Loading...
2001-154ORDINANCE NO - 45 AN ORDINANCE OF THE CITY OF DENTON, TEXAS APPROVING AND AUTHORIZING THE CITY MANAGER TO EXECUTE A FIRST AMENDED PROFESSIONAL SERVICES AGREEMENT WITH FREESE AND NICHOLS, INC FOR ENGINEERING SERVICES PERTAINING TO THE CONSTRUCTION PHASE AND POST- CONSTRUCTION PHASE FOR THE CITY OF DENTON LAKE RAY ROBERTS WATER TREATMENT PLANT, AUTHORIZING THE EXPENDITURE OF FUNDS THEREFOR, AND PROVIDING AN EFFECTIVE DATE WHEREAS, the City Council deems it in the public interest to continue to engage Freese and Nichols, Inc, a Texas corporation ("F&N"), to provide professional engineering services to the City pertaining to the construction phase and the post-construction phase for the City of Denton Lake Ray Roberts Water Treatment Plant, and WHEREAS, the City staff has reported to the City Council that there is a substantial need for the above-described professional engineering services, and that limited City staff clearly cannot adequately perform the services and tasks with its own personnel, and WHEREAS, Chapter 2254 of the Texas Government Code, known as the "Professional Services Procurement Act", generally provides that a City may not select a provider of professional services on the basis of competitive bids, but must select the provider on the basis of demonstrated competence, knowledge, and qualifications, and for a fair and reasonable price, and WHEREAS, the City Council has provided in its Capital Improvement Plans for the appropriation of funds to be used for the purchase of the professional engineering services, as set forth in the First Amended Professional Services Agreement, NOW, THEREFORE, THE COUNCIL OF THE CITY OF DENTON HEREBY ORDAINS SECTION 1 That the City Council approves, and the City Manager is hereby authorized to execute a First Amended Professional Services Agreement with Freese and Nichols, Inc , a Texas corporation, for professional engineering services pertaining to the construction phase and the post-construction phase for the City of Denton Lake Ray Roberts Water Treatment Plant, for an additional $987,090 00, in substantially the form of the First Amended Professional Services Agreement attached hereto and incorporated herewith by reference SECTION 2 That the award of this First Amended Agreement by the City is on the basis of the continued demonstrated competence, knowledge, and qualifications of F&N and the continued ability of F&N to perform the services needed by the City for a fair and reasonable price SECTION 3 That the expenditure of funds as provided in the attached First Amended Professional Services Agreement is hereby authorized SECTION 4 That this ordinance shall become effective immediately upon its passage and approval PASSED AND APPROVED this the day of 2001 &j4ol+g,.6zt' EULINE BROCK, MAYOR ATTEST JENNIFER WALTERS, CITY SECRETARY B APPROVED AS TO LEGAL FORM HERBERT L PROUTY, CITY ATTORNEY By V JA " S \Our DocumentAOrdmancesWIT&N First Amended PSA Ord Lake RR Wtr Turn Plant doe STATE OF TEXAS § COUNTY OF DENTON § FIRST AMENDED PROFESSIONAL SERVICES AGREEMENT FOR ENGINEERING SERVICES PERTAINING TO THE CONSTRUCTION PHASE AND POST-CONSTRUCTION PHASE FOR THE CITY OF DENTON LAKE RAY ROBERTS WATER TREATMENT PLANT THIS FIRST AMENDED AGREEMENT is made and entered into as of the /161day of a'ayL , 2001, by and between the City of Denton, Texas, a Texas Municipal Corporation, with its principal offices at 215 East McKinney Street, Denton, Texas 76201 (hereafter "OWNER") and Freese and Nichols, Inc , a Texas Corporation, with its offices at 4055 International Plaza, Suite 200, Fort Worth, Texas 76109 (hereafter "CONSULTANT"), the parties acting herein, by and through their duly-authonzed representatives and officers WHEREAS, OWNER and CONSULTANT entered into a certain "Professional Services Agreement for Engineering Service Pertaining to the Preliminary Design Phase of the Lake Ray Roberts Water Treatment Plant for the City of Denton, Texas" on the 2nd day of November, 1999, and WHEREAS, OWNER and CONSULTANT entered into a certain "Professional Services Agreement for Engineering Services Pertaining to the Final Design of, the Preparation of Construction Plans and Specifications for, and the Performance of Related Construction Phase Services for the City of Denton Lake Ray Roberts Water Treatment Plant" on the 16" day of November, which Agreement was approved by the City Council of the City of Denton, Texas on the 16" day of May, 2000, by enacting Ordinance No 2000-174, and which agreement is referred to as the "Agreement", and WHEREAS, at this time the Project is ready for the next phase, and the OWNER and CONSULTANT are ready to enter into a further "First Amended Professional Services Agreement for Engineering Services Pertaining to the Construction Phase and Post-Construction Phase for the City of Denton Lake Ray Roberts Treatment Plant", which agreement is referred to as the "First Amended Agreement" hereafter, NOW, THEREFORE, WITNESSETH, that in consideration of the mutual promises, covenants, agreements herein, and in consideration of the premises, the parties hereto do mutually AGREE as follows ARTICLE T EMPLOYMENT OF CONSULTANT The OWNER hereby contracts with CONSULTANT, as an independent contractor, and the CONSULTANT hereby agrees to perform the services herein in connection with the Project as stated in the Articles to follow, with diligence and in accordance with the professional standards customarily obtained for such services in the State of Texas The professional services set forth herein are in connection with the following described protect (the "Project") SWur Mcum=W nvmY1P11 mm&NkW],FW"m WPSR MWTPft Page 1 of 11 Professional engineering services pertaining to the Resident Representation of, the Post- Construction Phase Services of, and Special Services During Construction of the 20 MGD City of Denton, Lake Ray Roberts Water Treatment Plant ARTICLE TT SCOPE OF SERVICES The CONSULTANT shall perform the following Basic Services in a professional manner A To perform those professional services as set forth in the Scope of Services and Estimate of Hours and Costs Construction Phase and Post-Construction Phase Services" February 2001 [as mochfied on March 30,20011, prepared by CONSULTANT for OWNER, which document is attached hereto as Exhibit "A," and is incorporated herein by reference, which document is comprised of, and subdivided into the following sections 1 Narrative on Scope and Assumptions, 2 Scope of Services, and 3 Cost Proposal B If there is any conflict, or if any conflict arises between the terms of this First Amended Agreement and Exhibit "A" attached to this Agreement, the terms and conditions of this First Amended Agreement shall control over the terms and conditions of the Exhibit ARTICLE TTT ADDITIONAL SERVICES Any additional services to be performed by the CONSULTANT, if authorized by the OWNER, which are not included as Basic Services in the above-described Scope of Services, set forth as provided by Article II above, shall be later agreed-upon by OWNER and CONSULTANT, who shall determine, in writing, the scope of such additional services, the amount of compensation for such additional services, and other essential terms pertaining to the provision of such additional services by the CONSULTANT ARTICLE TV PERIOD OF SERVICE This Agreement shall become effective upon execution by the OWNER and the CONSULTANT and upon the issuance of a notice to proceed by the OWNER, and shall remain in force and effect for the period that may reasonably be required for the completion of the Project, including Additional Services, if any, and any required extensions approved by the OWNER This First Amended Agreement may be sooner terminated in accordance with the provisions hereof Tune is of the essence in this First Amended Agreement CONSULTANT shall make all reasonable efforts to complete the services set forth herein as expeditiously as possible and to meet the schedule reasonably established by the OWNER, acting through its City Manager, its Assistant City Manager for Utilities, or his designee S~AUr Dxumemf~C4nmcu101eArewe®Nlebole Pim AmmOW PSA LM"Pd. Page 2 of 11 ARTTC'T.F V COMPENSATION A COMPENSATION TERMS "Subcontract Expense" is defined as those expenses, if any, incurred by CONSULTANT in the employment of others in outside firms, for services in the area of professional engineering, or related services Any subcontractor or subconsultant billing reasonably incurred by the CONSULTANT in connection with the Project shall be invoiced to OWNER at the actual cost plus ten percent 2 "Direct Non-Labor Expense" is defined as that expense, based upon actual cost, for any out-of-pocket expense reasonably incurred by the CONSULTANT in the performance of this First Amended Agreement for long distance telephone charges, telecopy charges, messenger services, printing and reproduction expenses, out-of-pocket expenses for purchased computer time, prudently incurred travel expenses related to the work on the Project, and similar incidental expenses incurred in connection with the Project B BILLING AND PAYMENT For and in consideration of the professional services to be performed by the CONSULTANT herem, the OWNER agrees to pay CONSULTANT, based upon the satisfactory completion of the Basic Services tasks set forth in the Scope of Services as shown in Article II above, as follows 1 CONSULTANT shall perform its work on this Project in accordance with the provisions of those three (3) tasks which are described as "Task 2A- Construction Phase ($651,128), Task 3- Post-Construction Phase ($209,581), and Task 4A - Special Services During Construction Phase ($126,381)" as set forth in "Section B - Scope of Services" of Exhibit "A" as well as Exhibit "C" attached hereto and incorporated herewith by reference CONSULTANT shall be paid for services rendered pursuant to the First Amended Agreement on the basis set forth as follows Compensation shall be Cost tunes a Multiplier with a ceiling basis for Tasks 2A and 4A Compensation shall be a lump sum for Task 3 Compensation shall be actual salary with an overall multiplier of 3 2 for in-office staff and 3 0 for the Resident Representative The fee ceiling is estimated using the composite classification rates which are identified as year 2001 and 2002 in the Exhibit to the Agreement Tasks 2A and 4A are based on the 2001 rate Task 3 is based upon the year 2002 rate CONSULTANT shall bill from time sheets, on a once-monthly basis, in mimmum '/4 hour or smaller time increments, at the hourly rates or as otherwise provided OWNER agrees to pay to CONSULTANT for its professional services performed, for its Subcontractor Expense, and for its Direct Non-Labor out-of pocket expenses incurred in the Project, a total aggregate amount of fees and expenses of $987,090 2 Partial payments to the CONSULTANT will be made monthly in accordance with the statements reflecting the actual completion of the Basic Services, rendered to and approved by the OWNER through its City Manager, or its Assistant City Manager for Utilities, or lus S\Our PoCUmenu\GpuxW0lVkaaw RNialm6 Pim AmnWW P8A tMWTP4. Page 3 of 11 designee However, under no circumstances shall any monthly statement for services exceed the value of the work performed at the time a statement is rendered The OWNER may withhold the final ten (10%) percent of the above not-to-exceed amount until satisfactory completion of the Project by the CONSULTANT 3 Nothing contained in this Article shall require the OWNER to pay for any work which is unsatisfactory as reasonably determined by the City Manager, or the Assistant City Manager for Utilities or his designee, or which is not submitted by CONSULTANT to the OWNER in compliance with the terms of this First Amended Agreement The OWNER shall not be required to make any payments to the CONSULTANT at any time when the CONSULTANT is in default under this First Amended Agreement 4 It is specifically understood and agreed that the CONSULTANT shall not be authorized to undertake any work pursuant to this First Amended Agreement wluch would require additional payments by the OWNER for any charge, expense or reimbursement above the not-to-exceed amount as stated heremabove, without first having obtained the prior written authorization from the OWNER CONSULTANT shall not proceed to perform any services to be later provided for under Article III "Additional Services" without first obtaining prior written authorization from the OWNER C ADDITIONAL SERVICES For additional services authorized in writing by the OWNER in Article III heremabove, CONSULTANT shall be paid based on a to-be-agreed-upon Schedule of Charges Payments for additional services shall be due and payable upon submission by the CONSULTANT, and shall be in accordance with Article V B heremabove Statements for Basic Services and any additional services shall be submitted to OWNER no more frequently than once monthly D PAYMENT If the OWNER fails to make payments due the CONSULTANT for services and expenses within sixty (60) days after receipt of the CONSULTANT'S undisputed statement thereof, the amounts due the CONSULTANT will be increased by the rate of one percent (1%) per month from and after the said sixtieth (60th) day, and in addition, thereafter, the CONSULTANT may, after giving ten (10) days written notice to the OWNER, suspend services under this Agreement until the CONSULTANT has been paid in full for all amounts then due and owing, and not disputed by OWNER, for services, expenses and charges Provided, however, nothing herein shall require the OWNER to pay the late charge of one percent (11/o) per month as set forth herein, if the OWNER reasonably determines that the CONSULTANT's work is unsatisfactory, in accordance with Article V B of this Agreement, and OWNER has notified CONSULTANT of that fact in writing ARTICLE VT OBSERVATION AND REVIEW OF THE WORK The CONSULTANT will exercise reasonable care and due diligence in discovering and promptly reporting to the OWNER any defects or deficiencies in the work of the CONSULTANT or any of its subcontractors or subconsultants SWUr OOCamaMCOPIncW011P~wek NicJwlt Pum MeotlM PSA L0.RWTP Page 4 of 11 ARTICLE VTT OWNERSHIP OF DOCUMENTS All documents prepared or farrushed by the CONSULTANT (and CONSULTANT's subcontractors or subconsultants) pursuant to this First Amended Agreement are instruments of service and shall become the property of the OWNER upon the termination of this First Amended Agreement The CONSULTANT is entitled to retain copies of all such documents The documents prepared and furnished by the CONSULTANT are intended only to be applicable to this Project and OWNER'S use of these documents in other projects shall be at OWNER'S sole risk and expense In the event the OWNER uses the First Amended Agreement in another project or for other purposes than specified herein any of the information or materials developed pursuant to this First Amended Agreement, CONSULTANT is released from any and all liability relating to their use in that project ARTTCLE VTTT INDEPENDENT CONTRACTOR CONSULTANT shall provide services to OWNER as an independent contractor, not as an employee of the OWNER CONSULTANT shall not have or claim any right ansmg from employee status ARTICLE TX INDEMNITY AGREEMENT The CONSULTANT shall indemnify and save and hold harmless the OWNER and its officials, officers, agents, attorneys and employees from and against any and all liability, claims, demands, damages, losses and expenses, including but not limited to court costs and reasonable attorney fees incurred by the OWNER, and including without limitation damages for bodily and personal injury, death, or property damage, resulting from the negligent acts or omissions of the CONSULTANT or its officers, shareholders, agents, subcontractors, subconsultants, attorneys, and/or employees in the execution, operation, or performance of this First Amended Agreement Nothing in this First Amended Agreement shall be construed to create a liability to any person who is not a party to this First Amended Agreement and nothing herein shall waive any of the party's defenses, both at law or equity, to any claim, cause of action or litigation filed by anyone not a party to this First Amended Agreement, including the defense of governmental immunity, which defenses are hereby expressly reserved ARTTCI R X INSURANCE During the performance of the Services under this First Amended Agreement, CONSULTANT shall maintain the following insurance with an insurance company licensed to do business in the State of Texas by the State Insurance Board or any successor agency, that has a rating with A M Best Rate Carvers of at least an "A-" or above A Comprehensive General Liability Insurance with bodily injury limits of not less than $1,000,000 for each occurrence and not less than $1,000,000 in the aggregate, and with SAUr Dxumenu~CaoVOCYW1U4enekNkbole PAM AmwEM P9A LRRwwP Page 5 of 11 property damage limits of not less than $100,000 for each occurrence and not less than $100,000 in the aggregate B Automobile Liability Insurance with bodily injury limits of not less than $500,000 for each person and not less than $500,000 for each accident and with property damage limits for not less than $100,000 for each accident C Worker's Compensation Insurance in accordance with statutory requirements and Employer's Liability Insurance with limits of not less than $100,000 for each accident D Professional Liability Insurance with limits of not less than $2,000,000 annual aggregate E CONSULTANT shall famish insurance certificates or insurance policies to the OWNER to evidence such insurance coverage The insurance policies shall name the OWNER as an additional insured on all such policies to the extent that is legally possible, and shall contain a provision that such insurance shall not be cancelled or modified without at least thirty (30) days prior written notice to OWNER and CONSULTANT In such event, the CONSULTANT shall, prior to the effective date of the change or cancellation of coverage, deliver copies of any such substitute policies, furnishing at least the same policy limits and coverage, to OWNER AR TICI R XT ARBITRATION AND ALTERNATE DISPUTE RESOLUTION The parties may agree to settle any disputes under this First Amended Agreement by submitting the dispute to arbitration or other means of alternate dispute resolution such as mediation No arbitration or alternate dispute resolution ansmg out of or relating to, this First Amended Agreement involving one party's disagreement may include the other party to the disagreement without the other's approval ARTICLE XII TERMINATION OF AGREEMENT A Notwithstanding any other provision of this First Amended Agreement, either party may terminate this First Amended Agreement by providing thirty- (30) days advance written notice to the other party B Tlus First Amended Agreement may alternatively be terminated in whole or in part in the event of either party substantially failing to fulfill its obligations under this First Amended Agreement No such termination will be effected unless the other party is given (1) written notice (delivered by certified mail, return receipt requested) of intent to terminate and setting forth the reasons specifying the nonperformance or other reason(s), and not less than thirty (30) calendar days to cure the failure, and (2) an opportunity for consultation with the terminating party prior to termination C If this First Amended Agreement is terminated prior to completion of the services to be provided hereunder, CONSULTANT shall immediately cease all services upon receipt of the written notice of termination from OWNER, and shall render a final bill for services to the SburODUmenuMUM1wcuWlUTeeu6NkMl~PUrt MaJW PBA L WTPtl Page 6 of 11 OWNER within twenty (20) days after the date of termination The OWNER shall pay CONSULTANT for all services properly rendered and satisfactorily performed, and for reimbursable expenses prior to notice of termination being received by CONSULTANT, in accordance with Article V of this First Amended Agreement Should the OWNER subsequently contract with a new consultant for the continuation of services on the Project, CONSULTANT shall cooperate in providing information to the OWNER and to the new consultant If applicable, OWNER shall allow CONSULTANT a reasonable time to transition and to turn over the Project to a new consultant CONSULTANT shall turn over all documents prepared or firm shed by CONSULTANT pursuant to this First Amended Agreement to the OWNER on or before the date of termination, but may maintain copies of such documents for its files ARTICLE XTTT RESPONSIBILITY FOR CLAIMS AND LIABILITIES Approval of the work by the OWNER shall not constitute, nor be deemed a release of the responsibility and liability of the CONSULTANT, its officers, employees, agents, subcontractors, and subconsultants for the accuracy and competency of their designs or other work performed pursuant to this First Amended Agreement, nor shall such approval by the OWNER be deemed as an assumption of such responsibility by the OWNER for any defect in the design or other work prepared by the CONSULTANT, its principals, officers, employees, agents, subcontractors, and subconsultants ARTTCI R XTV NOTICES All notices, communications, and reports required or pemutted under tlus First Amended Agreement shall be personally delivered to, or telecopied to, or mailed to the respective parties by depositing same in the United States mail at the addresses shown below, postage prepaid, certified mail, return receipt requested, unless otherwise specified herem To CONSULTANT Freese and Nichols, Inc Robert Pence, Senior Vice-President 4055 International Plaza, Suite 200 Fort Worth, Texas 76109 Fax (817) 735-7491 To OWNER City of Denton, Texas City Manager 215 East McKinney Denton, Texas 76201 Fax (940) 349-8596 All notices given under this First Amended Agreement shall be effective upon their actual receipt by the party to whom such notice is given ARTTCTE XV ENTIRE AGREEMENT This First Amended Agreement consisting of eleven (11) pages and one (1) Exhibit constitutes the complete and final expression of the agreement of the parties and is intended as a complete and exclusive statement of the terms of their agreements, and supersedes all prior contemporaneous offers, promises, representations, negotiations, discussions, communications, S\Nr 0o[ummYMgol[[WWIMMe 6 NWhol[ P AIn WPBA LMWTPA Page 7 of 11 understandings, and agreements which may have been made in connection with the subject matter of this First Amended Agreement ARTTCTE XVT SEVERABILITY If any provision of this First Amended Agreement is found or deemed by a court of competent jurisdiction to be invalid or unenforceable, it shall be considered severable from the remainder of this First Amended Agreement, and shall not cause the remainder to be invalid or unenforceable In such event, the parties shall reform this First Amended Agreement, to the extent reasonably possible, to replace such stricken provision with a valid and enforceable provision which comes as close as possible to expressing the original intentions of the parties respecting any such stricken provision ARTICLE XVTT COMPLIANCE WITH LAWS The CONSULTANT shall comply with all federal, state, local laws, rules, regulations, and ordinances applicable to the work performed by CONSULTANT hereunder, as they may now read or as they may hereafter be amended ARTTCLE XVTTT DISCRIMINATION PROHIBITED In performing the services required hereunder, the CONSULTANT shall not discriminate against any person on the basis of race, color, religion, sex, national origin or ancestry, age, or physical handicap ARTTCT E XTX PERSONNEL A CONSULTANT represents that it has or will secure at its own expense all personnel required to perform all the services required under this First Amended Agreement Such personnel shall not be employees or officers of, nor have any contractual relations with the OWNER CONSULTANT shall immediately inform the OWNER in writing of any conflict of interest or potential conflict of interest that CONSULTANT may discover, or which may anse during the term of this First Amended Agreement B All services required hereunder will be performed by CONSULTANT or under its direct supervision All personnel engaged in performing the work provided for in this First Amended Agreement, shall be qualified, and shall be authorized and permitted under state and local laws to perform such services ARTTCLE XX ASSIGNABILITY The CONSULTANT shall not assign any interest in this First Amended Agreement and shall not transfer any interest in this First Amended Agreement (whether by assignment, novation or 9W.000wnenu~COw,cY~01\PfLpIC A NICMI, Pim Mm WPM LUWTPG Page 8 of 11 otherwise) without the prior written consent of the OWNER CONSULTANT shall promptly notify OWNER in writing of any change of its name as well as of any significant change in its corporate structure or in its operations ARTICLE XXT MODIFICATION No waiver or modification of this First Amended Agreement or of any covenant, condition, limitation herein contained shall be valid unless in writing and duly executed by the party to be charged therewith No evidence of any waiver or modification shall be offered or received in evidence in any proceeding ansing between the parties hereto ansmg out of, or affecting this First Amended I Agreement, or the rights or obligations of the parties hereunder, unless such waiver or modification is in writing, duly executed The parties further agree that the provisions of tlus Article will not be waived unless as herem set forth ARTICLE XXTT EFFECT OF AMENDMENT Except as specifically provided for by the First Amended Agreement, that all of the terms, covenants, conditions, agreements, rights, responsibilities, and obligations of the parties set forth in the previous Agreement, dated May 16, 2000, shall remain in full force and effect ARTTCT.F. XXTTT MISCELLANEOUS A The following exhibit is attached to, incorporated herewith by reference, and is made a part of this, First Amended Agreement for all purposes pertinent Exhibit "A!'- "Scope of Services and Estimate of Hours and Cost - Construction Phase and Post-Construction Phase Services" February 2001 [as modified on March 30, 2001] B CONSULTANT agrees that OWNER shall, until the expiration of four (4) years after the final payment made by OWNER under tlus First Amended Agreement, have access to and the right to examme any directly pertinent books, documents, papers and records of the CONSULTANT involving transactions relating to this First Amended Agreement CONSULTANT agrees that OWNER shall have access during normal working hours to all necessary CONSULTANT facilities and shall be provided adequate and appropriate working space in order to conduct examinations or audits in compliance with this Article OWNER shall give CONSULTANT reasonable advance notice of all intended examinations or audits C VeXime of any suit or cause of action under this First Amended Agreement shall he exclusively in Denton County, Texas This First Amended Agreement shall be governed by and construed in accordance with the laws of the State of Texas D For purposes of this First Amended Agreement, the parties agree that the Project Manager shall be Ray Longoria, Principal, P E, and the key persons who will perform most of the work as the Project Team, mcluding the Resident Representative, Steve Wilson, under, and in accordance with this First Amended Agreement, shall be as specifically identified and set SWUr Oarumwir\CpnincWAllPraeek NloMb PAM AmaAW P9A LMWTPtl. Page 9 of 11 forth in "Scope of Services and Estimate of Hours and Cost" document attached hereto as Exhibit "A' This First Amended Agreement has been entered into with the understanding, expectation, and the OWNER's reliance, that the above-stated employees of CONSULTANT shall perform all or a significant portion of the work on the Project Any proposed changes regarding the change of the Project Manager or other key personnel, requested by CONSULTANT, respecting one or more of the above-stated employees, shall be subject to the approval of the OWNER, which approval the OWNER shall not unreasonably withhold Nothing herein shall limit CONSULTANT from using other qualified and competent members of its firm to perform the other incidental services required herein, under its supervision or control E CONSULTANT shall commence, carry on, and complete its work on the Project with all applicable dispatch, and in a sound, economical, efficient manner, and in accordance with the provisions hereof In accomplishing the Project, CONSULTANT shall take such steps as are appropriate to ensure that the work involved is properly coordinated with any related work being earned on by the OWNER F The OWNER shall assist the CONSULTANT by placing at the CONSULTANT's disposal all available information pertinent to the Project, including previous reports, any other data relative to the Project and arranging for the access to, and make all provisions for the CONSULTANT to enter in or upon, public and private property as required for the CONSULTANT to perform professional services under this First Amended Agreement OWNER and CONSULTANT agree that CONSULTANT is entitled to rely upon information furnished to it by OWNER without the need for further inquiry or investigation into such information G The captions of this First Amended Agreement are for informational purposes only and shall not in any way affect the substantive terms or conditions of this First Amended Agreement IN WITNESS WHEREOF, the OWNER, the City of Denton, Texas has executed this First Amended Agreement in four (4) original counterparts, by and through its duly-authonzed City Manager, and CONSULTANT has executed this First Amended Agr ement by and through its duly-authonzed undersigned officer on this the _L7 -it day ofpf 2001 "OWNER" CITY OF DENTON, TEXAS By !kVANk HOWARD MARTIN, I ACTING CITY MANAGER swur~ uMCOMC m.WOMCM A Ne 19 AMMWW MA LUW?m Page 10 of 11 ATTEST JENNIFER WALTERS, CITY SECRETARY By APPROVED AS TO LEGAL FORM HERBERT L PROUTY, CITY ATTORNEY By "CONSULTANT" FREESE AND NICHOLS, INC A Te By ATTEST By 'yr C\WINNI\Peoflnyp~Tempa1vy Int=d FJn\OLMAP Nl~ hMM A.m PM LMR Page 11 of 11 Scope of Services and Estimate of Hours and Cost February 2001 Construction Phase and Post- ol Construction rim FIREESE - NICHOLS Montgomery Watson America Process Applications Incorporated Isbell Structural Engineers Prime; Subconsultants. TABLE OF CONTENTS A Narrative on Scope and Assumptions B Scope of Services C Cost Proposal L Simon W Freese P E 1900 1990 Marvin C Nichols P E 1896 1969 FREESE -~NICHOLS CITY OF DENTON LAKE RAY ROBERTS SURFACE WATER TREATMENT PLANT Memorandum TO Tim Fisher, P E FROM Raymond Longoria, P E SUBJECT Project and Cost Assumptions Construction Phase, and Post-Construction Phase Services OFF00050/DT63/1 10 DATE March 30, 2001 The Scope of Services and Estimate of Hours and Costs for the Construction Phase (Task 2A), Post- Construction Phase (Task 3) and Special Services during Construction Phase (Task 4A) for the Lake Ray Roberts Surface Water Treatment Plant are attached The Scope and Fee are based on the following assumptions SCOPE OF SERVICES The following relate to assumptions on the project scope and tasks ► Construction period of 24 months (21months to substantial completion & 3 months to final) ► Raw Water Transmission Line, Finished Water Transmission line and underground power to the Raw Water Pump Station by Others is to be completed prior to substantial completion date of SWTP ■ Single General Construction contract covering Raw Water Pump Station, Water Treatment Plant, and High Service Pump Station ► Full-time FNI Resident Representative for 24 months (21 months at 208 hrs/month`, and 3 months at 80 hrs/month) ► FNJ to provide specialty observation during construction for 8 months ► DWU is to provide one full time FTE for 24 months ► DWU is to provide on-site clerical support for 24 months ► General Contractor to provide and furnish Field Office facilities for FNI and DWU personnel ► FNI to provide O&M Manual (conventional and multimedia) ► FNI is to provide Construction Material Testing Services to support construction phase services via sub-contract with Isbell Engineering and Testing 1 Equivalent to 48 hours/week ► FNI is to provide ozone facilities operator training, start-up assistance, and ozone optimization via sub-contract arrangement with Process Application Inc ► DWU is to arrange for SCADA system configuration services via contract arrangement with MWA ► FNI to provide warranty follow-up assistance after completion of construction phase ► FNI to conduct CT testing at the intermediate ozone contactor per TNRCC guidelines ► FNI is to Develop Risk Management Program for the site CONTRACT AND FEE The following relate to assumptions on the contract document and development of the costs ► Contract will be handled as an amendment to the existing City of Denton A/E professional services agreement ► Compensation will be Cost times a Multiplier with a ceiling basis for Tasks 2A and 4A, and a lump sum basis for Task 3, with the exception of Warranty Follow-up which is to be Cost times a Multiplier with a ceiling basis ► The billing rates used will be actual salary with an overall multiplier of 3 2 for in-office staff and 3 0 for the Resident Representative ► The fee ceiling is estimated using the composite classification rates which are identified as year 2001 and 2002 in the current contract All construction phase services are based on year 2001 rate All post-construction phase services are base on year 2002 rate The Special Services also assumes the year 2001 rate ► A 10% markup is applied on all subconsultants and other direct costs (ODC's) that do not have an established rate ► Resident Representative will reside near lob site through substantial completion ► Living allowance of $850/month and lease/use of company vehicle at $400/month is included If circumstances require greater travel and travel costs for the Resident Representative than covered by the allowance, consideration will be given to compensate FNI for those costs ► Specialty Observation staff will travel daily from Fort Worth to project site ► Travel to project location is assumed to be two hours per day RT ► Travel allowance of $500/month is included for Specialty Observation ► Project Administration for the construction phase is already included in the General Representation None is included for Task 2A PA for post-construction phase and special services are included in the individual sub-tasks - END - S \Our Docummts\Comspondence\Memos\01\Lake Ray Roberts Treatment Plant-Memorandum-F&N doe [OFF00050]T \LRRWTP_CONSTR_SCOPE\PROJECT_COST_ASSUMPTIONS_MEMORANDUM DOC B SCOPE OF SERVICES Owner City of Denton Water Utilities Project Lake Ray Roberts 20 mgd Surface Water Treatment Plant Construction and Post-Construction Phase Scope of Services This scope of services includes the construction phase and post-construction phase engineering services related to the LRRWTP Project, as defined by the improvements designed by Freese and Nichols, Inc and contained in the following documents Lake Ray Roberts Water Treatment Plant -Final Plans, Specifications and Contract Documents (February, 2001) The LRRWTP Project includes a 20-mgd Lake Ray Roberts Raw Water Pump Station, a 20-mgd Ozone Water Treatment Plant, a 60-mgd High Service Pump Station and 6 MG of Storage The overall opinion of probable construction cost for the Project is estimated to range from $34 - 36 million dollars The specific elements of the Construction Phase and Post-Construction Phase portions of the Project include Task 2A Resident Representation Task 3 Post Construction Phase Services Task 4A - Special Services During Construction These scope of services tasks complement and complete the tasks presently authorized for the LRRWTP Project which include Task 1 - Final Design (Authorized 16AMY2000) Task 2 - Construction Phase Services (Authorized 16MAY2000) L Task 4 - Special Services during Design Phase (Authorized 16MAY2000) i The detailed scope of services for the Construction Phase and Post-Construction Phase of the LRRWTP Project is set forth below L Construction Phase Scope of Services LRRWTP February 16, 2001 Task 2A - Resident Representation Freese and Nichols, Inc will provide a permanent, full time Resident Representative at the site for 24 months (average of 48 hours per week through month 21, average of 80 hours per month from month 21 to 24), supplemented by Freese and Nichols, Inc staff providing Specialty Observation services for an aggregate total period of 8 months (40 hours per week) City of Denton will provide a full time FTE and field clerkfor the duration of the LRRWTP Project In providing the resident representative and specialty observation services Freese and Nichols will observe the work in progress to determine if the completed work will comply in general with the contract documents, assist with field administration of the construction contracts and endeavor to determine that the quality control programs of the contractors are producing acceptable results Freese and Nichols will not have control or charge of and will not be responsible for construction f means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the work, for the acts or omissions of the contractor, subcontractors or any other persons performing any of the work, or for the failure of any of them to carry out the work in accordance with the construction contract documents The duties, responsibilities, and limitations of authority of the resident representative will be as described in the Exhibit C Attachment, which will be added to the Agreement between Freese and Nichols, Inc and the City of Denton, dated May 16, 2000 Typical services of the Resident Representative will include a Attend pre-bid and pre-construction conferences with the Owner and F Contractor(s) Establish communication procedures with Owner and ' construction Contractor b Provide the services of a full time on-site semor resident project representative located at the LRRWTP site The resident representative will provide construction administration services for the project, and will coordinate the activities of all other inspectors provided by the Owner for the L purposes of observing the work on the pump station, pipeline, and WTP project The resident representative will observe the progress of the work, monitor compliance with the schedules and requirements of the contract documents and help resolve any conflicts needing attention The resident representative will also serve as the coordination and contact point for all communications between the Contractor and the Owner for the project c Submit monthly reports of construction progress Reports will describe L construction progress in general terms and summarized project costs, cash Construction Phase Scope of Services LRRWTP 2 February 16, 2001 F- flow, constriction schedule and pending and approved contract modifications d Maintain a document control system designed to track the processing of contractor's submittals and provide for filing and retrieval of project documentation Produce monthly reports indicating the status of all submittals in the review process Review contractor's submittals, including Requests for Information, modification requests, shop drawings, schedules, and other submittals in accordance with the requirements of the construction contract documents for the projects Monitor the progress of the contractor and Engineer in sending and processing submittals to see that documentation is being processed in accordance with schedules e Review contractors' application for payment and recommend payment in accordance with the procedures in the construction contract documents f Establish and maintain a project documentation system consistent with the requirements of the construction contract documents, including daily construction reports and tracking corrections to defective work g Provide a full time on-site representative as resident representative Provide documentation of observations made while at the site Additional full time on-site inspectors and inspectors for areas requiring specialized technical expertise will be make available on an as needed basis within the scope of this contract h Conduct weekly construction coordination meetings with the Contractor and submit weekly construction progress reports to the Owner 1 Establish and administer quality assurance procedures in accordance with the construction contract documents Notify contractors of non-conforming work observed Take action to initiate corrective procedures for defective work, coordinate special materials tests and performance tests needed to obtain a quality project L j Review quality related documents provided by the contractor such as test reports, equipment installation report or other documentation as required by the construction contract documents k Establish procedures for admimstenng constructive changes to the construction contracts Process contract modifications and negotiate with the contractor on behalf of the Owner to determine the cost and time impacts of these changes Prepare change/field order documentation for approved Construction Phase Scope of Services LRRWTP 3 February 16, 2001 It changes for execution by the Owner Routinely examine the contractor's "as-built" drawings to determine that information appears to be recorded in an accurate and timely manner by the contractor as required in the construction contract documents Se that these drawings are provided to the Design Consultant at the completion of the project so they can revise the original construction drawings in accordance with the information furnished by the construction contractor to reflect changes made in the project during construction in Assist in project completion activities at the conclusion of construction Observe completed construction for general conformance with the design concept and prepare a list of deficiencies to be corrected by the contractor before recommendation of final payment At substantial completion of the pump station and pipeline projects and completion of the lists of deficiencies, the on-site resident representative will leave the project site Additional time on the project, if required, would be considered an additional service Task 3 - Post Construction Services Post construction phase services that will be provided as a special service by FNI, if authorized by Owner, are described as follows 3 1 Operations and Maintenance Manual The Engineer will prepare a draft operation and maintenance manual for the LRRWTP Project Specific services to be performed by the Engineer will be to prepare the manual in the format that follows Prepare and submit to Owner for review a draft of the facility Operations and Maintenance manual, which will include a description of the facilities and recommendations for operation The following topics will be included L 1 Introduction Brief statement of manual purpose, description of unit processes and flow path, summary of permits and standards, which must be met, table of design criteria r t 2 Operations Considerations Discussion of operation theory, control variables, process control and process efficiency for the treatment facilities 3 Facilities Description Operation and Control of Facilities Discussion of the operation and purpose for each unit treatment process L Construction Phase Scope of Services LRRWTP 4 1 February 16, 2001 r 4 Description and Operation of the Non-Process Facilities Discussion of non-process systems, including the Administration/Operations Building, the Maintenance area and the slurry trench dewatering system 5 Utilities Descriptions and operational considerations for site utilities, including potable water, basin drain system, domestic wastewater septic tank system, and other systems 6 Electncal System Detailed description of the electrical system from the main substation to the facility's individual motor control centers 7 Maintenance Nameplate data for each mayor piece of equipment, list of the manufacturer's recommended spare parts, and schedule of equipment manufacturer's preventative maintenance activities 8 Appendices A glossary of treatment terms and abbreviations used pertinent to this facility Deliverables 5 copies of draft O&M Manual S copies offinal O&M Manual Engineer will produce and deliver the final O&M Manual for the LRRWTP Project in electronic format The O&M Manual will include all of the elements described in paragraph 3 la The electronic 0&M Manual will feature text, photographs, CAD drawings, and an image library Operating in a Microsoft Windows NT environment, the system will provide access to all 0&M Manual data L e L This specifically includes computerization of 0&M Manual text, approximately 300 CAD drawings, 50 process schematics, 200 related photographs, and creation of an image database with up to 2,000 letter-sized image pages The information will be produced electronically to create a multimedia document complete with hyperlinks, photographs, and CAD and scanned image viewing capability Concurrent with the production of the O&M Manual in electronic format, initial and final draft/demonstrations will be delivered to the Owner for review and comment Along with delivery of the final draft 0&M Manual, two (2) days of training will be provided to familiarize plant staff in use and maintenance of the electronic O&M Manual No hardware will be supplied as part of the Project Minimum computer operating requirements for the software to be supplied are Manufacturer Dell, Compaq, Gateway CPU Pentium 111 500 mhz or better Hard Drive 8 4 gigabyte Construction Phase Scope of Services LRRWTP 5 February 16, 2001 RAMfVideoRAM Graphics Monitor Optical Disk Software Sound and Video Cards (optional) 128 megabytes (RAM)/ 16 megabytes (video) 32 bit 21-inch Super VGA 16X CDROM (SCSI Compatible) Microsoft Windows NT or 2000 Soundblaster 16 0 (or equal) Included with the electronic 0&M Manual will be the software necessary to view and maintain the manual (FN will provide all of the software necessary to use the electronic O&M manual) r- 32 Startup and Personnel Training Water Treatment Plant Units and Process a Consult with Owner on training needs for pre-startup operation and prepare a schedule Coordinate and arrange with the mayor equipment providers for the training It is anticipated that pre-startup training will be conducted over four (4) one-week periods involving a total of 64 hours of classroom work b Provide 40 hours of onsite operation consultation, including a total of 6 trips to the site to consult on starting and optimizing pumping, chemical, treatment and other process controls Assist in establishing operating procedures for individual unit processes and for overall operation of the LRRWTP c Provide 40 hours of office consulting concerning the modification of items relating to the operations Advise Owner regarding modification of operations Ozone Start-up Training 4 Freese and Nichols, Inc via services provided by Process Applications, Inc will facilitate and coordinate ozone-process training through three workshop-training events as described below Each of the three training workshops will be 8-hr in length and will be presented in intervals of approximately four to six weeks Ozone System Operational Guidelines will be developed with applicable input by the plant staff Copes will be provided in printed form and electronic format The first training session will be scheduled about six to eight months prior to completion of construction to allow time for manufacturer's equipment training just prior to system startup i Startup Training Workshop No I L e Topics to be included are review of information regarding safety and Construction Phase Scope of Services LRRWTP February 16, 2001 6 I application of ozone and ozone equipment design and operating criteria Training workshops will involve safety procedures and wquipment selection criteria guidelines ii Startup Training Workshop No 2 Topics will include ozone contractor and off-gas process operation and determination of ozone disinfection inactivation credit Training workshops will cover off-gas system startup procedure, calculation of ozone disinfection credit and ozone system computer simulation The spreadsheet simulation model will be provided to the City of Denton WTP staff and training on use of simulator will be included ill Startup Training Workshop No Discussion topics will include liquid oxygen (LOX) and ozone generator operation and calibration of ozone residual analyzers Training workshops will include calibration of residual monitors, calculation of ozone parameters, generator and contractor switching and total ozone system startup, ozone system monitoring, contactor draining/inspection/filling, and review of key startup procedures Ozone Optimization f Follow-up technical assistance and training directed towards optimizing performance and L operation of the ozone system will provide following startup Follow-up technical consultation will consist of three site-visits plus phone consultation over a period of twelve months after startup A spreadsheet-based ozone data monitoring program will be developed for use by staff in assessment of long-term performance trends for purposes of achieving t optimized ozone system performance Training will be provided on the monitoring program during Construction Training Workshop No 3 and will be utilized during the first-year to assist staff in development of an optimized ozone system L 3 3 Warranty Assistance Provide 104 hours of office and on-site consulting, including travel, concerning the follow- up of contractor and equipment warranty items during the construction warranty period One month prior to the end of the construction warranty period, conduct a site visit and document all warranty items and assist in the coordination of the repairs/replacement of the defective work L Construction Phase Scope of Services LRRWTP February 16, 2001 3 4 CT Testing for Plant Conduct tracer testing based on TNRCC guidelines, to determine effective contact times in the plant A report will be prepared by Freese and Nichols, Inc and submitted to the City and TNRCC summarizing the results Deliverables 5 copies of testing results summary and report 3 5 Risk Management Program Develop Risk Management Program, Prevention Program 2 for the City covering the LRRWTP site The Risk Management Plan will be prepared on electronic diskette and submitted to EPA Deliverables 5 copies ofRMP, and one electronic copy ofRM Plan Task 4 - Special Services SPECIAL SERVICES Special Services to be performed by FNI which are not included in the above described basic services, are described as follows AA Additional General Representation services for an additional 2 months BB Additional Resident Representative services for an additional 2 months CC. Freese and Nichols will provide Construction Materials Testing at the site via a sub- contract with Isbell Engineering and Testing L L Construction Phase Scope of Services LRRWTP 8 February 16, 2001 O D r O M D N x D o C3 0 r ~ 0 O ~ D 2 1 0O ~00 X 1cu N m m z o z O N X m u 3A V 0-130'Or DN m m A< m m D0 0 8 m CA 0~3a ^ N o p Qu 0 m m $ m 5 O ~n j Go m a y 0 oo o j N N O a N O n N m_ v y S S O O a m m ~ m m ~ H r r m m m m m m m m a0 m pp N 5i C1 '-O m ~ N 0 3 O m 3 ppj m ~ ~ N N a rn p v O (p A m m p O A 0 o Opi OOi 0 0 A W A v 3 ,mom. 3 3 3 c En v~ f m O. N a O f S S>> m °3 O 00 3 6-0 )C f7i N N N Z 0 0 ElF m a ~o~°~~oo-o°000 v oho mo°o 0 0 °oo° °o ° 00 00 00 m n a 0 o a o o o 0 o o p O O d o 0 0 a o 0 0 o e e o e a o e N m ~ ~ a m m x y (ry y N W Fp ~ A O A S C p Q PO W.O N O 0 0 0 p N O 0 0 0 0 0 0 00 00 0 0 0 0 y -n 0 0 0 0 0 0 0 0 0 0 0 A 0 0 0 0 0 0 0 0 0 0 0 ZI O n O ~ m o 0 0 X p V a m N m f» V ~ V tJ V N O O b Of A m iw N O 0 0 O o w p A O A V ~ OAi ~ r O N W m o ~ o O O H 01 m A N O W m y D A m m 1 M v A m ca m 1 1 O Z a 71 x ;u z N D r v A xO N 3 O A a x0 Nm z GI 2 ym z O m N c 2 .11 A 0 N = x3 Am to 0 x = r N m p 0 N D Z D O 00 z G) m cmi 1 1 N N O O N ~ OVO A N A W f0 W O m m N m zZ O d Z_ J N 0 x O cn Z W N o N V ~ O N V O N O O N m z 8 pm N Z O O = m (n 0 W A A m N N ~ ~ W r m v Cl) m rn 0 (p 0 (A A 0 m m m 0 O -i 0 D r 0 D r m O A m z Q z m m X z G) a) C v G) m 1 0 M N O ~ 0 v; N, Z m{ 0 j0 { n { v {m Z ~0 Z w V A N O m 5- U) -i D O Z D r m A O r 0 0 o moc i o CO X r m z z o O w m A 0 D - j m DDo < m ~ p n F, 0 m ca S m o p N Q~ o p 0 t i w N _ H a a ~ m m m . B c 5 Q° 'm m Ov o r O N ♦ 0 ~ N n n ' j C7 ° 0 0 o m j N O I O N 61 N l N r Q V O m O ~ J ° ~ N A O N N m~ OO W O m J O ~ ~ O O N O W O ~ W I A ~ H N N !~0 d J£C (7i N 3~ N m O 0 fR N j !q V1 (.J M~ N~ W W N p A ~I O th N O ao O~ m V GQ1~ ° W~° O O O O N N O N 0 0 0 0 0 0 s 000°0 0 ° °O °1 000 0 0 0 o o e o o ~ v v (VNV" ONi p N ~ c N J m 0 0 W CO N N 0 O m° O m P O W O O T N p~ O W 0 0 0 0 0 0 0- 0 0 0 0 0 0 0 0 0 O N ~ 4 i~ No N O N N O N ° N O N J~ J M O ~ O o m o A WW N A ° 0 m (n J ~ 001 N N o m o w W o O1 J m A N b O b ~ W m N p NN W V + W m m [ Z 0 n n - D r v [ O n ~ Q ,ll l7 [ Q am z 2$O C 2 °n z O y [ m o no O C D 0 no = C K om 10 x [ m D r n m n O [ (n 0 n' m z 8 o r nz 0 O [m o nQ = A m n m 0 n U) 0 O 0 O n ~ ."0 Q J Q rC r O J D n r i r n D A ~ i N x w 0 LO 1 O z c n _1 Q z m m n m m 0 a r m O A D N A a 0 O z N 1 C 0 -1 O z a N Of m 7) z n D r v 0 3 O A a 0 xo N m m z O x ~ m N z 0 xK z cm) N x sM m m 0 N ' m z O 2 N 8 x mz c~ m ;u O N x X m m 0 s0 xN U) -i 0 0 0 x o ma 00 -i O D r o-4 C) N D r r ; ~ao~oooin ~noooo~nm ~n a~ ~ooooN~ ~oo~nom M N nGYO 69 6. 0 0 a a ` e o oeo Y o o~ g~ o 0000000 °0 0 0 0 0 008 0 0 0 m 000 M800 0 0 0 co m 0 O ¢ O N 0 N MO ~Lo 64~ 40 1* W y CO 2 C d L° C y Y 'D (D f : IL a~ia~y jE30:3 E Z 3 E O a-T CO a O~ 1n lO tON 0m 4 = IL N a CC = cC6 Z z Q C 4 E D CL N 0 ~ m E C L W W a U aN L) C11 N co N W !L ~ ~ N N y rn a 4) ! Q W N O d Z:~ r r~ 0 U a y C W O. y J J C! K Ljj R~ d d NJi88V 51~c C °r S.W l6 U) W CL a 0 m p m o c d o o c0i p L - V L z~ m o $a~c~~ $ g~yEo0~ g C°\l W <IL 0a¢ ~C d co C) F- g FrZ {C R N er ~~Z W O O LU IL l 00 a 6 _j m P- v .o U0~ W O Q Q ~ W }}Q O F ¢ CO U. Q m V LU N N t 5 bW 12 m 0 a 0i U O yi