991955 I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structuresassociated with the PROJECT. (2) The CITY may secure Builders Risk/Installation insurance at the replacementcost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertakenor defended by the CITY. In the event CITY requests such services of the ENGINEER, thisAGREEMENT shall be amended or a separate agreement will be negotiated between the parties K. Changes The CITY may make or approve changes within the general Scope of Services in thisAGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. SECTION 6 General Legal Provisions Amendments to Section 6, if any, are included in Attachment B. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of awritten Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for thisPROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration bythe CITY or by others acting through or on behalf of the CITY of any such instruments ofservice without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. CIty of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 12 of 18 DocuSign Envelope ID: 8CX71F51-6D93zID22-8A6 1-78@113991955 C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts ofGod, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER that prevent ENGINEER’s performance of its obligations hereunder. D. Termination (1 ) This AGREEMENT may be terminated: a. by the City for its convenience upon 30 days' written notice toENGINEER. b.by either the CITY or the ENGINEER for cause if either party failssubstantially to perform through no fault of the other and thenonperforming party does not commence correction of such nonperformance within 5 days’ written notice or thereafter fails todiligently complete the correction. (2) if this AGREEMENT is terminated for the convenience of the City, theENGINEER will be paid for termination expenses as follows: a. Cost of reproduction of partial or complete studies, plans, specificationsor other forms of ENGINEER'S work product; b. Out-of-pocket expenses for purchasing electronic data files and otherdata storage supplies or services; c. The time requirements for the ENGINEER'S personnel to document the work underway at the time of the CITY'S termination for convenience sothat the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to theCITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for theconvenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will bemade F. Indemnification City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 13 of 18 DocuSign Envelope ID: 8C471F5 1-6D934D22-8A61-788413991955 IN ACCORDANCE WITH TEXAS LOCAL GOVERNMENT CODE SECTION 271.904.THE ENGINEER SHALL INDEMNIFY OR HOLD HARMLESS THE CITY AGAINSTLIABILITY FOR ANY DAMAGE COMMITED BY THE ENGINEER OR ENGINEER’SAGENT, CONSULTANT UNDER CONTRACT, OR ANOTHER ENTITY OVER WHICHTHE ENGINEER EXERCISES CONTROL TO THE EXTENT THAT THE DAMAGE IS CAUSED BY OR RESULTING FROM AN ACT OF NEGLIGENCE. INTENTIONALTORT, INTELLECTUAL PROPERTY INFRINGEMENT, OR FAILURE TO PAY ASUBCONTRACTOR OR SUPPLIER. CITY IS ENTITLED TO RECOVER ITSREASONABLE ATrORNEY’S FEES IN PROPORTION TO THE ENGINEER’SLIABILITY G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior writtenconsent of the other party. H. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, itsinterpretation and performance, and any other claims related to it. The venue for anylitigation related to this AGREEMENT shall be Denton County, Texas. I. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceabilitywill not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Sections 5,F., 6.B., 6.D., 6.F., 6.H., and 6.1. shall survive termination of this AGREEMENT for any cause. J. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect thisAGREEMENT and the work hereunder, and shall observe and comply with all orders, lawsordinances and regulations which may exist or may be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding orignorance thereof shall be considered. ENGINEER AGREES TO DEFEND, INDEMNIFYAND HOLD HARMLESS CITY AND ALL OF ITS OFFICERS, AGENTS ANDEMPLOYEES FROM AND AGAINST ALL CLAIMS OR LIABILITY ARISING OUT OFTHE VIOLATION OF ANY SUCH ORDER, LAW, ORDINANCE. OR REGULATION.WHETHER IT BE BY ITSELF OR ITS EMPLOYEES. K. Immigration Nationality Act City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 14 of 18 DocuSign Envelope ID: 8G+71F51-6D93ztD224A61-78 M13991955 ENGINEER shall verify the identity and employment eligibility of its employees whoperform work under this AGREEMENT, including completing the Employment EligibilityVerification Form (1-9). Upon request by CITY, ENGINEER shall provide CITY withcopies of all 1-9 forms and supporting eligibility documentation for each employee whoperforms work under this AGREEMENT. ENGINEER shall adhere to all Federal and State laws as well as establish appropriate procedures and controls so that no services will be performed by any ENGINEER employee who is not legally eligible to performsuch services. ENGINEER SHALL INDEMNIFY CITY AND HOLD CITY HARMLESSFROM ANY PENALTIES, LIABILITIES, OR LOSSES DUE TO VIOLATIONS OF THISPARAGRAPH BY ENGINEER, ENGINEER’S EMPLOYEES, SUBCONTRACTORS,AGENTS, OR LICENSEES. CITY, upon written notice to ENGINEER, shall have theright to immediately terminate this AGREEMENT for violations of this provision byENGINEER L. Prohibition On Contracts With Companies Boycotting Israel ENGINEER acknowledges that in accordance with Chapter 2270 of the TexasGovernment Code, CITY is prohibited from entering into a contract with a company forgoods or services unless the contract contains a written verification from the companythat it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of thecontract. The terms “boycott Israel” and “company” shall have the meanings ascribed tothose terms in Section 808.001 of the Texas Government Code. By signing thisAGREEMENT, ENGINEER certifies that ENGINEER’S signature provides writtenverification to the CITY that ENGINEER: V) does not boycott Israel; and (2) willnot boycott Israel during the term of the AGREEMENT. Failure to meet or maintain the requirements under this provision will be considered a material breach. M. Prohibition On Contracts With Companies Doing Business with Iran, Sudan, or a Foreign Terrorist Organization Section 2252 of the Texas Government Code restricts CITY from contracting with companies that do business with Iran, Sudan, or a foreign terrorist organization. Bysigning this AGREEMENT, ENGINEER certifies that ENGINEER’S signatureprovides written verification to the CITY that ENGINEER, pursuant to Chapter2252, is not ineligible to enter into this AGREEMENT and will not becomeineligible to receive payments under this AGREEMENT by doing business withIran, Sudan, or a foreign terrorist organIzation. Failure to meet or maintain the requirements under this provision will be considered a material breach. N. Certificate of Interested Parties Electronic Filing In 2015, the Texas Legislature adopted House Bill 1295, which added section 2252.908of the Government Code. The law states that the City may not enter into this contractunless the Contractor submits a disclosure of interested parties (Form 1295) to the City City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 15 of 18 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 at the time the Engineer submits the signed contract. The Texas Ethics Commission has adopted rules requiring the business entity to file Form 1295 electronically with theCommission. Engineer will be required to furnish a Certificate of Interest Parties before the contract isawarded, in accordance with Government Code 2252.908. The contractor shall: 1. 2 3 4 5 6. Log onto the State Ethics Commission Website at : https://www.ethics.state.tx.us/whatsnew/elf info form1295.htmRegister utilizing the tutorial provided by the StatePrint a copy of the completed Form 1295 Enter the Certificate Number on page 2 of this contractComplete and sign the Form 1295 Email the form to purchasing@cityofdenton.com with the contract number insubject line. (EX: Contract 1234 – Form 1295) the The City must acknowledge the receipt of the filed Form 1295 not later than the 30th day after Council award. Once a Form 1295 is acknowledged, it will be posted to theTexas Ethics Commission’s website within seven business days. O. Prohibition Against Personal Interest in Contracts No officer, employee, independent consultant, or elected official of the City who isinvolved in the development, evaluation, or decision-making process of the performanceof any solicitation shall have a financial interest, direct or indirect, in the Contract resulting from that solicitation as defined in the City’s Ethic Ordinance 18-757 and in theCity Charter chapter 2 article XI(Ethics). Any willful violation of this section shall constitute impropriety in office, and any officer or employee guilty thereof shall be subject to disciplinary action up to and including dismissal. Any violation of thisprovision, with the knowledge, expressed or implied, of the Contractor shall render the Contract voidable by the City. The Engineer shall complete and submit the City’sConflict of Interest Questionnaire. P. Agreement Documents This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, which supersedes all prior written or oral understandings, and may only bechanged by a written amendment executed by both parties. This AGREEMENT may be executed in one or more counterparts and each counterpart shall, for all purposes, bedeemed an original, but all such counterparts shall together constitute but one and thesame instrument. The following attachments and schedules are hereby made a part ofthis AGREEMENT: City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 16 of 18 DocuSign Envelope ID: 8C471F51-6D934D224A61-788413991955 Attachment A - Scope of Services, Compensation, Project ScheduleAttachment B - Amendments to Standard Agreement for Engineering Services These documents make up the AGREEMENT documents and what is called for by oneshall be as binding as if called for by all. In the event of an inconsistency or conflict inany of the provisions of the AGREEMENT documents, the inconsistency or conflict shallbe resolved by giving precedence first to the written AGREEMENT then to the AGREEMENT documents in the order in which they are listed above. Duly executed by each party’s designated representative to be effective on the datesubscribed by the City Manager. ENGINEER KIMLEY-HORN AND ASSOCLATES, INC CITY OF DENTON, TEXASSARA HENSLEY, CITY MANAGER AUTHORIZED SIGNATURE BY: John AtkinsPrinted Name:ATTEST:ROSA RIOS. CITY SECRETARY Tide. vice Presldent 817-339-2272 PHONE NUMBER john . atk1 ns@k1 m1 ey-horn . com APPROVED AS TO LEGAL FORM:MACK REnqWAND. CITY ATTORNEY /''--••••••DocuSigned by:OM:'„"BY: \4B070831B4M438 , EMAIL ADDRESS 2022-873387 TEXAS ETHICS COMMISSION1295 CERTIFICATE NUMBER THIS AGREEMENT HAS BEENBOTH REVIEWED AND APPROVED as to financial and operational obligations andbusiness terms. Stephen D Gay SIGN-ATukE -PRINTED NAME D1 rector TITLE Water Uti 11 ties DEPARTMENT City of Denton, TexasStandard Agreement for Engineering Related Design ServicesRevised Date: 9/6/18 Page 17 of 18 DocuSign Envelope ID: 8C471 F51-6D93-4D22-8A61-788413991955ATTACHEMENT A PROFESSIONAL SERVICES AGREEMENT Professional Services Agreement:1-35 – SPLIT TO MILAM PHASE 2 Scope of Services The ENGINEER will perform its services pursuant to the requirements delineated below. Services under this attachment include engineering services for the design and construction phase services for the 1-35 – SPLIT TO MILAM PHASE 2 project under the Professional Service Agreement (7574-010) Project Understanding Under the first phase of the IH-35 utility Relocation contract, The CITY requested that the ENGINEER perform additional services to analyze the sewer basin projected flows for potential development in the Milam Creek to Loop 288 area to evaluate and determine the appropriate size of sewer infrastructure needed to meet peak flows for the proposed developments. This analysis indicated that the existing sewer infrastructure is undersized and would need to be upsized and rerouted to allow for several current proposed developments. Scope of Services The CITY has requested that the ENGINEER perform additional services to provide a design for an approximately Three-Million Gallon per Day (3.27-MGD) regional sanitary sewer lift station, force main, and gravity sewer mains in order to promote the future development planned for the l- 35 north west corridor and clear the conflicts identified with the 1-35 TxDOT project. This lift station will be designed to allow for the abandonment of the Border-Cowboy and TA lift stations and be phased to allow for initial flows of 1,200 gallons per minute (gpm) up to 2,300 gpm. The task descriptions listed below are in addition to the previously authorized items. Task 1 Design Management ENGINEER will provide the following additional services in accordance with the OriginalContract: A. Project Management 1. Attend up to one additional meeting with City. 2.Prepare and execute up to two (2) additional subconsultant amendments. Task 2 – ALIGNMENT STUDY A. Preliminary Investigation 1. Site Investigation a. Walk general alignment. 1-35 – SPLIT TO MELAM PHASE 2 February 17, 2022 1 of 14 DocuSign Envelope ID: 8CH71F51-6D93=ID22-8A6 1-788413991955 b.Document alignment corridor with photographs. c. Note visible potential alignment, conflicts and issues. Data Review with City2 a.Meet with City to review accuracy of record information. b. Interview City staff concerning historical, existing and fbture City plans along the alignment. B. Prepare Alignment Technical Memorandum. 1. Analysis of alignments indicating merits and challenges for each, and including the following considerations: a. b. C. d. e. f. Easement acquisition schedule and cost impacts. Existing development impacts. Existing potential horizontal and vertical conflicts. Accessibility for maintenance. Revise roll plot maps to include full project limits Prepare opinions of probable construction cost for each alignment. The ENGINEER has no control over the cost of labor, materials, equipment, or over the Contractor’s methods of determining prices or over competitive bidding or market conditions. Opinions of probable costs provided herein are based on the information known to ENGINEER at this time and represent only the ENGINEER’s judgment as a designprofessional familiar with the construction industry. The ENGINEER cannot and does not guarantee that proposals, bids, or actual construction costs will not vary from its opinions of probable costs. C. Deliverables 1. Digital .PDF copy of draft and final technical memorandum. D. Meetings 1. Conduct one (1) review meeting with City. 2. Revise memorandum based on City comments. Task 3 – PRELIMINARY DESIGN A. Geotechnical Engineering 1 Perform a geotechnical analysis of the alignment utilizing a qualified geotechnical laboratory to determine subsurface conditions and make recommendations regarding design parameters. The analysis shall include the following: a. Subsurface exploration including up to six (6) sample bores varying 10 to 40 feet depending upon location. b. Laboratory tests for classification purposes and strength characteristics. 1-35 – SPLIT TO MELAM PHASE 2 February 17, 2022 2 of 14 DocuSign Envelope ID: 8C471F51-6D93JID22-8A61-788413991955 C.Engineering services that address the following: i. soil and groundwater conditions ii. Comments on general excavatability of soils and shaleencountered iii. Recommendations for pipe installation, including bedding andbackfill iv. Recommendations for tunneling operations v. Recommendations for vault and wet well foundation type and allowable loading vi. Recommendations for lateral pressures for structural design 2.The previously provide geotechnical report will be amended and furnished by thegeotechnical engineer to present the results of the field and laboratory data as well as analyses and recommendations. Three (3) copies of the report will be provided by the geotechnical engineer, with one (1) copy going to the City. The datacontained in the geotechnical report will be made available to contractors during the bidding process for informational purposes. B.Subsurface Utility Engineering (SUE) 1.Level A investigation of existing water line connection point, and potential crossing utilities. The Level A investigation shall consist of performing up to two (2) level A testholes or “locates” of existing utilities. The Level A investigation will be conducted in accordance with ASCE publication CI/ASCE 38-02 and include the location of said utility in three dimensions obtained through non- destructive geophysical methods. 2.This task assumes that SUE data will be available from TxDOT and may be relied upon for design. C. Preliminary Waterline and Sanitary Sewer Line Design 1. 2. Visit the site to perform field verification of the survey. Additional Preliminary plan and profile drawings preparation for approximately 1,800 linear feet of 20-inch through 6-inch water main 330 linear feet of 12-inch sanitary sewer force main, and 13,500 feet of 1 8-inch through 36-inch gravity sanitary sewer line. a. Prepare (22“x34”) plan and profile drawings at 1”=40’ horizontal and1”=4’ vertical scale. b. Plan view of the base map shall have all above ground features shown and clearly labeled along with existing utilities based on field ties and recordinformation. C. d. Plan view shall include design notes for stationing, size, slope, pipe material, embedment, length and construction method. Profile view shall include design notes for stationing, size, slope, flow- line of pipe, pipe material, embedment, length and construction method. 1-35 – SPLIT TO MEAM PHASE 2 February 17, 2022 3 of 14 DocuSign Envelope ID: 8C471F51-6D93zID22-8A6 1-78@113991955 e. Design tunnels/bores including casing/tunnel liner plate minimum thickness and inside diameter, shafts, allowable methods, control of ground water, and appropriate tolerances with the chosen method. f. Perform one (1) site visit to verify preliminary design. Preliminary Traffic Control and Detour Plan Preparation. a. City and TxDOT typical traffic control details will be included as required. 3. 4.Franchise Utility Coordination a. Provide one set of drawings to each franchise utility encountered for their review. Request each franchise to mark up the drawings to show the size, type, and location of their utilities. b. Coordinate with franchise utilities if any relocations are required. Notify City if any relocations will be required. 5. 6. 7. Prepare preliminary general notes and details, including City Standard Details where applicable, Prepare preliminary technical specifications utilizing City Standard Specifications, and any special specifications. Compile and prepare an updated opinion of probable construction cost for the entire project using recent average unit bid prices which are representative of similar types of construction in the local area. a.The ENGINEER has no control over the cost of labor, materials, equipment, or over the Contractor’s methods of determining prices or over competitive bidding or market conditions. Opinions of probable costs provided herein are based on the information known to ENGINEER at this time and represent only the ENGINEER’s judgment as a designprofessional familiar with the construction industry. The ENGINEER cannot and does not guarantee that proposals, bids, or actual construction costs will not vary aom its opinions of probable costs. D. U.S. Army Corp of Engineer’s Nationwide Permit 12 Memo (USACE NWP 12) o ENGINEER will incorporate findings from additional field investigations into the previously authorized memorandum. E. Deliverables 1.Preliminary design submittal (60%) a. Submit four (4) copies to City for review and comment. b. Submittal shall include the following: 1. 11. ill. IV. Preliminary design plans (22“x34”) Preliminary technical specifications (table of contents) Geotech report (additional bores will be included in one report) NWP 12 Memo (additional findings included in memo) 1-35 – SPLIT TO MDLAM PHASE 2 February 17, 2022 4 of 14 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 v. Opinion of probable construction cost F.Meetings 1. Attend one (1) meeting with City to kick-off preliminary design. 2. Attend one (1) meeting with City on-site prior to submittal of preliminary plans, if required. 3. Attend one (1) meeting with City to present and review the preliminary design submittal Task 4 – FINAL DESIGN A.Final Waterline and Sanitary Sewer Design 1. Incorporate the preliminary design submittal review comments (one (1) round of comments is anticipated in proposed effort). Prepare updated opinion of probable construction cost. a. The ENGINEER has no control over the cost of labor. materials. equipment, or over the Contractor’s methods of determining prices or over competitive bidding or market conditions. Opinions of probable costs provided herein are based on the information known to ENGINEER at this time and represent only the ENGINEER’s judgment as a design professional familiar with the construction industry, The ENGINEER cannot and does not guarantee that proposals, bids, or actual construction costs will not vary from its opinions of probable costs. 3. Incorporate #anchise utility investigation information 4. Incorporate details and technical specifications. 5. Prepare surface repair sheets and details as necessary. 6. Prepare final abandonment layout sheet and letter for TxDOT submittal. 7. Prepare Project Manual using City Standard Construction Contract Documents. Deliverables : 1. Final Design Submittal (95%) a. Submit four (4) copies to the City for review and comment. b. Submittal shall include the following: i. Final design drawings ii. Final design project manual iii. Opinion of probable construction cost 2. B. C.Meetings 1. One (1) meeting with City to review Final Design Submittal. 1-35 – SPLIT TO MnAM PHASE 2 February 17, 2022 5 of 14 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 Task 5 – CONSTRUCTION CONTRACT DOCUMENTS A. Bidding Construction Contract Documents 1. Additional assistance to the previously authorized scope items. Task 6 – BID PHASE SERVICES A. Bid Phase Services 1. Additional assistance to the previously authorized scope items. Task 7 – CONSTRUCTION PHASE SERVICES A. Construction Phase Services 1. Additional assistance to the previously authorized scope items. Task 8 – RECORD DRAWINGS A. Record Drawings 1. Additional assistance to the previously authorized scope items. Task 9 – PERMITTING A. Permitting 1. Additional assistance to the previously authorized scope items. 2. Submit lift station plans to appropriate regulatory agencies: City, DME, TCEQ,and TDLR for review. 3 . The City will be responsible for administration ofPlatting, Zoning and Obtaining building permits for the City of Denton. The ENGINEER will prepare exhibits as directed by City, including preliminary and final plat exhibits. Task 10 – SURVEY AND EASEMENTS A.Design SUIvey 1. Utility and Property Owner Coordination a. Coordinate with DIG TESS and City of Denton to locate and mark existing franchise and public utilities prior to performing the field survey. b. Coordinate with Engineer Real Estate Agent on Right of Entries for up to seven (7) parcels. 2. Design Survey 1-35 – SPLIT TO MEAM PHASE 2 February 17, 2022 6 of 14 DocuSign Envelope ID: 8C471F51-6D93+D22-8A61-78 M13991955 a. The limits of the survey shall be a 100-foot wide alignment generally along IH-35, and along various crossings as shown on the ProjectLocation Map. The topographic survey will be approximately 13,700 linear feet. b. C. Establish up to five (5) horizontal control points based on the City of Denton Coordinate System using %-inch rebar with identifiable plastic cap, specific for this project. Establish a vertical control benchmark circuit tied to the City of Denton benchmark system, specific for this project, as well as tie into the TxDOTcontrol. d Perform a field survey to identify and locate all existing topographic elements within the alignment corridor including, but not limited to, the following: 1. 11. 111. IV. V. Property pins Existing pavement, curbs, sidewalks, barrier free ramps, etc. Lane Striping (where applicable) Driveways Existing storm sewer inlets, manholes, junction boxes, outfalls,and erosion control vi. Culverts and bridges vii. Guardrail Vlll.Utility manholes, vaults, water valves, water meters, sprinkler heads, telephone poles, power poles, utility markers, other publicutilities, and #anchise utilities IX. X. XI. Traffic signal poles, cabinets, and other signal equipment Signs (excluding temporary signs) Trees, 6-inch caliper and up (center of trunk as well as dripline) Xll. Xlll. XIV. XV. Buildings Retaining walls Fence limits and material types Other applicable physical features that could impact design: a) Field ties to the existing edge of pavement on Interstate Hwy 35. b) Field sketches of utility manholes and structures. c) Prepare a final topographic drawings in a digital format (including one-foot contours and breaklines) showing thefeatures located in the field as well as right-of-way strip map information, an ASCII coordinate file of the pointslocated in the field, and a hard copy of the coordinates and feature descriptions. 1-35 – SPLIT TO MEAM PHASE 2 February 17, 2022 7 of 14 DocuSign Envelope ID: 8C471 F51-6D934D22-8A61-788413991955 B. Easement Preparation 1. Upon receiving approval of 60% design drawings, ENGINEER will prepare up to seven (7) permanent water line easements and up to seven (7) temporaryconstructron easernents . 2.Easement instruments will consist ofmetes and bounds descriptions and exhibits. Task 11 – EASEMENT ACQUISTION SERVICES A. Easement Acquisition Services ENGINEER will coordinate with the Real Estate Agent to aid in property acquisition services for up to two (2) hours per parcel. ENGINEER will perform the following services for this task: 1. ENGINEER’s Real Estate Agent shall provide appraisals for proposed easements on up to six (6) parcels for the proposed lines. Appraisals will be approved by the City prior to beginning negotiations with property owners. The appraisals will be prepared by State Certified Appraisers in accordance with the Uniform Standardsof Professional Appraisal Practice Act (USPAP). The appraisals will be suitable for use in condemnation proceedings, if necessary. 2 3. ENGINEER’s Real Estate Agent shall engage an independent Appraisal Reviewer to submit an Appraisal Review to accompany any appraisal completed for up six (6) parcels. Provide property negotiation services for up to six (6) parcels for the proposed lineas follows: a. The offer to purchase the properties will be based on the appraisals as indicated above. The City will establish the value to be used in negotiation and the rangeof negotiating authority to be given to the right-of-way agent. ENGINEER’s Real Estate Agent will provide the services of qualified right-of-way agents to secure the required right-of-way for the project. The right-of-way agents will provide each property owner a copy of The Texas Landowner Bill of Rights, but will NOT be required to provide negotiation services under the Uniform Relocation and Acquisition Act (Uniform Act). b. ENGINEER’s Real Estate Agent will negotiate on behalf of the City and utilize conveyance documents and other necessary forms as prescribed by the City.ENGINEER’s Real Estate Agent will provide a good faith effort to acquire the rights-of-way through a negotiation process, which will generally consist of three (3) contacts with the property owner, or his authorized representative. A maximum of five (5) total contacts will be provided to reach an agreement with the property owner, or to determine that further negotiations will be non- productive and that eminent domain actions will be necessary to acquire the property. If absentee owners are involved, the negotiations may be conducted via telephone, fax, or by mail. If the schedule for acquisition of the right-of-way or other factors arise, which make it expedient, travel outside the project area to meet with the absentee owners may be desirable. If such events arise, the travel must be specifically authorized by the City. If such travel is 1-35 – SPLrr TO MEAM PHASE 2 February 17, 2022 8 of 14 DocuSign Envelope ID: 8C471F51-6D934D22-8A6 1-788413991955 authorized, the expenses involved, including the agent’s services, will beconsidered additional services. c. The initial offer made to the property owner will be based on the value authorized by the City. All counter-offers by the property owner, along with ENGINEER’s Real Estate Agent recommendations will be presented to theCity for consideration. The City must establish and recommend such counter offers before ENGINEER’s Real Estate Agent will be authorized to agree to the requested changes. All monetary offers made to the property owners will be within the limits authorized by the City in the various stages of the negotiation. d. After reaching an agreement with the landowner on the consideration and all other terms of the transaction, ENGINEER’s Real Estate Agent will forward to the City a Memorandum of Agreement (M/A) executed by the property owner to be ratified by the City. This M/A sets forth the compensation and any other terms and conditions agreed upon. The City will be responsible for obtaining the City’s ratification and for returning the ratified M/A to ENGINEER’s RealEstate Agent. ENGINEER’s Real Estate Agent will then inform the Title Company that the parcel is ready for closing. ENGINEER’s Real Estate Agent will coordinate contacts with the CITY to deliver any payments to the Title Company prior to closing. This Scope of Services assumes that costs for Title Commitments, Title Policies and recording fees will be purchased by the City through the assistance of the Real Estate Agent. The amount paid for the Title Policies will not exceed premium amounts set by the Texas Department of Insurance and agreed upon in advance between the City and the Title Company. Any additional Title Company services such as recording fees shall be agreed upon in advance between the City and theTitle Company. ENGINEER’s Real Estate Agent will review liens or other exceptions reported in the Title Commitment, ENGINEER will coordinate the location and the effect of any utility easements. ENGINEER will report the results of the Title Commitment to the City, recommending the disposition of the exceptions. The decision whether the reported exceptions are acceptable or must be eliminated will be the responsibility of the City. Any action required to clear title is not included in the Scope of Work for this project, and if required, will beconsidered Additional Services. 4. 5- 6. 7. 8 ENGINEER’s Real Estate Agent will coordinate and attend all closings at theTitle Company. ENGINEER’s Real Estate Agent will confirm that the Title Company records all documents at the Denton County Courthouse after closing. ENGINEER’s Real Estate Agent will confirm that the Title Company forwards copies of all recorded documents to the City. Task 13 – LIFT STATION PRELIMINARY ENGINEERING REPORT A.Prepare Preliminary Engineering Report (PER) for Lift Station Relocations 1. This task assumes that both the Border-Cowboy Lift Station on Barthold Road and the Love’s Lift Station on Milam Road will be abandoned and replaced with a new Ganzer lift station. The following tasks will be performed: 1-35 – SPLIT TO MEAM PHASE 2 February 17, 2022 9 of 14 DocuSign Envelope ID: 8C471 F51-6D932ID22-8A6 1-788413991955 2.Prepare and Submit a Preliminary Engineering Report per the City’s specifications for review including: a. Lift Station Capacity • Prepare and Submit a conceptual site plan for the proposed lift station replacement b. C. System and Pump Curves Wet Well Sizing 1. Sized to accommodate existing flows and interim flows from Denton Commerce site, approximately 1,200 gpm. Will be designed to be expandable up to 2,300 gpm peak flow. e. f. Site Access and Security per TCEQ Flood Protection h.Emergency Power (portable). Considerations will be made to add permanent backup generation if desired by City. 3.Prepare and Submit a conceptual site plan for the proposed lift station. B. Deliverables a.Digital .PDF copy of draft and final technical memorandum. C. Meetings a. Conduct one (1) review meeting with City. b. Revise PER based on City comments. Task 14 – LIFT STATION PRELIMINARY AND FINAL DESIGN A.Preliminary Lift Station Design 1. Prepare a preliminary site layout, including drainage, paving, yard piping sizing for initial as well as future capacity. and station configuration. 2. Prepare electrical site layout 3. Coordination with primary electric provider for design 4. The following items may be considered for inclusion into the design: a. b. C. d. e. f. Flow metering. Control Narrative – operational narrative of the pumps for normal, low flow and peak operations. SCADA System. City architectural requirements and City design preferences. Geotechnical and structural requirements. Site lighting requirements. 1-35 – SPLIT TO MELAM PHASE 2 February 17, 2022 10 of 14 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 g. h. 1. J. k. 1 Junction Structure/Manhole design for up to 4 structures for future phasing On-site generator considerations. Noise Control requirements. City landscaping requirements. City fencing requirements. City storm drainage detention requiremenb. 5.Prepare a preliminary lift station design including:a. Average and peak flow confirmationb. Hydraulic analysis c. Internal piping and valve layoutd. Lift station cross-sections Submit preliminary design to the City for review and comment.6. B. Final Lift Station Design 1. Prepare engineering plan sheets and specifications in accordance with thepreliminary design and for permitting and processing. 2 The plans will include: Civil sheets: general notes, site plan, grading plan, piping plan, security fence details, lift station mechanical plans anddetails 1 ii. Electrical sheets: general notes, site plan, grounding layout, section and elevations, one-line diagram, pump control schematic, SCADA layout, portable generator connection,and electrical details. iii. Structural sheets: general notes, structural details for wet well, valve vault, meter vault (if required), junction structures and slab-on-grade and specifications. 3. Specifications shall include technical specifications for materials andinstallation of the proposed facilities. C. Deliverables 1.Preliminary design submittal (60%) a. Submit four (4) copies to City for review and comment. b. Submittal shall include the following: vi. Preliminary design plans (22“x34”) vii. Preliminary technical specifications (table of contents) viii. Opinion of probable construction cost. 2.Final design submittal (90%) C.Submit four (4) copies to City for review and comment. 1-35 – SPLIT TO MnAM PHASE 2 February 17, 2022 11 of 14 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 d.Submittal shall include the following: ix. Preliminary design plans (22“x34”) x. Preliminary technical specifications (table of contents) xi. Opinion of probable construction cost D. Meetings 1. 2. 3. Attend one (1) meeting with City to kickoff preliminary design. Attend one (1) meeting with City on-site prior to submittal of preliminary plans, ifrequired. Attend one (1) meeting with City to present and review the preliminary designsubmittal Task 15 – LIFT STATION BID PHASE SERVICES This task assumes the lift stations to be bid as one bid package with the utility relocations. The services shown below will be performed concurrently with Task 6. A. Bid Phase Services 1. Provide additional bidding assistance as previously authorized to aid in bidding the larger, combined lift station. Task 16 – LIFT STATION CONSTRUCTION PHASE SERVICES This task assumes the lift station to be constructed concurrently with the utility relocations. Theservices shown below are similar to Task 7. A. Construction Phase Services 1, Provide additional construction phase services as previously authorized to aid in the larger, combined lift station. 1-35 – SPLIT TO MEAM PEASE 2 February 17, 2022 12 of 14 DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 Compensation Total compensation for the ENGINEER contemplated under the terms of this agreement shall be a total not-to-exceed $751,100 for all services including reimbursable expenses. The CITY shall compensate the ENGINEER as follows: For Tasks 1-16 the total compensation shall be on a reimbursable (hourly) basis and not to exceed $751,100. Progress payments for shall be paid monthly based on the actual work satisfactorily completed per month in each phase, with the following amounts of the total compensation for each phase of the Project Task TaskAmount Task 1 – Design Management Task 2 – Alignment Study Task 3 – Preliminary Design Task 4 – Final Design Task 5 – Construction Contract Documents Task 6 – Bid Phase Services Task 7 – Construction Phase Services Task 8 – Record Drawings Preparation Task 9 – Permitting Task 10 – Survey and Easements Task 11 – Easement Acquisition Services Task 12 – Conflict Analysis Task 13 – Lift Station Preliminary Engjneering Report (PERTasm+TLift Station Prelr Task 15 – Lift Station Bid Phase Services Task 16 – Lift Station Const. Phase Services $5,500 $ 19,700 $ 142,000 $98,600 84,600 $3,800 $6,600 $5,000 850,200 880, 100 $80,800N/A $26,000 $ 1 84,300 86,300 $37,600 Totals $751,100 ENGINEER will not exceed the total maximum labor fee shown without authorization from the CITY. Individual task amounts are provided for budgeting purposes only. ENGINEER reserves the right to reallocate amounts among tasks as necessary. Labor fee will be billed on an hourly basis according to our then-current rates. As to these tasks, direct reimbursable expenses such as express delivery services, fees, air travel, and other direct expenses will be billed at 1.10 times cost. A percentage of labor fee will be added to each invoice to cover certain other expenses as to these tasks such as telecommunications, in-house reproduction, postage, supplies, project related computer time, and local mileage. Administrative 1-35 – SPLIT TO MELAM PHASE 2 February 17, 2022 13 of 14 DocuSign Envelope ID: 8C471F51-6D932ID22-8A61-788113991955 time related to the project may be billed hourly. All permitting, application, and similar project fees will be paid directly by the CITY. Payment will be due within 25 days of your receipt of the invoice and should include the invoice number and Kimley-Horn project number. Duly executed by each party’s designated representative to be effective on the date subscribed by theCITY. BY: BY: CITY OF DENTON, TEXAS ENGINEER es, Inc P.a. Title: John Atkins. Vice President Date: 2/17/2022 laaIn Al. Title: Date: 1-35 – SPLIT TO MLAM PHASE 2 February 17, 2022 14 of 14 T)g NoiNxa (wrllw or UldS Mnscl WOUI)SNOllV3013U LUlllrl se-HINOIN3a JO ALIO <urzNv9 iO Hrnos)dVW NOllV901 9NllnouU3M3S XLIAVU9uid}{& Aal©!]‘iI;g gig : i ! !!!aZ LLI(9LU--1 1--1 { I jd \ +itA \ \'1 1 } II {/f /• / 1 / i i i 3 iE i i ! --\I /1- ‘ /Hin / +] DocuSign Envelope ID: 8C471F51-6D934D22-8A61-788413991955 Exhibit CIQ CONFLICT OF INTEREST QUESTIONNAIRE - For vendor or other person doing business with local governmental entit' I eg., Regular Session. FORM CIQ This questionnaire is being filed in accordance with Chapter 176, Local Government Code, by a vendor who has a business relationship asdefined by Section 176.001(1-a) with a local governmental entity and the vendor meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local government entity not later than the 7th business day afterthe date the vendor becomes aware of facts that require the statement to be filed. See Section 176.006(a-1), Local Government Code. A vendor commits an offense if the vendor knowingly violates Section 176,006, Local Government Code. An offense under this section is amisdemeanor. rE Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7th businessday after the date on which you became aware that the originally filed questionnaire was incomplete or inaccurate. d Name of local government officer about whom the information in this section is being disclosed. Name of Officer This section, (item 3 including subparts A, B, C & D), must be completed for each officer with whom the vendor has an employment or other business relationshipas defined by Section 176.001(1-a), Local Government Code. Attach additional pages to this Form CIQ as necessary. A.Is the local government officer named in this section receiving or likely to receive taxable income, other than investment income, from the vendor?n Yes E No B Is the vendor receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officernamed in this section AND the taxable income is not received from the local governmental entity?[] Yes [] No C. Is the filer of this questionnaire employed by a corporation or other business entity with respect to which the local government officer serves as anofficer or director, or holds an ownership of one percent or more? = Yes n No D Describe each employment or business and family relationship with the local government officer named in this section. 4 5 [8 1 have no Conflict of Interest to disclose. 4/13/2022 oing business with the governmental entity Date [Xx:uSign Certificate Of Completion Envelope Id: 8C471 F516D934D228A61788413991955 Subject: Please DocuSign: City Council Contract 7574-010–135 Split to Milam Phase II Status: Completed Source Envelope: Document Pages: 34 Certificate Pages: 7 Signatures: 6 Initials:1 Envelope Originator: Crystal Westbrook 901 B Texas Street Denton, TX 76209 AutoNav: Enabled Envelopeld StampIng: Enabled Time Zone: (UTC-06:00) Central Time (US & Canada)crystal.westbrook@cityofdenton.com IP Address: 198.49.140.104 Record Tracking Status: Original 4/7/2022 4:21 :30 PM Holder: Crystal Westbrook crystal.westbrook@cityofdenton.com Location: DocuSign Signer Events Crystal Westbrook crystal.westbrook@cityofdenton.com Senior Buyer City of Denton Security Level: Email, Account Authentication(None) Signature Timestamp Sent: 4/7/2022 4:27:48 PM Viewed: 4/7/2022 4:30:07 PM Signed: 4/7/2022 4:31 :42 PM Completed Signed by link sent to crystal.westbrook@cityofdenton.com Using IP Address: 198.49.140.104 Electronic Record and Signature Disclosure:Not Offered via DocuSign Lori Hewell lori.hewell@cityofdenton.com Purchasing Manager City of Denton Security Level: Email, Account Authentication(None) Sent: 4/7/2022 4:31 :45 PM Viewed: 4/7/2022 4:39:32 PM Signed: 4/7/2022 4:40:12 PM Signature Adoption: Pre-selected Style Signed by link sent to lori.hewell@cityofdenton.com Using IP Address: 198.49.140.10 Electronic Record and Signature Disclosure:Not Offered via DocuSign Marcella Lunn marcella.lunn@cityofdenton.com Deputy City Attorney City of Denton Security Level: Email, Account Authentication(None) IMAyulhtAhh .4B070&31B4AA438, Sent: 4/7/2022 4:40:15 PM Viewed: 4/12/2022 2:11 :46 PM Signed: 4/12/2022 2:14:56 PM Signature Adoption: Pre-selected Style Signed by link sent to marcella.lunn@cityofdenton.com Using IP Address: 198.49.140.104 Electronic Record and Signature Disclosure:Not Offered via DocuSign John Atkins john.atkins@kimley-horn.com Vice President Security Level: Email, Account Authentication(None) 'Doc&lShn•d bFlaw @Lita .25073Q3EA77F471 Sent: 4/12/2022 2:20:45 PM Viewed : 4/1 3/2022 9:11 :26 AM Signed: 4/13/2022 10:07:21 PM Signature Adoption: Pre-selected Style Signed by link sent to john.atkins@kimley-horn.com Using IP Address: 208.127.245.199 Electronic Record and Signature Disclosure: Signer Events Signature Accepted: 4/1 3/2022 9:11 :26 AMID: caOf2356-8aOa2ldb3-a921-50ece06c3baf Timestamp Stephen D. Gay stephen.gay@cityofdenton.com Director Security Level: Email, Account Authentication(None) 'DocuSigrnd brI ;'MP. „“FEB48B89726E4A9 Sent: 4/13/2022 10:07:24 PM Viewed: 4/14/2022 5:30:42 AM Signed: 4/14/2022 5:31 :42 AM Signature Adoption: Pre-selected Style Signed by link sent to stephen.gay@cityofdenton.com Using IP Address: 47.186.197.168 Signed using mobile Electronic Record and Signature Disclosure:Accepted: 4/14/2022 5:30:42 AMID: f2620225-3b422105d-bc31-9c317eadOOa2 John Atkins John.Atkins@kimley-horn.com Vice President Security Level: Email, Account Authentication(None) Completed Se-t: 5/13/2022 3:21 :23 PM_- Resent: 5/13/2022 3:34:37 PM Viewed: 5/1 3/2022 3:35:48 PM Signed by link sent to John.Atkins@kimley-horn'com Signed: 5/1 3/2022 3:36:08 PMUsing IP Address: 208.127.242.84 Electronic Record and Signature Disclosure:Accepted: 5/13/2022 3:35:48 PMID: 5d514af4-f65e4df5-b071-9de59a464ebd Cheyenne Defee cheyenne.defee@cityofdenton.com Procurement Administration Supervisor City of Denton Security Level: Email, Account Authentication (None) Completed Sent: 4/14/2022 5:31 :46 AM Viewed: 5/1 8/2022 12:48:43 PM Signed: 5/1 8/2022 12:49:03 PMSigned by link sent to cheyenne.defee@cityofdenton.com Using IP Address: 198.49.140.10 Electronic Record and Signature Disclosure:Not Offered via DocuSign Sara Hensley sara.hensley@cityofdenton.com City Manager City of Denton Security Level: Email, Account Authentication(None) Sent: 5/18/2022 12:49:06 PM Viewed: 5/1 8/2022 12:55:57 PM Signed: 5/1 8/2022 12:56:03 PM Signature Adoption: Pre-selected Style Signed by link sent to sara.hensley@cityofdenton.com Using IP Address: 198.49.140.10 Electronic Record and Signature Disclosure: Not Offered via DocuSign Rosa Rios rosa.rios@cityofdenton.com City Secretary Security Level: Email, Account Authentication(None) Sent: 5/1 8/2022 12:56:07 PM Viewed: 5/18/2022 1 :54:07 PM Signed: 5/1 8/2022 1:54:23 PM Signature Adoption: Pre-selected Style Signed by link sent to rosa.rios@cityofdenton.com Using IP Address: 198.49.140.10 Electronic Record and Signature Disclosure:Accepted: 5/18/2022 1 :54:07 PMID: 574b2372-a01d4b72-837c<i9b6229cf1 d8 In Person Signer Events Signature Timestamp Editor Delivery Events Status Status Timestamp Agent Delivery Events Timestamp Intermediary Delivery Events Status Timestamp Certified Delivery Events Status Timestamp Carbon Copy Events Cheyenne Defee cheyenne.defee@cityofdenton.com Procurement Administration Supervisor City of Denton Security Level: Email, Account Authentication(None) Electronic Record and Signature Disclosure:Not Offered via DocuSign Status Timestamp Sent: 4/7/2022 4:31 :45 PM Scott Arnold scott.arnold@kimley-horn.com Vice President Kimley-Horn and Associates, Inc. Security Level: Email, Account Authentication(None) ElectronIc Record and Signature Disclosure: Accepted: 3/27/2020 10:55:11 AMID: alf38400-e5cc2lb57-85484dd7e031355d Sent: 4/12/2022 2:20:48 PM Viewed: 4/13/2022 8:47:39 AM Gretna Jones gretna.jones@cityofdenton.com Legal Secretary City of Denton Security Level: Email, Account Authentication(None) Electronic Record and Signature Disclosure:Not Offered via DocuSign Sent: 4/14/2022 5:31 :45 AM Viewed: 4/15/2022 2:52:36 PM City Secretary Office citysecretary@cityofdenton.com Security Level: Email, Account Authentication(None) Electronic Record and Signature Disclosure:Not Offered via DocuSign Sent: 5/18/2022 1 :54:26 PM Viewed: 5/18/2022 2:15:01 PM Annie Bunger annie.bunger@cityofdenton.com Security Level: Email, Account Authentication(None) Electronic Record and Signature Disclosure:Not Offered via DocuSign Sent: 5/18/2022 1 :54:28 PM David Brown david.brown@cityofdenton.com Security Level: Email, Account Authentication (None) Electronic Record and Signature Disclosure:Accepted: 4/10/2019 2:54:36 PMID: 20238ddf-ccd6-+d52-988f-8c9f3436055e Sent: 5/1 8/2022 1 :54:29 PM Witness Events Signature Signature Timestamp Notary Events Timestamp Envelope Summary Events Envelope Sent Certified Delivered Signing Complete Completed Status Timestamps 4 m/2022 4:27:48 PM 5/1 8/2022 1 :54:07 PM 5/1 8/2022 1 :54:23 PM 5/1 8/2022 1 :54:29 PM Hashed/Encrypted Security Checked Security Checked Security Checked Payment Events Status Timestamps Electronic Record and Signature Disclosure Electronic Record and Signature Disclosure created on: 7/21/2017 3:59:03 PM Parties agreed to: John Atkins, Stephen D. Gay, John Atkins, Rosa Rios, Scott Arnold, David Brown ELECTRONIC RECORD AND SIGNATURE DISCLOSURE From time to time, City of Denton (we, us or Company) may be required by law to provide to you certain written notices or disclosures. Described below are the terms and conditions for providing to you such notices and disclosures electronically through your DocuSign, Inc. (DocuSign) Express user account. Please read the information below carefully and thoroughly,and if you can access this information electronically to your satisfaction and agree to these terms and conditions, please confirm your agreement by clicking the 'I agree' button at the bottom ofthis document. Getting paper copies At any time, you may request from us a paper copy of any record provided or made available electronically to you by us. For such copies, as long as you are an authorized user of the DocuSign system you will have the ability to download and print any documents we send to you through your DocuSign user account for a limited period of time (usually 30 days) after such documents are first sent to you. After such time, if you wish for us to send you paper copies of any such documents from our office to you, you will be charged a $0.00 per-page fee. You mayrequest delivery of such paper copies from us by following the procedure described below. Withdrawing your consent If you decide to receive notices and disclosures from us electronically, you may at any time change your mind and tell us that thereafter you want to receive required notices and disclosures only in paper format. How you must inform us of your decision to receive future notices and disclosure in paper format and withdraw your consent to receive notices and disclosures electronically is described below. Consequences of changing your mind If you elect to receive required notices and disclosures only in paper format, it will slow the speed at which we can complete certain steps in transactions with you and delivering services to you because we will need first to send the required notices or disclosures to you in paper format, and then wait until we receive back from you your acknowledgment of your receipt of such paper notices or disclosures. To indicate to us that you are changing your mind, you must withdraw your consent using the DocuSign 'Withdraw Consent' form on the signing page of your DocuSign account. This will indicate to us that you have withdrawn your consent to receive required notices and disclosures electronically from us and you will no longer be able to use your DocuSign Express user account to receive required notices and consents electronically from us or to sign electronically documents from us. All notices and disclosures will be sent to you electronically Unless you tell us otherwise in accordance with the procedures described herein, we will provide electronically to you through your DocuSign user account all required notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you during the course of our relationship with you. To reduce the chance of you inadvertently not receiving any notice or disclosure, we prefer to provide all of the required notices and disclosures to you by the same method and to the same address that you have given us. Thus, you can receive all the disclosures and notices electronically or in paper format through the paper mail delivery system. If you do not agree with this process, please let us know as described below. Please also see the paragraph immediately above that describes the consequences of your electing not to receive delivery of the notices and disclosures electronically from us. How to contact City of Denton: You may contact us to let us know of your changes as to how we may contact you electronically, to request paper copies of certain information from us, and to withdraw your prior consent to receive notices and disclosures electronically as follows: To contact us by email send messages to: purchasing@cityofdenton.com To advise City of Denton of your new e-mail address To let us know of a change in your e-mail address where we should send notices and disclosures electronically to you, you must send an email message to us at melissa.kraft@cityofdenton.com and in the body of such request you must state: your previous e-mail address, your new e-mail address. We do not require any other information from you to change your email address.. In addition, you must notify DocuSign, Inc to arrange for your new email address to be reflected in your DocuSign account by following the process for changing e-mail in DocuSign. To request paper copies from City of Denton To request delivery from us of paper copies of the notices and disclosures previously provided by us to you electronically, you must send us an e-mail to purchasing @cityofdenton.com and in the body of such request you must state your e-mail address, full name, US Postal address, and telephone number. We will bill you for any fees at that time, if any.To withdraw your consent with City of Denton To inform us that you no longer want to receive future notices and disclosures in electronic format you may: i. decline to sign a document from within your DocuSign account, and on the subsequent page, select the check-box indicating you wish to withdraw your consent, or you may; ii. send us an e-mail to purchasing@cityofdenton.com and in the body of such request youmust state your e-mail, full name, IS Postal Address, telephone number, and account number. We do not need any other information from you to withdraw consent.. The consequences of your withdrawing consent for online documents will be that transactions may take a longer time to process.. ReI lired hardware and software rating Systems0 Browsers (for SENDERS Browsers (for SIGNERS): r r lternet Explorer 6.0?, Mozilla FireFox 1.0NetSl}e 7.2 (or above),ccess to a valid email account x mr Screen Resolution abled Security Settings •Allow per session cookies •Users accessing the internet behind a Proxy Server must enable HTFP 1.1 settings viaroxy connection ++ These minimum requirements are subject to change. If these requirements change, we will provide you with an email message at the email address we have on file for you at that time providing you with the revised hardware and software requirements, at which time you will have the right to withdraw your consent. Acknowledging your access and consent to receive materials electronically To confirm to us that you can access this information electronically, which will be similar to other electronic notices and disclosures that we will provide to you, please verify that you were able to read this electronic disclosure and that you also were able to print on paper or electronically save this page for your future reference and access or that you were able toe-mail this disclosure and consent to an address where you will be able to print on paper or save it for your future reference and access. Further, if you consent to receiving notices anddisclosures exclusively in electronic format on the terms and conditions described above, please let us know by clicking the 'I agree' button below. By checking the 'I Agree' box, I confirm that: • I can access and read this Electronic CONSENT TO ELECTRONIC RECEIPT OF ELECTRONIC RECORD AND SIGNATURE DISCLOSURES document; and • I can print on paper the disclosure or save or send the disclosure to a place where I can print it, for future reference and access; and • Until or unless I notify City of Denton as described above, I consent to receive from exclusively through electronic means all notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to me by City of Denton during the course of my relationship with you.