2002-051AN ORDINANCE AUTHORIZING COMPETITIVE BIDS AND AWARDING A PUBLIC
WORKS CONTRACT FOR THE CONSTRUCTION OF SITE WORK, FOUNDATION,
GROUND GRID, CONDUIT SYSTEM AND FENCING FOR THE INUDUSTRIAL
SUBSTATION; PROVIDING FOR THE EXPENDITURE OF FUNDS THEREFORE; AND
PROVIDING AN EFFECTIVE DATE (BID 2795- INDUSTRIAL SUBSTATION SITE WORK,
AWARDED TO CAN-FER CONSTRUCTION COMPANY, IN THE AMOUNT OF $259,900).
WHEREAS, the City has solicited, received and tabulated competitive bi'ds for the
construction of public works or improvements in accordance with the procedures of STATE law and
City ordinances; and
WHEREAS, the City Manager or a designated employee has received and recommended that
the herein described bids are the lowest responsible bids for the construction of the public works or
improvements described in the bid invitation, bid proposals and plans and specifications therein;
NOW, THEREFORE,
THE COUNCIL OF THE CITY OF DENTON HEREBY ORDAINS:
SECTION I. That the following competitive bids for the construction of public works or
improvements, as described in the "Bid Invitations", "Bid Proposals" or plans and specifications on
file in the Office of the City's Purchasing Agent filed according to the bid number assigned hereto,
are hereby accepted and approved as being the lowest responsible bids:
BD
NUMBER CONTRACTOR AMOUNT
2795 Can-Fer Construction Company $259,900
SECTION 1I. That the acceptance and approval of the above competitive bids shall not
constitute a contract between the City and the person submitting the bid for construction of such
public works or improvements herein accepted and approved, until such person shall comply with all
requirements specified in the Notice to Bidders including the timely execution of a written contract
and furnishing of performance and payment bonds, and insurance certificate after notification of the
award of the bid.
SECTION Iii. That the City Manager is hereby authorized to execute all necessary written
contracts for the performance of the construction of the public works or improvements in accordance
with the bids accepted and approved herein, provided that such contracts are made in accordance
with the Notice to Bidders and Bid Proposals, and documents relating thereto specifying the terms,
conditions, plans and specifications, standards, quantities and specified sums contained therein.
SECTION IV. That upon acceptance and approval of the above competitive bids and the
execution o f contracts for the public works and improvements as authorized herein, the City Council
hereby authorizes the expenditure of funds in the manner and in the amount as specified in such
approved bids and authorized contracts executed pursuant thereto.
SECTION V. That this ordinance shall become effective immediately upon its passage and
approval.
PASSED AND APPROVED this the
i'6~ day of ~ff~~ ,2002
EULINE BROCK, MAYOR
ATTEST:
JENNIFER WALTERS, CITY SECRETARY
APPR~ )VED AS TO LEGAL FORM:
HERBERT L. PROUT~7TTORNEY
BID 2795 -Industrial S~- Contractual Ord.
;I
Ltl
0 ~ -
> o ~
0
~ X
~ °
o
z o~ ~ ~ > > z
CONTRACT AGREEMENT
STATE OF TEXAS §
COUNTY OF DENTON §
THIS AGREEMENT, made and entered into this 19~
A.D., 2002, by and between City of Denton
of the County of Denton
Michael A. Conduff
.day of February 20,
and State of Texas, acting through
thereunto duly authorized so to do,
hereinafter termed "OWNER," and
Can-fer Construction Company
11150 Morrison Ln
Dallas, TX 75229
of the City of Dallas ., County of Dallas
and State of Texas
, hereinafter termed "CONTRACTOR."
WlTNESSETH: That for and in consideration of the payments and agreements
hereinafter mentioned, to be made and performed by OWNER. and under the conditions
expressed in the bonds attached hereto, CONTRACTOR hereby agrees with OWNER to
commence and complete performance of the work specified below:
Bid 2795 Industrial Substation Site Work, Foundations, Ground Grid, Conduit System, and
Fence
in the amount of $259,900 and all extra work in connection therewith, under the terms
as stated in the General Conditions of the agreement; and at his (or their) own proper cost and
expense to furnish all materials, supplies, machinery, equipment, tools, superintendence,
labor, insurance, and other accessories and services necessary to complete the work specified
above, in accordance with the conditions and prices stated in the Proposal attached hereto, and
in accordance with all the General Conditions of the Agreement, the Special Conditions, the
Notice to Bidders (Advertisement for Bids), Instructions to Bidders, and the Performance and
Payment Bonds, all attached hereto, and in
CA- 1
accordance with the plans, which includes all maps, plats, blueprints, and other drawings and
printed or written explanatory matter thereof, and the Specifications therefore, as prepared by:
City of Denton Staff
all of which are made a part hereof and collectively evidence and constitute the entire contract.
Independent Status
It is mutually understood and agreed by and between City and Contractor that
Contractor is an independent contractor and shall not be deemed to be or considered an
employee of the City of Denton, Texas, for the purposes of income tax, withholding, social
security taxes, vacation or sick leave benefits, worker's compensation, or any other City
employee benefit. City shall not have supervision and control of Contractor or any employee
of Contractor, and it is expressly understood that Contractor shall perform the services
hereunder according to the attached specifications at the general direction of the City Manager
of the City of Denton, Texas, or his designee under this agreement.
Indemnification
Contractor shall and does hereby agree to indemnify and hold harmless the City of
Denton from any and all damages, loss, or liability of any kind whatsoever, by reason of
injury to property or third persons occasioned by any error, omission or negligent act of
Contractor, its officers, agents, employees, invitees, and other persons for whom it is legally
liable, with regard to the performance of this Agreement, and Contractor will, at its cost and
expense, defend and protect the City of Denton against any and all such claims and demands.
Choice of Law and Venue
This agreement shall be governed by the law of the State of Texas and venue for its
construction and enforcement shall lie in the courts of Denton County, Texas.
The CONTRACTOR hereby agrees to commence work on or after the date established
for the start of work as set forth in written notice to commence work and complete all work
within the time stated in the Proposal, subject to such extensions of time as are provided by
the General and Special Conditions.
The OWNER agrees to pay the CONTRACTOR in current funds the price or prices
shown in the Proposal, which forms a part of this contract, such payments to be subject to the
General and Special Conditions of the Contract.
CA - 2
IN WITNESS WHEREOF, the parties of these presents have executed this agreement
in the year and day first above written.
OWNER
BY: ~
ATTEST:
(SEAL)
CONTRACTOR
APPROVED AS TO FORM:
CA - 3
MAILING ADDRESS
PHONE NUMBER
FAX N~BER / /
C~ ~'~eeaet5 [/.P.
PRINTED NAME
(SEAL)
BID PROPOSAL
To:
City of Denton, Texas
Purchasing Department
901-B Texas Street
Denton, Texas
For Bid Number: 2795
Project Title: Industrial Substation Site Work~ Foundations,
Ground Grid, Conduit System, and Fence
From: Company Name: Can-Fer Construction Company
Mailing Address: 11150 Morrison Lane
City, Stme, Zip: Dallas, Texas 75229
T~ephone: (9723 484-4344
Fax: (972) 484-4223
We offer the bid price stated on the following page in accordance with the specification
for the above referenced project with materials to be delivered and work to be completed
on the Spencer Utihty Site in Denton, Texas.
In submitting the attached bids, Can-Fer Construction Company .(company
name) agrees that acceptance of any or all items by the City of Denton, Texas withJn 60
days constitutes a contract. The complete bid proposal must be properly priced, signed,
and returned.
Bidder:
Signature:
Title:
Vice President
Date:
January 31, 2002
Page 1 of 2
BID PROPOSAL
Industrial Substation Site Work, Foundations, Ground Grid, Conduit System, and Fence
City of Denton
Bid Number: 2795
Supplier: Can-Fer Construction Company
Bid Summary:
Item Price
· Earthwork 20,000
Gravel .' 65 ;~000
Foundations · 140,500
Ground Grid 15,000
Conduit System 17,500
Fence 21,900
Total Bid Price 259,900
Total bidpfice in words: Two Hundred Fifty Nine Thousand Nine Hundred Dollars
Construction can be completed between March 112002 and June 1, 2002? 'X Yes No
Are there any exceptions to the specifications? None
If there are exceptions to the specifications, explain all such exceptions (attach additional page if necessary).
Page 2 of 2
· . Bond No. TX 575951
PERFORMANCE BOND
STATE OF TEXAS §
COUNTY OF DENTON §
KNOW ALL MEN BY THESE PRESENTS: That Can-fer Construction Company
whose address is 11150 Morrison Ln, Dallas, TX 75229 ,
hereinafter called Principal, and Merchants Bondinq Company (Mutual) ,
a corporation organized and existing under the laws of the State of Iowa , and
fully authorized to transact business in the State of Texas, as Surety, are held and faxniy bound
unto the City of Denton, a municipal corporation organized and existing under the laws of the
State of Texas, hereinafter called Owner, in the penal sum of Two Hundred & Fifty Nine
Thousand, Nine Hundred DOLLARS ($ 259,900 ) plus ten percent of the stated penal sum as
an additional sum of money representing additional court expenses, attorneys fees, and
liquidated damages arising out of or connected with the below identified Contract, in lawful
money of the United States, to be paid in Denton County, T~xas, for the payment of which
sum well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators,
successors, and assigns, jointly and severally, fmuly by these presents. This Bond shall
automatically be increased by the amount of any Change Order or Supplemental Agreement
which increases the Contract price, but in no event shall a 'Change Order or Supplemental
Agreement which reduces the Contract price decrease the penal sum of this Bond.
THE OBLIGATION TO PAY SAME is conditioned as follows: Whereas, the
Principal entered into a certain Contract, identified by Ordinance Number 2002-051
with the City of Denton, the Owner, dated the 19~ day of February
A.D. 2002 ., a copy of which is hereto attached and made a part hereof, for
Bid 2795 - Industrial Substation Site Work, Foundations, Ground Grid, Conduit System, and
Fence.
NOW, THEREFORE, if the Principal shall well, truly and faithfully perform and
fulfill all of the undertakings, covenants, terms, conditions and agreements of said Contract in
accordance with the Plans, Specifications and Contract Documents during the original term
thereof and any extension thereof which may be granted by the Owner, with or without notice
to the Surety, and during the life of any guaranty or warranty required under this Contract,
and shall also well and truly perform and fulfill all the undertakings, covenants, terms,
conditions and agreements of any and all duly authorized modifications of said Contract that
may hereafter be made, notice of which modifications to the Surety being hereby waived; and,
if the Principal shall repair and/or replace all defects due to faulty materials and workmanship
that appear within a period of one (1) year from the date of final completion and final
acceptance of the Work by the Owner; and, if the Principal shall fully indemnify and save
harmless the Owner from all costs and damages which Owner may suffer by reason of failure
to so perform herein and shall fully reimburse and repay Owner all outlay and expense which
the Owner may incur in making good any default or deficiency, then this obligation shall be
void; otherwise, it shall remain in full force and effect.
PB - 1
PROVIDED FURTHER, that if any legal action be filed upon this Bond, exclusive
venue shall lie in Denton County, State of Texas.
AND PROVIDED FURTHER, that the said Surety, for value received, hereby
stipulates and agrees that no change, extension of time, alteration or addition to the terms of
the Contract, or to the Work to be performed thereunder, or to the Plans, Specifications,
Drawings, etc., accompanying the same, shall in anywise affect its obligation on this Bond,
and it does hereby waive notice of any such change, extension of time, alteration or addition to
the terms of the Contract, or to the Work to be performed thereunder, or to the Plans,
Specifications, Drawings, etc.
This Bond is given pursuant to the provisions of Chapter 2253 of the Texas
Government Code, as amended, and any other applicable statutes of the State of Texas.
The undersigned and designated agent is hereby designated by the Surety herein as the
Resident Agent in Denton County to whom any requisite notices may be delivered and on
whom service of process may be had in matters arising out of such suretyship, as provided by
Article 7.19-1 of the Insurance Code, Vernon's Annotated Civil Statutes of the State of Texas.
IN WITNESS WHEREOF, this instrument is executed in 4 copies, each one of
which shall be deemed an original, this the 19th day of F~bruarY ,2002 ·
ATTEST: PRINCIPAL
BY:
SECRETARY
Can-Fer Gonstruction
~lG~' PI~t-D~NT /
ATTEST: SURETY
BY: ' '
Merchants Bonding Company (Mutual)
BY: ~
ATTORN/Y~IN-FA~T Ray Watson
The Resident Agent of the Surety in Denton County, Texas for delivery of notice and service
of the process is:
NAME: Ray Watson
STREET ADDRESS:
1701 N. Greenville, Ste 811
Richardson, TX 75081
(NOTE: Date of Performance Bond must be date of Contract.
corporation, give a person's name.)
PB - 2
If Resident Agent is not a
Bond No. TX 575951
PAYMENT BOND
STATE OF TEXAS §
COUNTY OF DENTON §
KNOW ALL MEN BY THESE PRESENTS: That Can-fer Construction Company
whose address is 11150 Morrison Ln, Dallas, TX 75229 ,
hereinafter called Principal, and Merchants Bondinq Company (Mutual) ,
a corporation organized and existing under the laws of the State of Io~ra , and fully
authorized to transact business in the State of Texas, as Surety, are held and firmly bound unto
the City of Denton, a municipal corporation organized and existing under the laws of the State
of Texas, hereinafter called Owner, and unto all persons, fLrms, and corporations who may
furnish materials for, or perform labor upon, the building or improvements hereinafter
referred to, in the penal sum of Two Hundred & Fifty Nine Thousand, Nine Hundred
DOLLARS ($ 259,900 ) in lawful money of the United States, to be paid in Denton,
County, Texas, for the payment of which sum well and truly to be made, we hereby bind
ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally,
firrniy by these presents. This Bond shall automatically be increased by the amount of any
Change Order or Supplemental Agreement which increases the Contract price, but in no event
shah a Change Order or Supplemental Agreement which reduces the Contract price decrease
the penal sum of this Bond.
THE OBLIGATION TO PAY SAME is conditioned as follows: Whereas, the
Principal entered into a certain Contract, identified by Ordinance Number 2002-051
with the City of Denton, the Owner, dated the 19~ day of February
A.D. 2002 , a copy of which is hereto attached and made a part hereof, for
Bid 2795 - Industrial Substation Site Work, Foundations, Ground Grid, Conduit System, and
Fence.
NOW, THEREFORE, if the Principal shall well, truly and faithfully perform its duties
and make prompt payment to all persons, fLrms, subcontractors, corporations and claimants
supplying labor and/or material in the prosecution of the Work provided for in said Contract
and any and all duly authorized modifications of said Contract that may hereafter be made,
notice of which modifications to the Surety being hereby expressly waived, then this obligation
shall be void; otherwise it shall remain in full force and effect.
PROVIDED FURTHER, that if any legal action be ~ed on this Bond, exclusive venue
shall lie in Denton County, Texas.
AND PROVIDED FURTHER, that the said Surety, for value received, hereby
stipulates and agrees that no change, extension of time, alteration or addition to the terms of
the Contract, or to the Work to be performed thereunder, or to the Plans, Specifications,
Drawings, etc., accompanying the same, shall in anywise affect its obligation on this Bond,
and it does hereby waive notice of any such change, extension of time, alteration or addition to
the terms of the Contract, or to the Work to be performed thereunder, or to the Plans,
Specifications, Drawings, etc.
This Bond is given pursuant to the provisions of Chapter 2253 of the Texas
Government Code, as amended, and any other applicable statutes of the State of Texas.
The undersigned and designated agent is hereby designated by the Surety herein as the
Resident Agent in Denton County to whom any requisite notices may be delivered and on
whom service of process may be had in matters arising out of such suretyship, as provided by
Article 7.19-1 of the Insurance Code, Vemon's Annotated Civil Statutes of the State of Texas.
IN WITNESS WHEREOF, this instrument is executed in 4 copies, each one of
which shall be deemed an original, this the 19th day of Febr~ary , 2002
ATTEST:
SECRETARY
PRINCIPAL
Can-Fer CDnstruction C~pany
ATTEST:
SURETY
Merchants Bonding Cc~pany (Mutual)
ATTORN]~Y-IN-FA~T Ray Watson
The Resident Agent of the Surety in Denton County, Texas for delivery of notice and service
of the process is:
NAME: Ray Watson
STREET ADDRESS:
1701 N. Greenville, Ste 811
Richardson, TX 75081
(NOTE: Date of Payment Bond must be date of Contract. If Resident Agent is not a
corporation, give a person's name.)
PB - 4
" Merchants Bonding ComPanY
POWER OF ATTORNEY "
Know mi Per. ne Sy Thaea Pr~ent~, thai the MERCHANT8 I~0NDING COMPANY (MUTUAL), ~ corporation du~y or~an~zj~d under
the law~ of'the 8tote of Iowa, end having Ire principal cf~ce In the City of Des Melnes Counb/of Polk, 8~at¢ of I~wa;]~{h made,
~nsfl~t~ and =ppein[~, and d~s by ~e~
~ ".]>J.c~.~dson . and S~,te of T?xa~ Its ~e and la~l AEomey-ln-Fa~ with ~11
and a~ho~ hereby ~nfe~ed Ih I~ name, place and st~d] to sign, ex.ute, a~nowledg, and ~eJ~var In ~ ~ha~ aa sur.~ any
and all bonds, undeda~ngs, recogn~n~s or a~er w~en qbllga~o~ In the nature ~ereof. subj.[ to the Jlm~atlon Ihat any
ths~ment shall ~ot exc~d ~e amadnt a~
~ ~x,~oN (~,0~,000',00)
and to hind ~a MERC~TS ~ONDING COMPANY (M~UAL) ~emby aa ~lly and t¢ ~a eame a~ent as ~ au~ bend or
unda~aklng was signed by ~a ~uly au~e~ad effi~m of ~e M.ERC~T8 ~ONDING COMPLY ~U~), and all ~e ac~ ~
~ld AEomey-l~Fa~, p.umuant to ~e a~od~ herein given, ara hereby m~ad and co~ed.
~ls P~er~f-A~mey l~ made and ex~ pu~uan[ ~ and by au~od~ ~e followlng ~ended $u~tuted'and R~
~ws adopted by the ~oa~ ~ DIr~o~ ~ ~e MERCH~S BONDING COMP~ (MUTUAL) on October~, 1992,
~TICLE 11, SECTION B - The Cha~an of the Bo~ or President or any ~ce President or S~m~ shall hove ~e¢
su~od~ to ap~tnt AEo~In-Fact, and to au~odze Eom to execute on beha~ of ~e Company, a~d a~sch ~e Seal cf ~e
Compsn~ them[o, ~nds and undoings, r~o~niz~n~s, con~cts of lndemn[~ ~nd other wdflng~ eb[Ig~ In the nature
ther~f.
~TJCLE 11, SECTION 9 - The slgna[ur~ of any ~u~orEed effi~r and ~e Seal o~ the Company may be a~ by
to any Power of A~omay or Ce~tioh ~e~f a~o~ng ~e exe~u~on ~nd deflve~ of any ~nd, undertaking,
mc~nEance, or ~ther sure.shy ob[[g~ons of the Company, and such slgna~ure a~d s~l ~en ~ u~ sha~l have ~e
sams fore and effect ss ~ough ~anuafly
In ~b~ ~e~, MERO~S BONDING COMP~ ~UT~) ~as mu~d thee ~rss~nb ~ be signed by ~ Pr~idsnt and
STATE OF IOWA
GOUNT~ OF pOLK ss.
On ~hls l~t . ds~ o~ .Ta~LJ~'7 , ~00i ,
me pqmonsl~ known ~o being by ma duly sworn d~ say ~ he Is Pfa~Ident of ~e ME~CHANTS BONDING COMPANY (M~UAL,
the co~mUon d~cd~ In ~e foregoing [nst~ment, end that the Seal affixed
CoGora~on and thai ~e sold Ins[~ment was s~oned and sealed In beh~ of said ~o~oratlon by ~?d~ of It~ Soard of D~rectom,
J~ TastJ~ny ~srs~, I have hersun[o ~[ ~ hand and affix~ my ~[al Sea[ a[ ~e CJ~ ~ Dss MoJnes, Iow~, ~e ds~ and y~r tim[
~vs ~sn. ' · ·
STATE OF IOWA ~.l.t ~.~.'"'
COUN~ OF PO~
1,WI amWsmsr, Jr,,Sscrs s~of he MERCHANTS 80NDIHGCOMPA~Y{MUTUAL) dohs~ebyce~s[[he~5ovssndforsgolng
Is ~ ~s and m~ co~ of ~e PO~R-OF-A~O~NEY sx~u[~ by said MERCH~YS BOND[HG COMPLY (M~), ~1~
BUll In ~fce end
In ~ ~e~, [ have h~au~b s~ my hsnd a~ ~ he ~a[ & ~e ~mpany on
2002,
.
Merchants'Bond(n§ Company
Please send all notices Of' claim on this bond to:
Merchants Bonct~ng CompaaY (Mutual)
6850'Austin Center Blvd. Suite 200
P. O..Box 26720
· Austin; TX 78755.072~) "
(512) ¢43-9033 "
COMPLAINT NOTICE: Should any dispute arise about your premium
or about a claim that you have.filed, write to the:company that issued
· the bond or policy. If the problem is not resolved, you may also write
to the State Boai'd of Insurance, P.O. Box 149091, 'Austin, Texas
78714-9091, Fax # (5i2) 475-1771. '.This notice Of complaint procedure
is for information only'and does not become a part or condition of this
bond Or policy.
MSC 0838
CITY OF DENTON
INSURANCE REQUIREMENTS FOR CONTRACTORS
Bidder's attention is directed to the insurance requirements below. It is highly recommended
that bidders confer with their respective insurance carriers or brokers to determine in
advance of Bid submission the availability of insurance certificates and endorsements as
prescribed and provided herein. If an apparent low bidder fails to comply strictly with the
insurance requirements, that bidder may be disqualified from award of the contract. Upon
bid award, all insurance requirements shall become contractual obligations which the
successful bidder shall have a duty to maintain throughout the course of this contract.
STANDARD PROVISIONS:
Without limiting any of the other obligations or liabilities of the Contractor, the Contractor
shall provide and maintain until the contracted work has been completed and accepted by the
City of Denton, Owner, the minimum insurance coverage as indicated hereinafter.
As soon as practicable after notification of bid award, Contractor shall file with the
Purchasing Department satisfactory certificates of insurance, containing the bid number and
title of the project. Contractor may, upon written request to the Purchasing Department, ask
for clarification of any insurance requirements at any time; however, Contractors are strongly
advised to make such requests prior to bid opening, since the insurance requirements may not
be modified or waived after bid opening unless a written exception has been submitted with the
bid. Contractor shall not commence any work or deliver any material until he or she
receives notification that the contract has been accepted, approved, and signed by the City of
Denton.
All insurance policies proposed or obtained in satisfaction of these requirements shall comply
with the following general specifications, and shall be maintained in compliance with these
general specifications throughout the duration of the Contract, or longer, if so noted:
· Each policy shall be issued by a company authorized to do business in the State of
Texas with an A.M. Best Company rating of at least A
Any deductibles or self-insured retentions shall be declared in the bid proposal. If
requested by the City, the insurer shall reduce or eliminate such deductibles or
self-insured retentions with respect to the City, its
officials, agents, employees and volunteers; or, the contractor shall procure a bond
guaranteeing payment of losses and related investigations, claim administration and
defense expenses.
· Liability policies shall be endorsed to provide the following:
Name as additional insured the City of Denton, its Officials, Agents,
Employees and volunteers.
That such insurance is primary to any other insurance available to the
additional insured with respect to claims covered under the policy and that
this insurance applies separately to each insured against whom claim is made
or suit is brought. The inclusion of more than one insured shall not operate
to increase the insurer's limit of liability.
· All policies shall be endorsed to READ:
"SAID POLICY SHALL NOT BE CANCELLED, NONRENEWED OR
MATERIALLY CHANGE WITHOUT 30 DAYS ADVANCED WRITTEN
NOTICE BEING GIVEN TO THE OWNER (CITY) EXCEPT WHEN THE
POLICY IS BEING CANCELLED FOR NONPAYMENT OF PREMIUM IN
WHICH CASE 10 DAYS ADVANCE WRITTEN NOTICE IS REQUIRED".
Should any of the required insurance be provided under a form of coverage that
includes a general annual aggregate limit providing for claims investigation or
legal defense costs to be included in the general annual aggregate limit, the
Contractor shall either double the occurrence limits or obtain Owners and
Contractors Protective Liability Insurance.
Should any required insurance lapse during the contract term, requests for
payments originating after such lapse shall not be processed until the City receives
satisfactory evidence of reinstated coverage as required by this contract, effective
as of the lapse date. If insurance is not reinstated, City may, at its sole option,
terminate this agreement effective on the date of the lapse.
SPECIFIC ADDITIONAL INSURANCE REQUIREMENTS:
All insurance policies proposed or obtained in satisfaction of this Contract shall additionally
comply with the following marked specifications, and shall be maintained in compliance with
these additional specifications throughout the duration of the Contract, or longer, if so noted:
IX ] A. General Liability Insurance:
General Liability insurance with combined single limits of not less than
$1,000,000 shall be provided and maintained by the Contractor. The policy shall
be written on an occurrence basis either in a single policy or in a combination of
underlying and umbrella or excess policies.
If the Commercial General Liability form (ISO Form CG 0001 current edition) is
used:
Coverage A shall include premises, operations, products, and completed
operations, independent contractors, contractual liability covering this
contract and broad form property damage coverage.
· Coverage B shall include personal injury.
· Coverage C, medical payments, is not required.
If the Comprehensive General Liability form (ISO Form GL 0002 Current Edition
and ISO Form GL 0404) is used, it shall include at least:
Bodily injury and Property Damage Liability for premises, operations,
products and completed operations, independent contractors and property
damage resulting from explosion, collapse or underground (XCU)
exposures.
Broad form contractual liability (preferably by endorsement) covering this
contract, personal injury liability and broad form property damage
liability.
IX] Automobile Liability Insurance:
Contractor shall provide Commercial Automobile Liability insurance with Combined
Single Limits (CSL) of not less than $500,000 either in a single policy or in a
combination of basic and umbrella or excess policies. The policy will include bodily
injury and property damage liability arising out of the operation, maintenance and use
of all automobiles and mobile equipment used in conjunction with this contract.
Satisfaction of the above requirement shall be in the form of a policy endorsement for:
· any auto, or
· all owned, hired and non-owned autos.
[X ] Workers Compensation Insurance
Contractor shall purchase and maintain Worker's Compensation insurance which, in addition to
meeting the minimum statutory requirements for issuance of such insurance, has Employer's
Liability limits of at least $100,000 for each accident, $100,000 per each employee, and a
$500,000 policy limit for occupational disease. The City need not be named as an "Additional
Insured" but the insurer shall agree to waive all rights of subrogation against the City, its
officials, agents, employees and volunteers for any work performed for the City by the Named
Insured. For building or construction projects, the Contractor shall comply with the provisions
of Attachment 1 in accordance with §406.096 of the Texas Labor Code and role 28TAC
110.110 of the Texas Worker's Compensation Commission (TWCC).
[]
Owner's and Contractor's Protective Liability Insurance
The Contractor shall obtain, pay for and maintain at all times during the prosecution of the
work under this contract, an Owner's and Contractor's Protective Liability insurance policy
naming the City as insured for property damage and bodily injury which may arise in the
prosecution of the work or Contractor's operations under this contract. Coverage shall be on an
"occurrence" basis, and the policy shall be issued by the same insurance company that carries
the Contractor's liability insurance. Policy limits will be at least combined bodily injury
[]
£]
£]
and property damage per occurrence with a aggregate.
Fire Damage Legal Liability Insurance
Coverage is required if Broad form General Liability is not provided or is unavailable to the
contractor or if a contractor leases or rents a portion of a City building. Limits of not less than
each occurrence are required.
Professional Liability Insurance
Professional liability insurance with limits not less than per claim with respect to
negligent acts, errors or omissions in connection with professional services is required under
this Agreement.
Builders' Risk Insurance
Builders' Risk Insurance, on an All-Risk form for 100% of the completed value shall be
provided. Such policy shall include as "Named Insured" the City of Demon and all
subcontractors as their interests may appear.
Additional Insurance
Other insurance may be required on an individual basis for extra hazardous contracts and
specific service agreements. If such additional insurance is required for a specific contract, that
requirement will be described in the "Specific Conditions" of the contract specifications.
ATTACHMENT 1
ix ]
Worker's Compensation Coverage for Building or Construction Projects for
Governmental Entities
A. Definitions:
Certificate of coverage ("cerfiflcate")-A copy of a certificate of insurance, a
certificate of authority to self-imure issued by the commission, or a coverage
agreement (TWCC-81, TWCC-82, TWCC-83, or TWCC-84), showing statutory
workers' compensation insurance coverage for the person's or entity's employees
providing services on a project, for the duration of the project.
Duration of the project - includes the time from the beginning of the work on the
project until the contractor's/person's work on the project has been completed and
accepted by .the governmental entity.
Persons providing services on the project ("subcontractor" in §406.096) - includes
all persons or entities performing all or pan of the services the contractor has
undertaken to perform on the project, regardless of whether that person contracted
directly with the contractor and regardless of whether that person has employees.
This includes, without limitation, independent contractors, subcontractors, leasing
companies, motor carriers, owner-operators, employees of any such entity, or
employees of any entity which furnishes persons to provide services on the project.
"Services" include, without limitation, providing, hauling, or delivering
equipment or materials, or providing labor, transportation, or other service related
to a project. "Services" does not include activities unrelated to the project, such as
food/beverage vendors, office supply deliveries, and delivery of portable toilets.
The contractor shall provide coverage, based on proper reporting of classification
codes and payroll amounts and filing of any overage agreements, which meets the
statutory requirements of Texas Labor Code, Section 401.011(44) for all
employees of the Contractor providing services on the project, for the duration of
the project.
C. The Contractor must provide a certificate of coverage to the governmental entity
prior to being awarded the contract.
If the coverage period shown on the contractor's current certificate of coverage
ends during the duration of the project, the contractor must, prior to the end of the
coverage period, file a new certificate of coverage with the governmental entity
showing that coverage has been extended.
E. The contractor shall obtain from each person providing services on a project, and
provide to the governmental entity:
(1)
a certificate of coverage, prior to that person beginning work on the project,
so the governmental entity will have on file certificates of coverage showing
coverage for all persons providing services on the project; and
(2)
no later than seven days after receipt by the contractor, a new certificate of
coverage showing extension of coverage, if the coverage period shown on
the current certificate of coverage ends during the duration of the project.
The contractor shall retain all required certificates of coverage for the duration of
the project and for one year thereafter.
The contractor shall notify the governmental entity in writing by certified mail or
personal delivery, within 10 days after the contractor knew or should have known,
of any change that materially affects the provision of coverage of any person
providing services on the project.
The contractor shall post on each project site a notice, in the text, form and
manner prescribed by the Texas Workers' Compensation Commission, informing
all persons providing services on the project that they are required to be covered,
and stating how a person may verify coverage and report lack of coverage.
The contractor shall contractually require each person with whom it contracts to
provide services on a project, to:
(1)
provide coverage, based on proper reporting of classification codes and
payroll amounts and filing of any coverage agreements, which meets the
statutory requirements of Texas Labor Code, Section 401.011(44) for all of
its employees providing services on the project, for the duration of the
project;
(2)
provide to the contractor, prior to that person beginning work on the project,
a certificate of coverage showing, that coverage is being provided for all
employees of the person providing services on the project, for the duration of
the project;
(3)
provide the contractor, prior to the end of the coverage period, a new
certificate of coverage showing extension of coverage, if the coverage period
shown on the current certificate of coverage ends during the duration of the
project;
(4) obtain from each other person with whom it contracts, and provide to the
contractor:
(a) a certificate of coverage, prior to the other person beginning work on
the project; and
Co) a new certificate of coverage showing extension of coverage, prior to
the end of the coverage period, if the coverage period shown on the
current certificate of coverage ends during the duration of the project;
(5) retain all required certificates of coverage on file for the duration of the
project and for one year thereafter;
(6)
notify the governmental entity in writ'mg by certified mail or personal
delivery, within 10 days after the person knew or should have known, of any
change that materially affects the provision of coverage of any person
providing services on the project; and
(7)
contractually require each person with whom it contracts, to perform as
required by paragraphs (1) - (7), with the cerfificates of coverage to be
provided to the person for whom they are providing services.
By signing this contract or providing or causing to be provided a certificate of
coverage, the contractor is representing to the governmental entity that all
employees of the contractor who will provide services on the project will be
covered by workers' compensation coverage for the duration of the project, that
the coverage will be based on proper reporting of classification codes and payroll
amounts, and that all coverage agreements will be fried with the appropriate
insurance carrier or, in the case of a self-insured, with the commission's Division
of Self-Insurance Regulation. Providing false or misleading information may
subject the contractor to administrative penalties, criminal penalties, civil penalties,
or other civil actions.
The contractor's failure to comply with any of these provisions is a breach of
contract by the contractor which entitles the governmental entity to declare the
contract void if the contractor does not remedy the breach within ten days after
receipt of notice of breach from the governmental entity.
Feb 06 02 O?:~6a CAN-FER Construcsion Co. ~72~e~23
FEB-OS-2802 ~ :~
111~0 Mor~i~on
D&llas ~x 75229
OOVERAGES
P.01/~2
THI~; CERTIFICATE IS ISSUED A8 A MATTER OF INFORMATION
ONLY AND CONFERS ND RIGHTS UPON TH~ CERTIFICATE
INSURERS AFFORDING COVERAGE
CERtiFICATE HOLDER .I 'Z [ AW~OidA~ ~u~o;;Ni~[~ LET~R; CANCEL~OH
ACORD ~S-S (7197) ~ ACORD CORPO~ ~B8
~Nir~d Car ~D LZNZ~ $25 000
~occu. ) ..jc~,~mos cu132~16.00 12/31/01 12/31/02 ~A¢'~
~ ;.c 9~E~Si- ~oucv u~ I S 500 ~
aeass/R~t~ ;~ip IH132gS5900 m 12/31/01 12/3t/o2~ ~t~i~ soo,ooo
05,000 d~. m ~xhi~it l~50~rO00
~o~t 02-06
Feb OG O~ O?:~6a CMM~FER Constpucsion Co. 9724844~23 p.3
Pk~-05-~2 E~4:54 P.02/02
t~ff~n' '~' ':: '~; :''~ ': ~,:~: ~ '-.::~J.i ',, ~ ~.'!~ ~.'.'3'~. ~,,'{~'~!: '-',~-..~ :: ... :: ..... ~.~lq~l · : u ' ;,J ~ ..:.~G~ .~:~.~·
,,~,~~..~. ~ ~ ............... ~ ~ .~
.............. NSU S~ E ~ ~e Co~t~c~.Co ................ ~.~g~ ........ DA~E ~ .0~-~ -
city o~ O~on, its O~i~lals, Agents, ~loye~s, and Volunteers ag~ liste
~ a~ a~d~tiona~ insured, A waive= of s~=~ga~io~ app~&u~ t~ ~hs Work.rs'
~ o= mmtc=~ll~ Qhang~ without 30 ~yo a~v~nced written ~otice being g~v~n
TOTAL P.02